STANDARD AGREEMENT FOR COUNTRYSIDE RECREATION CENTER
,
- ,
THE
A M
E R I-C A N
I
NSTITUTE
o
Fl
ARCHITECTS
AlA Document B141
Standard Form of Agreement Between
Owner and Architect
1987 EDITION
THIS DOCUMEIVT HAS IMPORTANT LEGAL CONSEQUENCES; CONSULTATION WITH
AN ATTORNEY IS ENCOURAGED lX1ITH RESPECT TO ITS COMPLETION OR MODIFICATION.
AGREEMENT
~
Ninety
day of
r
in the year of
made as of the
Nineteen Hundred and
Four
BETWEEN the Owner:
THE CITY OF CLEARWATER
Post Office Box 4748
Clearwater, FL 34518-4748
(Name alld addl'ess)
and the Architect:
BITTERLI + ASSOC. ARCHITECTS, INC.
3950 Third Street No.
St. Petersburg, FL 33703
(Name mId addl'ess)
For the following Project:
(Include de/ailed deso-ipticm of Project, 10Ul/ion, addl'ess and scope.)
Professional architectural services consisting of the preparation of a certifiable site plan necessary for all applicable building
and other regulatory permits, preparation of construction plans, specifications and contract documents adequate to
construct all features of the site plan, including a community recreational building located at 2640 Sabal Springs Drive in
Clearwater.
Said building to contain approximately 15,000 square feet and may consist of a multi-purpose gymnasium, game room,
meeting room, kitchen, lobby, offices, restrooms, and other spaces as may be appropriate, etc.
The work will be accomplished as contained in this contact and as described hereafter, The total project costs, including
construction costs, all applicable fees, and site work and features of the site plan shall not exceed $1,200,000.
The Owner and Architect agree as set forth below.
~cOPyr~ght ]9]7, 1926, ]948, 195], 1953, ]958,-]96], ]963, 1966, ]967.19'70, ]9'74, ]9'77,@1987byTheAmericanlnstitute
of Architects. ] 735 New York /\\'enue, N.W., \X'ashington, D.C. 20006. Reproduction of the material herein or substantial
uotation of its provisions without written permission of lhe AlA violates the copyrighl Jaws of the United Stales and will be
subject to legal prosecution.
AlA DOCUMENT 8141 . OW'!'ER.ARCHITECT AGREEME!'T. FOl'RTEE!'TH EDITIO!'. AIA€ . ([198i
THE AMERICAN INSTITUTE OF ARCHITECTS. 1 i3S NEW' YORK A\'ENl'E. NW., \X"ASH1NGTOK DC. 20006
8141-1987 1
tJJ(Jif/ /"j
(;)
]
I
TERMS AND CONDITIONS OF AGREEMENT BETWEEN OWNER AND ARCHITECT
ARTICLE 1
ARCHITECT'S RESPONSIBILITIES
1.1 ARCHITECT'S SERVICES
1.1.1 The Architect's services consist of those services per-
formed by the Architect, Architect's employees and Architect's
consultants as enumerated in Anicles 2 and 3 of this Agreement
and any other services included in Article 12.
1.1.2 The Architect's services shall be performed as expedi-
tiously as is consistent with professional skill and care and the
orderly progress of the \X'ork. Upon request of the Owner, the
Architect shall submit for the Owner's approval a schedule for
the performance of the Architect's services which may be
adjusted as the Project proceeds, and shall include allowances
for periods of time required for the Owner's review and for
approval of submissions by authorities having jurisdiction over
the Project. Time limits established by this schedule approved
by the Owner shall not, except forreasonable cause,be exceeded
by the Architect or Owner.
1.1.3 The services covered by this Agreement are subject to
the time limitations contained in Subparagraph 11.5.1.
ARTICLE 2
SCOPE OF ARCHITECT'S BASIC SERVICES
2.1 DEFINITION
2.1.1 The Architect's Basic Ser,ices consist of those described
in Paragraphs 2.2 through 2.6 and any other ser.-ices identified
in Article 12 as pan of Basic Services. and include normal struc-
tural, mechanical and electrical engineering services.
2.2 SCHEMATIC DESIGN PHASE
2.2.1 The Architect shall re\'iew the program furnished by the
Owner to ascenain the requirements of the Project and shall
arrive at a mutual understanding of such requirements with the
Owner.
2.2.2 The Architect shall pro\'ide a preliminary evaluation of
the Owner's program, schedule and construction budget
requirements, each in terms of the other, subject to the limit;;!-
tions set forth in Subparagraph 5.2.1.
2.2.3 The Architect shall re\-iew with the Owner alternative
approaches to design and construction of the Project.
2.2.4 Based on the mutually agreed-upon program, schedule
and construction budget requirements, the Architect shall
prepare, for approval by the Owner, Schematic Design Docu.
ments consisting of drawings and ather documents illustrating
the scale and relationship of Project components.
2.2.5 The Architect shall submit to the Owner a preliminary
estimate of Construction Cost based on current area, volume or
other unit costs.
2.3 DESIGN DEVELOPMENT PHASE
2.3.1 Based on the appro\'ed Schematic Design Documents
and any adjustments authorized by the Owner in the program,
schedule or construction budget, the Architect shall prepare,
for approval by the Owner, Design Development Documents
consisting of drav,ings and other documents to fix and describe
the size and character of the Project as to architectural. struc-
tural, mechanical and electrical systems, materials and such
Other elements as may be appropriate.
2.3.2 The Architect shall advise the Owner of any adjustments
to the preliminary estimate of Construction Cost.
2.4 CONSTRUCTION DOCUMENTS PHASE
2.4.1 Based on the approved Design Development Docu-
ments and any funher adjustments in the scope or quality of
the Project or in the construction budget authorized by the
Owner, the Architect shall prepare, for approval by the Owner,
Construction Documents consisting of Drawings and Specifica.
tions selling fonh in detail the requirements for the construc-
tion of the Project.
2.4.2 The Architect shall assist the Owner in the preparation of
the necessary bidding information, bidding forms, the Condi-
tions of the Contract, and the form of Agreement between the
Owner and ContractOr.
2.4.3 The Architect shall advise the Owner of any adjustments
to previous preliminary estimates of Construction Cost indi-
cated by changes in requirements or general market conditions.
2.4.4 The Architect shall assist the Owner in connection with
the Owner's responsibility for filing documents required for
the appro\'al of governmental authorities having jurisdiction
over the Project.
2.5 BIDDING OR NEGOTIATION PHASE
2.5.1 The Architect, following the Owner's approval of the
Construction Documents and of the latest preliminary estimate
of Construction Cost, shall assist the Owner in obtaining bids
or negotiated proposals and assist in awarding and preparing
contracts for construction.
2.6 CONSTRUCTION PHASE-ADMINISTRATION
OF THE CONSTRUCTION CONTRACT
2.6.1 The Architect's responsibility to provide Basic Services
for the Construction Phase under this Agreement commences
with the award of the Contract for Construction and terminates
at the earlier of the issuance to the Owner of the final Cenificate
for Payment or 60 days after the date of Substantial Completion
of the W'ork, unless extended under the terms of Subparagraph
10.3.3.
2.6.2 The Architect shall provide administration of the Con.
tract for Construction as set fonh below and in the edition of
AlA Document A201. General Conditions of the Contract for
Construction, current as of the date of this Agreement, unless
otherwise provided in this Agreement.
2.6.3 Duties, responsibilities and limitations of authority of the
Architect shall not be restricted, modified or extended without
wrillen agreement of the Owner and Architect with consent of
the Contractor, which consent shall not be unreasonably
withheld.
AlA DOCUMENT e141 . O\J;':\ER.ARCHlTECT AGREEMEKT. FOl'RTEEKTH EDITIOK. AIA~ . <f::19S;
THE AMERICAK IKSTITL'TE OF ARCHITECTS, 1 ~35 NEW YORK A\"EKL'E. K,W" \XIASHINGTOK. D,C. 20006
B141-1987 2
I
2.6.4 The Architect shall be a representative of and shall advise
and consult with the Owner (1) during construction until final
payment to the Contractor is due, and (2) as an Additional Ser-
vice at the Owner's direction from time to time during the cor-
rection period described in the Contract for Construction. The
Architect shall have authority to act on behalf of the Owner
only to the extent provided in this Agreement unless othern-ise
modified by written instrument.
2.6.5 The Architect shall visit the site at intervals appropriate
to the stage of construction or as otherwise agreed by the
Owner and Architect in writing to become generally familiar
with the progress and quality of the Work completed and to
determine in general if the Work is being performed in a man-
ner indicating that the Work when completed will be in accor-
dance with the Contract Documents. However, the Architect
shall not be required to make exhaustive or continuous on-site
inspections to check the quality or quantity of the Work. On
the basis of on-site observations as an architect, the Architect
shall keep the Owner informed of the progress and quality of
the Work, and shall endeavor to guard the Owner against
defects and deficiencies in the Work. (More extensive site
representation may be agreed to as an Additional Service, as
described in paragrapb 3.2.)
2.6.6 The Architect shall not have control over or charge of
and shall not be responsible for construction means, methods,
techniques, sequences or procedures, or for safety precautions
and programs in connection with the Work, since these are
solely the Contractor's responsibility under the Contract for
Construction. The Architect shall not be responsible for the
Contractor's schedules or failure to carry out the Work in accor-
dance with the Contract Documents. The Architect shall not
have control over or charge of acts or omissions of the Contrac-
tor, Subcontractors, or their agents or employees, or of any
other persons performing portions of the Work.
2.6.7 The Architect shall at all tin1es have access to the Work
wherever it is in preparation or progress.
2.6.8 Except as may otherwise be provided in the Contract
Documents or when direct communications have been spe-
cially authorized. the Owner and Contractor shall communicate
through the Architect. Communications by and with the Archi-
tect's consultants shall be through the Architect.
2.6.9 Based on the Architect's observations and evaluations of
the Contractor's Applications for Payment, the Architect shall
review and certify the amounts due the Contractor.
2.6.10 The Architect's certification for payment shall consti-
tute a representation to the Owner, based on the Architect's
observations at the site as provided in Subparagraph 2,6.5 and
on the data comprising the Contractor's Application for Pay-
ment, that the Work has progressed to the point indicated and
that, to the best of the Architect's knowledge, information and
belief, quality of the Work is in accordance with the Contract
Documents. The foregoing representations are subject to an
evaluation of the Work for conformance with the Contract
Documents upon Substantial Completion, to results of subse-
quent tests and inspections, to minor deviations from the Con-
tract Documents correctable prior to completion and to spe-
cific qualifications expressed by the Architect. The issuance of a
Certificate for Payment shall further constitute a representation
that the Contractor is entitled to payment in the amount certi-
fied. However, the issuance of a Certificate for Payment shall
not be a representation that the Architect has (1) made exhaus-
tive or continuous on-site inspections to check the quality or
I
quantitv of the W'ork, (2) reviewed construction means, meth-
ods, techniques, sequences or procedures, (3) reviewed copies
of requisitions received from Subcontractors and material sup-
pliers and other data requested by the Owner to substantiate
the Contractor's right to payment or (4) ascertained how or for
what purpose the Contractor has used money previously paid
on account of the Contract Sum.
2.6.11 The Architect shall have authority to reject Work which
does not conform to the Contract Documents. 'j;Thenever the
Architect considers it necessary or advisable for implementa-
tion of the intent of the Contract Documents, the Architect ,vill
have authority to require additional inspection or testing of the
Work in accordance with the provisions of the Contract Docu-
ments, whether or not such Work is fabricated, installed or
completed. However, neither this authority of the Architect nor
a decision made in good faith either to exercise or not to exer-
cise such authority shall give rise to a duty or responsibility of
the Architect to the Contractor, Subcontractors, material and
equipment suppliers, their agents or employees or other per-
sons performing portions of the Work.
2.6.12 The Architect shall review and approve or take other
appropriate action upon Contractor's submittals such as Shop
Drawings, Product Data and Samples. but only for the limited
purpose of checking for conformance with information given
and the design concept expressed in the Contract Documents.
The Architect's action shall be taken with such reasonable
promptness as to cause no delay in the Work or in the con-
struction of the Owner or of separate contractors, while allow-
ing sufficient time in the Architect's professional judgment to
permit adequate review. Review of such submittals is not con-
ducted for the purpose of determining the accuracy and com-
pleteness of other details such as dimensions and quantities or
for substantiating instructions for installation or performance of
equipment or systems designed by the Contractor. all of which
remain the responsibility of the Contractor to the extent
required by the Contract Documents. The Architect's review
shall not constitute approval of safety precautions or, unless
otherwise specifically stated by the Architect, of construction
means, methods, techniques, sequences or procedures. The
Architect's approval of a specific item shall not indicate
approval of an assembly of which the item is a component.
When professional certification of performance characteristics
of materials, systems or equipment is required by the Contract
Documents, the Architect shall be entitled to rely upon such
certification to establish that the materials, systems or equip-
ment will meet the performance criteria required by the Con-
tract Documents,
2.6.13 The Architect shall prepare Change Orders and Con-
struction Change Directives, with supporting documentation
and data if deemed necessary by the Architect as provided in
Subparagraphs 3.1.1 and 3.3.3, for the Owner's approval and
execution in accordance with the Contract Documents, and
may authorize minor changes in the Work not involving an
adjustment in the Contract Sum or an extension of the Contract
Time which are not inconsistent with the intent of the Contract
Documents,
2.6.14 The Architect shall conduct inspections to determine
the date or dates of Substantial Completion and the date of final
completion, shall receive and forward to the Owner for the
Owner's review and records written warranties and related
documents required by the Contract Documents and assem-
bled by the Contr';lCtor. and shall issue a final Certificate for Pay-
ment upon compliance with the requirements of the Contract
Documents,
3 8141-1987
AlA DOCUMENT 8141 . OWNER-ARCHITECT AGREEMENT. FOURTEENTH EDITION. AlA'" . @]987
THE AMERICAN INSTITUTE OF ARCHITECTS. 1735 NEW YORK AVENUE. N,W" WASHINGTON. D,C. 20006
1
2.6.15 The Architect shall interpret and decide mailers con-
cerning performance of the Owner and Contractor under the
requiremeJ1ls of the COnlraCl Documents on wrinen request of
either the O'"\'ner or COJ1lractor. The luchitect's response to
such requests shall be made with reasonable prompll1ess and
within any time limits agreed upon.
2.6.16 Interpretations and decisions of the Architect shall be
consistent with the intenr of and reasonably inferable from the
Contract Documents and shall be in writing or in the form of
drawings. \\'hen making such interpretations and initial deci-
sions, the Architect shall endeavor to secure faithful perfor.
mance by both Owner and Contractor. shall not show partiality
to either, and shall not be liable for results of interpretations or
decisions so rendered in good faith.
2.6.17 The Architect's decisions on mailers relating to aesthe-
tic effect shall be final if consistent with the intent expressed in
the Contract Documents.
2.6.18 The Architect shall render wrinen decisions within a
reasonable time on all claims, disputes or other mailers in ques-
tion between the Owner and Contractor relating to the execu-
tion or progress of the Work as provided in the Contract
Documents.
2.6.19 The Architect's decisions on claims, disputes or other
maners, including those in question between the Owner and
Contractor, except for those relating to aesthetic effect as pro-
vided in Subparagraph 2.6.17, shall be subject to arbitration as
provided in this Agreement and in the Contract Documenrs.
ARTICLE 3
ADDITIONAL SERVICES
3.1 GENERAL
3.1.1 The sen'ices described in this Arricle 3 are not included
in Basic Services unless so identified in Arricle ] 2, and the\' shall
be paid for by the Owner as provided in this Agreement, in
addition to the compensation for Basic Sen'ices. The sen'ices
described under Paragraphs 3.2 and 3.4 shall only be pro\'ided
if authorized or confirmed in writing by the Owner. If sen'ices
described under Contingent Additional Sen'ices in Paragraph
3.3 are required due to circumstances beyond the Architect's
COntro!, the Architect shall notify the Owner prior to com.
mencing such sen'ices. If the Owner deems that such sen'ices
described under Paragraph 3.3 are not required. the O,mer
shall give prompt wrinen notice to the Architect. ]f the Owner
indicates in writing that all or pan of such Conringenr Addi-
tional Services are not required. the Architect shall have no obli-
gation to pro\'ide those sen'ices.
3.2 PROJECT REPRESENTATION BEYOND BASIC
SERVICES
3.2.1 If more extensive representation at the site than is
described in Subparagraph 2.6.5 is required. the Architeer shall
provide one or more Project Representati\'es to assist in carn'-
ing out such additional on-site responsibilities. '
3.2.2 Project Representati\'es shall be selected, emploved and
directed by the Architect, and the Architect shall be c'ompen-
sated therefor as agreed by the Owner and Architect. The
.duties, responsibilities and limitations of authority of Project
Represenrati\'es shall be as described in the edition of .\IA
Documenr B352 current as of the date of this Agreement. unless
otherwise agreed.
I
3.2.3 Through the obsen'ations by such l'roject Represen-
tatives, the Architect shall endeavor to provide funher protec-
tion for the Owner ;lgainst defects and deficiencies in lhe \X'ork,
but the furnishing of such project representation shall not
modify the rights, responsibilities or obligations of the Architect
as described elsewhere in this Agreement.
3.3 CONTINGENT ADDITIONAL SERVICES
3.3.1 Making revisions in Drawings, Specifications or other
documents when such revisions are:
.1 inconsistent with approvals or instructions previously
given by the Owner, including revisions made neces-
sary by adjustments in the Owner's program or Proj-
ect budget;
.2 required by the enactment or revision of codes, Jaws
or regulations subsequent to the preparation of such
documents; or
.3 due to changes required as a result of the Owner's fail-
ure to render decisions in a timely manner.
3.3.2 Pro"iding sen'ices required because of significant
changes in the Project including, but not limited to, size, qual.
ity, complexity, the Owner's schedule, or the method of bid-
ding or negotiating and contracting for construction, except for
sen'ices required under Subparagraph 5.2.5.
3.3.3 Preparing Drawings, Specifications and other documen-
tation andsupporring data, evaluating ContractOr's proposals,
and providing other sen'ices in connection with Change
Orders and Construction Change Directives.
3.3.4 Providing sen'ices in connection with e\'aluating substi-
tutions proposed by the Contractor and making subsequent
revisions to Drawings, Specifications and other documentation
resulting therefrom.
3.3.5 Providing consultation concerning replacement of Work
damaged by fire or other cause during construction, and fur-
nishing sen'ices required in connection with the replacement
of such W'ork.
3.3.6 Providing sen'ices made necessary by the default of the
Contractor, by major defects or deficiencies in the Work of the
Contractor, or by failure of performance of either the Owner or
Contractor under the Contract for Construction.
3.3.7 Providing sen'ices in evaluating an extensi\'e number of
claims submined by the Contractor or others in connection
with the Work.
3.3.8 Providing scn'ices in connection ",'jth a public hearing,
arbitration proceeding or legal proceeding except where the
Architect is pany thereto.
3.3.9 Preparing documents for alternate. separate or sequential
bids or providing sen' ices in connection with bidding. negotia-
tion or construction prior to the completion of the Construc-
tion Documents Phase.
3.4 OPTIONAL ADDITIONAL SERVICES
3.4.1 Providing analy~es of the Owner's needs and program-
ming the requirements of the Project.
3.4.2 Providing financial feasibility or other special ~tudies.
3.4.3 Pro\'iding planning sun'eys, site evaluations or com-
parative studies of prmpecti\'e sires.
AlA DOCUMENT 8141 . O\l:'\'ER'ARCHITECT AGREEME\'T. FOl"RTEE!'TH EDITlO!'. AIA~ . <S198-
THE A~1ERICA\' J!'\STITl'TE OF ARCHITECTS. J -~5 \'E\l:' YORK A\-E!'l"E. !'i.W., WASHINGTO:-;. D.C 20006
8141.1987 4
a
3.4.4 Providing special surveys, environmental studies and
submissions required for approvals of governmental authorities
or others having jurisdiction over the Project.
3.4.5 Providing services relative to future facilities, systems
and equipment.
3.4.6 Providing services to investigate existing conditions or
facilities or to make measured drawings thereof.
3.4.7 Providing services to verify the accuracy of drawings or
other information furnished by the Owner.
3.4.8 Providing coordination of construction performed by
separate contractors or by the Owner's own forces and coordi-
nation of services required in connection with construction
performed and equipment supplied by the Owner.
3.4.9 Providing services in connection with the work of a con-
struction manager or separate consultants retained by the
Owner.
3.4.10 Providing detailed estimates of Construction Cost.
3.4.11 Providing detailed quantity surveys or inventories of
material, equipment and labor.
3.4.12 Providing analyses of owning and operating costs.
3.4.13 Providing interior design and other similar services
required for or in connection with the selection, procurement
or installation of furniture, furnishings and related equipment.
3.4.14 Providing services for planning tenant or rental spaces.
3.4.15 Making investigations, inventories of materials or equip-
ment, or valuations and detailed appraisals of existing facilities.
3.4.16 Preparing a set of reproducible record drawings show-
ing significant changes in the Work made during construction
based on marked-up prints, drawings and other data furnished
by the Contractor to the Architect.
3.4.17 Providing assistance in the utilization of equipment or
systems such as testing, adjusting and balancing, preparation of
operation and maintenance manuals, training personnel for
ope'ration and maintenance, and consultation during operation.
3.4.18 Providing services after issuance to the Owner of the
final Certificate for Payment, or in the absence of a final Cer-
tificate for Payment, more than 60 days after the date of Sub-
stantial Completion of the Work.
3.4.19 Providing services of consultants for other than archi-
tectural, structural, mechanical and electrical engineering por-
tions of the Project provided as a part of Basic Services.
3.4.20 Providing any other services not otherwise included in
this Agreement or not customarily furnished in accordance
with generally accepted architectural practice.
ARTICLE 4
OWNER'S RESPONSIBILITIES
4.1 The Owner shall provide full information regarding
requirements for the Project, including a program which shall
set forth the Owner's objectives, schedule, constraints and cri-
teria, including space requirements and relationships, flexi-
bility, expandability, special equipment, systems and site
requirements.
I
4.2 The Owner shall establish and update an overall budget for
the Project. including the Construction Cost, the Owner's other
costs and reasonable cOI1lingencies related to all of these costs.
4.3 If requested by the Architect, the Owner shall furnish evi-
dence that financial arrangements have been made to fulfill the
Owner's obligations under this Agreement.
4.4 The Owner shall designate a representative authorized to
act on the Owner's behalf with respect to the Project. The
Owner or such authorized representative shall render decisions
in a timely manner pertaining to documents submitted by the:
Architect in order to avoid unreasonable delay in the orderly
and sequential progress of the Architect's services.
4.5 The Owner shall furnish surveys describing physical
characteristics, legal limitations and utility locations for the site
of the Project, and a written legal description of the site. The
surveys and legal information shall include, as applicable,
grades and lines of streets, alleys, pavements and adjoining
property and structures; adjacent drainage; rights-of-way,
restrictions, easements, encroachments, zoning, deed restric-
tions, boundaries and contours of the site; locations, dimen-
sions and necessary data pertaining to existing buildings, other
improvements and trees; and information concerning available
utility services and lines, both public and private, above and
below grade, including inverts and depths. All the information
on the survey shall be referenced to a project benchmark.
4.6 The Owner shall furnish the services of geotechnical engi-
neers when such services are requested by the Architect. Such
services may include but are not limited to test borings, test
pits, determinations of soil bearing values, percolation tests,
evaluations of hazardous materials, ground corrosion and resis-
tivity tests, including necessary operations for anticipating sub-
soil conditions. with reports and appropriate professional
recommendations.
4.6.1 The Owner shall furnish the services of other consul-
tants when such services are reasonably required by the scope
of the Project and are requested by the Architect.
4.7 The Owner shall furnish structural, mechanical, chemical,
air and water pollution tests, tests for hazardous materials, and
other laboratory and environmental tests, inspections and
reports required by law or the Contract Documents.
4.8 The Owner shall furnish all legal, accounting and insurance
counseling services as may be necessary at any time for the
Project, including auditing services the Owner may require to
verify the Contractor's Applications for Payment or to ascertain
how or for what purposes the Contractor has used the money
paid by or on behalf of the Owner.
4.9 The services, information, surveys and reports required by
Paragraphs 4.5 through 4.8 shall be furnished at the Owner's
expense, and the Architect shall be entitled to rely upon the
accuracy and completeness thereof.
4.10 Prompt written notice shall be given by the Owner to the
Architect if the Owner becomes aware of any fault or defect in
the Project or nonconformance with the Contract Documents.
4.11 The proposed language of certificates or certifications
requested of the Architect or Architect's consultants shall be
submitted to the Architect for review and approval at least 14
days prior to execution. The Owner shall not request certifica-
tions that would require knowledge or services beyond the
scope of this Agreement.
5 B141.1987
AlA DOCUMENT 8141 . OWNER-ARCHITECT AGREEMENT. FOURTEENTH EDITION. AlA'" . @1987
THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON. D.C. 20006
)
ARTICLE 5
CONSTRUCTION COST
5.1
DEFINITION
5.1.1 The Construction Cost shall be the total cost or esti-
mated cost to the Owner of all elements of the Project designed
or specified by the Architect.
5.1.2 The Construction Cost shall include the cost at current
market rates of labor and materials furnished by the Owner and
equipment designed, specified, selected or specially provided
for by the Architect. plus a reasonable allowance for the Con-
tractor's overhead and profit. In addition. a reasonable allm\'-
ance for contingencies shall be included for market conditions
at the time of bidding and for changes in the \X'ork during
construction.
5.1.3 Construction Cost does not include the compensation of
the luchitect and Architect's consultants, the costs of the land,
rights-of-way, financing or other COSts which are the respon-
sibility of the Owner as provided in Artjcle 4.
5.2 RESPONSIBILITY FOR CONSTRUCTION COST
5.2.1 Evaluations of the Owner's Project budget, preliminary
estimates of Construction Cost and detailed estimates of Con-
struction Cost, if any, prepared by the Architect, represent the
Architect's best judgment as a design professional familiar with
the construction industry. It is recognized, however. that nei-
ther the Architect nor the Owner has control over the cost of
labor, materials or equipment, over the Contractor's methods
of determining bid prices, or over competitive bidding, market
or negotiating conditions. Accordingly. the Architect cannot
and does not warrant or represent that bids or negotiated prices
will not vary from the Owner's Project budget or from any
estimate of Construction Cost or evaluation prepared or agreed
to by the Architect,
5.2.2 No fixed limit of Construction Cost shall be established
as a condition of this Agreement by the furnishing. proposal or
establishment of a Project budget, unless such fixed limit has
been agreed upon in writing and signed by the parties heretO. If
such a fixed limit has been established, the Architect shall be
permitted to include contingencies for design, bidding and
price escalation, to determine what materials, equipment, com-
ponent systems and types of construction are to be included in
the Contract Documents, to make reasonable adjustments in
the scope of the Project and to include in the Contract Docu.
ments alternate bids to adjust the Construction Cost to the fIXed
limit. Fixed limits, if any, shall be increased in the amount of an
increase in the Contract Sum occurring after execution of the
Contract for Construction.
5.2.3 If the Bidding or ~egotiation Phase has not commenced
within 90 davs after the Architect submitS the Construction
Documents to the Owner. any Project budget or fixed limit of
Construction Cost shall be adjusted to reflect changes in the
general level of prices in the construction industry between the
date of submission of the Construction Docu'ments to the
Owner and the date on which proposals are sought,
5.2.4 If a fixed limit of Construction COSt (adjusted as pro-
vided in Subparagraph 5.2.3) is exceeded by the lowest bona
fide bid or negotiated proposal, the Owner shall:
.1 give written approval of an increase_ in such fixed
limit;
.2 authorize rebidding or renegotiating of the Project
within a reasonable time;
I
.3 if the Project is abandoned, terminate in accordance
with Paragraph 8.3; or .
.4 cooperate in re\'ising the Project scope and quality as
required to reduce the Construction Cost.
5.2.5 If the Owner chooses to proceed under Clause 5.2.4.4,
the Architect, without additional charge, shall modify the Con-
tract Documents as necessary to comply with the fixed limit, if
established as a condition of this Agreement. The modification
of Contract Documents shall be the limit of the Architect's
responsibility arising out of the establishment of a fixed limit.
The Architect shall be entitled to compensation in accordance:
with this Agreement for all services performed whether or not
the Construction Phase is commenced.
ARTICLE 6
USE OF ARCHITECT'S DRAWINGS,
SPECIFICATIONS AND OTHER DOCUMENTS
6.1 The Drawings, Specifications and other documents pre-
pared by the Architect for this Project are instruments of the
Architect's seryice for use solely with respect to this Project
and, unless otherwise pro\'ided. the Architect shall be deemed
the author of these documents and shall retain all common law,
statutory and other reser.'ed rights, including the copyright,
The Owner shall be permitted to retain copies. including repro-
ducible copies. of the Architect's Drawings, Specifications and
other documents for information and reference in connection
with the Owner's use and occupancy of the Project. The Archi-
tect's Dra",-ings, Specifications or other documents shall not be
used bv the Owner or others on other projects. for additions to
this Project or for completion of this Project by others, unless
the Architect is adjudged to be in default under this Agreement,
except by agreement in writing and with appropriate compen-
sation to the Architect.
6.2 Submission or distribution of documents to meet official
regulatory requirements or for similar purposes in conTJection
with the Project is not to be construed as publication in deroga-
tion of the Architect's reser.'ed rights.
ARTICLE 7
ARBITRATION
7.1 Claims. disputes or other matters in question between the
parties to this Agreement arising out of or relating to this Agree-
ment or breach thereof shall be subject to and decided by arbi.
tration in accordance with the Construction Industry Arbitra-
tion Rules of the American Arbitration Association currently in
effect unless the parties mutually agree otherwise.
7.2 Demand for arbitration shall be filed in writing with the
other party to this Agreement and with the American A.rbitra-
tion Association. A demand for arbitration shall be made within
a reasonable time after the claim, dispute or other marr.er in
question has arisen. In noe\'ent shall the demand for arbitration
be made after the dale when institution of legal or equitable
proceedings based on such claim, dispute or Other matter in
question would be barred by the applicable Stdrutes of Jimjtdtions.
7.3 No arbitration.Jrising out of or relating to this Agreement
shall include, by consolidation,joinder or in any other manner.
an additional person or entity not a pJrty to this Agreemenr,
AlA DOCUMENT B141 . OW'l"ER-ARCHITECT AGREEMEl"T. FOCRTEENTH EDITION. AlA'" . <r1987
THE AMERICAN INSTITCTE OF ARCHITECTS, 1735 NEW YORK AVEl"l'E. N.W., WASHINGTOl". DC 20006
8141-1987 6
-
except by written consent containing a specific reference to
this Agreement signed by the Owner, Architect, and any other
person or entity sought to be joined. Consent to arbitration
involving an additional person or entity shall not constitute
consent to arbitration of any claim, dispute or other matter in
question not described in the written consent or with a person
or entity not named or described therein. The foregoing agree-
ment to arbitrate and other agreements to arbitrate with an
additional person or entity duly consented to by the parties to
this Agreement shall be specifically enforceable in accordance
with applicable law in any court having jurisdiction thereof.
7.4 The award rendered by the arbitrator or arbitrators shall be
final, and judgment may be entered upon it in accordance with
applicable law in any court having jurisdiction thereof.
ARTICLE 8
TERMINATION, SUSPENSION OR ABANDONMENT
8.1 This Agreement may be terminated by either party upon
not less than seven days' written notice should the other party
fail substantially to perform in accordance with the terms of this
Agreement through no fault of the party initiating the tennination.
8.2 If the Project is suspended by the Owner for more than 30
consecutive days, the Architect shall be compensated for ser-
vices performed prior to notice of such suspension. When the
Project is resumed, the Architect's compensation shall be equi-
tably adjusted to provide for expenses incurred in the interrup-
tion and resumption of the Architect's services.
8.3 This Agreement may be terminated by the Owner upon
not less than seven days' written notice to the Architect in the
event that the Project is permanently abandoned. If the Project
is abandoned by the Owner for more than 90 consecutive days,
the Architect may terminate this Agreement by giving written
notice.
8.4 Failure of the Owner to make payments to the Architect in
accordance with this Agreement shall be considered substantial
nonperformance and cause for termination.
8.5 If the Owner fails to make payment when due the Archi-
tect for services and expenses, the Architect may, upon seven
days' written notice to the Owner, suspend performance of ser-
vices under this Agreement. Unless payment in full is received
by the Architect within seven days of the date of the notice, the
suspension shall take effect without further notice. In the event
of a suspension of services, the Architect shall have no liability
to the Owner for delay or damage caused the Owner because
of such suspension of services.
8.6 In the event of termination not the fault of the Architect,
the Architect shall be compensated for services performed prior
to termination, together with Reimbursable Expenses then due
and all Termination Expenses as defined in Paragraph 8.7.
8.7 Termination Expenses are in addition to compensation for
Basic and Additional Services, and include expenses which are
directly attributable to termination. Termination Expenses shall
be computed as a percentage of the total compensation for
Basic Services and Additional Services earned to the lime of ter-
mination, as follows:
.1 Twenty percent of the total compensation for Basic
and Additional Ser,ices earned to date if termination
occurs before or during the predesign, site analysis, or
Schematic Design Phases; or
(
.2 Ten percent of the total compensatipn for Basic and
Additional Services earned to date if termination
occurs during the Design Development Phase; or
.3 Five percent of the total compensation for Basic and
Additional Services earned to date if termination
occurs during any subsequent phase.
ARTICLE 9
MISCELLANEOUS PROVISIONS
9.1 Unless otherwise provided, this Agreement shall be gov-
erned by the law of the principal place of business of the
Architect.
9.2 Terms in this Agreement shall have the sanle meaning as
those in AlA Document A20 I, General Conditions of the Con-
tract for Construction, current as of the date of this Agreement.
9.3 Causes of action between the parties to this Agreement
pertaining to acts or failures to act shall be deemed to have
accrued and the applicable statutes of limitations shall com-
mence to run not later than either the date of Substantial Com-
pletion for acts or failures to act occurring prior to Substantial
Completion, or the date of issuance of the final Certificate for
Payment for acts or failures to act occurring after Substantial
Completion.
9.4 The Owner and Architect waive all rights against each
other and against the contractors, consultants, agents and
employees of the other for damages, but only to the extent cov-
ered by property insurance during construction, except such
rights as they may have to the proceeds of such insurance as set
forth in the edition of AlA Document A20 1, General Conditions
of the Contract for Construction, current as of the date of this
Agreement. The Owner and Architect each shall require similar
waivers from their contractors, consultants and agents.
9.5 The Owner and Architect, respectively, bind themselves,
their partners, successors, assigns and legal representatives to
the other party to this Agreement and to the partners, succes-
sors, assigns and legal representatives of such other party with
respect to all covenants of this Agreement. Neither Owner nor
Architect shall assign this Agreement without the written con-
sent of the other.
9.6 This Agreement represents the entire and integrated agree-
ment between the Owner and Architect and supersedes all
prior negotiations, representations or agreements, either writ-
ten or oral. This Agreement may be amended only by written
instrument signed by both Owner and Architect.
9.7 Nothing contained in this Agreement shall create a contrac-
tual relationship with or a cause of action in favor of a third
party against either the Owner or Architect.
9.8 Unless otherwise provided in this Agreement, the Architect
and Architect's consultants shall have no responsibility for the
discovery, presence, handling, removal or disposal of or expo-
sure of persons to hazardous materials in any form at the Project
site, including but not limited to asbestos, asbestos products,
polychlorinated biphenyl (PCB) or other toxic substances.
9.9 The Architect shall have the right to include representa-
tions of the design of the Project, including photographs of the
exterior and interior, among the Architect's promotional and
professional materials. The Architect's materials shall not
include the Owner's confidential or proprietary information if
the Owner has previously advised the Architect in writing of
7 B141-1987
AlA DOCUMENT 8141 . OWNER-ARCHITECT AGREEMENT. FOURTEENTH EDITION. AlA'" . <S)1987
THE AMERICAN INSTITUTE OF ARCHITECTS. 1735 NEW YORK AVENUE, N.W., WASHINGTON. D.C 20006
I
the specific information considered by the Owner to be confi-
dential or proprietary, The Owner shall provide professional
credit for the Architect on the construction sign ;md in the pro-
motional materials for the Project.
ARTICLE 10
PA YMENTS TO THE ARCHITECT
10.1 DIRECT PERSONNEL EXPENSE
10.1.1 Direct Personnel Expense is defined as the direct
salaries of the Architect's personnel engaged on the Project and
the portion of the cost of their mandator'\' and customary con-
tributions and benefits related thereto, 'such as emplo~'ment
ta.xes and Other statutory employee benefits, insurance, sick
leave, holidays. \'3cations. pensions and similar contributions
and benefits.
10.2 REIMBURSABLE EXPENSES
10.2.1 Reimbursable Expenses are in addition to compensa-
tion for Basic and Additional Services and include expenses
incurred by the Architect and Architect's employees and con-
sultants in the interest of the Project, as identified in the f01l0w-
ing Clauses.
10.2.1.1 Expense of transportation in connection with the
Project; expenses in connection with authorized out-of-town
travel; long.distance communications; and fees paid for secur-
ing approval of authorities having jurisdiction O\'er the Project.
10.2.1.2 Expense of reproductions, postage and handling of
Drawings, Specifications and other documents.
10.2.1.3 If authorized in advance by the Owner, expense of
overtime work requiring higher than regular rates,
10.2.1.4 Expense of renderings, models and mock-ups requested
by the Owner,
10.2.1.5 Expense of additional insurance coverage or limits,
including professional liability insurance, requested by the
Owner in excess of that norma1ly carried by the Architect and
Architect's consultants.
10.2.1,6 Expense of computer.aided design and drafting
equipment time when used in connection v.'ith the Project.
I
10.3 PAYMENTS ON ACCOUNT OF BASIC SERVICES
10.3,1 An initial payment as set forth in Paragraph 11.1 is the
minimum payment under this Agreement,
10.3.2 Subsequent payments for Basic Services shall be made
monthly and, where applicable, shall be in proportion to ser-
vices performed within each phase of service, on the basis set
forth in Subparagraph 11.2,2.
10.3.3 If and to the extent that the time initially established in
Subparagraph 11.5.1 of this Agreement is exceeded or extendeo
through no fault of the Architect, compensation for any ser-:
vices rendered during the additional period of time shall be
computed in the manner set forth in Subparagraph 11.3.2,
10.3.4 \X'hen compensation is ba.<;ed on a percentage of Con-
struction Cost and any portions of the Project are deleted or
otherwise not constructed, compensation for those portions of
the Project shall be payable to the extent services are per-
formed on those portions, in accordance with the schedule set
forth in Subparagraph 1 1 ,2.2, based on (1) the lowest bona fide
bid or negotiated proposal, or (2) if no such bid or proposal is
recei\'ed. the most recent preliminary estimate of Construction
Cost or detailed estimate of Construction Cost for such por-
tions of the Project,
10.4 PAYMENTS ON ACCOUNT OF ADDITIONAL
SERVICES
10.4.1 Payments on account of the Architect's Additional
Services and for Reimbursable Expenses shall be made monthly
upon presentation of the Architect's statement of services ren-
dered or expenses incurred.
10.5 PAYMENTS WITHHELD
1 0.5.1 ~o deductions shall be made from the Architect's com-
pensation on account of penalty. liquidated damages or other
sums v.'ithheld from payments to contractors, or on account of
the cost of changes in the \X'ork other than those for which the
Architect has been found to be liable.
10.6 ARCHITECT'S ACCOUNTING RECORDS
10.6.1 Records of Reimbursable Expenses and expenses per-
taining to Additional Services and services performed on the
basis of a multiple of Direct Personnel Expense shall be avail-
able to the Owner or the Owner's authorized representative at
mutua1ly com'enient times.
ARTICLE 11
BASIS OF COMPENSATION
The Owner shall compensate the Architect as follows:
11.1 A~ 1~ITIAL PAYME?\T of ----NO---- Dollars (5 -0-
shall be made upon execution of this Agreement and credited to the Owner's account at final payment.
11.2 BASIC COMPENSATION
11.2.1 FOR BASIC SER\']CES, as described in Article 2, and am' other services included in Article 12 as pan of Basic Ser,ices, Basic
Compensation shall be computed as f01l0ws: .
(hlserl basis oJ compensation, J"ncludi1l8 .qr[mlnled sums. mulf1j)J'es or peneJjfu}!,es. and idct11(fl" jihases to ubich pa,"ticuJa,- 11/rthods (!( compensatiuJ1 apjJ~)'. ~r
necessary)
LUMP SUM, $79,500.00 -- SEE ARTICLE 12 FOR BREAKDOWN OF SERVICES
AlA DOCUMENT 6141 . O\X-:"ER,_,RC!iJTECT AGREE~IE:"T . FOL'RTEE:"TH EDJTIO~ . AIA~ . is 19fC
THE AMERICA:" I"'STlTL'TE OF _,RCH,TECTS_ 1 -,c, :"E\X YORK A\'E:"L'E. :"W. \X'ASHINGTON. DL 20006
B141-1987 8
,
I
11.2.2 Where compensation is based on a stipulated sum or percentage of Construction Cost, progress payments for Basic Services
in each phase shall total the following percentages of the total Basic Compensation payable: .
(Insert additional phases as appropriate) . ... ... _.
Architect shall invoice Owner monthly based upon progress made on services to date. Submittals shall be made at conclusion of Schematic
Design Development and Construction Documents Phases. Monthly billings shall not exceed the aggregate percentages as set forth below.
for basic services. Additional services shall be invoiced in accordance with percent completion and shall not be limited to these
percentages.
Schematic Design Phase:
Design Development Phase:
Construction Documents Phase:
percent ( 10%)
percent ( 15 %)
percent ( 45 % )
percent ( 3 %)
percent ( 27%)
Bidding or Negotiation Phase:
Construction Phase:
Total Basic Compensation:
one hundred percent (100%)
11.3 COMPENSATION FOR ADDITIONAL SERVICES
11.3.1 FOR PROJECT REPRESENTATION BEYOND BASIC SERVICES, as described in Paragraph 3.2, compensation shall be com-
puted as follows:
NO WORK MAY BE PERFORMED UNDER THIS CATEGORY OF SERVICES EXCEPT AS BY WRITTEN
AUTHORIZATION FROM CITY.
SEE ARTICLE 12 AND ATTACHMENT 'A'.
11.3.2 FOR ADDITIONAL SERVICES OF THE ARCHITECT, as described in Articles 3 and 12, other than (1) Additional Project
Representation, as described in Paragraph 3.2, and (2) services included in Article 12 as part of Additional Services, but excluding ser-
vices of consultants, compensation shall be computed as follows:
(Insert basis of compensation, including rates and/or multiples of Direcl Persomrel Expe7lSe for Prim:ipals and employees, and identify Principals and class.fy
employees. if required. Identlfv speCIfic se,'vices to which particular methods of compensation apply, If necessary)
NO WORK MAY BE PERFORMED UNDER THIS CATEGORY OF SERVICES EXCEPT AS BY WRITTEN
AUTHORIZATION FROM CITY.
SEE ARTHICLE 12 AND ATTACHMENT 'A'.
11.3.3 FOR ADDITIONAL SERVICES OF CONSULTANTS, including additional structural, mechanical and electrical engineering
services and those provided under Subparagraph 3.4.19 or identified in Article 12 as part of Additional Services, a multiple of
ONE AND ONE TENTH ( 1.1) times the amounts billed to the Architect for such services.
(Identify speCIfic types of consultants in Article J 2, if required)
11.4 REIMBURSABLE EXPENSES
11.4.1 FOR REIMBURSABLE EXPENSES, as described in Paragraph 10.2, and any other items included in Article 12 as Reimbursable
Expenses, a multiple of ONE AND ONE TENTH 1 .1 ) times the expenses incurred by the Architect, the Architect's
employees and consultants in the interest of the Project.
11.5 ADDITIONAL PROVISIONS
11.5.1 IF THE BASIC SERVICES covered by this Agreement have not been completed within EIGHTEEN
( 18 ) months of the date hereof, through no fault of the Architect, extension of the Architect's services beyond that time shall be
compensated as provided in Subparagraphs 10,3.3 and 11.3.2.
11.5.2 Payments are due and payable FIFTEEN 15 ) days from the date of the Architect's invoice.
Amounts unpaid TH I RTY ( 30 ) days after the invoice date shall bear interest at the rate entered below, or
in the absence thereof at the legal rate prevailing from time to time at the principal place of business of the Architect.
(Jnsertrateofinterestagreedupon) ONE AND ONE-HALF PERCENT (1.5%) PER MONTH
(Usury laws and requirements under the Federal Truth in Lending Act, similar state and local consumer credit laws and other regulations at the Ou'ner's and Archi-
tecl's principal places of business, the location of the Project and elsewhere may affect the vatidity of this prol'ision. Specific legal adl'ice should be obtained with
respeClto deletio7lS or modIfications, and also regarding requirements such as wriUen disclosures or waivers)
9 8141-1987
AlA DOCUMENT 8141 . OWNER-ARCHITECT AGREEMENT. FOURTEENTH EDITION . AIA~ . @I987
THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006
I
,
11.5.3 The rates and multiples set forth for Additional Services shaH be annually adjusted in accordance with normal salary review
practices of the Architect. . .
ARTICLE 12
OTHER CONDITIONS OR SERVICES
(Insert descrrptions of otber serr'ices, ide7llify Additional Ser!'ices included u'ilbin Basic Compr!7/Salioll alld mod/ficaliolls 10 tbe pal'mt'1lt a/ld compellsatioll terms
included il7 Ihis Agreeme7ll.) ,
The following items (12.1 - 12.5) are to be performed as basic services.
12.1 Add: 12.6.5 For the purpose of this agreement, Architect shall visit the site no less than once
weekly, provided work is progressing on the project.
12.2 Add: 12.1.11
Such testing as required by ;the Architect shall be with prior review and
approval by the Owner.
12.3 Add: 14.5
Architect shall assist Owner in acquiring survey by preparing A.I.A. Document
G601 Land Survey Agreement, specifically for this project.
12.4 Add: 14.6
Architect shall assist Owner in acquiring geotechnical report by supplying a
drawing of general locations of soil borings for building bearing capacity,
pavement bearing capacity, and retention pond percolation.
12.5 The basic services fee of $79,500.00 includes mechanical, electrical, plumbing, structural, and civil
engineering services.
12,6 FIXED LIMITS OF CONSTRUCTION COSTS: Architect and Owner agree to endeavor to limit the costs
of this project. The following are those fixed (maximum) project cost limits agreed upon at project
commencement:
Building Cost
Site Work Cost
Project Contingency Reserve
$ 875,000.00
130,000.00
60,000,00
Total Construction Cost
Soft Costs
$1,065,000.00
1 35,000.00
TOTAL PROJECT COST
$1,200,00Q.00
(CONTINUED ON NEXT PAGE)
This Agreement entered into as of the day and year first written above.
(Signatw'e)
9'f;W-
TTERLI + ASSOC. ARCHITECTS, INC.
OWNER CITY OF CLEARWATER, FLORIDA
ELIZABETH M. DEPTULA, CITY MANAGER ROBERT J. BITTERLI ,-- A:I.:A:,' 7RESIQOO':
(Pl'ilJ1ed name and title) f dd .. l' (P'~'lIIe{i 'lame mid litle) -
\see reverse or a ltlona slgnaturesJ
AlA DOCUMENT 8141 . O'V;'!'\ER'ARCHITECT AGREEME!'\T. FOl'RTEE!'\TH EDJTIO~. AJA<< . <S1987
THE AMERICA." 1l"ST1TCTE OF ARCHITECTS. 1-35 !'\E'V;' YORK A\'E!'\l'E. !'\\l:'.. 'V;'ASHl~GTO!'\, DC 20006
B141:-1~81 :'10
,
I
2.
Project Contingency Reserve may be utilized by mutual agreement of Owner and
Architect as circumstances may arise.
Owner may authorize adjustments in this budget as the project proceeds, re-distributing
budgeted items as Owner deems appropriate. Architect shall advise Owner, based
upon "estimates of Construction Cost" as the project design proceeds.
Notes: 1.
12.7 GUARANTEED BID: Architect stipulates that the design of the construction project will be such that
a qualified contractor, to whom the award of contract would otherewise be appropriate, will bid a total
construction cost of $1,035,000 or less; and that in the event that no bidder as described above
submits a bid for $1,035,000 or less, the City may at its sole discression, either :
(a) accept a bid greater than $1,035,000;
(b) negotiate a change order with the Contractor;
(c) allow the Architect to revise plans (such plan revisions to be acceptable to the City) and re-bid the
project; or
(d) terminate Architect's services, with Architect to receive no more than payments made to that date.
12.8 SCHEDULE OF FEES AND SERVICES
I. FEES & SERVICES AND REIMBURSABLE EXPENSES
A. Basic Architectural Services (7.7% of Construction) ............. $79,500.00
(Includes Mechanical, Electrical, Plumbing, Basic Structural, and
Basic Civil Engineering)
ADDITIONAL SERVICES/REIMBURSIBLE EXPENSES
B. Permitting, Environmental Services, "Hurricane Hardening", and
two (2) public meetings. ................................. 15,500.00
C. Land Planning (T,H. Davis, P.A.) . . . . . . . . . . . . . . . . . . . . . . . . . . . .. 4,000.00
D. Acoustics/Sound System (Dave Fagen) ........................ 4,000.00
E.
Reimbursible Expense Allowance
(Maximum, Not to Exceed)
5,000.00
Subtotal $108,000.00
II. OTHER SERVICES/FEES (Outside Contracts)
A. Geotechnical (Allowance) ............................... $ 5,000.00
B. Survey (Allowance) .................................... 15,000.00
C.
Soil/Concrete Testing (Allowance) .d.......................
7.000.00
TOTAL ALL SERVICES AND REIMBURSABLE EXPENSES $135,000.00
12.9 ATTACHMENT 'A' -- HOURLY RATE SCHEDULE
Attest:
Approved as to form and correctness:
M. A. Galbraith,
Senior Assistant
Attorney
~
- "
11 -B14t~1~1~7
3/87
. .r'
( -~
I
f
ATTACHMENT 'A'
January, 1994
STANDARD HOURLY RATE SCHEDULE
PRINCIPAL/ARCHITECT ................................,................., $95.00/HR.
ASSOCIATE ARCHITECT. . . . . . . . , . . . . . . . . . . . . . . . , . . . . . . . . . . . . . . , . . . . . . . . . .. $85.00/HR.
PROJECT MANAGER/SR. DESIGNER ......................,.......",........ $60.00/HR.
SR. DRAFTING/DESIGNER ..."",...........,..........,..."..,....."... $45.00/HR.
DRAFTING ...""......"".......""....,.......,......,............. $35.00/HR.
ADMINISTRATOR .......... . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .. $35.00/HR.
1. Reimbursable expenses charged at 1.1 times their actual expense.
2. Invoices are due upon receipt and shall be paid within 15 days from date of invoice.
3. Unpaid amounts will be charged interest at the rate of 1.5% per month.
4. Claim related depositions and testimony shall be performed by Principal Architects at
the rate of $125.00 per hour.
BITTERLI + ASSOC. ARCHITECTS, INC.
3950 - 3rd Street North
St. Petersburg, FL 33703
AA C01329
813/823-9110 * FAX: 813/822-3634