CM @ RISK PROPOSAL (2)KEYSTONE EXCAVATORS, INC.
371 Scarlet Blvd CUC 1225782
Oldsmar, FL 34677 FPC22-000140
Phone 813-854-2342 Fax 813-854-2993
CM @ Risk Proposal
June 29th, 2026
To: Mr. Craig Wilson
Parks Senior Division Manager
City of Clearwater
100 S. Myrtle Ave., Suite 120
Clearwater, FL 33756
RE: Clearwater Parks & Recreation — Countryside Community Park
City Project No. - TBD
As requested, enclosed is the proposal for site improvements at Countryside
Community Park for a Guaranteed Maximum Price of $1.449.136.15
Scope of Work:
Overall site improvements to include; Pickleball Courts, Exercise Stations, Pond
Construction, and lighting.
Cost Detail:
Description
Amount
Cost of Work
$ 1,291,051.50
Subtotal
$ 1,291,051.50
General Conditions (Bond)
$ 26,345.00
Contingency _10_%
$ 131,739.65
Guaranteed Maximum Price
$ 1,449,136.15
Project Duration shall be _145_ calendar days from the date of the Notice to Proceed.
KEYSTONE EXCAVATORS, INC.
371 Scarlet Blvd
Oldsmar. FI, 34677
Phone 813-854-2342
CUC 1225782
FPC22-000140
Fax 813-854-2993
Existing Contract This proposal is submitted in conjunction with the existing Construction
Manager at Risk Services Continuing Contract entered into with the City of Clearwater on
October 3 202 based on RFO #51-24.
If GMP Exceeds $150,000: Per Section III, Article 5.1 of the Contract Specifications, the
contractor shall provide to the public entity a certified copy of the recorded bond. Once the City
receives a certified copy of the recorded bond, a Notice to Proceed may be issued. Include the
attached bond form as well as the Power of Attorney.
For work performed, invoices shall be submitted to the City of Clearwater, Parks Department,
Attention: Craig Wilson, 100 S. Myrtle Avenue, Suite 120, Clearwater, Florida, 33756.
Contingency services may be billed only after written authorization is provided by the City to
proceed with those services.
KEYSTONE EXCAVATORS, INC.
By: /
Marcus Epling, Vice Pruden
CITY OF CLEARWATER, FLORIDA
Approved as to form:
elissa Isabel
Senior Assistant City Attorney
Countersigned:
Bruc
Mayor
$"ita 149)
Dat
Attest:
By:
4/3c/z(e
Date
Rosemarie Call
City Clerk
Jeibnrferoirrier
City M ager
9/i )Tho2,(o
Date
Bond No.:
PUBLIC CONSTRUCTION BOND
(1)
This bond is given to comply with § 255.05, Florida Statutes, and any action instituted by a claimant under this bond for
payment must be in accordance with the notice and time limitation provisions in subsections (2) and (10).
Pursuant to § 255.05(1)(b), Florida Statutes, "Before commencing the work or before recommencing the work after a
default or abandonment, the contractor shall provide to the public entity a certified copy of the recorded bond.
Notwithstanding the terms of the contract or any other law governing prompt payment for construction services, the public
entity may not make a payment to the contractor until the contractor has complied with this paragraph."
CONTRACTOR SURETY OWNER
KEYSTONE EXCAVATORS, INC.
371 SCARLET BLVD.
OLDSMAR, FL 34677
813-854-2342
Travelers Casualty and Surety
Company of America
One Tower Square
Hartford, CT 06183
727-258-0808
City of Clearwater
Parks & Recreation Dept
100 S. Myrtle Avenue
Clearwater, FL 33756
(727) 562-4285
PROJECT NAME: Countryside Community Park
PROJECT NO.: TBD
PROJECT DESCRIPTION: Overall site improvements to include; Pickleball Courts, Exercise Stations, Pond
Construction, and lighting.
BY THIS BOND, We, KEYSTONE EXCAVATORS, INC, as Contractor, and Travelers Casualty and Surety
Company of America, a corporation, as Surety, are bound to the City of Clearwater, Florida, herein called Owner, in the
sum of $1,449,136.15, for payment of which we bind ourselves, our heirs, personal representatives, successors, and assigns,
jointly and severally.
THE CONDITION OF THIS BOND is that if Contractor:
1. Performs the proposal dated June 19, 2026, between Contractor and Owner for construction of, the contract
documents being made a part of this bond by reference (which include the Advertisement for Bids, Proposal, Contract,
Surety Bond, Instructions to Bidders, General Conditions, Plans, Technical Specifications and Appendix, and such
alterations as may be made in said Plans and Specifications as therein provided for), at the times and in the manner prescribed
in the contract; and
2. Promptly makes payments to all claimants, as defined in Section 255.05(1), Florida Statutes, supplying Contractor
with labor, materials, or supplies, used directly or indirectly by Contractor in the prosecution of the work provided for in
the contract; and
3. Pays Owner all losses, damages, expenses, costs, and attorney's fees, including appellate proceedings, that Owner
sustains because of a default by Contractor under the contract; and
Bond No.:
PUBLIC CONSTRUCTION BOND
(2)
4. To the limits of § 725.06(2), Florida Statutes, shall indemnify and hold harmless Owner, their officers and
employees, from liabilities, damages, losses and costs, including, but not limited to, reasonable attorney's fees, to the extent
caused by the negligence, recklessness, or intentional wrongful misconduct of Contractor and persons employed or utilized
by Contractor in the performance of the construction contract; and
5. Performs the guarantee of all work and materials furnished under the contract for the time specified in the contract,
then this bond is void; otherwise it remains in full force.
6. Any action instituted by a claimant under this bond for payment must be in accordance with the notice and time
limitation provisions in Section 255.05(2), Florida Statutes.
7. Any changes in or under the contract documents and compliance or noncompliance with any formalities connected
with the contract or the changes does not affect Surety's obligation under this bond, and Surety does hereby waive notice
of any such change, extension of time, alteration or addition to the terms of the contract or to the work or to the specifications.
IN TESTIMONY WHEREOF, witness the hands and seals of the parties hereto this day of
,20 .
(If sole Ownership or Partnership, two (2) Witnesses required).
(If Corporation, Secretary only will attest and affix seal).
Keystone Excavators, Inc.
By:
Title: President
Print Name: Jeff Truxton
WITNESS: WITNESS:
Corporate Secretary or Witness Print Name:
Print Name: Christie Truxton
(affix corporate seal) Travelers Casualty and Surety Company of America
By:
ATTORNEY-IN-FACT
Print Name:
(affix corporate seal)
(Power of Attorney must be attached)