Loading...
51-24 CMAR CONTRACT CONSTRUCTION MANAGER AT RISK (8) Docusign Envelope ID:65A8D10B-445D-4534-82FF-2B602F4F0366 51-24 CMAR Contract Construction Manager at Risk This n r into on this 3rd y of October 2 01y, y and n the C i ty of Clearwater, Florida, municipal corporation, rin r designated the "City" r " r", and CREATIVEINC,_, authorized to do businessi Pinellas County and State of Florida, hereinafter designated as the "Construction Manager". The contracting ii II collectively be known as the "Parti ." WHEREAS, the Clearwater City Council has approvedusing n tructi n Manager at Risk approach n appropriate projectsdetermined ity's Engineering Depar n ; and WHEREAS, the City ites to engage the servicesf the Construction Manager to provide management f the necessary construction, i n, and preconstruction services (collectively referred to as the "Servic " subject rms and conditions set forth in this Contractn n agreement incorporated into i Contract reference; an WHEREAS, the City I cted the Construction Manager in accordance withcompetitive selection r n information and representations giv n by the Construction Manager in a response u for Qualifications (RFQ) 51-24. THEREFORE, IT IS AGREED BY AND BETWEEN THE PARTIES THAT THE ABOVE RECITALS AND REPRESENTATIONS ARE TRUE AND ACCURATE AND ARE INCORPORATED HEREIN BY REFERENCE AND THE PARTIES FURTHER AGREE AS ARTICLE 1: SCOPE OF WORK, CONTRACT DOCUMENTS, AND TERM 1.1 The Construction Manager and its successors, assigns, r administrators, in consideration of the sumsf money, herein after set forth to be paidi Construction n r, shall and will at its own cost andexpense r r ll labor, furnish II materials, tools andequipment for all individual projects assignedresult f this Contract. 1.2 For each individual project assigned, in accordance withsuch proposal and technical supplemental cific tin nsuch r special provisions andr in , if any, is ill be submittedCity, together with anyv i n , instructions to bi r , general cn ii n r I and bond, which may be heretoattached, and anyr in , i any, whichherein referred to, are herebyf this Contract, and all of said work to be performedn completed contractor n its successorsn i n II be fully completed in a good andworkmanlike nn r to the satisfaction of the City. 1.3 Unless otherwise specifiedin this Contract, all work shall be completed in accordance with Section III and Section IV of the City of Clearwater Contract Specifications "Specifications"). For the purposesf this Contract, the termnr c r in Section III shall include n tructi n Manager. The Specifications, n changed, I n ith this Contractconstitute the "Conr c cu n II terms and 1 Docusign Envelope ID:65A8D10B-445D-4534-82FF-2B602F4F0366 conditions set forth in RFQ 51-24, Standard Terms and Conditions are incorporated by reference and attached hereto. Any inconsistency in documents relating tothis Contract shaII be resolved by giving precedence int following order: (i) Proposals(s); (ii) this Contract and any amendments; (iii) Specifications; (iv) RFQ 51-24, Standard Terms and Conditions. 1.4 The term ofthis Contract shall commence upon execution of this Contract by the Parties and shall terminate after completion and acceptance of the Projects as provided herein and upon final payment in accordance with the Contract Documents. ARTICLE ® CONSTRIJ!QTIQN_MANAQEEI_QUIIEIAMQ_§IAIUS 2.1 The Construction Manager recognizes the relationship of trust and confidence established between it and the City by this Contract, and agrees with the City to furnish its best skill and judgment and the overall supervision of its executives; to furnish efficient business administration and superintendence; and to use every effort to keep upon the project site at all times an adequate supply of workforce and materials to secure its execution and completion int most expeditious and economical manner. 2.2 The Construction Manager represents that it has made a thorough examination of the premises and is thoroughly familiar with the conditions under is it is to work. 2.3 The Construction Manager agrees to perform and complete the Services in accordance with laws, rules, and regulations of all governmental authorities and departments thereof. 2.4 The Construction Manager agrees to cooperate with the City, Arch it c - ng in eer, or any other Design Professional in all respects, including, but not limited to, providing necessary precon struction services, such as evaluation of methods, availability and costs of the various components of the Services it under design consideration; supervising the Services and the progress thereof; the coordination oft Services and suggesting changes in the Services; and supplying information as to costs and availability of materials and methods of construction in order, amongst other things, to reduce costs wherever the same may be practicably consistent with the quality of the Services presented int Contract Documents. 2.5 The Construction Manager agrees tot following: a) Inconnection with the performance of work under this Contract, the Construction Manager agrees not to discriminate against any employee or applicant for employment because of race, sex, religion, color, national origin, or any other protected class under federal or state law. The aforesaid provision shall include, but not be limited to, the following employment: - upgrading - demotion or transfer - recruitment or recruitment advertising - lay-off or termination - rates of pay or other forms of compensation;and 2 Docusign Envelope ID:65A8D10B-445D-4534-82FF-2B602F4F0366 - selection for training, including apprenticeship b) The Construction Manager agrees to post hereafter in conspicuous places, available for employees or applicants for employment, notices to be provided by the contracting officer setting forth the provisions of the non-discrimination clause. c) The Construction Manager further agrees to insert the foregoing provisions in all contracts hereunder, including contracts or agreements with labor unions and/or worker's representatives, except sub-contractors for standard commercial supplies or raw materials. ARTICLE 3: SQQPE I QF THE �ERVIQES 3.1 The services that the Construction Manager shall provide include but are not limited to those described in the following sections. 3.2 Reporting. Written reports shall be provided with the monthly pay requests asfollows: a) Monthly Executive Summary which provides an overview of current issues and pending decisions, future developments and expected achievements, and any problems or delays, including code violations found by any permitting agency. b) A Monthly Construction Progress Report that includes a cost narrative, a scheduling narrative and that summarizes the work oft various subcontractors. This report shall include information from the weekly job site meetings as applicable such as: - general conditions - long lead supplies - current deliveries - safety and labor relations programs permits - construction problems and recommendations;and - plans for the succeeding month ® Scheduling a) Upon award ofthis Contract, the Construction Manager shall submit a master project schedule covering the planning and design approvals, construction, and Owner occupancy oft project. This schedule will serve as the framework for the subsequent development of all detailed schedules. The master project schedule shall be produced and updated monthly throughout the project. b) Within thirty (30) days after the date of the Owner's issuance of a Notice to Proceed, the Construction Manager shall prepare and submit tot Owner two copies of a Critical Path Method (CPM) construction schedule graphically depicting the activities contemplated to occur as a necessary incident to performance of the work required to complete the project, showing the sequence in is the Construction Manager proposes for each such activity to occur and duration (dates of commencement and completion, respectively) of each activity. 3 Docusign Envelope ID:65A8D10B-445D-4534-82FF-2B602F4F0366 c} Following developmentn itt I of the construction schedule, the Construction Manager shall, at the endof each calendar month duringproject, or at such earlier intervals as circumstances may require, and/or revise r cti schedule to show the actual progress of the workr the occurrencesof all events which havec o ss of performance of workalready r will affect the progress of the performancef the workyet to be performedin contrast withthe planned s of performancef such work, as depicted on the original construction schedule ll updates and/or revisions ther t s reflected in the updated and/or revised construction sc ul last submitted prior to submittal o c such t ly update andrevision. c such update and/or revision tot construction c ul shall be submitted to the Owner in duplicate. } The Construction Manager shall provide current scheduling information nprovide direction and coordination regarding m!1 to i ni finishing dat , responsibilities for performance and the relationships f the Construction is work to the workf his subcontractors n suppliers to enable them r their respective tasks sot the development of construction ro r s s in a smooth efficient manner in conformance wit the overall project schedule. schedule shall include ll phases of the construction work, material supplies, long lease procurement, approval of shop r in s, change r r in progress, schedules for change orders, and performancetesting requirements. n tructio Manager shall advise the Owner, its representatives n the Architect-Eng i nee r of their required ici ti in any meeting or inspection givin c least one-week notice unless such ti is made impossible by conditions yond his control. The Construction Manager shall hold job- site meetings at least once eachmonth it on tructi n Team and at least nc each week with the subcontractors and the Archit ct- n ineer's Fieldt s nt tiv , r more frequently as required ork progress, to review r r s, discuss problems and their solutions andcoordinate future work with all subcontractors. Twice r month corresponding as closely as possiblei r res review tin , a "two week" look report shall be preparedn submitted to Owner and Architect f Engineer. 3.4 Design ReviewRecommendations a) The ConstructionManager shall familiarize hi s If thoroughly withevolving architectural, civil, mechanical, plumbing, electrical and structural plans and specifications n ll follow the development of design through Contract Documents. The Construction Manager shall make recommendations i respect to the selection o systems and materials, and cost reducing It rn tiv s including is nc o the Arch itect-Eng ineer and Owner in evaluating alternativecomparisons v r s long term cost effect. The evaluationll speak to the benefits of the speed of erection and early completion of the project. The Construction Manager shall furnish pertinent information as to the availability of materialsn labor that will be required. tru i n Manager shall submit to the Owner and Architect-Eng inee r suc comments s may be appropriate concerning construction, feasibility, and practicality. The Construction Manager shall bring to the Owner and the Architect-Engineer's attentionany apparent Docusign Envelope ID:65A8D10B-445D-4534-82FF-2B602F4F0366 defects in the design, drawing and specifications, or other documents. The Construction Manager shall prepare an estimate of the construction cost at appropriate milestones during the design and shall evaluate such estimate with the project budget. The Construction Manager shall recommend cost saving alternatives, as appropriate, at each design milestone. At each design milestone the Owner, Architect Engineer and Construction Manager shall conduct a value engineering review. b) After receiving the Construction Documents for each phase oft project, the Construction Manager shall perform a specific review thereof. Promptly after completion oft review,the Construction Manager shall submit to the Owner, with a duplicate to the Arch it c - ineer, a written report covering suggestions or recommendations previously submitted, additional suggestions or recommendations as the Construction Manager may deem appropriate, and all actions taken by the Arch itect-Eng ineer with respect to same, any comments he may deem to be appropriate with respect to separating the work into separate contracts and/or alternative materials. c) At completion of the Construction Manager's review of the plans and specifications, except only as to specific matters as may be identified by appropriate comments pursuant to this section, the Construction Manager shall warrant, without assuming any architectural or engineering responsibility, that the plans and specifications are consistent, practical,feasible and constructible. The Construction Manager shall warrant that the work described in the plans and specifications for the various bidding packages is constructible within the scheduled construction time. d) The Construction Manager shall review the design for the purpose of identifying long lead procurement it (i.e. machinery, equipment, materials, and supplies). When each it is identified, the Construction Manager shall notify the subcontractors, the Owner, and the Arch itect-Eng in of the required procurement and schedule. Such information shall be included int bid documents and made a part of all affected sub- contracts. As soon as the Arch itect-Eng in r has completed drawings and technical specifications and the Construction Manager has obtained permitting approval, the Construction Manager shall prepare invitations for bids. The Construction Manager shall keep informed of the progress of the respective subcontractors or suppliers, manufacturing or fabricating such items and advise Project Director, Owner and Arch itect-Eng ineer of any problems or prospective delay in delivery. 3.5 Staffing. Key personnel assigned to City projects by the Construction Manager shall not be removed from the project until alternate personnel acceptable tot City are approved in writing by the City. 3.6 Soliciting Bids a) Without assuming responsibilities of the Architect-Engineer, and unless waived in writing by the Owner, the Construction Manager shall prepare invitations for bids, or requests for proposal when applicable, for all procurements of long lead items, materials and services, and for Subcontractor contracts. Such invitations for bids shall be prepared in accordance with the following guidelines: 5 Docusign Envelope ID:65A8D10B-445D-4534-82FF-2B602F4F0366 i) Contracts totaling $1,000 but not exceeding $10,000 may be entered into by the Construction Manager with the firm is is qualified and submits the lowest verbal quotation. The Construction Manager shall obtain a minimum of two (2) verbal quotations. These quotationss ll be entered on a bid tabulation sheet and a copy of such tabulation sent tot Owner, Arch itect-Eng r and to each firm. Thesuccessful quotation shall be confirmed by written contract or purchase order to the low bid firm defining the scope and quality of work to be provided. ii) Contracts totaling $10,000 but not exceeding $200,000 may be entered into by the Construction Manager with the firm who is qualified and submits the lowest responsive proposal. The Construction Manager shall request at least three (3) firms to submit sealed written proposals based on written drawings and/or specifications. The written proposals shall all be opened publicly at the location, date and time named by the Construction Manager in his request for proposal. A tabulation of the results shall be furnished to the Owner, Arch itect-Engineer and to each firm. iii) Contracts totaling $200,000 but not exceeding $500,000 may be entered into by the Construction Manager with the firm who is pre-qualified and submits the lowest responsive proposal. The Construction Manager shall advertise these projects at least once with the last advertisement appearing at least 21 calendar days prior to the established bid opening date. These proposals shall be based on approved plans and specifications. Bids shall be received and opened publicly at the location, date and time established int bid advertisement. iv) Contracts totaling $500,000 or greater shall be treated the same as described under iii above except that the advertisement shall be run for at least 30 days prior tot established bid opening and at least 5 days prior to any scheduled pre-bid conference. v) Individual purchases of materials or rentals or leases of equipment of up to $999.99 each may be made without bids or quotes when reasonably necessary to expedite work on the project; however, the Construction Manager shall not divide ors r t rocurement in order to avoid the requirements set forth above. A) Site utilities may be acquired at market rates from the entity(ies) providing such int franchise area. b) For each separate construction contract exceeding $35,000, the Construction Manager shall, unless waived by Owner, conduct a pre-bid conference with prospective bidders, the Arch it c - I nee r, and the Owner. Int event questions are raised which require an interpretation of the bidding documents or otherwise indicate a need for clarification or correction oft invitation, the Construction Manager shall transmit these to the Arch itect-Engineer and upon receiving clarification or correction in writing shall prepare an addendum to the bidding document, and issue same to all oft prospective bidders. 3.7 Quality Control. The Construction Manager shall develop and maintain a program, 6 t Docusign Envelope ID:65A8D10B-445D-4534-82FF-2B602F4F0366 acceptable to the Owner and Arch itect-Eng I nee r that assures quality control of the construction. The Construction Manager shall supervise the work of all subcontractors providing instruction to each when their work does not conform to the requirements of the plans and specifications and shall continue to assert influence and control over each subcontractor to ensure that corrections are made in a timely manner so as to not affect the efficient progress of the work. Should disagreement occur between the Construction Manager, the Owner or the Arch itect-Engineer over acceptability of work and conformance with the requirements of the specifications and plans, the Owner shall be the final judge of performance and acceptability. 3.8 Subcontractor Interfacing. The Construction Manager shall be the single point of interface with all subcontractors for any work done under this Contract. The Construction Manager shall negotiate all change orders, field orders and request for proposals, with all affected subcontractors and shall review the costs ofthose proposals and advise the Owner and Arch itect-Engi neer of it validity and reasonableness, acting in the Owner's best interest prior to requesting approval of each change order from the Owner. Before any work is begun on any change order, a written authorization from the Owner must be issued. When health and safety are threatened, however, the Construction Manager shall act immediately to remove such threat to health and safety. The Construction Manager shall also carefully review all shop drawings and then forward the same tot Arch itect-Engineer for review and actions. The Arch itect-Eng ineer will transmit them back to the Construction Manager who will then issue the shop drawings to the affected subcontractor for fabrication or revision. The Construction Manager shall maintain a record to promote expeditious handling. The Construction Manager shall request the Arch itect-Engin r to make interpretations of the drawings orspecifications requested of him by the subcontractors and shall maintain a record to promote timely response. The Construction Manager shall advise the Owner and Arch itect-Eng ineer when timely response is not occurring on any oft above. The Construction Manager shall collect, review, and submit to the Owner, all project closeout documentation including operation, maintenance, and training manuals. ARTICLE 4: MAXIMUM PROJECT COST AND FEES FOR SERVICES 4.1 Guaranteed Maximum Price for Construction a) When the Construction Documents are sufficiently complete to establish the scope of work for the project or any portion thereof, the Construction Manager will establish and submit in writing tot Owner for his approval a Guaranteed Maximum Price (GMP) guaranteeing the maximum price to the Owner, for the construction cost of the project or designated part thereof. Such Guaranteed Maximum Price will be subject to modification for changes in the project as provided in article 4.1(e) below. Actual price paid for the work by the Owner, however, shall be the actual cost of all or subcontracts, supply contracts, direct labor costs, direct supervision costs and direct job costs, plus the Construction Manager's fees or the GMP, whichever is less when the work is complete. Invoicing shall occur monthly for completed work with 5% retainage withheld until final completion and acceptance of all or covered in the contract documents in accordance with the City's General Conditions. GMP Proposals will be incorporated by reference 7 Docusign Envelope ID:65A8D10B-445D-4534-82FF-2B602F4F0366 and attached hereto as exhibits. b) At the time of submission of a Guaranteed Maximum Price, the Construction Manager will verify the time schedule for activities and work which were adopted and used to determine the Construction Manager's cost of work. In addition to the cost of work, a GMP will include an agreed upon sum as the construction contingency which is included for the purpose of defraying the expenses due to unforeseen circumstances relating to construction. The Construction Manager will be required to furnish documentation evidencing expenditures charged to the contingency prior to the release of funds by the Owner. If bids are received below the applicable line items in the GMP, the surplus will be added to the contingency. c) If bids are received above the applicable line item in the GMP, the deficiency will be taken from the contingency; however, such occurrence shall not be cause to increase the GMP. d) If bids are not received for a portion of the work at or below the applicable line item amount in the GMP, the Construction Manager reserves the right to perform that portion of the work as acknowledged by the Owner or negotiate for its performance for the specified line item lump sum amount or less. e) The increase or decrease in the Guaranteed Maximum Price resulting from a change in the project shall be determined in one or more of the following ways: i. By mutual acceptance of a lump sum properly itemized and supported by sufficient substantiating data to permit evaluation by the Architect-Engineer and Owner; H. By unit prices stated in the agreement or subsequently agreed upon; iii. If none of the methods is agreed upon, the Construction Manager, provided it has received a signed written order by the Owner, shall promptly proceed with the work involved. The cost of such work shall then be determined on the basis of the reasonable expenditures and savings of those performing the work attributed to the change. In the event a change order is issued under these conditions, however, the Architect-Engineer will establish an estimated cost of the work and the Construction Manager shall not perform any work whose cost exceeds that estimate without prior written approval by the Owner. In such case, the Construction Manager shall keep and present, in such form as the Owner may prescribe, an itemized accounting together with appropriate supporting data of the increase in the cost of the project. The amount of decrease in the Guaranteed Maximum Price to be allowed by the Construction Manager to the Owner for any deletion or change which results in a net decrease in cost will be the amount of the actual net decrease; iv. The Architect-Engineer will have authority to order minor changes in the project not involving an adjustment in the Guaranteed Maximum Price or an extension of the Construction Completion Date and not inconsistent with the intent of the 8 Docusign Envelope ID:65A8D10B-445D-4534-82FF-2B602F4F0366 Drawings and Specifications. Such changes shall be affected by written order. Documentation of changes shall be determined by the Arch it c ® ineer. Changes shall be approved by the Architect-Engineer. 4.2 Construction Manager's Fee. Inconsideration of the performance of the contract, the Owner agrees to pay the Construction Manager as compensation for his services, fees as set forth below: Precon&LrUctIpnPhag_q Fq _ 1. This fee shall be based on design costs if applicable, constructabilii y review, value engineering and fee determination of Guaranteed Maximum Price. The fee for this phase into amount of J.LBQ shall be paid at the negotiated price upon receipt of the Guaranteed Maximum Price. Preconstruction Service Proposals will be incorporated by reference and attached hereto as exhibits. gons ction Phase Fee. Prior to commencement of the Construction Phase, the Owner will direct the Construction Manager in writing to proceed into the Construction Phase. The Construction Manager's compensation for work or service performed during the Construction Phase shall be a fee of The Construction Phase Fee shall be invoiced and paid in TBD months. Payments will be remitted monthly at the cost of each and one final monthly payment of The first monthly payment shall become due thirty days following the issuance of the first Construction Authorization and the final monthly payment shall be paid only when construction of the project is completed and occupancy of the project accepted by the Owner. If construction is authorized only for a part oft project, the fee paid shall be proportionate to the amount of work authorized by the Owner. ARTICLE 5: TERMINATION AND TIME OF THE ESSENCE 5.1 If the Construction Manager is adjudged bankrupt or makes a general assignment for the benefit of creditors, or if a receiver is appointed on account of its insolvency, or if refuses or fails, except in cases for is an extension of time is provided, to supply enough properly skilled workmen or proper materials for the Services, or otherwise be guilty of a substantial violation of any provision of this Contract as determined by the certificate of the Architect, the Owner may, without prejudice and reserving any other right or remedy the Owner may have, after giving the Construction Manager seven (7) days' written notice, terminate this Contract with the Construction Manager and take possession of the premises and all materials, tools, and appliances thereon and finish the project in whatever manner the Owner may deem expedient. The City may also terminate this Contract pursuant to Article 15, Section III of the Contract Specifications. 52 It is mutually agreed between the Parties hereby that time is of the essence of this Contract, and int event that the Substantial Completion Date is not achieved within the time stipulated herein, it is then further agreed that the City may deduct from such sums or compensation as may be due tot Construction Manager, the sum of$1,,Q00.00,,R1LdU for each day that the work to be performed by the Construction Manager remains incomplete beyond the time limit specified herein, is sum Of$1.000.00-Der day shall only and solely represent damages is the City has sustained by reason of the failure of 9 Docusign Envelope ID:65A8D10B-445D-4534-82FF-2B602F4F0366 the Construction Manager to complete the work within the time stipulated, it being further agreed that the sum is not to be construed as a penalty but is only to be construed as liquidated damages for failure of the Construction Manager to complete and perform all work within the time period as specified in this Contract. ARTICLE 6: INDEMNIFICATION 6.1 To the fullest extent permitted by law, Construction Manager agrees to defend, indemnify, and of the City, its officers, agents, and employees, harmless from and against any and all liabilities, demands, claims, suits, losses, damages, causes of action, fines or judgments, including costs, attorneys', witnesses', and expert witnesses' fees, and expenses incident thereto, relating to, arising out of, or resulting from: (i) the services provided by the Construction Manager, its contractors, subcontractors, agents, employees, or personnel under this Contract; (ii) any negligent acts, errors, mistakes or omissions by Construction Manager, its contractors, subcontractors, agents, employees, or, personnel; and (iii) Construction Manager, its contractors, subcontractors, agents, employees, or personnel failure to comply with or fulfill the obligations established by this Contract. 6.2 The Construction Manager will update the City during the course oft litigation to timely notify the City of any issues that may involve the independent negligence of the City that is not covered by this indemnification. 6.3 The City assumes no liability for actions of Construction Manager and will not indemnify or of Construction Manager or any third party harmless for claims based on this Contract or use of Construction Manager provided supplies orservices. 6.4 Nothing contained herein shall be construed as a waiver of any immunity from or limitation of liability the City (Owner) may be entitled to under the doctrine of sovereign immunity or section 768.28, Florida Statutes. 6.5 This article shall survive the termination ofthis Contract. ARTICLE 7: TITLE TO THE PROJECT 7.1 The title of all work, completed portions of the project and in the course of construction, and of all materials on account of which payment has been made shall be in the Owner. ARTICLE 8: ASSIGNMENT 8.1 This Contract shall be binding upon and inure to the benefit of the Parties hereto and their respective successors and assigns, except that this Contract may not be assigned by either party without the prior written consent of the other party. Any assignment made without such prior written consent shall not vest rights in the assignee. ARTICLE 9: ADDITIONAL PROVISIONS 10 Docusign Envelope ID:65A8D10B-445D-4534-82FF-2B602F4F0366 9.1 This Contract shall be governed by and construed in accordance with the laws of the State of Florida, and the venue for any dispute under this Contract shall be an appropriate court of competent jurisdiction in Pinellas County, Florida. 9.2 Any notice required to be given by the terms and provisions of this Contract or by any law or governmental regulation, either by the Owner or Construction Manager, shall be in writing unless otherwise required by such law or regulation and shall be deemed to have been served and given when deposited in either Registered or Certified Mail in United States Branch Post Office, addressed to the party hereto to whom directed, at the address specified in the Specifications. 9.3 The language in this Contract shall be construed according to its customary meaning within the Florida building industry. Whenever used, the singular shall include the plural, the plural the singular, and the use of any gender shall be applicable to all genders. 9.4 If any provision of the Contract Documents is invalid or unenforceable as against any person or party, the remainder of the Contract Documents and the applicability of such provision to other persons or parties shall not be affected thereby. 9.5 The Parties are acting herein solely as independent contractors. Nothing herein contained will create or be construed as creating a partnership,joint venture, or agency relationship between the Parties. Each Party acknowledges and agrees that it neither has nor will give the appearance or impression of having any legal authority to bind or commit the other Party in any way. Each Party will be solely responsible for all wages, income taxes, worker's compensation, and any other requirements for all personnel it supplies in connection with this Contract. 9.6 The City's performance and obligation to pay under this Contract is contingent upon an annual appropriation by the Clearwater City Council.. 11 Docusign Envelope ID:65A8D10B-445D-4534-82FF-2B602F4F0366 IN WITNESS , the parties hereto have made andof this Contract on the date andr firsti n. (Corporate I FIRM NAME By: Print Name: Alan ot n h Title: Chief f3perating Officer WITNESS: By: Print Name: e f t s ey s—Ace t,o Countersigned: CITY OF CLEARWATER Signed by: Signed by: bmu- Bruce Rector Jennifer Poirrier Mayor City Manager Approved s to form: Attest- as Signed by: DocuSigned by: � 41���I1 , ,�t,VY'b�, Slw�pSbin, Rs�en�.un.iz E-B�AS�F-B�SA�.faG1 - 6x99{a5FEBFFE46 ... __. Jerrod Simpson Rosemarie Call Sr. Assistant City Attorneyit I r 12