The URL can be used to link to this page

CHANGE ORDER NO 1 - VULNERABILITY ASSESSMENT WITH CITY STIMULATOR - 22PLN91CHANGE ORDER No. 1 DEP AGREEMENT No. 22PLN91 VULNERABILITY ASSESSMENT WITH CITY STIMULATOR GRANTEE: City of Clearwater P.O. Box 4748 Clearwater, Florida 33758 This agreement entered into on August 2, 2022, is hereby revised as follows: WHEREAS, the DEPARTMENT has requested an update to Attachment 3 to update the Consequences for Non -Performance; and WHEREAS, the DEPARTMENT has requested an update to Attachment I and Attachment 2 following updates from the Office of the General Counsel. NOW, THEREFORE, in consideration of the mutual benefits to be derived herefrom, the DEPARTMENT and the GRANTEE do hereby agree as follows: 1. Attachment 1, Standard Terms and Conditions, is hereby deleted in its entirety and replaced with Attachment 1-A, Revised Standard Terms and Conditions, attached hereto and made a part of the Agreement. All references in the Agreement to Attachment 1 shall hereinafter refer to Attachment 1-A, Revised Standard Terms and Conditions. 2. Attachment 2, Special Terms and Conditions, is hereby deleted in its entirety and replaced with Attachment 2-A, Revised Special Terms and Conditions, attached hereto and made a part of the Agreement. All references in the Agreement to Attachment 2 shall hereinafter refer to Attachment 2-A, Revised Special Terms and Conditions. 3. Attachment 3, Grant Work Plan is hereby deleted in its entirety and replaced with Attachment 3-A, Revised Grant Work Plan, attached hereto and made a part of the Agreement. All references in the Agreement to Attachment 3 shall hereinafter refer to Attachment 3-A, Revised Grant Work Plan. 4. All other terms and conditions of the Agreement shall remain unchanged. REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK DEP Agreement No. 22PLN91, Change Order No. 1, Page 1 of 2 IN WITNESS WHEREOF,the parties have caused these presents to be duly executed,the day and year,last written below. CITY OF CLEARWATER FLORIDA DEPARTMENT OF ENVIROMENTAL PROTECTION a Hanna TIIIOtSOn Digita Ily signed by Hanna Tillotson By: - By: Date:2022.10.2407:10:51-.VY •7 City Manager Program Administrator l Hanna Tillotson,Program Administrator Print Name and Title — Print Name and Title 10/24/2022 Date: Date: FEID No.: 59-6000289 If someone other than the City Manager signs this Agreement, a resolution, statement or other documentation authorizing that person to sign the Agreement on behalf of the City must accompany the Agreement. List of Attachments/Exhibits included as part of this Agreement: Specify Letter/ Type Number Description(include number of pages) Attachment I-A Revised Standard Terms and Conditions(12 pages) Attachment 2-A Revised Special Terms and Conditions(3 pages) Attachment 3-A Revised Grant Work Plan(5 pages) Approved as to farm: Attest: rz)'�A-7 A- wexa Kehler Rosemarie Call Assistant City Attorney City Clerk j �4 \V DEP Agreement No.22PLN91,Change Order No. 1,Page 2 of 2 STATE OF FLORIDA DEPARTMENT OF ENVIRONMENTAL PROTECTION REVISED STANDARD TERMS AND CONDITIONS APPLICABLE TO GRANT AGREEMENTS ATTACHMENT 1-A 1. Entire Agreement. This Grant Agreement, including any Attachments and Exhibits referred to herein and/or attached hereto (Agreement), constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, whether written or oral, with respect to such subject matter. Any terms and conditions included on Grantee's forms or invoices shall be null and void. 2. Grant Administration. a. Order of Precedence. If there are conflicting provisions among the documents that make up the Agreement, the order of precedence for interpretation of the Agreement is as follows: i. Standard Grant Agreement ii. Attachments other than Attachment 1, in numerical order as designated in the Standard Grant Agreement iii. Attachment 1, Standard Terms and Conditions iv. The Exhibits in the order designated in the Standard Grant Agreement b. All approvals, written or verbal, and other written communication among the parties, including all notices, shall be obtained by or sent to the parties' Grant Managers. All written communication shall be by electronic mail, U.S. Mail, a courier delivery service, or delivered in person. Notices shall be considered delivered when reflected by an electronic mail read receipt, a courier service delivery receipt, other mail service delivery receipt, or when receipt is acknowledged by recipient. If the notice is delivered in multiple ways, the notice will be considered delivered at the earliest delivery time. c. If a different Grant Manager is designated by either party after execution of this Agreement, notice of the name and contact information of the new Grant Manager will be submitted in writing to the other party and maintained in the respective parties' records. A change of Grant Manager does not require a formal amendment or change order to the Agreement. d. This Agreement may be amended, through a formal amendment or a change order, only by a written agreement between both parties. A formal amendment to this Agreement is required for changes which cause any of the following: (1) an increase or decrease in the Agreement funding amount; (2) a change in Grantee's match requirements; (3) a change in the expiration date of the Agreement; and/or (4) changes to the cumulative amount of funding transfers between approved budget categories, as defined in Attachment 3, Grant Work Plan, that exceeds or is expected to exceed twenty percent (20%) of the total budget as last approved by Department. A change order to this Agreement may be used when: (1) task timelines within the current authorized Agreement period change; (2) the cumulative transfer of funds between approved budget categories, as defined in Attachment 3, Grant Work Plan, are less than twenty percent (20%) of the total budget as last approved by Department; (3) changing the current funding source as stated in the Standard Grant Agreement; and/or (4) fund transfers between budget categories for the purposes of meeting match requirements. This Agreement may be amended to provide for additional services if additional funding is made available by the Legislature. e. All days in this Agreement are calendar days unless otherwise specified. 3. Agreement Duration. The term of the Agreement shall begin and end on the dates indicated in the Standard Grant Agreement, unless extended or terminated earlier in accordance with the applicable terms and conditions. The Grantee shall be eligible for reimbursement for work performed on or after the date of execution through the expiration date of this Agreement, unless otherwise specified in Attachment 2, Special Terms and Conditions. However, work performed prior to the execution of this Agreement may be reimbursable or used for match purposes if permitted by the Special Terms and Conditions. Attachment 1-A 1 of 12 Rev. 10/3/2022 4. Deliverables. The Grantee agrees to render the services or other units of deliverables as set forth in Attachment 3, Grant Work Plan. The services or other units of deliverables shall be delivered in accordance with the schedule and at the pricing outlined in the Grant Work Plan. Deliverables may be comprised of activities that must be completed prior to Department making payment on that deliverable. The Grantee agrees to perform in accordance with the terms and conditions set forth in this Agreement and all attachments and exhibits incorporated by the Standard Grant Agreement. 5. Performance Measures. The Grantee warrants that: (1) the services will be performed by qualified personnel; (2) the services will be of the kind and quality described in the Grant Work Plan; (3) the services will be performed in a professional and workmanlike manner in accordance with industry standards and practices; (4) the services shall not and do not knowingly infringe upon the intellectual property rights, or any other proprietary rights, of any third party; and (5) its employees, subcontractors, and/or subgrantees shall comply with any security and safety requirements and processes, if provided by Department, for work done at the Project Location(s). The Department reserves the right to investigate or inspect at any time to determine whether the services or qualifications offered by Grantee meet the Agreement requirements. Notwithstanding any provisions herein to the contrary, written acceptance of a particular deliverable does not foreclose Department's remedies in the event deficiencies in the deliverable cannot be readily measured at the time of delivery. 6. Acceptance of Deliverables. a. Acceptance Process. All deliverables must be received and accepted in writing by Department's Grant Manager before payment. The Grantee shall work diligently to correct all deficiencies in the deliverable that remain outstanding, within a reasonable time at Grantee's expense. If Department's Grant Manager does not accept the deliverables within 30 days of receipt, they will be deemed rejected. b. Rejection of Deliverables. The Department reserves the right to reject deliverables, as outlined in the Grant Work Plan, as incomplete, inadequate, or unacceptable due, in whole or in part, to Grantee's lack of satisfactory performance under the terms of this Agreement. The Grantee's efforts to correct the rejected deliverables will be at Grantee's sole expense. Failure to fulfill the applicable technical requirements or complete all tasks or activities in accordance with the Grant Work Plan will result in rejection of the deliverable and the associated invoice. Payment for the rejected deliverable will not be issued unless the rejected deliverable is made acceptable to Department in accordance with the Agreement requirements. The Department, at its option, may allow additional time within which Grantee may remedy the objections noted by Department. The Grantee's failure to make adequate or acceptable deliverables after a reasonable opportunity to do so shall constitute an event of default. 7. Financial Consequences for Nonperformance. a. Withholding Payment. In addition to the specific consequences explained in the Grant Work Plan and/or Special Terms and Conditions, the State of Florida (State) reserves the right to withhold payment when the Grantee has failed to perform/comply with provisions of this Agreement. None of the financial consequences for nonperformance in this Agreement as more fully described in the Grant Work Plan shall be considered penalties. b. Invoice reduction If Grantee does not meet a deadline for any deliverable, the Department with reduce the invoice by 1% for each day the deadline is missed, unless an extension is approved in writing by the Department. c. Corrective Action Plan. If Grantee fails to correct all the deficiencies in a rejected deliverable within the specified timeframe, Department may, in its sole discretion, request that a proposed Corrective Action Plan (CAP) be submitted by Grantee to Department. The Department requests that Grantee specify the outstanding deficiencies in the CAP. All CAPs must be able to be implemented and performed in no more than sixty (60) calendar days. i. The Grantee shall submit a CAP within ten (10) days of the date of the written request from Department. The CAP shall be sent to the Department's Grant Manager for review and approval. Within ten (10) days of receipt of a CAP, Department shall notify Grantee in writing whether the CAP proposed has been accepted. If the CAP is not accepted, Grantee shall have ten (10) days from receipt of Department letter rejecting the proposal to submit a revised proposed CAP. Failure to obtain Department approval of a CAP as specified above may result in Department's termination of this Agreement for cause as authorized in this Agreement. ii. Upon Department's notice of acceptance of a proposed CAP, Grantee shall have ten (10) days to commence implementation of the accepted plan. Acceptance of the proposed CAP by Department does not relieve Grantee of any of its obligations under the Agreement. In the event the CAP fails to correct or eliminate performance deficiencies by Grantee, Department shall retain the right to Attachment 1-A 2 of 12 Rev. 10/3/2022 require additional or further remedial steps, or to terminate this Agreement for failure to perform. No actions approved by Department or steps taken by Grantee shall preclude Department from subsequently asserting any deficiencies in performance. The Grantee shall continue to implement the CAP until all deficiencies are corrected. Reports on the progress of the CAP will be made to Department as requested by Department's Grant Manager. iii. Failure to respond to a Department request for a CAP or failure to correct a deficiency in the performance of the Agreement as specified by Department may result in termination of the Agreement. 8. Payment. a. Payment Process. Subject to the terms and conditions established by the Agreement, the pricing per deliverable established by the Grant Work Plan, and the billing procedures established by Department, Department agrees to pay Grantee for services rendered in accordance with Section 215.422, Florida Statutes (F.S.). b. Taxes. The Department is exempted from payment of State sales, use taxes and Federal excise taxes. The Grantee, however, shall not be exempted from paying any taxes that it is subject to, including State sales and use taxes, or for payment by Grantee to suppliers for taxes on materials used to fulfill its contractual obligations with Department. The Grantee shall not use Departments exemption number in securing such materials. The Grantee shall be responsible and liable for the payment of all its FICA/Social Security and other taxes resulting from this Agreement. c. Maximum Amount of Agreement. The maximum amount of compensation under this Agreement, without an amendment, is described in the Standard Grant Agreement. Any additional funds necessary for the completion of this Project are the responsibility of Grantee. d. Reimbursement for Costs. The Grantee shall be paid on a cost reimbursement basis for all eligible Project costs upon the completion, submittal, and approval of each deliverable identified in the Grant Work Plan. Reimbursement shall be requested on Exhibit C, Payment Request Summary Form. To be eligible for reimbursement, costs must be in compliance with laws, rules, and regulations applicable to expenditures of State funds, including, but not limited to, the Reference Guide for State Expenditures, which can be accessed at the following web address: https://www.myfloridacfo.com/Division/AA/Manuals/documents/ReferenceGuideforStateExpenditures.pd£ e. Invoice Detail. All charges for services rendered or for reimbursement of expenses authorized by Department pursuant to the Grant Work Plan shall be submitted to Department in sufficient detail for a proper pre -audit and post -audit to be performed. The Grantee shall only invoice Department for deliverables that are completed in accordance with the Grant Work Plan. f. Interim Payments. Interim payments may be made by Department, at its discretion, if the completion of deliverables to date have first been accepted in writing by Departments Grant Manager. g. Final Payment Request. A final payment request should be submitted to Department no later than sixty (60) days following the expiration date of the Agreement to ensure the availability of funds for payment. However, all work performed pursuant to the Grant Work Plan must be performed on or before the expiration date of the Agreement. h. Annual Appropriation Contingency. The State's performance and obligation to pay under this Agreement is contingent upon an annual appropriation by the Legislature. This Agreement is not a commitment of future appropriations. Authorization for continuation and completion of work and any associated payments may be rescinded, with proper notice, at the discretion of Department if the Legislature reduces or eliminates appropriations. i. Interest Rates. All interest rates charged under the Agreement shall be calculated on the prevailing rate used by the State Board of Administration. To obtain the applicable interest rate, please refer to: www.myfloridacfo.com/Division/AA/Vendors/default.htm. j. Refund of Payments to the Department. Any balance of unobligated funds that have been advanced or paid must be refunded to Department. Any funds paid in excess of the amount to which Grantee or subgrantee is entitled under the terms of the Agreement must be refunded to Department. If this Agreement is funded with federal funds and the Department is required to refund the federal government, the Grantee shall refund the Department its share of those funds. 9. Documentation Required for Cost Reimbursement Grant Agreements and Match. If Cost Reimbursement or Match is authorized in Attachment 2, Special Terms and Conditions, the following conditions apply. Supporting documentation must be provided to substantiate cost reimbursement or match requirements for the following budget categories: Attachment 1-A 3of12 Rev. 10/3/2022 a. Salary/Wages. Grantee shall list personnel involved, position classification, direct salary rates, and hours spent on the Project in accordance with Attachment 3, Grant Work Plan in their documentation for reimbursement or match requirements. b. Overhead/Indirect/General and Administrative Costs. If Grantee is being reimbursed for or claiming match for multipliers, all multipliers used (i.e., fringe benefits, overhead, indirect, and/or general and administrative rates) shall be supported by audit. If Department determines that multipliers charged by Grantee exceeded the rates supported by audit, Grantee shall be required to reimburse such funds to Department within thirty (30) days of written notification. Interest shall be charged on the excessive rate. c. Contractual Costs (Subcontractors). Match or reimbursement requests for payments to subcontractors must be substantiated by copies of invoices with backup documentation identical to that required from Grantee. Subcontracts which involve payments for direct salaries shall clearly identify the personnel involved, salary rate per hour, and hours spent on the Project. All eligible multipliers used (i.e., fringe benefits, overhead, indirect, and/or general and administrative rates) shall be supported by audit. If Department determines that multipliers charged by any subcontractor exceeded the rates supported by audit, Grantee shall be required to reimburse such funds to Department within thirty (30) days of written notification. Interest shall be charged on the excessive rate. Nonconsumable and/or nonexpendable personal property or equipment costing $5,000 or more purchased for the Project under a subcontract is subject to the requirements set forth in Chapters 273 and/or 274, F.S., and Chapter 691-72, Florida Administrative Code (F.A.C.) and/or Chapter 691-73, F.A.C., as applicable. The Grantee shall be responsible for maintaining appropriate property records for any subcontracts that include the purchase of equipment as part of the delivery of services. The Grantee shall comply with this requirement and ensure its subcontracts issued under this Agreement, if any, impose this requirement, in writing, on its subcontractors. i. For fixed-price (vendor) subcontracts, the following provisions shall apply: The Grantee may award, on a competitive basis, fixed-price subcontracts to consultants/contractors in performing the work described in Attachment 3, Grant Work Plan. Invoices submitted to Department for fixed- price subcontracted activities shall be supported with a copy of the subcontractor's invoice and a copy of the tabulation form for the competitive procurement process (e.g., Invitation to Bid, Request for Proposals, or other similar competitive procurement document) resulting in the fixed-price subcontract. The Grantee may request approval from Department to award a fixed-price subcontract resulting from procurement methods other than those identified above. In this instance, Grantee shall request the advance written approval from Department's Grant Manager of the fixed price negotiated by Grantee. The letter of request shall be supported by a detailed budget and Scope of Services to be performed by the subcontractor. Upon receipt of Department Grant Manager's approval of the fixed-price amount, Grantee may proceed in finalizing the fixed-price subcontract. ii. If the procurement is subject to the Consultant's Competitive Negotiation Act under section 287.055, F.S. or the Brooks Act, Grantee must provide documentation clearly evidencing it has complied with the statutory or federal requirements. d. Travel. All requests for match or reimbursement of travel expenses shall be in accordance with Section 112.061, F.S. e. Direct Purchase Equipment. For the purposes of this Agreement, Equipment is defined as capital outlay costing $5,000 or more. Match or reimbursement for Grantee's direct purchase of equipment is subject to specific approval of Department, and does not include any equipment purchased under the delivery of services to be completed by a subcontractor. Include copies of invoices or receipts to document purchases, and a properly completed Exhibit B, Property Reporting Form. f. Rental/Lease of Equipment. Match or reimbursement requests for rental/lease of equipment must include copies of invoices or receipts to document charges. g. Miscellaneous/Other Expenses. If miscellaneous or other expenses, such as materials, supplies, non-excluded phone expenses, reproduction, or mailing, are reimbursable or available for match or reimbursement under the terms of this Agreement, the documentation supporting these expenses must be itemized and include copies of receipts or invoices. Additionally, independent of Grantee's contract obligations to its subcontractor, Department shall not reimburse any of the following types of charges: cell phone usage; attorney's fees or court costs; civil or administrative penalties; or handling fees, such as set percent overages associated with purchasing supplies or equipment. h. Land Acquisition. Reimbursement for the costs associated with acquiring interest and/or rights to real property (including access rights through ingress/egress easements, leases, license agreements, or other site access agreements; and/or obtaining record title ownership of real property through purchase) must be supported by the following, as applicable: Copies of Property Appraisals, Environmental Site Assessments, Surveys and Legal Attachment 1-A 4of12 Rev. 10/3/2022 Descriptions, Boundary Maps, Acreage Certification, Title Search Reports, Title Insurance, Closing Statements/Documents, Deeds, Leases, Easements, License Agreements, or other legal instrument documenting acquired property interest and/or rights. If land acquisition costs are used to meet match requirements, Grantee agrees that those funds shall not be used as match for any other Agreement supported by State or Federal funds. 10. Status Reports. The Grantee shall submit status reports quarterly, unless otherwise specified in the Attachments, on Exhibit A, Progress Report Form, to Department's Grant Manager describing the work performed during the reporting period, problems encountered, problem resolutions, scheduled updates, and proposed work for the next reporting period. Quarterly status reports are due no later than twenty (20) days following the completion of the quarterly reporting period. For the purposes of this reporting requirement, the quarterly reporting periods end on March 31, June 30, September 30 and December 31. The Department will review the required reports submitted by Grantee within thirty (30) days. 11. Retainage. The following provisions apply if Department withholds retainage under this Agreement: a. The Department reserves the right to establish the amount and application of retainage on the work performed under this Agreement up to the maximum percentage described in Attachment 2, Special Terms and Conditions. Retainage may be withheld from each payment to Grantee pending satisfactory completion of work and approval of all deliverables. b. If Grantee fails to perform the requested work, or fails to perform the work in a satisfactory manner, Grantee shall forfeit its right to payment of the retainage associated with the work. Failure to perform includes, but is not limited to, failure to submit the required deliverables or failure to provide adequate documentation that the work was actually performed. The Department shall provide written notification to Grantee of the failure to perform that shall result in retainage forfeiture. If the Grantee does not correct the failure to perform within the timeframe stated in Department's notice, the retainage will be forfeited to Department. c. No retainage shall be released or paid for incomplete work while this Agreement is suspended. d. Except as otherwise provided above, Grantee shall be paid the retainage associated with the work, provided Grantee has completed the work and submits an invoice for retainage held in accordance with the invoicing procedures under this Agreement. 12. Insurance. a. Insurance Requirements for Sub -Grantees and/or Subcontractors. The Grantee shall require its sub -grantees and/or subcontractors, if any, to maintain insurance coverage of such types and with such terms and limits as described in this Agreement. The Grantee shall require all its sub -grantees and/or subcontractors, if any, to make compliance with the insurance requirements of this Agreement a condition of all contracts that are related to this Agreement. Sub -grantees and/or subcontractors must provide proof of insurance upon request. b. Deductibles. The Department shall be exempt from, and in no way liable for, any sums of money representing a deductible in any insurance policy. The payment of such deductible shall be the sole responsibility of the Grantee providing such insurance. c. Proof of Insurance. Upon execution of this Agreement, Grantee shall provide Department documentation demonstrating the existence and amount for each type of applicable insurance coverage prior to performance of any work under this Agreement. Upon receipt of written request from Department, Grantee shall furnish Department with proof of applicable insurance coverage by standard form certificates of insurance, a self- insured authorization, or other certification of self-insurance. d. Duty to Maintain Coverage. In the event that any applicable coverage is cancelled by the insurer for any reason, or if Grantee cannot get adequate coverage, Grantee shall immediately notify Department of such cancellation and shall obtain adequate replacement coverage conforming to the requirements herein and provide proof of such replacement coverage within ten (10) days after the cancellation of coverage. e. Insurance Trust. If the Grantee's insurance is provided through an insurance trust, the Grantee shall instead add the Department of Environmental Protection, its employees, and officers as an additional covered party everywhere the Agreement requires them to be added as an additional insured. 13. Termination. a. Termination for Convenience. When it is in the State's best interest, Department may, at its sole discretion, terminate the Agreement in whole or in part by giving 30 days' written notice to Grantee. The Department shall notify Grantee of the termination for convenience with instructions as to the effective date of termination or the specific stage of work at which the Agreement is to be terminated. The Grantee must submit all invoices for work to be paid under this Agreement within thirty (30) days of the effective date of termination. The Department shall not pay any invoices received after thirty (30) days of the effective date of termination. Attachment 1-A 5 of 12 Rev. 10/3/2022 b. Termination for Cause. The Department may terminate this Agreement if any of the events of default described in the Events of Default provisions below occur or in the event that Grantee fails to fulfill any of its other obligations under this Agreement. If, after termination, it is determined that Grantee was not in default, or that the default was excusable, the rights and obligations of the parties shall be the same as if the termination had been issued for the convenience of Department. The rights and remedies of Department in this clause are in addition to any other rights and remedies provided by law or under this Agreement. c. Grantee Obligations upon Notice of Termination. After receipt of a notice of termination or partial termination unless as otherwise directed by Department, Grantee shall not furnish any service or deliverable on the date, and to the extent specified, in the notice. However, Grantee shall continue work on any portion of the Agreement not terminated. If the Agreement is terminated before performance is completed, Grantee shall be paid only for that work satisfactorily performed for which costs can be substantiated. The Grantee shall not be entitled to recover any cancellation charges or lost profits. d. Continuation of Prepaid Services. If Department has paid for any services prior to the expiration, cancellation, or termination of the Agreement, Grantee shall continue to provide Department with those services for which it has already been paid or, at Department's discretion, Grantee shall provide a refund for services that have been paid for but not rendered. e. Transition of Services Upon Termination, Expiration, or Cancellation of the Agreement. If services provided under the Agreement are being transitioned to another provider(s), Grantee shall assist in the smooth transition of Agreement services to the subsequent provider(s). This requirement is at a minimum an affirmative obligation to cooperate with the new provider(s), however additional requirements may be outlined in the Grant Work Plan. The Grantee shall not perform any services after Agreement expiration or termination, except as necessary to complete the transition or continued portion of the Agreement, if any. 14. Notice of Default. If Grantee defaults in the performance of any covenant or obligation contained in the Agreement, including, any of the events of default, Department shall provide notice to Grantee and an opportunity to cure that is reasonable under the circumstances. This notice shall state the nature of the failure to perform and provide a time certain for correcting the failure. The notice will also provide that, should the Grantee fail to perform within the time provided, Grantee will be found in default, and Department may terminate the Agreement effective as of the date of receipt of the default notice. 15. Events of Default. Provided such failure is not the fault of Department or outside the reasonable control of Grantee, the following non- exclusive list of events, acts, or omissions, shall constitute events of default: a. The commitment of any material breach of this Agreement by Grantee, including failure to timely deliver a material deliverable, failure to perform the minimal level of services required for a deliverable, discontinuance of the performance of the work, failure to resume work that has been discontinued within a reasonable time after notice to do so, or abandonment of the Agreement; b. The commitment of any material misrepresentation or omission in any materials, or discovery by the Department of such, made by the Grantee in this Agreement or in its application for funding; c. Failure to submit any of the reports required by this Agreement or having submitted any report with incorrect, incomplete, or insufficient information; d. Failure to honor any term of the Agreement; e. Failure to abide by any statutory, regulatory, or licensing requirement, including an entry of an order revoking the certificate of authority granted to the Grantee by a state or other licensing authority; f. Failure to pay any and all entities, individuals, and furnishing labor or materials, or failure to make payment to any other entities as required by this Agreement; g. Employment of an unauthorized alien in the performance of the work, in violation of Section 274 (A) of the Immigration and Nationality Act; h. Failure to maintain the insurance required by this Agreement; i. One or more of the following circumstances, uncorrected for more than thirty (30) days unless, within the specified 30 -day period, Grantee (including its receiver or trustee in bankruptcy) provides to Department adequate assurances, reasonably acceptable to Department, of its continuing ability and willingness to fulfill its obligations under the Agreement: i. Entry of an order for relief under Title 11 of the United States Code; ii. The making by Grantee of a general assignment for the benefit of creditors; iii. The appointment of a general receiver or trustee in bankruptcy of Grantee's business or property; and/or Attachment 1-A 6 of 12 Rev. 10/3/2022 iv. An action by Grantee under any state insolvency or similar law for the purpose of its bankruptcy, reorganization, or liquidation. 16. Suspension of Work. The Department may, in its sole discretion, suspend any or all activities under the Agreement, at any time, when it is in the best interest of the State to do so. The Department shall provide Grantee written notice outlining the particulars of suspension. Examples of reasons for suspension include, but are not limited to, budgetary constraints, declaration of emergency, or other such circumstances. After receiving a suspension notice, Grantee shall comply with the notice. Within 90 days, or any longer period agreed to by the parties, Department shall either: (1) issue a notice authorizing resumption of work, at which time activity shall resume; or (2) terminate the Agreement. If the Agreement is terminated after 30 days of suspension, the notice of suspension shall be deemed to satisfy the thirty (30) days' notice required for a notice of termination for convenience. Suspension of work shall not entitle Grantee to any additional compensation. 17. Force Majeure. The Grantee shall not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of Grantee or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond Grantee's control, or for any of the foregoing that affect subcontractors or suppliers if no altemate source of supply is available to Grantee. In case of any delay Grantee believes is excusable, Grantee shall notify Department in writing of the delay or potential delay and describe the cause of the delay either (1) within ten days after the cause that creates or will create the delay first arose, if Grantee could reasonably foresee that a delay could occur as a result; or (2) if delay is not reasonably foreseeable, within five days after the date Grantee first had reason to believe that a delay could result. THE FOREGOING SHALL CONSTITUTE THE GRANTEE'S SOLE REMEDY OR EXCUSE WITH RESPECT TO DELAY. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages, other than for an extension of time, shall be asserted against Department. The Grantee shall not be entitled to an increase in the Agreement price or payment of any kind from Department for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist Grantee shall perform at no increased cost, unless Department determines, in its sole discretion, that the delay will significantly impair the value of the Agreement to Department, in which case Department may: (1) accept allocated performance or deliveries from Grantee, provided that Grantee grants preferential treatment to Department with respect to products subjected to allocation; (2) contract with other sources (without recourse to and by Grantee for the related costs and expenses) to replace all or part of the products or services that are the subject of the delay, which purchases may be deducted from the Agreement quantity; or (3) terminate Agreement in whole or in part. 18. Indemnification. a. The Grantee shall be fully liable for the actions of its agents, employees, partners, or subcontractors and shall fully indemnify, defend, and hold harmless Department and its officers, agents, and employees, from suits, actions, damages, and costs of every name and description arising from or relating to: i. personal injury and damage to real or personal tangible property alleged to be caused in whole or in part by Grantee, its agents, employees, partners, or subcontractors; provided, however, that Grantee shall not indemnify for that portion of any loss or damages proximately caused by the negligent act or omission of Department; ii. the Grantee's breach of this Agreement or the negligent acts or omissions of Grantee. b. The Grantee's obligations under the preceding paragraph with respect to any legal action are contingent upon Department giving Grantee: (1) written notice of any action or threatened action; (2) the opportunity to take over and settle or defend any such action at Grantee's sole expense; and (3) assistance in defending the action at Grantee's sole expense. The Grantee shall not be liable for any cost, expense, or compromise incurred or made by Department in any legal action without Grantee's prior written consent, which shall not be unreasonably withheld. c. Notwithstanding sections a. and b. above, the following is the sole indemnification provision that applies to Grantees that are governmental entities: Each party hereto agrees that it shall be solely responsible for the negligent or wrongful acts of its employees and agents. However, nothing contained herein shall constitute a waiver by either party of its sovereign immunity or the provisions of Section 768.28, F.S. Further, nothing herein shall be construed as consent by a state agency or subdivision of the State to be sued by third parties in any matter arising out of any contract or this Agreement. Attachment 1-A 7of12 Rev. 10/3/2022 d. No provision in this Agreement shall require Department to hold harmless or indemnify Grantee, insure or assume liability for Grantee's negligence, waive Department's sovereign immunity under the laws of Florida, or otherwise impose liability on Department for which it would not otherwise be responsible. Any provision, implication or suggestion to the contrary is null and void. 19. Limitation of Liability. The Department's liability for any claim arising from this Agreement is limited to compensatory damages in an amount no greater than the sum of the unpaid balance of compensation due for goods or services rendered pursuant to and in compliance with the terms of the Agreement. Such liability is further limited to a cap of $100,000. 20. Remedies. Nothing in this Agreement shall be construed to make Grantee liable for force majeure events. Nothing in this Agreement, including financial consequences for nonperformance, shall limit Department's right to pursue its remedies for other types of damages under the Agreement, at law or in equity. The Department may, in addition to other remedies available to it, at law or in equity and upon notice to Grantee, retain such monies from amounts due Grantee as may be necessary to satisfy any claim for damages, penalties, costs and the like asserted by or against it. 21. Waiver. The delay or failure by Department to exercise or enforce any of its rights under this Agreement shall not constitute or be deemed a waiver of Department's right thereafter to enforce those rights, nor shall any single or partial exercise of any such right preclude any other or further exercise thereof or the exercise of any other right. 22. Statutory Notices Relating to Unauthorized Employment and Subcontracts. a. The Department shall consider the employment by any Grantee of unauthorized aliens a violation of Section 274A(e) of the Immigration and Nationality Act. If Grantee/subcontractor knowingly employs unauthorized aliens, such violation shall be cause for unilateral cancellation of this Agreement. The Grantee shall be responsible for including this provision in all subcontracts with private organizations issued as a result of this Agreement. b. Pursuant to Sections 287.133, 287.134, and 287.137 F.S., the following restrictions apply to persons placed on the convicted vendor list, discriminatory vendor list, or the antitrust violator vendor list: i. Public Entity Crime. A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity; may not be awarded or perform work as a Grantee, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017, F.S., for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list. ii. Discriminatory Vendors. An entity or affiliate who has been placed on the discriminatory vendor list may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity; may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity. iii. Antitrust Violator Vendors. A person or an affiliate who has been placed on the antitrust violator vendor list following a conviction or being held civilly liable for an antitrust violation may not submit a bid, proposal, or reply on any contract to provide any good or services to a public entity; may not submit a bid, proposal, or reply on any contract with a public entity for the construction or repair of a public building or public work; may not submit a bid, proposal, or reply on leases of real property to a public entity; may not be awarded or perform work as a Grantee, supplier, subcontractor, or consultant under a contract with a public entity; and may not transact new business with a public entity. iv. Notification. The Grantee shall notify Department if it or any of its suppliers, subcontractors, or consultants have been placed on the convicted vendor list, the discriminatory vendor list, or antitrust violator vendor list during the life of the Agreement. The Florida Department of Management Services is responsible for maintaining the discriminatory vendor list and the antitrust violator vendor list and posts the list on its website. Questions regarding the discriminatory vendor list or antitrust violator vendor list may be directed to the Florida Department of Management Services, Office of Supplier Diversity, at (850) 487-0915. Attachment 1-A 8 of 12 Rev. 10/3/2022 23. Compliance with Federal, State and Local Laws. a. The Grantee and all its agents shall comply with all federal, state and local regulations, including, but not limited to, nondiscrimination, wages, social security, workers' compensation, licenses, and registration requirements. The Grantee shall include this provision in all subcontracts issued as a result of this Agreement. b. No person, on the grounds of race, creed, color, religion, national origin, age, gender, or disability, shall be excluded from participation in; be denied the proceeds or benefits of; or be otherwise subjected to discrimination in performance of this Agreement. c. This Agreement shall be governed by and construed in accordance with the laws of the State of Florida. d. Any dispute concerning performance of the Agreement shall be processed as described herein. Jurisdiction for any damages arising under the terms of the Agreement will be in the courts of the State, and venue will be in the Second Judicial Circuit, in and for Leon County. Except as otherwise provided by law, the parties agree to be responsible for their own attorney fees incurred in connection with disputes arising under the terms of this Agreement. 24. Build America, Buy America Act (BABA). Recipients or Subrecipients of an award of Federal financial assistance from a program for infrastructure are required to comply with the Build America, Buy America Act (BABA), including the following provisions: a. All iron and steel used in the project are produced in the United States --this means all manufacturing processes, from the initial melting stage through the application of coatings, occurred in the United States; b. All manufactured products used in the project are produced in the United States -this means the manufactured product was manufactured in the United States; and the cost of the components of the manufactured product that are mined, produced, or manufactured in the United States is greater than 55 percent of the total cost of all components of the manufactured product, unless another standard for determining the minimum amount of domestic content of the manufactured product has been established under applicable law or regulation; and c. All construction materials are manufactured in the United States -this means that all manufacturing processes for the construction material occurred in the United States. The Buy America preference only applies to articles, materials, and supplies that are consumed in, incorporated into, or affixed to an infrastructure project. As such, it does not apply to tools, equipment, and supplies, such as temporary scaffolding, brought to the construction site and removed at or before the completion of the infrastructure project. Nor does a Buy America preference apply to equipment and furnishings, such as movable chairs, desks, and portable computer equipment, that are used at or within the finished infrastructure project but are not an integral part of the structure or permanently affixed to the infrastructure project. 25. Scrutinized Companies. a. Grantee certifies that it is not on the Scrutinized Companies that Boycott Israel List or engaged in a boycott of Israel. Pursuant to Section 287.135, F.S., the Department may immediately terminate this Agreement at its sole option if the Grantee is found to have submitted a false certification; or if the Grantee is placed on the Scrutinized Companies that Boycott Israel List or is engaged in the boycott of Israel during the term of the Agreement. b. If this Agreement is for more than one million dollars, the Grantee certifies that it is also not on the Scrutinized Companies with Activities in Sudan, Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List, or engaged with business operations in Cuba or Syria as identified in Section 287.135, F.S. Pursuant to Section 287.135, F.S., the Department may immediately terminate this Agreement at its sole option if the Grantee is found to have submitted a false certification; or if the Grantee is placed on the Scrutinized Companies with Activities in Sudan List, or Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List, or engaged with business operations in Cuba or Syria during the term of the Agreement. c. As provided in Subsection 287.135(8), F.S., if federal law ceases to authorize these contracting prohibitions then they shall become inoperative. 26. Lobbying and Integrity. The Grantee agrees that no funds received by it under this Agreement will be expended for the purpose of lobbying the Legislature or a State agency pursuant to Section 216.347, F.S., except that pursuant to the requirements of Section 287.058(6), F.S., during the term of any executed agreement between Grantee and the State, Grantee may lobby the executive or legislative branch concerning the scope of services, performance, term, or compensation regarding that agreement. The Grantee shall comply with Sections 11.062 and 216.347, F.S. 27. Record Keeping. Attachment 1-A 9of12 Rev. 10/3/2022 The Grantee shall maintain books, records and documents directly pertinent to performance under this Agreement in accordance with United States generally accepted accounting principles (US GAAP) consistently applied. The Department, the State, or their authorized representatives shall have access to such records for audit purposes during the term of this Agreement and for five (5) years following the completion date or termination of the Agreement. In the event that any work is subcontracted, Grantee shall similarly require each subcontractor to maintain and allow access to such records for audit purposes. Upon request of Department's Inspector General, or other authorized State official, Grantee shall provide any type of information the Inspector General deems relevant to Grantee's integrity or responsibility. Such information may include, but shall not be limited to, Grantee's business or financial records, documents, or files of any type or form that refer to or relate to Agreement. The Grantee shall retain such records for the longer of: (1) three years after the expiration of the Agreement; or (2) the period required by the General Records Schedules maintained by the Florida Department of State (available at: http://dos.myflorida.comilibrary-archives/records-management/general-records-schedules/). 28. Audits. a. Inspector General. The Grantee understands its duty, pursuant to Section 20.055(5), F.S., to cooperate with the inspector general in any investigation, audit, inspection, review, or hearing. The Grantee will comply with this duty and ensure that its sub -grantees and/or subcontractors issued under this Agreement, if any, impose this requirement, in writing, on its sub -grantees and/or subcontractors, respectively. b. Physical Access and Inspection. Department personnel shall be given access to and may observe and inspect work being performed under this Agreement, with reasonable notice and during normal business hours, including by any of the following methods: i. Grantee shall provide access to any location or facility on which Grantee is performing work, or storing or staging equipment, materials or documents; ii. Grantee shall permit inspection of any facility, equipment, practices, or operations required in performance of any work pursuant to this Agreement; and, iii. Grantee shall allow and facilitate sampling and monitoring of any substances, soils, materials or parameters at any location reasonable or necessary to assure compliance with any work or legal requirements pursuant to this Agreement. c. Special Audit Requirements. The Grantee shall comply with the applicable provisions contained in Attachment 5, Special Audit Requirements. Each amendment that authorizes a funding increase or decrease shall include an updated copy of Exhibit 1, to Attachment 5. If Department fails to provide an updated copy of Exhibit 1 to include in each amendment that authorizes a funding increase or decrease, Grantee shall request one from the Department's Grants Manager. The Grantee shall consider the type of financial assistance (federal and/or state) identified in Attachment 5, Exhibit 1 and determine whether the terms of Federal and/or Florida Single Audit Act Requirements may further apply to lower tier transactions that may be a result of this Agreement. For federal financial assistance, Grantee shall utilize the guidance provided under 2 CFR §200.331 for determining whether the relationship represents that of a subrecipient or vendor. For State financial assistance, Grantee shall utilize the form entitled "Checklist for Nonstate Organizations Recipient/Subrecipient vs Vendor Determination" (form number DFS -A2 -NS) that can be found under the "Links/Forms" section appearing at the following website: https:\\apps.fldfs.com\fsaa. d. Proof of Transactions. In addition to documentation provided to support cost reimbursement as described herein, Department may periodically request additional proof of a transaction to evaluate the appropriateness of costs to the Agreement pursuant to State guidelines (including cost allocation guidelines) and federal, if applicable. Allowable costs and uniform administrative requirements for federal programs can be found under 2 CFR 200. The Department may also request a cost allocation plan in support of its multipliers (overhead, indirect, general administrative costs, and fringe benefits). The Grantee must provide the additional proof within thirty (30) days of such request. e. No Commingling of Funds. The accounting systems for all Grantees must ensure that these funds are not commingled with funds from other agencies. Funds from each agency must be accounted for separately. Grantees are prohibited from commingling funds on either a program -by -program or a project -by -project basis. Funds specifically budgeted and/or received for one project may not be used to support another project. Where a Grantee's, or subrecipient's, accounting system cannot comply with this requirement, Grantee, or subrecipient, shall establish a system to provide adequate fund accountability for each project it has been awarded. i. If Department finds that these funds have been commingled, Department shall have the right to demand a refund, either in whole or in part, of the funds provided to Grantee under this Agreement for non-compliance with the material terms of this Agreement. The Grantee, upon such written notification from Department shall refund, and shall forthwith pay to Department, the amount of Attachment 1-A 10 of 12 Rev. 10/3/2022 money demanded by Department. Interest on any refund shall be calculated based on the prevailing rate used by the State Board of Administration. Interest shall be calculated from the date(s) the original payment(s) are received from Department by Grantee to the date repayment is made by Grantee to Department. ii. In the event that the Grantee recovers costs, incurred under this Agreement and reimbursed by Department, from another source(s), Grantee shall reimburse Department for all recovered funds originally provided under this Agreement and interest shall be charged for those recovered costs as calculated on from the date(s) the payment(s) are recovered by Grantee to the date repayment is made to Department. iii. Notwithstanding the requirements of this section, the above restrictions on commingling funds do not apply to agreements where payments are made purely on a cost reimbursement basis. 29. Conflict of Interest. The Grantee covenants that it presently has no interest and shall not acquire any interest which would conflict in any manner or degree with the performance of services required. 30. Independent Contractor. The Grantee is an independent contractor and is not an employee or agent of Department. 31. Subcontracting. a. Unless otherwise specified in the Special Terms and Conditions, all services contracted for are to be performed solely by Grantee. b. The Department may, for cause, require the replacement of any Grantee employee, subcontractor, or agent. For cause, includes, but is not limited to, technical or training qualifications, quality of work, change in security status, or non-compliance with an applicable Department policy or other requirement. c. The Department may, for cause, deny access to Department's secure information or any facility by any Grantee employee, subcontractor, or agent. d. The Department's actions under paragraphs b. or c. shall not relieve Grantee of its obligation to perform all work in compliance with the Agreement. The Grantee shall be responsible for the payment of all monies due under any subcontract. The Department shall not be liable to any subcontractor for any expenses or liabilities incurred under any subcontract and Grantee shall be solely liable to the subcontractor for all expenses and liabilities incurred under any subcontract. e. The Department will not deny Grantee's employees, subcontractors, or agents access to meetings within the Department's facilities, unless the basis of Department's denial is safety or security considerations. f. The Department supports diversity in its procurement program and requests that all subcontracting opportunities afforded by this Agreement embrace diversity enthusiastically. The award of subcontracts should reflect the full diversity of the citizens of the State. A list of minority-owned firms that could be offered subcontracting opportunities may be obtained by contacting the Office of Supplier Diversity at (850) 487-0915. g. The Grantee shall not be liable for any excess costs for a failure to perform, if the failure to perform is caused by the default of a subcontractor at any tier, and if the cause of the default is completely beyond the control of both Grantee and the subcontractor(s), and without the fault or negligence of either, unless the subcontracted products or services were obtainable from other sources in sufficient time for Grantee to meet the required delivery schedule. 32. Guarantee of Parent Company. If Grantee is a subsidiary of another corporation or other business entity, Grantee asserts that its parent company will guarantee all of the obligations of Grantee for purposes of fulfilling the obligations of Agreement. In the event Grantee is sold during the period the Agreement is in effect, Grantee agrees that it will be a requirement of sale that the new parent company guarantee all of the obligations of Grantee. 33. Survival. The respective obligations of the parties, which by their nature would continue beyond the termination or expiration of this Agreement, including without limitation, the obligations regarding confidentiality, proprietary interests, and public records, shall survive termination, cancellation, or expiration of this Agreement. 34. Third Parties. The Department shall not be deemed to assume any liability for the acts, failures to act or negligence of Grantee, its agents, servants, and employees, nor shall Grantee disclaim its own negligence to Department or any third party. This Agreement does not and is not intended to confer any rights or remedies upon any person other than the parties. If Department consents to a subcontract, Grantee will specifically disclose that this Agreement does not create any third - party rights. Further, no third parties shall rely upon any of the rights and obligations created under this Agreement. 35. Severability. Attachment 1-A 11 of 12 Rev. 10/3/2022 If a court of competent jurisdiction deems any term or condition herein void or unenforceable, the other provisions are severable to that void provision, and shall remain in full force and effect. 36. Grantee's Employees, Subcontractors and Agents. All Grantee employees, subcontractors, or agents performing work under the Agreement shall be properly trained technicians who meet or exceed any specified training qualifications. Upon request, Grantee shall furnish a copy of technical certification or other proof of qualification. All employees, subcontractors, or agents performing work under Agreement must comply with all security and administrative requirements of Department and shall comply with all controlling laws and regulations relevant to the services they are providing under the Agreement. 37. Assignment. The Grantee shall not sell, assign, or transfer any of its rights, duties, or obligations under the Agreement, or under any purchase order issued pursuant to the Agreement, without the prior written consent of Department. In the event of any assignment, Grantee remains secondarily liable for performance of the Agreement, unless Department expressly waives such secondary liability. The Department may assign the Agreement with prior written notice to Grantee of its intent to do so. 38. Compensation Report. If this Agreement is a sole -source, public-private agreement or if the Grantee, through this agreement with the State, annually receive 50% or more of their budget from the State or from a combination of State and Federal funds, the Grantee shall provide an annual report, including the most recent IRS Form 990, detailing the total compensation for the entities' executive leadership teams. Total compensation shall include salary, bonuses, cashed -in leave, cash equivalents, severance pay, retirement benefits, deferred compensation, real -property gifts, and any other payout. The Grantee must also inform the Department of any changes in total executive compensation between the annual reports. All compensation reports must indicate what percent of compensation comes directly from the State or Federal allocations to the Grantee. 39. Execution in Counterparts and Authority to Sign. This Agreement, any amendments, and/or change orders related to the Agreement, may be executed in counterparts, each of which shall be an original and all of which shall constitute the same instrument. In accordance with the Electronic Signature Act of 1996, electronic signatures, including facsimile transmissions, may be used and shall have the same force and effect as a written signature. Each person signing this Agreement warrants that he or she is duly authorized to do so and to bind the respective party to the Agreement. Attachment 1-A 12 of 12 Rev. 10/3/2022 STATE OF FLORIDA DEPARTMENT OF ENVIRONMENTAL PROTECTION Revised Special Terms and Conditions AGREEMENT NO. 22PLN91 ATTACHMENT 2-A These Special Terms and Conditions shall be read together with general terms outlined in the Standard Terms and Conditions, Attachment 1. Where in conflict, these more specific terms shall apply. 1. Scope of Work. The Project funded under this Agreement is Vulnerability Assessment with City Stimulator. The Project is defined in more detail in Attachment 3, Grant Work Plan. 2. Duration. a. Reimbursement Period. The reimbursement period for this Agreement is the same as the term of the Agreement. b. Extensions. There are extensions available for this Project. c. Service Periods. Additional service periods may be added in accordance with 2.a above and are contingent upon proper and satisfactory technical and administrative performance by the Grantee and the availability of funding. 3. Payment Provisions. a. Compensation. This is a cost reimbursement Agreement. The Grantee shall be compensated under this Agreement as described in Attachment 3. b. Invoicing. Invoicing will occur as indicated in Attachment 3. c. Advance Pay. Advance Pay is not authorized under this Agreement. 4. Cost Eligible for Reimbursement or Matching Requirements. Reimbursement for costs or availability for costs to meet matching requirements shall be limited to the following budget categories, as defined in the Reference Guide for State Expenditures, as indicated: Reimbursement Match Category ❑ ❑ Salaries/Wages Overhead/Indirect/General and Administrative Costs: ❑ ❑ a. Fringe Benefits, N/A. O ❑ b. Indirect Costs, N/A. El ® Contractual (Subcontractors) O 0 Travel, in accordance with Section 112, F.S. ❑ ❑ Equipment ❑ ❑ Rental/Lease of Equipment ❑ ❑ Miscellaneous/Other Expenses ❑ o Land Acquisition 5. Equipment Purchase. No Equipment purchases shall be funded under this Agreement. 6. Land Acquisition. There will be no Land Acquisitions funded under this Agreement. 7. Match Requirements The Agreement requires at least a 10.8% match on the part of the Grantee. Therefore, the Grantee is responsible for providing $24,000 through cash or third party in-kind towards the project funded under this Agreement. The Grantee may claim allowable project expenditures made on July 1, 2021 or after for purposes of meeting its match requirement as identified above. Attachment 2-A 1 of 3 Rev. 10/3/2022 Each payment request submitted shall document all matching funds and/or match efforts (i.e., in-kind services) provided during the period covered by each request. The final payment will not be processed until the match requirement has been met. 8. Insurance Requirements Required Coverage. At all times during the Agreement the Grantee, at its sole expense, shall maintain insurance coverage of such types and with such terms and limits described below. The limits of coverage under each policy maintained by the Grantee shall not be interpreted as limiting the Grantee's liability and obligations under the Agreement. All insurance policies shall be through insurers licensed and authorized to issue policies in Florida, or alternatively, Grantee may provide coverage through a self-insurance program established and operating under the laws of Florida. Additional insurance requirements for this Agreement may be required elsewhere in this Agreement, however the minimum insurance requirements applicable to this Agreement are: a. Commercial General Liability Insurance. The Grantee shall provide adequate commercial general liability insurance coverage and hold such liability insurance at all times during the Agreement. The Department, its employees, and officers shall be named as an additional insured on any general liability policies. The minimum limits shall be $250,000 for each occurrence and $500,000 policy aggregate. b. Commercial Automobile Insurance. If the Grantee's duties include the use of a commercial vehicle, the Grantee shall maintain automobile liability, bodily injury, and property damage coverage. Insuring clauses for both bodily injury and property damage shall provide coverage on an occurrence basis. The Department, its employees, and officers shall be named as an additional insured on any automobile insurance policy. The minimum limits shall be as follows: $200,000/300,000 Automobile Liability for Company -Owned Vehicles, if applicable $200,000/300,000 Hired and Non -owned Automobile Liability Coverage c. Workers' Compensation and Employer's Liability Coverage. The Grantee shall provide workers' compensation, in accordance with Chapter 440, F.S. and employer liability coverage with minimum limits of $100,000 per accident, $100,000 per person, and $500,000 policy aggregate. Such policies shall cover all employees engaged in any work under the Grant. d. Other Insurance. None. 9. Quality Assurance Requirements. There are no special Quality Assurance requirements under this Agreement. 10. Retainage. No retainage is required under this Agreement. 11. Subcontracting. The Grantee may subcontract work under this Agreement without the prior written consent of the Department's Grant Manager except for certain fixed-price subcontracts pursuant to this Agreement, which require prior approval. The Grantee shall submit a copy of the executed subcontract to the Department prior to submitting any invoices for subcontracted work. Regardless of any subcontract, the Grantee is ultimately responsible for all work to be performed under this Agreement. 12. State-owned Land. The work will not be performed on State-owned land. 13. Office of Policy and Budget Reporting. There are no special Office of Policy and Budget reporting requirements for this Agreement. 14. Build America, Buy America Act (BABA). Recipients or Subrecipients of an award of Federal finanFial assistance from a program for infrastructure are required to comply with the Build America, Buy America Act (BABA), including the following provisions: a. All iron and steel used in the project are produced in the United States --this means all manufacturing processes, from the initial melting stage through the application of coatings, occurred in the United States; Attachment 2-A 2 of 3 Rev. 10/3/2022 b. All manufactured products used in the project are produced in the United States -this means the manufactured product was manufactured in the United States; and the cost of the components of the manufactured product that are mined, produced, or manufactured in the United States is greater than 55 percent of the total cost of all components of the manufactured product, unless another standard for determining the minimum amount of domestic content of the manufactured product has been established under applicable law or regulation; and c. All construction materials are manufactured in the United States -this means that all manufacturing processes for the construction material occurred in the United States. The Buy America preference only applies to articles, materials, and supplies that are consumed in, incorporated into, or affixed to an infrastructure project. As such, it does not apply to tools, equipment, and supplies, such as temporary scaffolding, brought to the construction site and removed at or before the completion of the infrastructure project. Nor does a Buy America preference apply to equipment and furnishings, such as movable chairs, desks, and portable computer equipment, that are used at or within the finished infrastructure project but are not an integral part of the structure or permanently affixed to the infrastructure project. 15. Common Carrier. a. Applicable to contracts with a common carrier — firm/person/corporation that as a regular business transports people of commodities from place to place. If applicable, Contractor must also fill out and return PUR 1808 before contract execution] If Contractor is a common carrier pursuant to section 908.111(1)(a), Florida Statutes, the Department will terminate this contract immediately if Contractor is found to be in violation of the law or the attestation in PUR 1808. b. Applicable to solicitations for a common carrier — Before contract execution, the winning Contractor(s) must fill out and return PUR 1808, and attest that it is not willfully providing any service in furtherance of transporting a person into this state knowing that the person unlawfully present in the United States according to the terms of the federal Immigration and Nationality Act, 8 U.S.C. ss. 1101 et seq. The Department will terminate a contract immediately if Contractor is found to be in violation of the law or the attestation in PUR 1808 16. Additional Terms. Documentary Evidence Requirement for Subcontractor(s). If any work associated with this Agreement is completed by a subcontractor(s), the Grantee shall require that such subcontractor(s) submit documentary evidence (e.g., workshop agendas; meeting recordings) to Grantee demonstrating that the subcontractor(s) has fully performed its Project obligation(s). The Grantee shall forward copies of all such documentary evidence to the Department with the Grantee's relevant deliverable(s), using the approved Project Timeline set forth in Attachment 3 to this Agreement (Grant Work Plan). Sea Level Impact Projection Study Requirement. If the project is within the designated area, pursuant to Section 161.551, F.S. and Chapter 62S-7, Florida Administrative Code, the Grantee is responsible for performing a Sea Level Impact Projection (SLIP) study and submitting the resulting report to the Department. The SLIP study report must be received by the Department, approved by the Department, and be published on the Department's website for at least thirty (30) days before construction can commence. This rule went into effect July 1, 2021, and applies to certain state -funded construction projects located in the coastal building zone as defined in the rule. Attachment 2-A 3 of 3 Rev. 10/3/2022 STATE OF FLORIDA DEPARTMENT OF ENVIRONMENTAL PROTECTION REVISED GRANT WORK PLAN AGREEMENT NO. 22PLN91 ATTACHMENT 3-A PROJECT TITLE: Vulnerability Assessment with City Stimulator PROJECT LOCATION: The Project is located in the City of Clearwater within Pinellas County, Florida. PROJECT DESCRIPTION: The Vulnerability Assessment with City Stimulator Project (Project) will conduct a comprehensive Vulnerability Assessment (VA) pursuant to Section 380.093, Florida Statutes for the City of Clearwater. The Project will use the City Stimulator tool to stress -test and analyze important community elements for long-term resilience goals and the results will guide the City's capital investment planning process and assist the creation of a future climate action report. The Project includes outreach and a comprehensive VA. TASKS AND DELIVERABLES: Task 1: Kick Off Meeting Description: After a notice -to -proceed is issued, the Grantee will meet to develop an overall project management plan and to address initial actions. Meeting attendees should discuss the project scope, project goals, schedule, key milestones, and deliverables in order to develop a consistent project approach. The kick-off meeting will be hosted by the Grantee and should identify potential representatives to serve on both the Project Action Team (PAT) and Technical Advisory Committee (TAC). Prior to the meeting, the Grantee will prepare the sign -in sheet, draft project schedule, and other meeting materials as necessary. The Grantee will prepare a draft list of representatives to serve on the PAT and TAC based on discussions with the Grantee. It is recommended that the committees be limited to no more than 10 representatives to better manage meeting outcomes. Deliverables: The Grantee will provide the following: 1) a draft list of the PAT and TAC members; 2) kick-off meeting minutes, which documents all decisions and agreed upon outcomes of the meeting; and 3) a draft email to potential members to request their participation on the PAT and TAC. The email shall include the project purpose, goals, schedule, project meeting dates and locations, and overall desired outcomes. Task 2: Assemble PAT and TAC Description: The Grantee will review and approve the PAT and TAC member list and then distribute the draft email prepared in Task 1 to the members. The email requests PAT and TAC member participation and to provide confirmation of acceptance or denial. Deliverables: The Grantee will provide the list of local representatives that have confirmed participation on the PAT and TAC. The list shall include the name, organization/affiliation, position title, and contact information. DEP Agreement No.: 22PLN91 Page 1 of 5 Rev. 2.11.22 Task 3: Conduct TAC Meetings Description: The Grantee will coordinate and schedule the quantity, dates, times, and locations for the TAC meetings, based on critical decision points in the project process. The purpose of the TAC meetings is to assist in reviewing the goals of the project, review draft materials, provide input for study direction, assist in identifying geographic context, appropriate modeling methodologies, assist in identifying available data and resources, identify relevant assets, and review project findings and recommendations. A minimum of two TAC meetings is recommended, at the beginning and end of the project, however, more may be necessary to provide guidance at critical decision points throughout the project process. Deliverables: The Grantee will provide the following: 1) meeting agendas to include location, date, and time of meeting; 2) meeting sign -in sheets with attendee names and affiliation; 3) a copy of the presentation(s) and any materials created for distribution at the meeting, as applicable; and 4) a summary report of committee recommendations and guidance, to include attendee input, meeting outcomes, methodologies selected, appropriate resources and data, relevant assets and review of study deliverables for accuracy and applicability. Task 4: Acquire Background Data and Populate Digitak Twin Geodatabases Description: The Grantee will research and compile the data needed to perform the Vulnerability Assessment (VA), based on the requirements as defined in Section 380.093, Florida Statute (F.S.)_ Three main categories of data are required to perform a VA: 1) critical and regionally significant asset inventory, 2) topographic data, and 3) flood scenario -related data. GIS metadata should incorporate a layer for each of the four asset types as defined in s. 380.093(2) 1-4, F.S. GIS files and associated metadata must adhere to the Resilient Florida Program's GIS Data Standards (Exhibit I), and raw data sources shall be defined within the associated metadata. Sea level rise projection data shall include the 2017 National Oceanic and Atmospheric Administration (NOAA) intermediate -high and intermediate -low projections for 2040 and 2070, at a minimum. Other projections can be used at the Grantees discretion. Storm surge data used must be equal to or exceed the 100 -year return period (1% annual chance) flood event. In the process of researching background data, the Grantee shall identify data gaps, where missing data or low -quality information may limit the VA's extent or reduce the accuracy of the results. The Grantee shall rectify any gaps of necessary data. The Grantee will also research and compile data needed to develop the digital twin in City Simulator, including the appropriate geodatabases to store the digital twin information. Deliverables: The Grantee will provide the following: 1) a technical report to outline the data compiled for both the VA and the digital twin and findings of the gap analysis; 2) a summary report to include recommendations to address the identified data gaps and actions taken to rectify them, if applicable; 3) GIS files with appropriate metadata of the data compiled for both the VA and the digital twin, to include locations of critical assets owned or maintained by the Grantee as well as regionally significant assets that are classified and as defined in s. 380.093(2) 1-4, F.S. Task 5: Exposure Analysis and Climate Change Forecasts Description: The Grantee will perform an exposure analysis to identify the depth of water caused by each sea level rise, storm surge, and/or flood scenario. The water surface depths (i.e. flood scenarios) used to evaluate assets shall include the following data: tidal flooding, current and future storm surge flooding, rainfall -induced flooding, and compound flooding, all as applicable, as well as the scenarios and standards DEP Agreement No.: 22PLN91 Page 2 of 5 Rev. 2.11.22 used for the exposure analysis shall be pursuant to s. 380.093, F.S. GIS files and associated metadata must adhere to the Resilient Florida Program's GIS Data Standards (Exhibit I), and raw data sources shall be defined within the associated metadata. The Grantee will also develop forecasts for climate change using the StormCaster module within City Simulator, to include future rainfall, temperature, and sea level. Deliverables: The Grantee will provide the following: 1) a draft Vulnerability Assessment report that provides details on the modeling process, type of models utilized, and resulting tables and maps illustrating flood depths for each flood scenario; 2) GIS files with results of the exposure analysis for each flood scenario as well as the appropriate metadata that identifies the methods used to create the flood layers; and 3) results of the StormCaster module within City Simulator. Task 6: Sensitivity Analysis Description: The Grantee will perform the sensitivity analysis to measure the impact of flooding on assets and to apply the data from the exposure analysis to the inventory of critical assets created in the Exposure Analysis Task. The sensitivity analysis should include an evaluation of the impact of flood severity on each asset type and at each flood scenario and assign a risk level based on percentages of land area inundated and number of critical assets affected. The Grantee will run up to 15 scenarios to get an initial understanding of future climate vulnerabilities and implications to the City. The outputs from the scenario modeling will provide results and performance metrics. Deliverables: The Grantee will provide the following: 1) a draft Vulnerability Assessment report that provides details on the findings of the exposure analysis, sensitivity analysis, and modeling of the 15 scenarios, and includes visual presentation of the data via maps and tables, based on the statutory -required scenarios and standards; and 2) an initial list of critical and regionally significant assets that are impacted by flooding. The list of critical and regionally significant assets must be prioritized by area or immediate need and must identify which flood scenario(s) impacts each asset. Task 7: Final Vulnerability Assessment Report, Maps, and Tables Description: The Grantee will finalize the Vulnerability Assessment (VA) report pursuant to the requirements in s. 380.093, F.S. and based upon the PAT and TAC and public outreach efforts. The final VA must include all results from the exposure and sensitivity analyses, as well as a summary of identified risks and assigned focus areas. It should contain a list of critical and regionally significant assets that are impacted by flooding and sea -level rise, specifying for each asset the flood scenario(s) impacting the asset. GIS files and associated metadata must adhere to the Resilient Florida Program's GIS Data Standards (Exhibit I), and raw data sources shall be defined within the associated metadata. The Grantee will also develop a Community Resilience Report to summarize the planning process, digital twin City Simulator creation, scenarios evaluated, and results. Deliverables: The Grantee will provide the following: 1) Final Vulnerability Assessment Report that provides details on the results and conclusions, including illustrations via maps and tables, based on the statutory -required scenarios and standards in s. 380.093, F.S.; 2) a final list of critical and regionally significant assets that are impacted by flooding. The list of critical and regionally significant assets must be prioritized by area or immediate need and must identify which flood scenario(s) impacts each asset.; 3) all electronic mapping data used to illustrate flooding and sea level rise impacts identified in the VA, to include the geospatial data in an electronic file format and GIS metadata; 4) a signed Vulnerability Assessment DEP Agreement No.: 22PLN91 Page 3 of 5 Rev. 2.11.22 Compliance Checklist Certification; and 5) Community Resilience Report to summarize the planning process, digital twin City Simulator creation, scenarios evaluated, and results. Task 8: Public Presentation Description: The Grantee will present the final VA results to local governing boards, technical committees, or other appropriate officers and elected officials. The purpose of the presentation is to share the findings from the final VA and provide recommendations of actions for adaptation strategies and future project funding. The presentation will also inform the public of the results and the future risk of sea level rise and increased flooding and encourage community participation when identifying mitigation strategies to address the flooding vulnerabilities. The Grantee will prepare all social media notifications, meeting invitations, meeting materials, presentations, and graphics utilized during the meeting, as applicable. Deliverables: The Grantee will provide the following: 1) meeting agendas to include location, date, and time of meeting; 2) meeting sign -in sheets with attendee names and affiliation (i.e. local stakeholder, resident, PAT and TAC member, local government staff); 3) a copy of the presentation(s) and any materials created in preparation of or for distribution at the meeting (i.e. social media posts, public announcements, graphics), as applicable; 4) a copy of the file or weblink of the video or audio recording from the meeting, if applicable; and 5) a summary report including attendee input and meeting outcomes. PERFORMANCE MEASURES: The Grantee will submit all deliverables for each task to the Department's Grant Manager on or before the Task Due Date listed in the Project Timeline. The Grantee must also submit Exhibit A, Progress Report Form, to the Department's Grant Manager, with every deliverable and payment request. For interim payment requests, Exhibit A may serve as the deliverable for a task. The Department's Grant Manager will review the deliverable(s) to verify that they meet the specifications in the Grant Work Plan and the task description, to include any work being performed by any subcontractor(s). Upon review and written acceptance by the Department's Grant Manager of deliverables under the task, the Grantee may proceed with payment request submittal. CONSEQUENCES FOR NON-PERFORMANCE: For each task deliverable not received by the Department at one hundred percent (100%) completion and by the specified due date listed in the Agreement's most recent Project Timeline, the Department will reduce the relevant Task Funding Amount(s) paid to Grantee in proportion to the percentage of the deliverable(s) not fully completed and/or submitted to the Department in a timely manner. PAYMENT REQUEST SCHEDULE: Following the Grantee's full completion of a task, the Grantee may submit a payment request for cost reimbursement using both Exhibit A, Progress Report Form, and Exhibit C, Payment Request Summary Form. Interim payment requests cannot be made more frequently than quarterly and must be made using Exhibit A, detailing all work progress made during that payment request period, and Exhibit C. Upon the Department's receipt of Exhibit A and C, along with all supporting fiscal documentation and deliverables, the Department's Grant Manager will have ten (10) working days to review and approve or deny the payment request. PROJECT TIMELINE AND BUDGET DETAIL: The tasks must be completed by, and all deliverables received by, the corresponding task due date listed in the table below. Cost -reimbursable grant funding must not exceed the budget amounts indicated below. Requests for any change(s) must be submitted prior to the current task due date listed in the Project Timeline. Requests are to be sent via email to the Department's Grant Manager, with the details of the request and the reason for the request made clear. DEP Agreement No.: 22PLN91 Page 4 of 5 Rev. 2.11.22 Task No. Task Title Budget Category DEP Amount Match Amount Total Amount Task Start Date Task Due Date 1 Kick Off Meeting Contractual Services $20,897 $0 $20,897 7/1/2021 3/31/2024 2 Assemble PAT and TAC Contractual Services $5,000 $0 $5,000 7/1/2021 3/31/2024 3 Conduct TAC Meetings Contractual Services $16,900 $0 $16,900 7/1/2021 3/31/2024 4 Acquire Background Data and Populate Twin Digitak Geodatabases Contractual Services $30,456 $0 $30,456 7/1/2021 3/31/2024 5 Exposure Analysis and Climate Change Forecasts Contractual Services $60,132 $0 $60,132 7/1/2021 3/31/2024 6 Sensitivity Analysis Contractual Services $26,310 $0 $26,310 7/1/2021 3/31/2024 7 Final Vulnerability Assessment Report, Maps, and Tables Contractual Services $37,153 $20,000 $57,153 7/1/2021 3/31/2024 8 Public Presentation Contractual Services $1,000 $4,000 $5,000 7/1/2021 3/31/2024 Total: $197,848 $24,000 $221,848 DEP Agreement No.: 22PLN91 Page 5 of 5 Rev. 2.11.22