DEL ORO PARK IMPROVEMENTS NEW RESTROOM BUILDING - 16-0020-PL11/17/2021
CERTUS
BUILDERS Design/Build - Construction Management
PO Box 116
Bristol, Florida 3 321
T:i�i1�JJ
f8131 4•4=..13 (!
Bristol 856 53c'-56 .1
Proposal
TO: Leroy Chin, Park Planning & Project Manager
City of Clearwater
100 S. Myrtle Ave., Suite 120
Clearwater, FL 33756
RE: DEL ORO PARK IMPROVEMENTS NEW RESTROOM BUILDING
CONTRACT NO. 16 -0020 -PL
CITY PROJECT NO. 2016022
As requested, enclosed is the proposal for construction of the Del Oro Park Improvements New
Restroom Building submitted in accordance with technical specs/plans/study/clarifications of this
letter/attached line item work,etc., for a Guaranteed Maximum Price of $431,991.00.
Scope °, }rVor.k:
As per plans by Plisko Archtiecture, P.A. AIA dated 7/15/2020, specifications dated 7/15/2020,
and attached Summary with list of clarifications dated 11/4/2021.
f O5t il¢°a1;111
Description
Amount
Cost of Work
$289,316.30
Subtotal
$289,316.30
General Conditions
$52,405.28
GL and Builders Risk Insurance
$9,742.50
P&P Bond
$13,856.00
Construction Management Fee
$27,399.01
Contingency 10%
$39,271.91
Guaranteed Maximum Price
$431,991.00
Project Duration shall be 180 calendar days from the date of the Notice to Proceed.
1 a: i St ! !l !. C; : t t is r' :i IN t This proposal is submitted in conjunction with the existing Construction
Manager at Risk Services Continuing Contract entered into with the City of Clearwater on
September 23, 2020, based on RFO #40-20.
1f GMP 1 :ct til,, '‘150,000: Per Section III, Article 5.1 of the Contract Specifications, the
contractor shall provide to the public entity a certified copy of the recorded bond. Once the City
receives a certified copy of the recorded bond, a Notice to Proceed may be issued. Include the
attached bond form as well as the Power of Attorney.
For work performed, invoices shall be submitted to the City of Clearwater, Parks & Recreation
Department, Attn: Leroy Chin, Park, Planning and Project Manager, P.O. Box 4748, Clearwater,
Florida, 33758-4748. Contingency services may be billed only after written authorization is
provided by the City to proceed with those services.
CERTUS BUILDERS, INC.
By:
Sharon A Sumner
President
1/1/-1//k/
2c�
'Date
CITY OF CLEARWATER, FLORIDA
App o d as to ft m: Attest:
Owen Kohler
Assistant City Attorney
Countersigned:
194,4d1
Frank Hibbard Jon Jennings
Mayor City Manager
60%. P.
•
/a'
Date
t 11/262!
Date
/°""CERTU
L D E S
��♦B Y 1 R S
SUMMARY
Del Oro Park Improvements
New Restroom Building
Revised Bid Date:
11/4/2021
TRADE
COST
Site and Landscape
By Site Contractor
Concrete and Masonry
$
80,263.00
Carpentry
$
28,721.00
Vanity Counters
$
2,124.12
Roof
$
9,616.98
Doors & Hardware
$
8,843.16
Drywall
$
7,700.00
Paint
$
4,350.00
Quartz Floors
$
5,675.00
Stucco & Cement Board
$
25,230.00
Toilet Accessories
$
11,275.25
HVAC
$
7,585.00
Plumbing
$
33,000.00
Electrical
$
27,930.00
Additional Scope Items
Sunshade Shelters
$
33,219.28
Re -Paint Existing Picnic Pavillion
$
2,800.00
Add Receptacle at Rear of Building for Irrigation
$
276.00
5'x5' Concrete Slab at Utility Chase Entrance
Included in Base Bid
Knox Box (Model #3200 Recessed)
$
707.51
Subtotal Cost of Work
$
289,316.30
General Conditions
$
52,405.28
GL and Builders Risk Insurance
$
9,742.50
P&P Bond
$
13,856.00
OH & Profit 7.5%
$
27,399.01
Owner's Contingency 10%
$
39,271.91
Total Bid
$
431,991.00
Clarifications
We are assuming the site will be "Pad Ready". No earthwork, imported fill, site grading, etc is included.
No site concrete ie: sidewalks, pole bases, electric service encasement, etc is included.
All concrete slab under roof is included.
Temporary Fence by Others
Knox Box price includes sales tax, shipping, and installation.
Proposal is based on Technical Specifications and Plans dated 7/15/20.
Price is based on a January 2022 start of construction.
Alternates
Alternate Doors and Frames to meet specification in lieu of Steelcraft DEDUCT $ (2,792.00)
Bond No.: TBD
PUBLIC CONSTRUCTION BOND
(1)
This bond is given to comply with § 255.05, Florida Statutes, and any action instituted by a claimant under this bond for
payment must be in accordance with the notice and time limitation provisions in subsections (2) and (10).
Pursuant to § 255.05(1)(b), Florida Statutes, "Before commencing the work or before recommencing the work after a
default or abandonment, the contractor shall provide to the public entity a certified copy of the recorded bond.
Notwithstanding the terms of the contract or any other law governing prompt payment for construction services, the public
entity may not make a payment to the contractor until the contractor has complied with this paragraph."
CONTRACTOR SURETY
Certus Builders, Inc.
PO Box 116
Bristol, FL 32321
(850) 558-5693
Westfield Insurance Company
P. O. Box 5001, Westfield Center,
OH 44251 - 5001.
(330) 887-0101
OWNER
City of Clearwater
Parks & Recreation Department
100 S. Myrtle Avenue
Clearwater, FL 33756
(727) 562-4856
PROJECT NAME: Del Oro Park Improvements New Restroom Building
PROJECT NO.: 2016022
PROJECT DESCRIPTION: construct new restroom facility at the Del Oro park
BY THIS BOND, We Cercus Builders, Inc., as Contractor, and Westfield Insurance Company, a corporation, as Surety,
are bound to the City of Clearwater, Florida, herein called Owner, in the sum of $431,991.00, for payment of which we
bind ourselves, our heirs, personal representatives, successors, and assigns, jointly and severally.
THE CONDITION OF THIS BOND is that if Contractor:
1. Performs the proposal dated 11/17/2021, between Contractor and Owner for construction of Del Oro Park
Improvements New Restroom Building, the contract documents being made a part of this bond by reference (which include
the Advertisement for Bids, Proposal, Contract, Surety Bond, Instructions to Bidders, General Conditions, Plans, Technical
Specifications and Appendix, and such alterations as may be made in said Plans and Specifications as therein provided for),
at the times and in the manner prescribed in the contract; and
2. Promptly makes payments to all claimants, as defined in Section 255.05(1), Florida Statutes, supplying Contractor
with labor, materials, or supplies, used directly or indirectly by Contractor in the prosecution of the work provided for in
the contract; and
3. Pays Owner all losses, damages, expenses, costs, and attorney's fees, including appellate proceedings, that Owner
sustains because of a default by Contractor under the contract; and
Bond No.: TBD
PUBLIC CONSTRUCTION BOND
(2)
4. To the limits of § 725.06(2), Florida Statutes, shall indemnify and hold harmless Owner, their officers and
employees, from liabilities, damages, losses and costs, including, but not limited to, reasonable attorney's fees, to the extent
caused by the negligence, recklessness, or intentional wrongful misconduct of Contractor and persons employed or utilized
by Contractor in the performance of the construction contract; and
5. Performs the guarantee of all work and materials furnished under the contract for the time specified in the contract,
then this bond is void; otherwise it remains in full force.
6. Any action instituted by a claimant under this bond for payment must be in accordance with the notice and time
limitation provisions in Section 255.05(2), Florida Statutes.
7. Any changes in or under the contract documents and compliance or noncompliance with any formalities connected
with the contract or the changes does not affect Surety's obligation under this bond, and Surety does hereby waive notice
of any such change, extension of time, alteration or addition to the terms of the contract or to the work or to the specifications.
IN TESTIMONY WHEREOF, witness the hands and seals of the parties hereto this day of
20
(If sole Ownership or Partnership, two (2) Witnesses required).
(If Corporation, Secretary only will attest and affix seal).
Certus Builders, Inc.
By:
Title:
WITNESS: WITNESS:
Corporate Secretary or Witness Print Name:
Print Name:
(affix corporate seal) Westfield Insurance Company
(Power of Attomey must be attached)
By:
ATTORNEY-IN-FACT
Print Name: Kevin Woitowicz
Print Name:
(affix corporate seal)
HieNIELSON, WOJrOWICz, NEU & ASSOCIATES
A NIELSON HOOVER GROUP COMPANY
November 30, 2021
City of Clearwater
100 S. Myrtle Ave., Suite 120
Clearwater, FL 33756
Project: DEL ORO PARK IMPROVEMENTS NEW RESTROOM BUILDING
Estimated Amount: $431,991.00
To Leroy Chin, Park Planning & Project Manager,
it is the intent of Nielson, Wojtowicz, Neu and Associates, as agent Westfield Insurance
mpany,as y, to provide 100% performance and -payment bonds on
behalf of Certus Builders, Inc for the above referenced project.
We hope the above demonstrates our utmost confidence in Certus Builders, Inc., we
have bonded them for years with no problems whatsoever. We hold them in the
highest regards with respects to both character and expertise.
As always, Westfield Insurance Company reserves the right to perform normal
underwriting at the time of any bond request, including, without limitation, prior review
and approval of relevant contract documents, bond forms, and project financing. We
assume no liability to any Obligee, Certus Builders, Inc., or their affiliates if for any
reason we do not execute such bonds.
Westfield Insurance Company is listed on the U.S. Treasury Department's Listing of
Approved Sureties (Department Circular 570), and is rated A XV by A.M. Best Company.
Sincerely,
0,„
Kevin Wojtowicz
Attorney -In -Fact
1000 Central Avenue
Suite 200
St. Petersburg, FL 33705
P: 727.209.1803
F: 727.209.1335