MARSHALL STREET WRF SAND FILTER REHABILITATION -20-0011-UTWalbridge
100 S Ashley Dr., Suite 350 I Tampa, Florida 33602 1 813-622-8900 1 www.walbridge.com
City of Clearwater Marshall Street WRF Sand Filter Rehabilitation
Date October 12, 2021
TO: Kaylynn Price
City of Clearwater — Engineering Department
100 S. Myrtle Ave., Suite 200
Clearwater, FL 33756
RE: Marshall Street WRF Sand Filter Rehabilitation 20 -0011 -UT
As requested, enclosed is the proposal for Sand Filter Rehabilitation at the Marshall Street
Water Reclamation Facility submitted in accordance with the Tetra Tech Plans and
Specifications indicated, for a Guaranteed Maximum Price of $1,681,538.)
Scope of Work:
Sand Filter Rehabilitation at the Marshall Street Water Reclamation Facility
Cost Detail:
Description
Amount
Cost of Work
1,311,016
Subtotal
1,311,016
General Conditions (or General
Conditions/Supervision/Insurance/Bond)
171,314
Construction Management Fee
68,106
Contingency 10%
131,102
Guaranteed Maximum Price
1,681,538
Project Duration shall be estimated 270 calendar days from the date of the Notice to Proceed.
Existing Contract: This proposal is submitted in conjunction with the existing Construction
Manager at Risk Services Continuing Contract entered into with the City of Clearwater on August
21, 2020, based on RFQ #40-20.
If GMP Exceeds $150,000: Per Section III, Article 5.1 of the Contract Specifications, the
contractor shall provide to the public entity a certified copy of the recorded bond. Once the City
Walbridge
100 S Ashley Dr., Suite 350 1 Tampa, Florida 33602 1 813-622-8900 1 www.walbridge.com
receives a certified copy of the recorded bond, a Notice to Proceed may be issued. Include the
attached bond form as well as the Power of Attorney.
Code: 3217321-546700-96213
For work performed, invoices shall be submitted to the City of Clearwater, Engineering
Department, Attn: Veronica Josef, Senior Staff Assistant, P.O. Box 4748, Clearwater, Florida,
33758-4748. Contingency services may be billed only after written authorization is provided by
the City to proceed with those services.
Approved as to form:
tA
Owen Kohler
Assistant City Attorney
ou�}tersigned:
ank Hibbard
Mayor
Date
glut(
Walbridge
Project Director
ate
CITY OF CLEARWATER, FLORIDA
Attest:
By: .f�dlVtil12.� `--4-DC
Rosemarie Call
City Clerk
7iVlicah Maxwell
Interim City Manager
Date
Walbridge
100 S Ashley Dr., Suite 350 I Tampa, Florida 33602 1 813-622-8900 1 www.walbridge.com
PUBLIC CONSTRUCTION BOND
(1)
Bond No.:
This bond is given to comply with § 255.05, Florida Statutes, and any action instituted by a claimant under this
bond for payment must be in accordance with the notice and time limitation provisions in subsections (2) and
(10).
Pursuant to § 255.05(1)(b), Florida Statutes, "Before commencing the work or before recommencing the work
after a default or abandonment, the contractor shall provide to the public entity a certified copy of the
recorded bond. Notwithstanding the terms of the contract or any other law governing prompt payment for
construction services, the public entity may not make a payment to the contractor until the contractor has complied
with this paragraph."
CONTRACTOR SURETY OWNER
[name] [name] City of Clearwater
[principal business address] [principal business address] Engineering Department
[phone number] [phone number] 100 S. Myrtle Avenue
Clearwater, FL 33756
(727) 562-4747
PROJECT NAME: project name
PROJECT NO.: project number
PROJECT DESCRIPTION: construct a gravity sewer system including approximately 250 LF of gravity sewer
piping, 3 precast manholes, and other appurtenances
BY THIS BOND, We [contractor], as Contractor, and [surety], a corporation, as Surety, are bound to the City of
Clearwater, Florida, herein called Owner, in the sum of $[x,xxx,xxx.xx], for payment of which we bind ourselves,
our heirs, personal representatives, successors, and assigns, jointly and severally.
THE CONDITION OF THIS BOND is that if Contractor:
1. Performs the proposal dated [ ], between Contractor and Owner for construction of
[project name] , the contract documents being made a part of this bond by reference (which include the
Advertisement for Bids, Proposal, Contract, Surety Bond, Instructions to Bidders, General Conditions, Plans,
Technical Specifications and Appendix, and such alterations as may be made in said Plans and Specifications as
therein provided for), at the times and in the manner prescribed in the contract; and
2. Promptly makes payments to all claimants, as defined in Section 255.05(1), Florida Statutes, supplying
Contractor with labor, materials, or supplies, used directly or indirectly by Contractor in the prosecution of the
work provided for in the contract; and
3. Pays Owner all losses, damages, expenses, costs, and attorney's fees, including appellate proceedings,
that Owner sustains because of a default by Contractor under the contract; and
Walbridge
100 S Ashley Dr., Suite 350 1 Tampa, Florida 33602 1 813-622-8900 1 www.walbridge.com
PUBLIC CONSTRUCTION BOND
(2)
Bond No.:
4. To the limits of § 725.06(2), Florida Statutes, shall indemnify and hold harmless Owner, their officers and
employees, from liabilities, damages, losses and costs, including, but not limited to, reasonable attorney's fees,
to the extent caused by the negligence, recklessness, or intentional wrongful misconduct of Contractor and persons
employed or utilized by Contractor in the performance of the construction contract; and
5. Performs the guarantee of all work and materials furnished under the contract for the time specified in the
contract, then this bond is void; otherwise it remains in full force.
6. Any action instituted by a claimant under this bond for payment must be in accordance with the notice
and time limitation provisions in Section 255.05(2), Florida Statutes.
7. Any changes in or under the contract documents and compliance or noncompliance with any formalities
connected with the contract or the changes does not affect Surety's obligation under this bond, and Surety does
hereby waive notice of any such change, extension of time, alteration or addition to the terms of the contract or
to the work or to the specifications.
IN TESTIMONY WHEREOF, witness the hands and seals of the parties hereto this day of
20
(If sole Ownership or Partnership, two (2) Witnesses required).
(If Corporation, Secretary only will attest and affix seal).
[TYPE LEGAL NAME OF CONTRACTORI
By:
Title:
Name:
WITNESS: WITNESS:
Corporate Secretary or Witness Print Name:
Print Name:
Print
(affix corporate seal) [Leave blank for Name of Corporate Surety]
By:
ATTORNEY-IN-FACT
Print Name:
(affix corporate seal)
(Power of Attorney must be attached)