Loading...
CONSTRUCTION MANAGER AT RISK SERVICES - RFQ #52-19 - IMAGINE CLEARWATERConstruction Manager at Risk Services Skanska USA Building, Inc. RFQ #52-19 — Imagine Clearwater This CONTRACT made and entered into this 19th day of December 2019, by and between the City of Clearwater, Florida, a municipal corporation, hereinafter designated as the "City" or "Owner", and Skanska USA Building, Inc., a corporation incorporated in Delaware and authorized to do business in Pinellas County and State of Florida, hereinafter designated as the "Construction Manager". The contracting entities shall collectively be known as the "Parties." WITNESSETH: WHEREAS, the Clearwater City Council has approved using the Construction Manager at Risk approach on appropriate projects as determined by the City's Engineering Department; and WHEREAS, the City desires to engage the services of a Construction Manager (CM) at Risk firm to provide management of the preconstruction and construction services (the "Services") as described herein for the Imagine Clearwater Project (Project # 17-0031-EN); and WHEREAS, the City selected the Construction Manager in accordance with the competitive selection process based on information and representations given by the Construction Manager in a response to Request For Qualifications #52-19; and WHEREAS, the City has engaged the services of Stantec Consulting Services, Inc. hereinafter designated as the "Architect-Engineer" to manage the design services to be performed by itself and its other design consultants. NOW, THEREFORE, IT IS AGREED BY THE PARTIES: ARTICLE 1: SCOPE OF WORK AND CONTRACT DOCUMENTS 1.1 The Construction Manager and its successors, assigns, executors or administrators, in consideration of the sums of money, as herein after set forth to be paid by the City to the Construction Manager, shall and will at its own cost and expense perform all labor, furnish all materials, tools and equipment for all individual projects assigned as a result of this contract. 1.2 For each individual project assigned, in accordance with such proposal and technical supplemental specifications and such other special provisions and drawings, if any, which will be submitted by the City, together with any advertisement, instructions to bidders, general conditions, proposal and bond, which may be hereto attached, and any drawings, if any, which may be herein referred to, are hereby made a part of this contract, and all of said work to be performed and completed by the contractor and its successors and assigns shall be fully completed in a good and workmanlike manner to the satisfaction of the City. 3 Unless otherwise specified in this Contract, all work shall be completed in accordance with Section III and Section IV of the City of Clearwater Contract Specifications (the "Specifications"). For the purposes of this Contract, the term Contractor in Section III shall include the Construction Manager. The Specifications, as may be supplemented and changed, along with this Contract constitute the "Contract Documents." All terms and conditions as set forth in RFQ #52-19, Standard Terms of Conditions are incorporated by reference and attached hereto. Any inconsistency in documents relating to this Contract shall be resolved by giving precedence in the following order: (i) GMP Proposal(s); (ii) this Contract and any subsequent amendments; (iii) Specifications; (iv) RFQ #52-19, Standard Terms and Conditions; and (v) Preconstruction Services Proposal(s). ARTICLE 2: CONSTRUCTION MANAGER'S DUTIES AND STATUS 2.1 The Construction Manager recognizes the relationship of trust and confidence established between it and the City by this Agreement, and agrees with the City to furnish its best skill and judgment and the overall supervision of its executives; to furnish efficient business administration and superintendence; and to use every effort to keep upon the project site at all times an adequate supply of workforce and materials to secure its execution and completion in the most expeditious and economical manner. 2.2 The Construction Manager represents that it has made a thorough examination of the premises and is thoroughly familiar with the conditions under which it is to work. 2.3 The Construction Manager agrees to perform and complete the Services in accordance with laws, rules, and regulations of all governmental authorities and departments thereof. 2.4 The Construction Manager agrees to cooperate with the City, Architect-Engineer, or any other Design Professional in all respects, including, but not limited to, providing necessary preconstruction services, such as evaluation of inethods, availability and costs of the various components of the Services while under design consideration; supervising the Services and the progress thereof; the coordination of the Services and suggesting changes in the Services; and supplying information as to costs and availability of materials and methods of construction in order, amongst other things, to reduce costs wherever the same may be practicably consistent with the quality of the Services presented in the Contract Documents. 2.5 The Construction Manager agrees to the following: a) In connection with the perFormance of work under this Contract, the Construction Manager agrees not to discriminate against any employee or applicant for employment because of race, sex, religion, color, or national origin. The aforesaid provision shall include, but not be limited to, the following employment: - upgrading - demotion or transfer - recruitment or recruitment advertising - lay-off or termination - rates of pay or other forms of compensation; and 2 selection for training, including apprenticeship b) The Construction Manager agrees to post hereafter in conspicuous places, available for employees or applicants for employment, notices to be provided by the contracting officer setting forth the provisions of the non-discrimination clause. c) The Construction Manager further agrees to insert the foregoing provisions in all contracts hereunder, including contracts or agreements with labor unions and/or worker's representatives, except sub-contractors for standard commercial supplies or raw materials. ARTICLE 3: SCOPE OF THE SERVICES 3.1 The services that the Construction Manager shall provide include but are not limited to those described in the following sections. 3.2 Reporting - Written reports shall be provided with the monthly pay requests as follows: a) Monthly Executive Summary which provides an overview of current issues and pending decisions, future developments and expected achievements, and any problems or delays, including code violations found by any permitting agency. b) A Monthly Construction Progress Report that includes a cost narrative, a scheduling narrative and that summarizes the work of the various subcontractors. This report shall include information from the weekly job site meetings as applicable such as: - general conditions - long lead supplies - current deliveries - safety and labor relations programs permits - construction problems and recommendations; and - plans for the succeeding month 3.3Scheduling a) Upon award of this Contract, the Construction Manager shall submit a master project schedule covering the planning and design approvals, construction, and Owner occupancy of the Project. This schedule will serve as the framework for the subsequent development of all detailed schedules. The master project schedule shall be produced and updated monthly throughout the project. b) Within thirty (30) days after the date of the Owner's issuance of a Notice to Proceed, the Construction Manager shall prepare and submit to the Owner two copies of a Critical Path Method (CPM) construction schedule graphically depicting the activities contemplated to occur as a necessary incident to performance of the work required to complete the project, showing the sequence in which the Construction Manager 3 proposes for each such activity to occur and duration (dates of commencement and completion, respectively) of each activity. c) Following development and submittal of the construction schedule the Construction Manager shall, at the end of each calendar month during the project, or at such earlier intervals as circumstances may require, update and/or revise the construction schedule to show the actual progress of the work performed and the occurrences of all events which have affected the progress of performance of work already performed or will affect the progress of the performance of the work yet to be performed in contrast with the planned progress of performance of such work, as depicted on the original construction schedule and all updates and/or revisions thereto as reflected in the updated and/or revised construction schedule last submitted prior to submittal of each such monthly update and revision. Each such update and/or revision to the construction schedule shall be submitted to the Owner in duplicate. d) The Construction Manager shall provide current scheduling information and provide direction and coordination regarding milestones, beginning and finishing dates, responsibilities for performance and the relationships of the Construction Manager's work to the work of his subcontractors and suppliers to enable them to perform their respective tasks so that the development of construction progresses in a smooth and efficient manner in conformance with the overall project schedule. The schedule shall include all phases of the construction work, material supplies, long lease procurement, approval of shop drawings, change orders in progress, schedules for change orders, and performance testing requirements. The Construction Manager shall advise the Owner, its representatives, and the Architect-Engineer of their required participation in any meeting or inspection giving each at least one week notice unless such notice is made impossible by conditions beyond his control. The Construction Manager shall hold job-site meetings at least once each month with the Construction Team and at least once each week with the subcontractors and the Architect-Engineer's Field Representative, or more frequently as required by work progress, to review progress, discuss problems and their solutions and coordinate future work with all subcontractors. e) Twice per month corresponding as closely as possible with progress review meetings, a"two week" look ahead report shall be prepared and submitted to Owner and Architect / Engineer. 3.4Design Review and Recommendations a) The Construction Manager shall familiarize himself thoroughly with the evolving architectural, civil, mechanical, plumbing, electrical and structural plans and specifications and shall follow the development of design through Contract Documents. The Construction Manager shall make recommendations with respect to the selection of systems and materials, and cost reducing alternatives including assistance to the Architect-Engineer and Owner in evaluating alternative comparisons versus long term cost effect. The evaluation shall speak to the benefits 0 of the speed of erection and early completion of the project. The Construction Manager shall furnish pertinent information as to the availability of materials and labor that will be required. The Construction Manager shall submit to the Owner and Architect-Engineer such comments as may be appropriate concerning construction, feasibility, and practicality. The Construction Manager shall bring to the Owner and the Architect-Engineer's attention any apparent defects in the design, drawing and specifications, or other documents. The Construction Manager shall prepare an estimate of the construction cost at appropriate milestones during the design and shall evaluate such estimate with the project budget. The Construction Manager shall recommend cost saving alternatives, as appropriate, at each design milestone. At each design milestone the Owner, Architect Engineer and Construction Manager shall conduct a value engineering review. b) After receiving the Construction Documents for each phase of the project, the Construction Manager shall perform a specific review thereof. Promptly after completion of the review, the Construction Manager shall submit to the Owner, with a duplicate to the Architect-Engineer, a written report covering suggestions or recommendations previously submitted, additional suggestions or recommendations as the Construction Manager may deem appropriate, and all actions taken by the Architect-Engineer with respect to same, any comments he may deem to be appropriate with respect to separating the work into separate contracts and/or alternative materials. c) At completion of the Construction Manager's review of the plans and specifications, except only as to specific matters as may be identified by appropriate comments pursuant to this section, the Construction Manager shall warrant, without assuming any architectural or engineering responsibility, that the plans and specifications are consistent, practical, feasible and constructible. The Construction Manager shall warrant that the work described in the plans and specifications for the various bidding packages is constructible within the scheduled construction time. d) The Construction Manager shall review the design for the purpose of identifying long lead procurement items (i.e. machinery, equipment, materials, and supplies). When each item is identified, the Construction Manager shall notify the subcontractors, the Owner, and the Architect-Engineer of the required procurement and schedule. Such information shall be included in the bid documents and made a part of all affected sub-contracts. As soon as the Architect-Engineer has completed drawings and technical specifications and the Construction Manager has obtained permitting approval, the Construction Manager shall prepare invitations for bids. The Construction Manager shall keep informed of the progress of the respective subcontractors or suppliers, manufacturing or fabricating such items and advise Project Director, Owner and Architect-Engineer of any problems or prospective delay in delivery. 5 3.5Staffing - Key personnel assigned to City projects by the Construction Manager shall not be removed from the project until alternate personnel acceptable to the City are approved in writing by the City. 3.6Soliciting Bids a) Without assuming responsibilities of the Architect-Engineer, and unless waived in writing by the Owner, the Construction Manager shall prepare invitations for bids, or requests for proposal when applicable, for all procurements of long lead items, materials, and services, and for Subcontractor contracts. Such invitations for bids shall be prepared in accordance with the following guidelines: i) Contracts totaling $1,000 but not exceeding $10,000 may be entered into by the Construction Manager with the firm which is qualified and submits the lowest verbal quotation. The Construction Manager shall obtain a minimum of two (2) verbal quotations. These quotations shall be entered on a bid tabulation sheet and a copy of such tabulation sent to the Owner, Architect-Engineer and to each firm. The successful quotation shall be confirmed by written contract or purchase order to the low bid firm defining the scope and quality of work to be provided. ii) Contracts totaling $10,000 but not exceeding $200,000 may be entered into by the Construction Manager with the firm who is qualified and submits the lowest responsive proposal. The Construction Manager shall request at least three (3) firms to submit sealed written proposals based on written drawings and/or specifications. The written proposals shall all be opened publicly at the location, date and time named by the Construction Manager in his request for proposal. A tabulation of the results shall be furnished to the Owner, Architect- Engineer and to each firm. iii) Contracts totaling $200,000 but not exceeding $500,000 may be entered into by the Construction Manager with the firm who is pre-qualified and submits the lowest responsive proposal. The Construction Manager shall advertise these projects at least once with the last advertisement appearing at least 21 calendar days prior to the established bid opening date. These proposals shall be based on approved plans and specifications. Bids shall be received and opened publicly at the location, date and time established in the bid advertisement. iv) Contracts totaling $500,000 or greater shall be treated the same as described under iii above except that the advertisement shall be run for at least 30 days prior to the established bid opening and at least 5 days prior to any scheduled pre-bid conference. v) Individual purchases of materials or rentals or leases of equipment of up to $999.99 each may be made without bids or quotes when reasonably necessary to expedite work on the project; however, the Construction Manager shall not � divide or separate a procurement in order to avoid the requirements set forth above. vi) Site utilities may be acquired at market rates from the entity(ies) providing such in the franchise area. b) For each separate construction contract exceeding $35,000, the Construction Manager shall, unless waived by Owner, conduct a pre-bid conference with prospective bidders, the Architect-Engineer, and the Owner. In the event questions are raised which require an interpretation of the bidding documents or otherwise indicate a need for clarification or correction of the invitation, the Construction Manager shall transmit these to the Architect-Engineer and upon receiving clarification or correction in writing shall prepare an addendum to the bidding document, and issue same to all of the prospective bidders. 3.7 Quality Control - The Construction Manager shall develop and maintain a program, acceptable to the Owner and Architect-Engineer that assures quality control of the construction. The Construction Manager shall supervise the work of all subcontractors providing instruction to each when their work does not conform to the requirements of the plans and specifications and shall continue to assert influence and control over each subcontractor to ensure that corrections are made in a timely manner so as to not affect the efficient progress of the work. Should disagreement occur between the Construction Manager, the Owner, or the Architect-Engineer over acceptability of work and conformance with the requirements of the specifications and plans, the Owner shall be the final judge of performance and acceptability. 3.8 Subcontractor Interfacing - The Construction Manager shall be the single point of interface with all subcontractors for any work done under this Contract. The Construction Manager shall negotiate all change orders, field orders and request for proposals, with all affected subcontractors and shall review the costs of those proposals and advise the Owner and Architect-engineer of their validity and reasonableness, acting in the Owner's best interest prior to requesting approval of each change order from the Owner. Before any work is begun on any change order, a written authorization from the Owner must be issued. When health and safety are threatened, however, the Construction Manager shall act immediately to remove such threat to health and safety. The Construction Manager shall also carefully review all shop drawings and then forward the same to the Architect-Engineer for review and actions, The Architect-Engineer will transmit them back to the Construction Manager who will then issue the shop drawings to the affected subcontractor for fabrication or revision. The Construction Manager shall maintain a record to promote expeditious handling. The Construction Manager shall request the Architect-Engineer to make interpretations of the drawings or specifications requested of him by the subcontractors and shall maintain a record to promote timely response. The Construction Manager shall advise the Owner and Architect-Engineer when timely response is not occurring on any of the above. The Construction Manager shall collect, review, and submit to the Owner, all project closeout documentation including operation, maintenance, and training manuals. 7 ARTICLE 4: MAXIMUM PROJECT COST AND FEES FOR SERVICES 4.1 Guaranteed Maximum Price for Construction a) When the Construction Documents are sufficiently complete to establish the scope of work for the project or any portion thereof, the Construction Manager will establish and submit in writing to the Owner for his approval a Guaranteed Maximum Price (GMP) guaranteeing the maximum price to the Owner, for the construction cost of the project or designated part thereof. Such Guaranteed Maximum Price will be subject to modification for changes in the project as provided in article 4.1(e) below. Actual price paid for the work by the Owner, however, shall be the actual cost of all work subcontracts, supply contracts, direct labor costs, direct supervision costs and direct job costs, plus the Construction Manager's fees or the GMP, whichever is less when the work is complete. Invoicing shall occur monthly for completed work with 5% retainage withheld until final completion and acceptance of all work covered in the contract documents in accordance to the City's General Conditions. GMP Proposals will be incorporated by reference and attached hereto as an exhibit. b) At the time of submission of a Guaranteed Maximum Price, the Construction Manager will verify the time schedule for activities and work which were adopted and used to determine the Construction Manager's cost of work. In addition to the cost of work, a GMP will include an agreed upon sum as the construction contingency which is included for the purpose of defraying the expenses due to unforeseen circumstances relating to construction. The Construction Manager will be required to furnish documentation evidencing expenditures charged to the contingency prior to the release of funds by the Owner. If bids are received below the applicable line items in the GMP, the surplus will be added to the contingency. c) If bids are received above the applicable line item in the GMP, the deficiency will be taken from the contingency; however, such occurrence shall not be cause to increase the GMP. d) If bids are not received for a portion of the work at or below the applicable line item amount in the GMP, the Construction Manager reserves the right to perform that portion of the work as acknowledged by the Owner or negotiate for its performance for the specified line item lump sum amount or less. e) The increase or decrease in the Guaranteed Maximum Price resulting from a change in the Project shall be determined in one or more of the following ways: By mutual acceptance of a lump sum properly itemized and supported by sufficient substantiating data to permit evaluation by the Architect Engineer and Owner; By unit prices stated in the Agreement or subsequently agreed upon; iii. If none of the methods is agreed upon, the Construction Manager, provided it has received a signed written order by the Owner, shall promptly proceed : with the work involved. The cost of such work shall then be determined on the basis of the reasonable expenditures and savings of those performing the work attributed to the change. In the event a Change Order is issued under these conditions, however, the Architect-Engineer will establish an estimated cost of the work and the Construction Manager shall not perform any work whose cost exceeds that estimate without prior written approval by the Owner. In such case, the Construction Manager shall keep and present, in such form as the Owner may prescribe, an itemized accounting together with appropriate supporting data of the increase in the Cost of the Project. The amount of decrease in the Guaranteed Maximum Price to be allowed by the Construction Manager to the Owner for any deletion or change which results in a net decrease in cost will be the amount of the actual net decrease; iv. The Architect-Engineer will have authority to order minor changes in the Project not involving an adjustment in the Guaranteed Maximum Price or an extension of the Construction Completion Date and not inconsistent with the intent of the Drawings and Specifications. Such changes shall be affected by written order. Documentation of changes shall be determined by the Architect-Engineer. Changes shall be approved by the Architect- Engineer. 4.2Construction Manager's Fee - In consideration of the performance of the contract, the Owner agrees to pay the Construction Manager as compensation for his services, fees as set forth below: Preconstruction Phase Fee - shall be based on design costs if applicable, constructability review, value engineering and fee determination of Guaranteed Maximum Price. The fee for this phase in the amount of $425,000.00 shall be paid at the negotiated price upon receipt of the Guaranteed Maximum Price. Preconstruction Services Proposals will be incorporated by reference and attached hereto as an exhibit. Construction Phase Fee - Prior to commencement of the Construction Phase, the Owner will direct the Construction Manager in writing to proceed into the Construction Phase. The Construction Manager's compensation for work or service performed during the Construction Phase shall be a fee of TBD. The Construction Phase Fee shall be invoiced and paid in TBD months. Payments will be remitted monthly at the cost of TBD each and one final monthly payment of � TBD. The first monthly payment shall become due thirty days following the issuance of the first Construction Authorization and the final monthly payment shall be paid only when construction of the project is completed and occupancy of the project accepted by the Owner. If construction is authorized only for a part of the project, the fee paid shall be proportionate to the amount of work authorized by the Owner. �7 ARTICLE 5: TERMINATION AND TIME OF THE ESSENCE 5.1 If the Construction Manager is adjudged bankrupt or makes a general assignment for the benefit of creditors, or if a receiver is appointed on account of its insolvency, or if refuses or fails, except in cases for which an extension of time is provided, to supply enough properly skilled workmen or proper materials for the Services, or otherwise be guilty of a substantial violation of any provision of this Agreement as determined by the certificate of the Architect, the Owner may, without prejudice and reserving any other right or remedy the Owner may have, after giving the Construction Manager seven (7) days' written notice, terminate the employment of the Construction Manager and take possession of the premises and all materials, tools, and appliances thereon and finish the Project in whatever manner the Owner may deem expedient. 5.2 It is mutually agreed between the parties hereby that time is of the essence of this contract, and in the event that the Substantial Completion Date is not achieved within the time stipulated herein, it is then further agreed that the City may deduct from such sums or compensation as may be due to the Construction Manager, the sum of $1,000.00 per dav for each day that the work to be performed by the Construction Manager remains incomplete beyond the time limit specified herein, which sum of $1,000.00 per dav shall only and solely represent damages which the City has sustained by reason of the failure of the Construction Manager to complete the work within the time stipulated, it being further agreed that the sum is not to be construed as a penalty but is only to be construed as liquidated damages for failure of the Construction Manager to complete and perform all work within the time period as specified in this contract. ARTICLE 6: INDEMNIFICATION 6.1The Construction Manager and his or its successors and assigns does hereby agree to assume the defense of any legal action which may be brought against the City as a result of the Construction Manager's activities arising out of this contract and furthermore, in consideration of the terms, stipulations and conditions as contained herein, agrees to hold the city free and harmless from any and all claims for damages, costs of suits, judgments or decrees resulting from any claims made under this contract against the city or the contractor or the contractor's sub-contractors, agents, servants or employees resulting from activities by the aforementioned contractor, sub-contractor, agent servants or employees. 6.2 Nothing contained herein shall be construed as a waiver of any immunity from or limitation of liability the City (Owner) may be entitled to under the doctrine of sovereign immunity or section 768.28, Florida Statutes. ARTICLE 7: TITLE TO THE PROJECT 7.1 The title of all work, completed portions of the Project and in the course of construction, and of all materials on account of which payment has been made shall be in the Owner. 10 ARTICLE 8: ASSIGNMENT 8.1 This Agreement shall be binding upon and inure to the benefit of the Parties hereto and their respective successors and assigns, except that this Agreement may not be assigned by either party without the prior written consent of the other party. Any assignment made without such prior written consent shall not vest rights in the assignee. ARTICLE 9: ADDITIONAL PROVISIONS 9.1 This Agreement shall be governed by and construed in accordance with the laws of the State of Florida, and the venue for any dispute under this Agreement shall be an appropriate court of competent jurisdiction in Pinellas County, Florida. 9.2 Any notice required to be given by the terms and provisions of this Agreement or by any law or governmental regulation, either by the Owner or Construction Manager, shall be in writing unless otherwise required by such law or regulation and shall be deemed to have been served and given when deposited in either Registered or Certified Mail in United States Branch Post Office, addressed to the party hereto to whom directed, at the address specified in the Specifications. 9.3 The language in this Agreement shall be construed according to its customary meaning within the Florida building industry. Whenever used, the singular shall include the plural, the plural the singular, and the use of any gender shall be applicable to all genders. 9.4 If any provision of the Contract Documents is invalid or unenforceable as against any person or party, the remainder of the Contract Documents and the applicability of such provision to other persons or parties shall not be affected thereby. 9.5 Nothing contained in this Agreement shall be construed to mean that the Construction Manager and Owner are joint venturers or partners. 9.6 Neither party will be liable for incidental, special, or consequential damages. 9.7The City's performance and obligation to pay under this Contract is contingent upon an annual appropriation by the Clearwater City Council. In the event the Clearwater City Council does not appropriate funds in a sufficient amount for the City to perform its obligations under this Contract, the City may terminate this Contract upon thirty (30) days written notice to the Contraction Manager. 11 IN WITNESS WHEREOF, the parties hereto have made and executed this Contract on the date and year first above written. (Corporate Seal) `��.•�"Sp suild'y•. a•�� o�OR/IrF h9i ;.���` L y� , �Fj � ,. , y, �'• •��C, ����''ti... � DELA�P�''�� Countersigned: — C,�e�o r�c.nc�c�.�os George N. Cretekos Mayor Approved as to form: � Owen Kohler Assistant City Attorney SKANSKA USA BUILDING, INC. Print Name: nn�cnaei c. arown, P.E. xecut�ve ice resi ent an Title: WITNESS: gy. L' �ur.w�.�� �� G�Pr-4a✓r Print Name: c h�a- <<—s �: Jh� /o� CITY OF CLEARWATER h «�,� ��x�r�l Willia� . Horne II � City Manager Attest: ��� � Rcisemarie Call City Clerk 12 ti.p►��Ql�' �'''' � � . c.,, t,c.�- ' _ o '�►;:�� �, � _ ;� `' R..�, .: a . �s���� C�9�a�`'� RFQ #52-19 — Standard Terms and Conditions S.1 INDEPENDENT CONTRACTOR. It is expressly understood that the relationship of Contractor to the City will be that of an independent contractor. Contractor and all persons employed by Contractor, either directly or indirectly, are Contractor's employees, not City employees. Accordingly, Contractor and Contractor's employees are not entitled to any benefits provided to City employees including, but not limited to, health benefits, enroliment in a retirement system, paid time off or other rights afforded City employees. Contractor employees will not be regarded as City employees or agents for any purpose, inciuding the payment of unemployment or workers' compensation. If any Contractor employees or subcontractors assert a claim for wages or other employment benefits against the City, Contractor will defend, indemnify and hold harmless the City from all such claims. S.2 SUBCONTRACTING. Contractor may not subcontract work under this Agreement without the express written permission of the City. If Contractor has received authorization to subcontract work, it is agreed that all subcontractors performing work under the Agreement must comply with its provisions. Further, all agreements between Contractor and its subcontractors must provide that the terms and conditions of this Agreement be incorporated therein. S.3 ASSIGNMENT. This Agreement may not be assigned either in whole or in part without first receiving the City's written consent. Any attempted assignment, either in whole or in part, without such consent will be null and void and in such event the City will have the right at its option to terminate the Agreement. No granting of consent to any assignment will relieve Contractor from any of its obligations and liabilities under the Agreement. S.4 SUCCESSORS AND ASSIGNS, BINDING EFFECT. This Agreement will be binding upon and inure to the benefit of the parties and their respective permitted successors and assigns. S.5 NO THIRD PARTY BENEFICIARIES. This Agreement is intended for the exclusive benefit of the parties. Nothing set forth in this Agreement is intended to create, or will create, any benefits, rights, or responsibilities in any third parties. S.6 NON- EXCLUSIVITY. The City, in its sole discretion, reserves the right to request the materials or services set forth herein from other sources when deemed necessary and appropriate. No exclusive rights are encompassed through this Agreement. S.7 AMENDMENTS. There will be no oral changes to this Agreement. This Agreement can only be modified in a writing signed by both parties. No charge for extra work or material will be allowed unless approved in writing, in advance, by the City and Contractor. S.8 TIME OF THE ESSENCE. Time is of the essence to the performance of the parties' obligations under this Agreement. S.9 COMPLIANCE WITH APPLICABLE LAWS. a. General. Contractor must procure all permits and licenses, and pay all charges and fees necessary and incidental to the lawful conduct of business. Contractor must stay fully informed of existing and future federal, state, and local laws, ordinances, and regulations that in any manner affect the fulfillment of this Agreement and must comply with the same at its own expense. Contractor bears full responsibility for training, safety, and providing necessary equipment for all Contractor personnel to achieve throughout the term of the Agreement. Upon request, Contractor will demonstrate to the City's satisfaction any programs, procedures, and other activities used to ensure compliance. b. Drug-Free Workplace. Contractor is hereby advised that the City has adopted a policy establishing a drug-free workplace for itself and those doing business with the City to ensure the safety and health of all persons working on City contracts and projects. Contractor will require a drug-free workplace for all Contractor personnel working under this Agreement. Specifically, all Contractor personnel who are working under this Agreement must be notified in writing by Contractor that they are prohibited from the manufacture, distribution, dispensation, possession, or unlawful use of a controlled substance in the workplace. Contractor agrees to prohibit the use of intoxicating substances by all Contractor personnel, and will ensure that Contractor personnel do not use or possess illegal drugs while in the course of perForming their duties. c. Federal and State Immigration Laws. Contractor agrees to comply with the Immigration Reform and Control Act of 1986 (IRCA) in performance under this Agreement and to permit the City and its agents to inspect applicable personnel records to verify such compliance as permitted by law. Contractor will ensure and keep appropriate records to demonstrate that all Contractor personnel have a legal right to live and work in the United States. (i) As applicable to Contractor, under this provision, Contractor hereby warrants to the City that Contractor and each of its subcontractors will comply with, and are contractually obligated to comply with, all federal immigration laws and regulations that relate to their employees (hereinafter "Contractor Immigration Warranty"). (ii) A breach of the Contractor Immigration Warranty will constitute as a material breach of this Agreement and will subject Contractor to penalties up to and including termination of this Agreement at the sole discretion of the City. (iii) The City retains the legal right to inspect the papers of all Contractor personnel who provide services under this Agreement to ensure that Contractor or its subcontractors are complying with the Contractor Immigration Warranty. Contractor agrees to assist the City in regard to any such inspections. (iv) The City may, at its sole discretion, conduct random verification of the employment records of Contractor and any subcontractor to ensure compliance with the Contractor Immigration Warranty. Contractor agrees to assist the City in regard to any random verification performed. (v) Neither Contractor nor any subcontractor will be deemed to have materially breached the Contractor Immigration Warranty if Contractor or subcontractor establishes that it has complied with the employment verification provisions prescribed by Sections 274A and 274B of the Federal Immigration and Nationality Act. d. Nondiscrimination. Contractor represents and warrants that it does not discriminate against any employee or applicant for employment or person to whom it provides services because of race, color, religion, sex, national origin, or disability, and represents and warrants that it complies with all applicable federal, state, and local laws and executive orders regarding employment. Contractor and Contractor's personnel will comply with applicable provisions of Title VII of the U.S. Civil Rights Act of 1964, as amended, Section 504 of the Federal Rehabilitation Act, the Americans with Disabilities Act (42 U.S.C. § 12101 et seq.), and applicable rules in performance under this Agreement. S.10 SALESIUSE TAX, OTHER TAXES. a. Contractor is responsible for the payment of all taxes including federal, state, and local taxes related to or arising out of Contractor's services under this Agreement, including by way of illustration but not limitation, federal and state income tax, Social Security tax, unemployment insurance taxes, and any other taxes or business license fees as required. If any taxing authority should deem Contractor or Contractor employees an employee of the City, or should otherwise claim the City is liable for the payment of taxes that are Contractor's responsibility under this Agreement, Contractor will indemnify the City for any tax liability, interest, and penalties imposed upon the City. b. The City is exempt from paying state and local sales/use taxes and certain federal excise taxes and will furnish an exemption certificate upon request. S.11 AMOUNTS DUE THE CITY. Contractor must be current and remain current in all obligations due to the City during the performance of services under the Agreement. Payments to Contractor may be offset by any delinquent amounts due the City or fees and charges owed to the City. 2 S.12 OPENNESS OF PROCUREMENT PROCESS. Written competitive proposals, replies, oral presentations, meetings where vendors answer questions, other submissions, correspondence, and all records made thereof, as well as negotiations or meetings where negotiation strategies are discussed, conducted pursuant to this RFP, shall be handled in compliance with Chapters 119 and 286, Florida Statutes. Proposals or replies received by the City pursuant to this RFP are exempt from public disclosure until such time that the City provides notice of an intended decision or until 30 days after opening the proposals, whichever is earlier. If the City rejects all proposals or replies pursuant to this RFP and provides notice of its intent to reissue the RFP, then the rejected proposals or replies remain exempt from public disclosure until such time that the City provides notice of an intended decision concerning the reissued RFP or until the City withdraws the reissued RFP. A proposal or reply shall not be exempt from public disclosure longer than 12 months after the initial City notice rejecting all proposals or replies. Oral presentations, meetings where vendors answer questions, or meetings convened by City staff to discuss negotiation strategies, if any, shall be closed to the public (and other proposers) in compliance with Chapter 286 Florida Statutes. A complete recording shall be made of such closed meeting. The recording of, and any records presented at, the exempt meeting shall be available to the public when the City provides notice of an intended decision or until 30 days after opening proposals or final replies, whichever occurs first. If the City rejects all proposals or replies pursuant to this RFP and provides notice of its intent to reissue the RFP, then the recording and any records presented at the exempt meeting remain exempt from public disclosure until such time that the City provides notice of an intended decision concerning the reissued RFP or until the City withdraws the reissued RFP. A recording and any records presented at an exempt meeting shall not be exempt from public disclosure longer than 12 months after the initial City notice rejecting all proposals or replies. S.13 AUDITS AND RECORDS. Contractor must preserve the records related to this Agreement for five (5) years after completion of the Agreement. The City or its authorized agent reserves the right to inspect any records related to the performance of work specified herein. In addition, the City may inspect any and all payroll, billing or other relevant records kept by Contractor in relation to the Agreement. Contractor will permit such inspections and audits during normal business hours and upon reasonable notice by the City. The audit of records may occur at Contractor's place of business or at City offices, as determined by the City. However, to the extent that any lump sums, billable rates, fixed percentages, or multipliers are negotiated and established in advance within the Contract Documents, they will be auditable only to confirm their proper application and not their composition. S.14 BACKGROUND CHECK. The City may conduct criminal, driver history, and all other requested background checks of Contractor personnel who would perform services under the Agreement or who will have access to the City's information, data, or facilities in accordance with the City's current background check policies. Any officer, employee, or agent that fails the background check must be replaced immediately for any reasonable cause not prohibited by law. S.15 SECURITY CLEARANCE AND REMOVAL OF CONTRACTOR PERSONNEL. The City will have final authority, based on security reasons: (i) to determine when security clearance of Contractor personnel is required; (ii) to determine the nature of the security clearance, up to and including fingerprinting Contractor personnel; and (iii) to determine whether or not any individual or entity may provide services under this Agreement. If the City objects to any Contractor personnel for any reasonable cause not prohibited by law, then Contractor will, upon notice from the City, remove any such individual from performance of services under this Agreement. S.16 DEFAULT. a. A party will be in default if that party: (i) Is or becomes insolvent or is a party to any voluntary bankruptcy or receivership proceeding, makes an assignment for a creditor, or there is any similar action that affects Contractor's capability to perform under the Agreement; 3 (ii) Is the subject of a petition for involuntary bankruptcy not removed within sixty (60) calendar days; (iii) Conducts business in an unethical manner or in an illegal manner; or (iv) Fails to carry out any term, promise, or condition of the Agreement. b. Contractor will be in default of this Agreement if Contractor is debarred from participating in City procurements and solicitations in accordance with Section 27 of the City's Purchasing and Procedures Manual. c. Notice and Opportunity to Cure. In the event a party is in default then the other party may, at its option and at any time, provide written notice to the defaulting party of the default. The defaulting party will have thirty (30) days from receipt of the notice to cure the default; the thirty (30) day cure period may be extended by mutual agreement of the parties, but no cure period may exceed ninety (90) days. A default notice will be deemed to be sufficient if it is reasonably calculated to provide notice of the nature and extent of such default. Failure of the non- defaulting party to provide notice of the default does not waive any rights under the Agreement. d. Anticipatory Repudiation. Whenever the City in good faith has reason to question Contractor's intent or ability to perForm, the City may demand that Contractor give a written assurance of its intent and ability to perform. In the event that the demand is made and no written assurance is given within five (5) calendar days, the City may treat this failure as an anticipatory repudiation of the Agreement. S.17 REMEDIES. The remedies set forth in this Agreement are not exclusive. Election of one remedy will not preclude the use of other remedies. In the event of default: I. The non-defaulting party may terminate the Agreement, and the termination will be effective immediately or at such other date as specified by the terminating party. II. The City may purchase the services required under the Agreement from the open market, complete required work itself, or have it completed at the expense of Contractor. If the cost of obtaining substitute services exceeds the contract price, the City may recover the excess cost by: (i) requiring immediate reimbursement to the City; (ii) deduction from an unpaid balance due to Contractor; (iii) collection against the proposal and/or performance security, if any; (iv) collection against liquidated damages (if applicable); or (v) a combination of the aforementioned remedies or other remedies as provided by law. Costs includes any and all, fees, and expenses incurred in obtaining substitute services and expended in obtaining reimbursement, including, but not limited to, administrative expenses, attorneys' fees, and costs. III. The non-defaulting party will have all other rights granted under this Agreement and all rights at law or in equity that may be available to it. IV. Neither party will be liable for incidental, special, or consequential damages. S.18 CONTINUATION DURING DISPUTES. Contractor agrees that during any dispute between the parties, Contractor will continue to perform its obligations until the dispute is settled, instructed to cease performance by the City, enjoined or prohibited by judicial action, or otherwise required or obligated to cease perFormance by other provisions in this Agreement. S.19 TERMINATION FOR CONVENIENCE. The City reserves the right to terminate this Agreement in part or in whole upon thirty (30) calendar days' written notice. S.20 TERMINATION FOR CONFLICT OF INTEREST F.S. Section 112. Pursuant to F.S. Section 112, the City may cancel this Agreement without penalty or further obligation, if any person significantly involved in initiating, securing, drafting, or creating the Agreement for the City becomes an employee or agent of Contractor. S.21 TERMINATION FOR NON-APPROPRIATION AND MODIFICATION FOR BUDGETARY CONSTRAINT. The City is a governmental agency which relies upon the appropriation of funds by its governing body to satisfy its obligations. If the City reasonably determines that it does not have funds to meet its obligations under this Agreement, the City will have the right to terminate the Agreement without penalty on the last day of the fiscal period for which funds were legally available. In the event of such termination, the City agrees to provide written notice of its intent to terminate thirty (30) calendar days prior to the stated termination date. S.22 PAYMENT TO CONTRACTOR UPON TERMINATION. Upon termination of this Agreement, Contractor will be entitled only to payment for those services perFormed up to the date of termination, and any authorized expenses already incurred up to such date of termination. The City will make final payment within thirty (30) calendar days after the City has both completed its appraisal of the materials and services provided and received Contractor's properly prepared final invoice. S.23 NON-WAIVER OF RIGHTS. There will be no waiver of any provision of this agreement unless approved in writing and signed by the waiving party. Failure or delay to exercise any rights or remedies provided herein or by law or in equity, or the acceptance of, or payment for, any services hereunder, will not release the other party of any of the warranties or other obligations of the Agreement and will not be deemed a waiver of any such rights or remedies. S.24 INDEMNIFICATION/LIABILITY. a. To the fullest extent permitted by law, Contractor agrees to defend, indemnify, and hold the City, its officers, agents, and employees, harmless from and against any and all liabilities, demands, claims, suits, losses, damages, causes of action, fines orjudgments, including costs, attorneys', witnesses', and expert witnesses' fees, and expenses incident thereto, relating to, arising out of, or resulting from: (i) the services provided by Contractor personnel under this Agreement; (ii) any negligent acts, errors, mistakes or omissions by Contractor or Contractor personnel; and (iii) Contractor or Contractor personnel's failure to comply with or fulfill the obligations established by this Agreement. b. Contractor will update the City during the course of the litigation to timely notify the City of any issues that may involve the independent negligence of the City that is not covered by this indemnification. c. The City assumes no liability for actions of Contractor and will not indemnify or hold Contractor or any third party harmless for claims based on this Agreement or use of Contractor-provided supplies or services. S.25 WARRANTY. Contractor warrants that the services and materials will conform to the requirements of the Agreement. Additionally, Contractor warrants that all services will be performed in a good, workman-like and professional manner. The City's acceptance of service or materials provided by Contractor will not relieve Contractor from its obligations under this warranty. If any materials or services are of a substandard or unsatisfactory manner as determined by the City, Contractor, at no additional charge to the City, will provide materials or redo such services until in accordance with this Agreement and to the City's reasonable satisfaction. Unless otherwise agreed, Contractor warrants that materials will be new, unused, of most current manufacture and not discontinued, will be free of defects in materials and workmanship, will be provided in accordance with manufacturer's standard warranty for at least one (1) year unless otherwise specified, and will perform in accordance with manufacturer's published specifications. S.26 THE CITY'S RIGHT TO RECOVER AGAINST THIRD PARTIES. Contractor will do nothing to prejudice the City's right to recover against third parties for any loss, destruction, or damage to City property, and will at the City's request and expense, furnish to the City reasonable assistance and cooperation, including assistance in the prosecution or defense of suit and the execution of instruments of assignment in favor of the City in obtaining recovery. S.27 NO GUARANTEE OF WORK. Contractor acknowledges and agrees that it is not entitled to deliver any specific amount of materials or services or any materials or services at all under this Agreement and acknowledges and agrees that the materials or services will be requested by the City on an as needed basis at the sole discretion of the City. Any document referencing quantities or performance frequencies represent the City's best estimate of current requirements, but will not bind the City to purchase, accept, or pay for materials or services which exceed its actual needs. 5 S.28 OWNERSHIP. All deliverables, services, and information provided by Contractor or the City pursuant to this Agreement (whether electronically or manually generated) including without limitation, reports, test plans, and survey results, graphics, and technical tables, originally prepared in the performance of this Agreement, are the property of the City and will not be used or released by Contractor or any other person except with prior written permission by the City. S.29 USE OF NAME. Contractor will not use the name of the City of Clearwater in any advertising or publicity without obtaining the prior written consent of the City. S.30 PROHIBITED ACTS. Pursuant to Constitution Article I I Section 8, a current or former public officer or employee within the last two (2) years shall not represent another organization before the City on any matter for which the officer or employee was directly concerned and personally participated in during their service or employment or over which they had a substantial or material administrative discretion. S.31 FOB DESTINATION FREIGHT PREPAID AND ALLOWED. All deliveries will be FOB destination freight prepaid and allowed unless otherwise agreed. S.32 RISK OF LOSS. Contractor agrees to bear all risks of loss, injury, or destruction of goods or equipment incidental to providing these services and such loss, injury, or destruction will not release Contractor from any obligation hereunder. S.33 SAFEGUARDING CITY PROPERTY. Contractor will be responsible for any damage to City real property or damage or loss of City personal property when such property is the responsibility of or in the custody of Contractor or its employees. S.34 WARRANTY OF RIGHTS. Contractor warrants it has title to, or the right to allow the City to use, the materials and services being provided and that the City may use same without suit, trouble or hindrance from Contractor or third parties. S.35 PROPRIETARY RIGHTS INDEMNIFICATION. Without limiting the foregoing, Contractor will without limitation, at its expense defend the City against all claims asserted by any person that anything provided by Contractor infringes a patent, copyright, trade secret or other intellectual property right and must, without limitation, pay the costs, damages and attorneys' fees awarded against the City in any such action, or pay any settlement of such action or claim. Each party agrees to notify the other promptly of any matters to which this provision may apply and to cooperate with each other in connection with such defense or settlement. If a preliminary or final judgment is obtained against the City's use or operation of the items provided by Contractor hereunder or any part thereof by reason of any alleged infringement, Contractor will, at its expense and without limitation, either: (a) modify the item so that it becomes non-infringing; (b) procure for the City the right to continue to use the item; (c) substitute for the infringing item other item(s) having at least equivalent capability; or (d) refund to the City an amount equal to the price paid, less reasonable usage, from the time of installation acceptance through cessation of use, which amount will be calculated on a useful life not less than five (5) years, plus any additional costs the City may incur to acquire substitute supplies or services. S.36 CONTRACT ADMINISTRATION. The contract will be administered by the Purchasing Department and/or an authorized representative from the using department. All questions regarding the contract will be referred to the Purchasing Department for resolution. Supplements may be written to the contract for the addition or deletion of services. S.37 FORCE MAJEURE. Failure by either party to perform its duties and obligations will be excused by unforeseeable circumstances beyond its reasonable control, including acts of nature, acts of the public enemy, riots, fire, explosion, legislation, and governmental regulation. The party whose performance is so affected will within five (5) calendar days of the unforeseeable circumstance notify the other party of all pertinent facts and identify the force majeure event. The party whose performance is so affected must also take all reasonable steps, promptly and diligently, to prevent such causes if it is feasible to do so, or to minimize or eliminate the effect thereof. The delivery or performance date will be extended for a period equal to the time lost by reason of delay, plus such additional time as may be reasonably necessary to overcome the effect of the delay, provided however, under no circumstances will delays caused by a force majeure extend beyond one 0 hundred-twenty (120) calendar days from the scheduled delivery or completion date of a task unless agreed upon by the parties. S.38 COOPERATIVE USE OF CONTRACT. The City has entered into various cooperative purchasing agreements with other Florida government agencies, including the Tampa Bay Area Purchasing Cooperative. Under the Cooperative Purchasing Agreement, any contract may be extended for use by other municipalities, school districts and government agencies with the approval of Contractor. Any such usage by other entities must be in accordance with the statutes, codes, ordinances, charter and/or procurement rules and regulations of the respective government agency. Orders placed by other agencies and payment thereof will be the sole responsibility of that agency. The City is not responsible for any disputes arising out of transactions made by others. S.39 FUEL CHARGES AND PRICE INCREASES. No fuel surcharges will be accepted. No price increases will be accepted without proper request by Contractor and response by the City's Purchasing Division. S.40 NOTICES. All notices to be given pursuant to this Agreement must be delivered to the parties at their respective addresses. Notices may be (i) personally delivered; (ii) sent via certified or registered mail, postage prepaid; (iii) sent via overnight courier; or (iv) sent via facsimile. If provided by personal delivery, receipt will be deemed effective upon delivery. If sent via certified or registered mail, receipt will be deemed effective three (3) calendar days after being deposited in the United States mail. If sent via overnight courier or facsimile, receipt will be deemed effective two (2) calendar days after the sending thereof. S.41 GOVERNING LAW, VENUE. This Agreement is governed by the laws of the State of Florida. The exclusive venue selected for any proceeding or suit in law or equity arising from or incident to this Agreement will be Pinellas County, Florida. S.42 INTEGRATION CLAUSE. This Agreement, including all attachments and exhibits hereto, supersede all prior oral or written agreements, if any, between the parties and constitutes the entire agreement between the parties with respect to the work to be performed. S.43 PROVISIONS REQUIRED BY LAW. Any provision required by law to be in this Agreement is a part of this Agreement as if fully stated in it. S.44 SEVERABILITY. If any provision of this Agreement is declared void or unenforceable, such provision will be severed from this Agreement, which will otherwise remain in full force and effect. The parties will negotiate diligently in good faith for such amendment(s) of this Agreement as may be necessary to achieve the original intent of this Agreement, notwithstanding such invalidity or unenforceability. S.45 SURVIVING PROVISIONS. Notwithstanding any completion, termination, or other expiration of this Agreement, all provisions which, by the terms of reasonable interpretation thereof, set forth rights and obligations that extend beyond completion, termination, or other expiration of this Agreement, will survive and remain in full force and effect. Except as specifically provided in this Agreement, completion, termination, or other expiration of this Agreement will not release any party from any liability or obligation arising prior to the date of termination. S.46 POLLUTION INSURANCE. The Contractor agrees to maintain Contractor's Pollution Legal Liability with minimum limits of $5,000,000 (five million dollars). For policies written on a"Claims- Made" basis the Contractor agrees to maintain a retroactive date prior to or equal to the effective date of this contract. In the event the policy is canceled, non-renewed, switched to occurrence form, or any other event which triggers the right to purchase a Supplemental Extended Reporting Period (SERP) during the life of this contract the Contractor agrees to purchase the SERP with a minimum reporting period of not less than two years. Purchase of the SERP shall not relieve the Contractor of the obligation to provide replacement coverage. 7 SECTION III GENERAL CONDITIONS Table of Contents: 1. DEFINITIONS .................................................................................................1 2. PRELIMINARY MATTERS ..........................................................................5 2.1. DELIVERY OF BONDS AND CERTIFICATES OF INSURANCE ................................5 2.2. COPIES OF DOCUMENTS ................................................................................................5 2.3. COMMENCEMENT OF CONTRACT TIME/NOTICE TO PROCEED; STARTING THEPROJECT ....................................................................................................................5 2.4. BEFORE STARTING CONSTRUCTION ..........................................................................5 2.5. PRECONSTRUCTION CONFERENCE ............................................................................6 2.6. PROGRESS MEETINGS ....................................................................................................6 3. CONTRACT DOCUMENTS, INTENT ........................................................6 3.1. INTENT ...............................................................................................................................6 3.2. REPORTING AND RESOLVING DISCREPANCIES ......................................................7 4. AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; REFERENCE POINTS .......................................................7 4.1. AVAILABILITY OF LANDS .............................................................................................7 4.2. INVESTIGATIONS AND REPORTS ................................................................................7 4.3. PHYSICAL CONDITIONS, LINDERGROUND FACILITIES .........................................8 4.4. REFERENCE POINTS ........................................................................................................8 5. BONDS AND INSURANCE ...........................................................................8 5.1. PERFORMANCE AND PAYMENT BOND/CONTRACT BOND ...................................8 5.2. INSURANCE REQUIREMENTS .......................................................................................9 5.2.1. COMMERCIAL GENERAL LIABILITY INSURANCE ...............................................9 5.2.2. COMMERCIAL AUTOMOBILE LIABILITY INSURANCE .......................................9 5.2.3. WORKERS' COMPENSATION AND EMPLOYER'S LIABILITY INSLJRANCE...10 5.2.4. PROFESSIONAL LIABILITY/MALPRACTICE/ERRORS OR OMISSIONS INSURANCE..................................................................................................................10 5.2.5. CONTRACTOR' S EQUIPMENT/INLAND MARINE/PROPERTY INSURANCE ...10 5.2.6. BUILDER'S RISK INSURANCE ..................................................................................10 5.3. OTHER INSURANCE PROVISIONS ..............................................................................10 5.4. WAIVER OF RIGHTS ......................................................................................................11 6. CONTRACTORS RESPONSIBILITIES ....................................................12 6.1. SUPERVISION AND SUPERINTENDENCE .................................................................12 6.2. LABOR, MATERIALS AND EQUIPMENT ...................................................................12 6.3. SUBSTITUTES AND "OR EQUAL" ITEMS ..................................................................13 6.4. SUBCONTRACTORS, SUPPLIERS AND OTHERS ......................................................14 SECTION III 6.5. 6.5.1. 6.5.2. 6.6. 6.7. 6.8. 6.9. 6.10. 6.11. 6.11.1. 6.11.2. 6.11.3. 6.11.4. 6.12. 6.13. 6.14. 6.15. 6.16. SECTION III — General Conditions USEOF PREMISES ..........................................................................................................14 STAGINGAREAS .........................................................................................................15 RESTORATION TIME LIMITS.......--� ..........................................................................15 LICENSE AND PATENT FEES, ROYALTIES AND TAXES .......................................15 LAWS AND REGULATIONS ..........................................................................................16 PERMIT S . . . . . . . . . . . . . . . . . . . . . . . . . . . .. .... . . . . . . . . . . . . . . .. . . . . . . . . . . . . . . . . . . ... . . . . . . . . . . . . . . . . . . . . . .... .. . . . . . . ... . . . . . . . . . . . . . . .. .16 SAFETY AND PROTECTION .........................................................................................16 EMERGENCIES................................................................................................................17 DRAWINGS......................................................................................................................18 SHOP DRAWINGS, SAMPLES, RFIs, AND SUBMITTAL REVIEW .......................18 AS-BUILT DRAWINGS ................................................................................................19 CADSTANDARDS .......................................................................................................21 DELIVERABLES...........................................................................................................22 CONTRACTOR'S GENERAL WARRANTY AND GUARANTEE ...............................23 CONTINUINGTHE WORK ............................................................................................23 INDEMNIFICATION........................................................................ ................................23 CHANGES IN COMPANY CONTACT INFORMATION ..............................................24 PUBLICRECORDS ..........................................................................................................24 7. OTHER WORK .............................................................................................25 7.1. RELATED WORK AT SITE ............................................................................................25 7.2. COORDINATION .............................................................................................................25 8. OWNERS RESPONSIBILITY .....................................................................25 9. OWNER REPRESENTATIVE'S STATUS DURING CONSTRUCTION ..........................................................................................................................26 9.1. OWNERS REPRESENTATIVE .......................................................................................26 9.2. CLARIFICATIONS AND INTERPRETATIONS ............................................................26 9.3. REJECTING OF DEFECTIVE WORK ............................................................................26 9.4. SHOP DRAWINGS, CHANGE ORDERS, AND PAYMENTS ......................................27 9.5. DECISIONS ON DISPUTES ............................................................................................27 9.6. LIMITATIONS ON OWNER REPRESENTATIVE'S RESPONSIBILITIES .................28 10. CHANGES IN THE WORK .........................................................................28 11. CHANGES IN THE CONTRACT PRICE ..................................................29 11.1. CHANGES IN THE CONTRACT PRICE ........................................................................29 11.2. ALLOWANCES AND FINAL CONTRACT PRICE ADJUSTMENT ...........................30 11.3. UNIT PRICE WORK ........................................................................................................31 12. CHANGES IN THE CONTRACT TIME ...................................................31 13. TESTS AND INSPECTIONS, CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK .................................................32 13.1. TESTS AND INSPECTION ..............................................................................................32 SECTION III ii 13.2. 13.3. 13.4. 13.5. 13.6. 13.7. 14. 14.1. 14.2. 14.3. 14.4. 14.5. 14.6. 14.7. 14.8. SECTION III — General Conditions LJNCOVERING THE WORK ................................................ OWNER'S REPRESENTATIVE MAY STOP THE WORK CORRECTION OR REMOVAL OF DEFECTIVE WORK.. WARRANTY/CORRECTION PERIOD ............................... ACCEPTANCE OF DEFECTIVE WORK ............................ OWNER MAY CORRECT DEFECTIVE WORK ................ .....................................33 .....................................3 3 .....................................33 .....................................33 .....................................34 .....................................34 PAYMENTS TO CONTRACTOR AND COMPLETION ........................35 APPLICATION FOR PROGRESS PAYMENT ...............................................................35 CONTRACTOR'S WARRANTY OF TITLE ...................................................................35 REVIEW OF APPLICATIONS FOR PROGRESS PAYMENTS ....................................36 PARTIAL UTILIZATION ................................................................................................37 FINALINSPECTION .......................................................................................................37 FINAL APPLICATION FOR PAYMENT .......................................................................37 FINAL PAYMENT AND ACCEPTANCE .......................................................................38 WAIVEROF CLAIMS .....................................................................................................38 15. SUSPENSION OF WORK AND TERMINATION ...................................38 15.1. OWNER MAY SUSPEND THE WORK ..........................................................................38 15.2. OWNER MAY TERMINATE ...............................................................:..........................39 15.3. CONTRACTOR MAY STOP WORK OR TERMINATE ...............................................40 16. DISPUTE RESOLUTION .............................................................................40 17. 17.1. 17.2. 17.3. 17.4. 17.5. 17.6. 17.7. MISCELLANEOUS.......................................................................................41 SUBMITTAL AND DOCUMENT FORMS .....................................................................41 GIVINGNOTICE ..............................................................................................................41 NOTICEOF CLAIM .........................................................................................................41 PROFESSIONAL FEES AND COURT COSTS INCLUDED .........................................41 ASSIGNMENT OF CONTRACT .....................................................................................41 RENEWALOPTION ........................................................................................................41 ROLL-OFF CONTAINERS AND/OR DUMPSTERS .....................................................41 18. ORDER AND LOCATION OF THE WORK .............................................42 19. MATERIAL USED ........................................................................................42 20. CONFLICT BETWEEN PLANS AND SPECIFICATIONS ....................42 21. 21.1. 21.2. 21.3. 21.4. OWNER DIRECT PURCHASE (ODP) ......................................................42 SALESTAX SAVINGS ....................................................................................................42 TITLEAND OWNER RISK .............................................................................................42 CONTRACTOR'S RECEIPT OF MATERIALS ..............................................................43 ODP RECORDS, WARRANTIES AND INDEMNIFICATION .....................................43 22. RESIDENT NOTIFICATION OF START OF CONSTRUCTION.........44 SECTION III iii 22.1. GENERAL 22.2. EXAMPLE SECTION III—General Conditions � ............................ .44 .45 23. PROJECT INFORMATION SIGNS ...........................................................45 23.1. SCOPE AND PURPOSE ...................................................................................................45 23.2. PROJECT SIGN, FIXED OR PORTABLE ......................................................................46 23.3. FIXED SIGN .....................................................................................................................46 23.4. PORTABLE SIGNS ..........................................................................................................46 23.5. SIGN COLORING .............................................................................................................46 23.6. SIGN PLACEMENT .........................................................................................................46 23.7. SIGN MAINTENANCE ....................................................................................................46 23.8. TYPICAL PROJECT SIGN ..............................................................................................47 24. AWARD OF CONTRACT, WORK SCHEDULE AND GUARANTEE .47 25. SCRUTINIZED COMPANIES AND BUSINESS OPERATIONS WITH CUBA AND SYRIA CERTIFICATION FORM AND ISRAEL CERTIFICATION FORM ............................................................................48 SECTION III iv SECTION III — General Conditions 1. DEFINITIONS Addenda Written ar graphic instruments issued prior to the opening of Bids which clarify, correct or change the Bidding Requirements or the contract documents. Agent Architect, engineer or other outside agency, consultant or person acting on behalf of the City. Agreement The written contract between Owner and Contractor covering the Work to be performed; other Contract Documents are attached to the Agreement and made a part thereof as provided therein. Application for Payment The form accepted by Engineer which is to be used by Contractor in requesting progress or final payments and which is to be accompanied by such supporting documentation as is required by the Contract Documents. Approve The ward approve is defined to mean satisfactory review of the material, equipment or methods for general compliance with the design concepts and with the information given in the Contract Documents. It does not imply a responsibility on the part of the Engineer to verify in every detail conformance with the Drawings and Specifications. Bid The offer or proposal of the bidder submitted on the prescribed form setting forth the prices for the work to be performed. Bidding Documents The advertisement or invitation to Bid, instructions to bidders, the Bid form, and the proposed Contact Documents (including all Addenda issued prior to receipt of Bids). Bonds Performance and payment bonds and other instruments of security. Change Order A written order to Contractor signed by Owner and Contractor authorizing an addition, deletion or revision in the Work, ar an adjustment in the Contract Price or the Contract Time issued on or after the effective date of the Agreement. City The City of Clearwater, Pinellas County, Florida. Construction Inspector A person who is the authorized representative of the Construction Manager and inspects City construction projects in order to insure the Contractor's wark complies with the intent of the Contract Documents. Contract Documents The Agreement, Addenda (which pertain to the Contract Documents), Contractor's Bid (including documentation accompanying the bid and any post-Bid documentation submitted prior to the execution of the Agreement) when attached as an e�ibit to the SECTION III Page 1 of 49 SECTION III—General Conditions Agreement, the Bonds, Instructions to Bidders, these General Conditions, any Supplementary Conditions, the Specifications and the Drawings, any other exhibits identified in the Agreement, together with all Modifications issued after the execution of the Agreement. Contract Price The Contract price constitutes the total compensation (subject to authorized adjustments) payable by Owner to Contractor far performing the Work. Contract Time The number of days or the date stated in the Agreement for the completion of the Work. Contractor The Person with whom the Owner has entered into the Agreement. For the purposes of this contract, the person, firm or corporation with whom this contract or agreement has been made by the City of Clearwater or its duly autharized representative. Critical Path Method Construction Schedule—CPM A graphic format construction schedule that displays construction activities as they relate to one another for the purpose of identifying the most efficient way to perform the work in a timely manner. The critical path identifies which activity is critical to the execution of the schedule. Day A calendar day of twenty-four (24) hours measured from midnight to the next midnight. Defective An adjective which when modifying the word Work refers to Wark that is unsatisfactory, faulty or deficient, or does not conform to the Contract Documents or does not meet the requirements of any inspection, reference standard, test or approval referred to in the Contract Documents, or has been damaged prior to Engineers recommendation of final payment. Drawings The drawings, which will be identified in Technical Specifications or the Agreement, which show the character and scope of the Work to be performed and which have been prepared or approved by Engineer and are referred to in the contract documents. Shop drawings are not Drawings as so deiined. Engineer The duly appointed representative of the City Manager of the City of Clearwater. For the purposes of this contract, the City Engineer of the City of Clearwater, Pinellas County, Florida, or his authorized representative. For certain projects, the Engineer may serve as the Owner's Representative during construction. Engineer's Consultant A Person having a contract with Engineer to furnish services as Engineer's independent professional associate or consultant with respect to the Project and who is identified as such in the Supplementary Conditions. F.D.O. T Specifications The Standard Specifications for Road and Bridge Construction as issued by the Florida Department of Transportation (latest English edition). SECTION III Page 2 of 49 SECTION III — General Conditions Furnish The words "furnish", "furnish and install", "install", and "provide" or words of similar meaning shall be interpreted, unless otherwise specifically stated, to mean "furnish and install complete in place and ready for service". Inspection The term "inspection" and the act of inspecting means examination of construction to ensure that it conforms to the design concept expressed in the Drawings and Specifications. These terms shall not be construed to mean supervision, superintending or overseeing. Laws and Regulations Any and all applicable laws, rules, regulations, ordinances, codes and orders of any kind of governmental bodies, agencies, authorities and courts having jurisdiction. Liens Liens, charges, security interests or encumbrances upon real property ar personal property. Milestone A principal event specified in the contract Documents relating to an intermediate completion date or time prior to the final completion date. Notice to Proceed (NTP) A written notice given by the Owner to the Contractor fixing the date on which the Contract Time will commence to run and on which Contractor shall start to perform his obligations under the Contract Documents. Owner The City of Clearwater, Florida. For the purposes of this contract, the person who is the City's autharized representative from the City's Department with whom will be responsible for the maintenance and operation of the Work once the Work is completed. For certain projects, a designee of the Owner may serve as the Owner's Representative during construction. Owner's Representative Designee of the Owner with authority to act on behalf of the Owner during construction. Person A natural person, or a corporation, partnership, firm, organization, or other artificial entity. Project The total construction of which the Work to be provided under the Contract Documents may be the whole or a part as indicated elsewhere in the Contract Documents. Partial Utilization Use by Owner of a substantially completed part of the Work for the purpose for which is intended (or a related purpose) priar to Final Completion of all the Wark. Representative of Contractor The Contractor shall assign a responsible person or persons, one of whom shall be at the construction site at all times that work is progressing. The names and positions of these persons shall be submitted to the City Engineer at the time of the pre-construction conference. This person or persons shall not be changed without written approval of City Engineer. SECTION III Page 3 of 49 SECTION III—General Conditions Request for Information (RFI) An official written request for clarification of the intent of the contract documents from the Contractor to the Engineer. Shop Drawing All drawings, diagrams, illustrations, schedules and other data which are specifically prepared by or for Contractor to illustrate some portion of the Work and all illustrations, brochures, standard schedules, performance charts, instructions, diagrams and other information prepared by a supplier and submitted by Contractor to illustrate material or equipment for some portion of the Work. Specifications Those portions of the Contract Documents consisting of written technical descriptions of materials, equipment, construction systems, standards and workmanship as applied to the Work and certain administrative details applicable thereto. Subcontractor A person having a direct contract with Contractor or with any other Subcontractor for the performance of a part of the Work at the site. Substantial Completion The Work (or a specified part thereo� which has progressed to the point where, in the opinion of Engineer, as evidenced by Engineer's definitive certificate of Substantial Completion, it is sufficiently complete, in accordance with the Contract documents, so that the Work (or specified part) can be utilized for the purposes for which it is intended; or if no such certificate is issued, when the Work is complete and ready for final payment as evidenced by the Engineer's recommendation of iinal payment. The terms "substantially complete" and "substantially completed" as applied to all or part of the Work refer to Substantial Completion thereof. Supplementary Conditions The part of the Contract which amends or supplements these General Conditions. Supplier A manufacturer, fabricator, supplier, distributor, material man or vendar having a direct contract with Contractor or with any Subcontractor to furnish materials or equipment to be incorporated in the Work by the Contractor. Surety Any person, iirm or corporation which is bound with Contractor and which engages to be responsible for Contractor and his acceptable performance of the Wark by a Bid, Performance or Payment Bond. Underground Facilities All pipelines, conduits, ducts, cables, wires manholes, vaults, tanks, tunnels or other such facilities ar attachments, and any encasements containing such facilities which have been installed underground to furnish any of the following services or materials: electricity, gases, steam, liquid petroleum products, telephone or other communications, cable television, sewage and drainage removal or treatment, traffic or other control systems or water. Unit Price Work Wark to be paid for on the basis of unit prices. SECTION III Page 4 of 49 Work SECTION III — General Conditions The entire completed construction or the various separately identifiable parts thereof required to be furnished under the Contract Documents. Work includes and is the result of performing or furnishing labor and incorporating materials and equipment into the construction, and performing or furnishing services and furnishing documents, all as required by the Contract Documents. WoYk Change Directive A written directive to Contractor, issued on or after the Effective Date of the Agreement and signed by the Engineer, ordering an addition, deletion, or revision in the Work, or responding to differing or unforeseen physical conditions under which the Work is to be performed or emergencies. Work Change Directive will not change the Contract Price or Contract Time but is evidence that the parties expect that the change directed or documented by a Work Change Directive will be incorporated in a subsequently issued Change Order following negotiations by the parties as to its effect, if any, on the Contract Price ar Contract Times. 2. PRELIMINARY MATTERS 2.1. DELIVERY OF BONDS AND CERTIFICATES OF INSURANCE When Contractor delivers the executed Agreements to the Owner, Contractor shall also deliver to the Owner such Bonds and Certiiicates of Insurance as Contractor may be required to furnish by this contract. 2.2. COPIES OF DOCUMENTS Engineer shall furnish to Contractor one (1) copy of Contract Documents for execution. Additional copies will be furnished, upon request, at the cost of reproduction. 2.3. COMMENCEMENT OF CONTRACT TIME/NOTICE TO PROCEED; STARTING THE PROJECT The Contract Time will commence on the day indicated in the Notice to Proceed. Contractor shall start to perform the work on the date the Contract Time commences to run. No work shall be done at the site prior to the date that the Contract Time commences to run. Pursuant to Section 255.05(1)(b), Florida Statutes, the Notice to Proceed cannot be issued until Contractor provides City with a certified copy of the recorded bond issued by the Pinellas County Clerk of Court. 2.4. BEFORE STARTING CONSTRUCTION Before undertaking each part of the Work, Contractor shall carefully study and compare the Contract Documents and check and verify pertinent figures shown thereon and all applicable field measurements. Contractor shall promptly report in writing to Engineer any conflict, error or discrepancy which Contractor may discover; and shall obtain a written interpretation or clarification from Engineer before proceeding with any work effected thereby; however, Contractor shall not be liable to the Owner for failure to report any conflict, error or discrepancy in the Drawings ar Specifications, unless Contractor had actual knowledge thereof or should reasonably have known thereof. SECTION III Page 5 of 49 SECTION III — General Conditions No verbal agreement or conversation with any ofiicer, Agent or employee of the Owner or Engineer's Consultant, either before or after the execution of this Contract, shall affect or modify any of the terms or obligations herein contained. Contractor shall not commence any work at any time without approved insurance required by these General Conditions. Failure to obtain this insurance will be the sole responsibiliry of the Contractor. 2.5. PRECONSTRUCTION CONFERENCE After Contract has been fully executed and before the start of the Work, the Owner's Representative shall schedule a preconstruction conference to be attended by Contractar, Engineer, Owner and others as appropriate to establish a working understanding among the parties as to the Work and to discuss the schedule of the Work and general Contract procedures. The Contractor shall submit to the Owner's Representative prior to the Notice to Proceed, a color Critical Path Method (CPM) Construction Schedule. This is to be a sequence of events including submittal review and procurement. Notice to Proceed is usually established at the preconstruction conference and such date can be inserted into the schedule at that time. The Contractor shall also submit a Submittal Schedule for review by the Engineer. This is to make sure that the list is complete, and this schedule shall be the basis of a Submittal Log. The Contractor shall submit to the Owner's Representative prior to the Notice to Proceed, a completed Emergency Call List, a completed Authorized Signature List, and Verification of Illegal Discharge Construction Site Training. 2.6. PROGRESS MEETINGS The Contractor is required to attend Progress Meetings. These meetings will be scheduled on a weekly, bi-weekly, or monthly basis depending on the needs of the project. The Contractor shall bring to each meeting an updated submittal log, an updated request for information (RFI) log, a look-ahead schedule to cover the project activity from the current meeting to the next meeting, and all material test reports generated in the same time period. 3. CONTRACT DOCUMENTS, INTENT 3.1. INTENT The Contract Documents comprise the entire Agreement between Owner and the Contractor concerning the Wark. They may be altered only by written agreement. The Contract Documents are complementary; what is called for by one is as binding as if called for by all. It is the intent of the Contract Documents to describe a functionally complete project (or part thereo� to be constructed in accordance with the Contract Documents. Any Work, materials or equipment which may reasonably be inferred from the Contract Documents or from prevailing custom or from trade usage as being required to produce the intended result will be furnished and performed whether or not specifically called for. When words or phrases, which have a well-known technical or construction industry or trade meaning, are used to describe Work, materials or equipment, such words or phrases shall be interpreted in accordance with that meaning. Clarifications and interpretations of the Contract Documents shall be issued by the Owner's Representative. Reference to standards, specifications, manuals or codes of any technical society, organization or association, or to the code, Laws or Regulation of any governmental authority, whether such reference be specific or by implication, shall mean the latest standard speciiication, manual or code, or Laws or Regulations in effect at the time of opening of Bids except as may be otherwise SECTION III Page 6 of 49 SECTION III—General Conditions specifically stated in the Contract Documents. However, no provision of any referenced standard specification, manual or code, whether or not specially incorporated by reference in the responsibilities of Owner or Contractor as set forth in the Contract Documents, shall change the duties and responsibilities of Owner, Contractor, Engineer or Owner's Representative, or any of their Agents or employees from those set forth in the Contract Documents. Clarifications and interpretations of the Contract shall be issued by the Owner's Representative. Each and every provision of law and clause required by law to be inserted in these Contract documents shall be deemed to be inserted herein, and they shall be read and enforced as through it were included herein, and if through mistake or otherwise, any such provision is not inserted, ar if not correctly inserted, then upon the application of either party, the Contract Documents shall forthwith be physically amended to make such insertion. 3.2. REPORTING AND RESOLVING DISCREPANCIES If, during the performance of the Work, Contractor discovers any conflict, error, ambiguity or discrepancy within the Contract Documents ar between the Contract Documents and any provision of any such Law or Regulation applicable to the performance of the Work or of any such standard, specification, manual or code or of any instruction of any Supplier, Contractor shall report it to the Owner's Representative in writing at once, and Contractor shall not proceed with the Work affected thereby (except in an emergency) until an amendment or supplement to Contract Documents has been issued by one of the methods provided in these General Specifications, provided however, that Contractor shall not be liable to Owner, or Owner's Representative for failure to report any such conflict, error, ambiguity or discrepancy unless Contractor knew or reasonably should have known thereof. 4. AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; REFERENCE POINTS 4.1. AVAILABILITY OF LANDS The Owner shall furnish, as indicated in the Contract Documents, the lands upon which the Work is to be Performed, rights-of-way, easements, rights of entry for access thereto, and such other lands which are designated for the use of contractor. The Owner shall identify any encumbrances or restrictions not of general application but specifically related to use of lands so furnished with which contractor will have to comply in performing the Work. Easements for permanent structures or permanent changes in existing facilities will be obtained and paid for by the Owner, unless otherwise provided in the Contract Documents. 4.2. INVESTIGATIONS AND REPORTS Reference is made to the Supplementary Conditions and Technical Specifications for identification of those reports of investigations and tests of subsurface and latent physical conditions at the site or otherwise affecting cost, progress ar performance of the Work which have been relied upon by Engineer in preparation of the Drawings and Specifications. Such reports are not guaranteed as to accuracy or completeness and are not part of the Contract Documents. Contractar shall promptly notify the Owner's Representative in writing of any subsurface or latent physical conditions at the site, or in an existing structure, differing materially from those indicated or referred to in the Contract Documents. Engineer will promptly review those conditions and advise if further investigation or tests are necessary. Owner or Engineer shall obtain the necessary additional SECTION III Page 7 of 49 SECTION III—General Conditions investigations and tests and furnish copies to the Engineer and Contractor. If Engineer finds that the results of such investigations or tests indicate that there are subsurface or latent physical conditions, which differ materially from those, indicated in the contract Documents, and which could not reasonably have been anticipated by Contractor, a work change, or Change Order will be issued incorporating the necessary revisions. 4.3. PHYSICAL CONDITIONS, UNDERGROUND FACILITIES The information and data shown or indicated in the Contract Documents with respect to existing Underground Facilities at or contiguous to the site is based on information and data furnished to Owner or Engineer by the owners of such Underground Facilities or by others. Unless otherwise expressly provided in the Contract Documents, Owner and Engineer shall not be responsible for the accuracy or completeness of any such information or data; and the cost of all the following will be included in the Contract Price and contractor shall have full responsibility for. (i) reviewing and checking all such information and data, (ii) locating all Underground Facilities shown or indicated in the Contract Documents, (iii) coordination of the Work with the owners of such Underground Facilities during construction, and (iv) the safety and protection of all such Underground Facilities and repairing any damage thereto resulting from the Work. The Contractor is required to call the Sunshine State One Call of Florida prior to any excavation per State regulations and to notify any utility owners who are not a member of the Sunshine State One Call of Florida prior to any excavation. The Sunshine State One Call of Florida is an agency for the protection and location of utilities prior to any excavation and contact number is available in local telephone directory. 4.4. REFERENCE POINTS Engineer shall provide engineering surveys to establish reference points for construction, which in Engineer's judgment are necessary to enable Contractor to proceed with the Work. Contractor shall be responsible for laying out the Work, unless otherwise noted in the Contract, shall protect and preserve the established reference points and shall make no changes or relocations without the prior written approval of the Owner and Engineer. Contractor shall report to Engineer whenever any reference point is lost or destroyed or requires relocation because of necessary changes in grades or locations and shall be responsible for the accurate replacement or relocation of such reference points by a surveyor licensed in the State of Florida. The Contractor is referred to the Technical Specifications for more specific information regarding the provision of construction surveys. If a City survey crew is assigned to the project and there is excessive stake replacement caused by negligence of Contractor's forces after initial line and grade have been set, as determined by the Engineer, the Contractor will be charged at the rate of $100.00 per hour. Time shall be computed for actual time on the project. All time shall be computed in one-hour increments with a minimum charge of one hour. 5. BONDS AND INSURANCE 5.1. PERFORMANCE AND PAYMENT BOND/CONTRACT BOND Contractor shall furnish a Performance and Payment Bond pursuant to Section 255.05, Florida Statutes in an amount equal to the Contract Price as security for the faithful performance and payment of all Contractor's obligations under the Contract Documents. This bond shall remain in effect at least one year after the date when final payment becomes due, unless a longer period of time is prescribed by laws and regulations or by the Contract Documents. Contractor shall also SECTION III Page 8 of 49 SECTION III—General Conditions furnish such other Bonds as are required by the Supplementary Conditions. All Bonds shall be in the form prescribed by the Contract Documents in Section V and shall be executed by such sureties as are named in the current list of "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies" as published in Circular 570 (amended) by the Audit Staff, Bureau of Government Financial Operations, U.S. Treasury Department. All bonds signed by an agent must be accompanied by a certified copy of such agents' authority to act. All bonds shall be deemed to contain all of the Conditions of Section 255.05, Florida Statutes, even if such language is not directly contained within the bond and the Surety shall be licensed and qualified to do business in the State of Florida. Owner reserves the right to reject any surety. If the Surety on any Bond furnished by the Contractor is declared bankrupt or becomes insolvent or its right to do business is terminated in any state where any part of the Project is located or it ceases to meet the requirements of these Contract Documents, the Contractor shall within five days after notice thereof substitute another Bond and surety, both of which must be acceptable to Owner. The Contractor may require its subcontractors to provide Performance and Payment Bonds as security for the faithful performance of all of their obligations under the lower tier agreements, or in the alternative, if approved by Owner in the GMP Proposal, the faithful performance by lower tier contractors may be secured by purchasing Subcontractor Default Insurance ("SDI"). 5.2. INSURANCE REQUIREMENTS The Contractor shall, at its own cost and expense, acquire and maintain (and cause any sub- contractors, representatives or agents to acquire and maintain) during the term with the City, sufficient insurance to adequately protect the respective interest of the parties. Coverage shall be obtained with a carrier having an AM Best Rating of A-VII or better. Specifically, the Contractor must carry the following minimum types and amounts of insurance on an occurrence basis or in the case of coverage that cannot be obtained on an occurrence basis, then coverage can be obtained on a claims-made basis with a minimum four (4) year tail following the termination or expiration of this Agreement: The following insurance limits may be achieved by a combination of primary and umbrella/excess liability policies. Contractor may provide all or part of the insurance required by itself and its subcontractors through a Contractar Controlled Insurance Program ("CCIP") upon approval by the City through a GMP Proposal. 5.2.1. COMMERCIAL GENERAL LIABILITY INSURANCE Commercial General Liability Insurance coverage, including but not limited to, premises operations, products/completed operations, products liability, contractual liabiliry, advertising injury, personal injury, death, and property damage in the minimum amount of $2,000,000 (two million dollars) per occurrence and $5,000,000 (five million dollars) general aggregate. 5.2.2. COMMERCIAL AUTOMOBILE LIABILITY INSURANCE Commercial Automobile Liability Insurance coverage for any owned, non-owned, hired or borrowed automobile combined single limit. is required in the minimum amount of $2,000,000 (two million dollars) SECTION III Page 9 of 49 SECTION III — General Conditions 5.2.3. WORKERS' COMPENSATION AND EMPLOYER'S LIABILITY INSURANCE Statutory Workers' Compensation Insurance coverage in accordance with the laws of the State of Florida, and Employer's Liability Insurance in the minimum amount of $100,000 (one hundred thousand dollars) each employee each accident, $100,000 (one hundred thousand dollars) each employee by disease and $500,000 (five hundred thousand dollars) aggregate by disease with beneiits afforded under the laws of the State of Flarida. Coverage should include Voluntary Compensation, Jones Act, and U.S. Longshoremen's and Harbor Worker's Act coverage where applicable. Coverage must be applicable to employees, contractars, subcontractors, and volunteers, if any. 5.2.4. PROFESSIONAL LIABILITY/MALPRACTICE/ERRORS OR OMISSIONS INSURANCE Professional Liability/Malpractice/Errors or Omissions Insurance coverage appropriate for the type of business engaged in by the Contractor with minimum limits of $2,000,000 (two million dollars) per occurrence. If a claims-made form of coverage is provided, the retroactive date of coverage shall be no later than the inception date of claims-made coverage, unless prior policy was extended indefinitely to cover prior acts. Coverage shall be extended beyond the policy year either by a supplemental extended reporting period (ERP) of as great a duration as available, and with no less coverage and with reinstated aggregate limits, or by requiring that any new policy provide a retroactive date no later than the inception date of claims-made coverage. 5.2.5. CONTRACTOR'S EQUIPMENT/INLAND MARINE/PROPERTY INSURANCE If Contractor is using its own property in connection with the performance of its obligations under this Agreement, then Contractor's Equipment—Inland Marine Insurance and/or Property Insurance on an "All Risks" basis with replacement cost coverage for property and equipment in the care, custody and control of others is recommended. City is not responsible for Contractor's (or any sub-contractors, representatives, or agents) equipment or property. 5.2.6. BUILDER'S RISK INSURANCE The City will provide at its expense, Builder's Risk Insurance for the project to cover all risks of loss in the complete and full value of the project. Contractor agrees to cooperate in a timely manner with providing any information ar documentation required for the application and by the carrier as the project proceeds. The City will be responsible for all deductibles. 5.3. OTHER INSURANCE PROVISIONS Upon approval of this Agreement by City Council, and then annually upon the anniversary date(s) of the insurance policy's renewal date(s) far as long as this Agreement remains in effect, the Contractor will fiunish the City with a Certificate of Insurance(s) (using appropriate ACORD certificate, SIGNED by the Issuer, and with applicable endorsements) evidencing all of the coverage set forth above and naming the City as an "Additional Insured." In addition, when requested in writing from the City, Contractor will make copies of all applicable policies available for review by appointment with Contractor's VP, Insurance and Surety. The address where such certificates shall be sent or delivered is as follows: SECTION III Page 10 of 49 SECTION III — General Conditions City of Clearwater Engineering Department Attn: Construction Office Specialist P.O. Box 4748 Clearwater, FL 33758-4748 1. The Description (of Operations/Locations/Vehicles) should specify Project Name and Project Number. 2. Contractor shall provide thirty (30) days written notice of any cancellation, non-renewal, termination, material change or reduction in coverage. 3. Contractor's insurance as outlined above shall be primary and non-contributory coverage for Contractor's negligence. 4. Contractor reserves the right to appoint legal counsel to provide for the Contractor's defense, for any and all claims that may arise related to Agreement, work performed under this Agreement, or to Contractor's design, equipment, or service. Contractor agrees that the City shall not be liable to reimburse Contractar far any legal fees or costs as a result of Contractor providing its defense as contemplated herein. The stipulated limits of coverage above shall not be construed as a limitation of any potential liability to the City, and the City's failure to request evidence of this insurance shall not be construed as a waiver of Contractor's (or sub-contractors, representatives, or agents) obligation to provide the insurance coverage specified. 5.4. WAIVER OF RIGHTS The Owner and Contractor intend that all policies purchased in accordance with Article on Insurance will protect the Owner, Contractor, Subcontractors, and Engineer. Owner is to be listed as additional insured in such policies and will provide primary coverage for all losses and damages caused by the perils covered thereby. All such policies shall contain provisions to the effect that in the event of payment of any loss or damage the insurers will have no rights of recovery against any of the insured or additional insured thereunder, the Owner and Contractor waive all rights against each other and their respective ofiicers, directors, employees and agents for all losses and damages caused by, arising out of or resulting from any of the perils covered by such policies and any other property insurance applicable to the work; and, in addition, waive all such rights against Sub-contractors, Engineer, Engineer's Consultants and all other persons or entities identified in the Supplementary Conditions to be listed as insured or additional insured under such policies for losses and damages so caused. None of the above waivers shall extend to the rights that any party making such waiver may have to the proceeds of insurance otherwise payable under any policy so issued. In addition, the Owner waives all rights against Contractor, Subcontractors, Engineer, Engineer's Consultant and the officers, directors, employees and agents of any of them for: (i) loss due to business interruption, loss of use or other consequential loss extending beyond direct physical loss or damage to the Owner property or the Work caused by, arising out of or resulting from fire or other peril, whether or not insured by the Owner and; (ii) loss or damage to the completed Project or part thereof caused by, arising out of or resulting from fire or other insured peril covered by any property insurance maintained on the completed Project or part thereof by the Owner during partial utilization, after substantial completion or after final payment. If the waiver of subrogation applies to any separate contractors of Owner, Owner will include a reciprocal waiver of subrogation within all agreements with the separate contractors under contract with Owner. SECTION III Page 11 of 49 SECTION III—General Conditions 6. CONTRACTORS RESPONSIBILITIES 6.1. SUPERVISION AND SUPERINTENDENCE Contractor shall supervise, inspect and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. Contractor shall be solely responsible for the means, methods, techniques, sequences and procedures of construction. Contractor shall not be responsible for the negligence of others in the design or specification of a specific means, method, technique, sequence or procedure of construction which is shown or indicated in and expressly required by the Contract Documents. Contractor shall be responsible to see that the completed work complies accurately with the Contract Documents. Contractor shall keep on the work at all times during its progress a competent resident superintendent, who shall not be replaced without notice to the Owner's Representative except under extraordinary circumstances. The superintendent will be Contractor's representative at the site and shall have authority to act on behalf of Contractor. All communications to the superintendent shall be as binding as if given to Contractor. The Contractor's superintendent shall keep a mobile cell phone on his person, so he can be contacted whenever necessary. Contractor shall employ only competent persons to do the work and whenever the Owner's Representative shall notify Contractor, in writing, that any person on the work appears to be incompetent, unfaithful, disorderly, disrespectful or otherwise unsatisfactory, such person shall be removed from the project and shall not again be employed on it except with the written consent of the Owner's Representative. Contractor represents the City of Clearwater and shall conduct themselves in a professional manner to the public at all times. Contractor shall reimburse Owner for additional engineering and inspection costs incurred as a result of overtime work in excess of the regular working hours or on the Owner normally approved holidays. At such times when Inspectar overtime is required, the Contractor shall sign an overtime slip documenting such hours and the Contractor shall be provided a copy for his records. At the end of the project and prior to payment of withheld retainage funds, the Contractor shall deliver to the Owner a check made out to the Owner of Clearwater far full reimbursement of all Inspectar overtime hours. Withheld retainage shall not be released until the Owner has received this check. Minimum number of chargeable hours for inspection costs on weekends or holidays shall be four hours. The cost of overtime inspection per hour shall be $80.00 per hour. Contractor shall provide and maintain in a neat and sanitary condition, such sanitary accommodations for the use of Contractor's employees as may be necessary to comply with the requirements of Laws and Regulations and the Engineer. 6.2. LABOR, MATERIALS AND EQUIPMENT Contractor shall provide competent, suitably qualified personnel to survey, lay out and construct the work as required by the Contract Documents. Contractor shall at all times maintain good discipline and order at the site. Except as otherwise required for the safety or protection of persons or the work or property at the site or adjacent thereto, and except as otherwise indicated in the Contract Documents, all work at the site shall be performed during regular working hours. Contractor shall adhere to the Community Development Code, Section 3-1508 regarding noise restrictions from 6:00 p.m. to 7:00 a.m. any day and all day Sunday. Contractor will not permit SECTION III Page 12 of 49 SECTION III — General Conditions overtime work or the performance of wark on Saturday, Sunday, ar any legal holiday without Owner consent given after prior notice to Engineer. Unless otherwise speciiied in the General Requirements, Contractor shall furnish and assume full responsibility for all materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, heat, telephone, water, sanitary facilities, temporary facilities, and all other facilities and incidentals necessary for the furnishing, performance, testing, start-up and completion of the Work. All materials and equipment installed in the Work shall be of good quality and new, except as otherwise provided in the Contract Documents. If required by Engineer, Contractors shall furnish satisfactory evidence (including reports of required tests) as to the quality of materials and equipment. The Contractor shall provide suitable and secure storage for all materials to be used in the Work so that their quality shall not be impaired or injured. Materials that are improperly stored, may be rejected by the Engineer without testing. All materials and equipment shall be applied, installed, connected, erected, used, cleaned and conditioned in accordance with the instructions of the applicable manufacturer, fabricator, supplier, or distributor, except as otherwise provided in the Contract Documents. The City of Clearwater, at its sole discretion, reserves the right to purchase major equipment ar materials to be incorporated into the Work under the Owner Direct Purchase (ODP) Option, per Section III, Article 21. In such event, the Contractor shall cooperate and assist the Owner of Clearwater, at no additional cost, to implement the ODP documents and procedures. 6.3. SUBSTITUTES AND "OR EQUAL" ITEMS Whenever an item of material or equipment is specified ar described in the Contract Documents by using the name of a proprietary item or the name of a particular Supplier, the specification or description is intended to establish the type, function and quality required. Unless the specification or description contains or is followed by words reading that no like, equivalent or "or equal" item or no substitution is permitted, other items of material or equipment or material or equipment of other Suppliers may be accepted by Engineer. If in Engineer's sole discretion an item of material or equipment proposed by Contractor is functionally equal to that named and sufficiently similar so that no change in related Work will be required, it may be considered by Engineer for approval. If in the Engineer's sole discretion an item of material or equipment proposed by Contractor does not qualify as an "or equal" item, it may be considered as a proposed substitute item. Contractor shall submit sufficient information as required by the Engineer to allow the Engineer to determine that the item of material or equipment proposed is essentially equivalent to that named and is an acceptable substitute therefare. Request for review of proposed substitute and "or equal" will be not be accepted by Engineer from anyone other than Contractor. Request far substitute and "or equal" items by Contractor must be submitted in writing to Owner's Representative and will contain all information as Engineer deems necessary to make a determination. Request for substitute shall identify why a substitute is submitted and include advantages to the Owner. All data provided by Contractor in support of any proposed substitute or "or equal" item will be at Contractor's expense. Engineer will be allowed a reasonable time to evaluate each proposal ar submittal made per this paragraph. Engineer will be sole judge of acceptability. SECTION III Page 13 of 49 SECTION ill — General Conditions 6.4. SUBCONTRACTORS, SUPPLIERS AND OTHERS The Contractor shall deliver to the Owner's Representative before or at the preconstruction conference a list of all Subcontractors, suppliers and other persons and organizations proposed by the Contractor for Work to be performed on the Project. The Contractor shall include with this list the qualifications and references for each Subcontractor, supplier ar other person and organization for review and approval. Any changes to this list must be submitted to the Owner's Representative for approval prior to the substitution of any Subcontractors, suppliers or other persons and arganizations before performing any Work on the Project for the Contractor. Contractor shall be fully responsible to Owner and Engineer for all acts and omissions of the Subcontractors, Suppliers and other persons performing or furnishing any of the work under a direct or indirect contract with Contractor just as Contractor is responsible for Contractor's own acts and omissions. Nothing in the Contract Documents shall create for the benefit of any such Subcontractor, Supplier or other person any contractual relationship between Owner or Engineer and any Subcontractor, Supplier or other person, nor shall it create any obligation on the part of Owner or Engineer to pay or to see to the payment of any moneys due any such Subcontractor, Supplier or other person. Contractor shall be solely responsible for scheduling and coordinating the work of Subcontractors, Suppliers and other persons performing or furnishing any of the work under a direct or indirect contract with Contractor. Contractor shall require all Subcontractars, Suppliers and such other persons performing or furnishing any of the work to communicate with the Engineer through Contractor. The divisions and sections of the Specifications and the identifications of any Drawings shall not control Contractor in dividing the work among Subcontractors or Suppliers or delineating the work to be performed by any specific trade. All work performed for Contractor by a Subcontractor or Supplier will be pursuant to an appropriate agreement between Contractor and the Subcontractor or Supplier which specifically binds the Subcontractor or Supplier to the applicable terms and conditions of the Contract Documents far the benefit of Owner and Engineer. Contractor shall not pay or employ any Subcontractor, Supplier or other person or organization whether initially or as a substitute, against whom Owner or Engineer may have reasonable objection. Contractor shall not be required to employ any Subcontractor, Supplier or other person or organization to furnish or perform any of the work against whom Contractor has reasonable objection. Owner or Engineer will not undertake to settle any differences between Contractor and his Subcontractors or between Subcontractors. 6.5. USE OF PREMISES Contractor shall confine construction equipment, the storage of materials and equipment and the operations of works to the site and land areas identified in and permitted by the Contract Documents on other land areas permitted by Laws and Regulations, right-of-way, permits and easements, and shall not unreasonably encumber the premises with construction equipment or other materials or equipment. Contractor shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof or of any adjacent land or areas, resulting from the performance of the Work. Should any claim be made by any such owner or occupant because of the performance of the Work, Contractor shall promptly settle with such other party by negotiation or otherwise resolve the claim by arbitration or other dispute resolution proceed in ar SECTION III Page 14 of 49 SECTION III — General Conditions at law. Contractor shall, to the fullest extent permitted by Laws and Regulations, indemnify and hold harmless Owner, and their officials, directors, employees and agents (excluding any design professionals) from and against all claims, costs, losses and damages arising out of or resulting from any claim ar action, legal or equitable, brought by any such owner or occupant against Owner, Engineer or any other party indemnified hereunder to the extent caused by or based upon Contractor's performance of the Work. During the progress of the Work, Contractor shall keep the premises free from accumulations of waste materials, rubbish and other debris resulting from the Work. At the completion of the Work or at intervals established by the Engineer, Contractor shall remove all waste materials, rubbish and debris from and about the premises as well as all tools, appliances, construction equipment and machinery and surplus materials. Contractar shall restore to original condition all property not designated for alteration by the Contract Documents. 6.5.1. STAGING AREAS The Contactor shall obtain and deliver to the City written permission for the use of all staging and storage areas outside of the Limits of Construction. Use of right of way within the limits of construction must be approved by the City. All applicable erosion control, tree barricade and restoration, including time limits, specifications, etc., must be followed. 6.5.2. RESTORATION TIME LIMITS The timely restoration of all impacted areas, especially right-of-ways, is very important to the Citizens of Clearwater therefore, these time limits are imposed: • Debris piles shall be removed within five (5) consecutive calendar days. • Concrete driveways and sidewalks shall be replaced within ten (10) consecutive calendar days of removal. Resident access shall be maintained at all times. • All arterial and collector roadways shall be restored ASAP. • Local streets and asphalt driveways shall be restored as soon as a sufiicient quantity is generated, however, this is never to exceed fifteen (15) consecutive calendar days. Local and resident access shall be maintained at all times. • Any irrigation systems or components damaged or impacted by construction activities shall be repaired ar replaced "in-kind" within forty-eight (48) hours to minimize the loss of turfgrass or landscape plantings, particularly during periods of drought. • Sod must be restored "in-kind" within fourteen (14) consecutive calendar days of a successful pipe pressure test, removal of concrete forms, backfill of excavations, replacement of driveways or sidewalks ar another project specific milestone. It must be watered for a period of thirty (30) days after it is placed. Erosion control and dust control of denuded areas must be maintained at all times. If the project or a portion of it does not involve right-of ways, then a different schedule of sod restoration may be considered. 6.6. LICENSE AND PATENT FEES, ROYALTIES AND TAXES Contractar shall pay all license fees and royalties and assume all costs incident to the use in the performance of the work or the incorparation in the Work of any invention, design, process, product or device which is the subject of patent rights or copyrights held by others. If a particular invention, design, process, product ar device is specified in the Contract Documents for use in the SECTION III Page 15 of 49 SECTION ill — General Conditions performance of the work and if to the actual knowledge of Owner or Engineer its use is subject to patent rights or copyrights calling for the payment of any license fee or royalty to others, the existence of such rights shall be disclosed by Owner or Engineer in the Contract Documents. To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify and hold harmless Owner, Engineer, Engineer's Consultants and the officers, directors, employees, agents and other consultants of each and any of them from and against all claims, costs, losses and damages arising out of or resulting from any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product or device not specified in the Contract Documents, and shall defend all such claims in connection with any alleged infringement of such rights. Contractor shall pay all sales, consumer, use and other taxes required to be paid by Contractor in accordance with the Laws and Regulations of the State of Florida and other governmental agencies, which are applicable during the performance of the work. 6.7. LAWS AND REGULATIONS Contractor shall give all notices and comply with all Laws and Regulations applicable to furnishing and performance of the Work. Except where otherwise expressly required by applicable Laws and Regulations, neither Oumer nor Owner's Representative shall be responsible for monitoring Contractor's compliance with any Laws ar Regulations. If Contractor performs any work knowing or having reason to know that it is contrary to Laws or Regulations, Contractor shall bear all claims, costs, losses and damages caused by or arising out of such work: however, it shall not be Contractor's primary responsibility to make certain that the Specifications and Drawings are in accordance with Laws and Regulations, but this shall not relieve Contractor of Contractor's obligations to the Owner to report and resolve discrepancies as described above. When City projects include Federal or State funding, the requirements of Executive Order 11-02 shall be adhered to utilizing the Homeland Security E-Verify System to verify employment eligibility. 6.8. PERMITS Unless otherwise provided in the Supplementary Conditions, Contractor shall obtain and pay for all construction permits and licenses. The Owner shall assist Contractor, when necessary, in obtaining such permits and licenses. Contractor shall pay all governmental charges and inspection fees necessary for the prosecution of the Work, which are applicable at the time of opening of Bids. Contractor shall pay all charges of utility owners far connections to the work, and the Owner shall pay all charges of such utility owners for capital costs related thereto such as plant investment fees. Unless otherwise stated in the Contract Documents, Clearwater Building Permit Fees will be waived. 6.9. SAFETY AND PROTECTION Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. Contractar shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: (i) all persons on the work site or who may be affected by the work, (ii) all the Work and materials and equipment to be incorporated therein, whether in storage on or off the site; and (iii) other property SECTION III Page 16 of 49 SECTION ill — General Conditions at the site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures, utilities and Underground Facilities not designated for removal, relocation or replacement in the course of construction. In the event of temporary suspension of the work, or during inclement weather, or whenever Owner's Representative may direct; Contractor shall, and shall cause Subcontractors, to protect carefully the Work and materials against damage or injury from the weather. If, in the opinion of the Owner's Representative, any portion of Work or materials shall have been damaged ar injured by reason of failure on the part of the Contractor ar any Subcontractors to so protect the Work, such Work and materials shall be removed and replaced at the expense of Contractor. The Contractor shall initiate and maintain an accident prevention program which shall include but shall not be limited to the establishment and supervision of programs for the education and training of employees in the recognition, avoidance and prevention of unsafe conditions and acts. Contractor shall provide first aid services and medical care to his employees. The Contractar shall develop and maintain an effective fire protection and prevention program and good housekeeping practices at the site of contract performance throughout all phases of construction, repair, alteration or demolition. Contractor shall require appropriate personal protective equipment in all operations where there is exposure to hazardous conditions. The Engineer may order that the work stop if a condition of immediate danger to the Owner's employees, equipment or if property damage exists. This provision shall not shift responsibility or risk of loss for injuries of damage sustained from the Contractor to Owner, and the Contractor shall remain solely responsible for compliance with all safety requirements and for the safety of all persons and property at the site of Contract performance. The Contractor shall instruct his employees required to handle or use toxic materials or other harmful substances regarding their safe handling and use. The Contractor shall take the necessary precautions to protect pedestrians and motorists from harm, and to prevent disruptions of such traffic due to construction activity. Contractor shall comply with all applicable Laws and Regulations of any public body having jurisdiction for safety of persons or properiy and to protect them from damage, injury or loss; and shall erect and maintain all necessary safeguards for such safety and protection. Contractar shall notify owners of adjacent property and of Underground Facilities and utility owners when execution of the work may affect them, and shall cooperate with them in the protection, removal, relocation and replacement of their property. All damage, injury or loss to any property caused, directly or indirectly, in whole or part, by Contractor, any Subcontractor, Supplier or any other person or organization directly or indirectly employed by any of them to perform or furnish any of the work or anyone for whose acts any of them may be liable, shall be remedied by Contractor. Contractor's duties and responsibilities for safety and for protection of the Work shall continue until such time as all the Work is completed and Engineer has issued a notice to Owner and Contractor that the Work is acceptable. 6.10. EMERGENCIES In emergencies affecting the safety or protection of persons or the Work or property at the site or adjacent thereto, Contractor, with or without special instruction or authorization from Owner or the Owner's Representative, is obligated to act to prevent damage, injury or loss. Contractor shall give Engineer prompt written notice if Contractor believes that any significant changes in the Wark or variations from the Contract Documents have been caused thereby. If the Owner's Representative determines that a change in the Contract Documents is required because of the action taken by Contractor in response to such an emergency, a Work Change Directive or Change Order will be issued to document the consequences of such action. SECTION III Page 17 of 49 SECTION III — General Conditions 6.11. DRAWINGS 6.11.1. SHOP DRAWINGS, SAMPLES, RFIs, AND SUBMITTAL REVIEW Contractor shall submit Shop Drawings to Engineer for review and approval as called for in the Technical Specifications or required by the Engineer. The data shown on the Shop Drawings will be complete with respect to quantities, dimensions, specified performance and design criteria, materials and similar data to show Engineer the materials and equipment Contractor proposes to provide and to enable Engineer to review the information. Contractor shall also submit Samples to Engineer for review and approval. Before submitting each Shop Drawing or Sample, Contractor shall have determined and verified: (i) all field measurements, quantities, dimensions, specified performance criteria, installation requirements, materials, catalog numbers and similar information with respect thereto, (ii) all materials with respect to intended use, fabrication, shipping, handling, storage, assembly and installation pertaining to the performance of the Work, and (iii) all information relative to Contractor's sole responsibilities in respect to means, methods, techniques, sequences and procedures of construction and safety precautions and programs incident thereto. Contractor shall also have reviewed and coordinated each Shop Drawing or Sample with other Shop Drawings and Samples with the requirements of the Work and the Contract Documents. Each submittal will have a transmittal cover sheet identifying the shop drawing name, number, and technical specification reference; will bear a stamp or specific written indication that Contractor has satisfied Contractor's obligations under the Contract Documents with respect to Contractor's review and approval of that submittal. At the time of submission, Contractor shall give Engineer specific written notice of such variations, if any, that the Shop Drawing or Sample submitted may have from the requirements of the Contract Documents, such notice to be in a written communication separate from the submittal; and, in addition, shall cause a speciiic notation to be made on each Shop Drawing and Sample submitted to Engineer for review and approval of each such variation. The Contractor shall maintain a submittal log as mentioned in Article 2.5. The Engineer shall receive updated copies at each progress meeting, and the Engineer shall respond to each submittal within fourteen (14) consecutive calendar days. The Contractor shall maintain a request for information (RFI) log as mentioned in Article 2.5. The Engineer shall receive updated copies at each progress meeting, and the Engineer shall respond to each RFI within fourteen (14) consecutive calendar days. The untimely submission of Submittal or RFIs shall not be grounds for a delay claim from the Contractor. Engineer's review and approval of Shop Drawings and Samples will be only to determine if the items covered by the submittals will, after installation or incorporation in the Wark, conform to the information given in the Contract Documents and be compatible with the design concept of the completed Project as a functioning whole as indicated the Contract Documents. Engineer's review and approval will not extend to means, methods, techniques, sequences or procedures of construction (except where a particular means method, technique, sequence or procedure of construction is specifically and expressly called for by the Contract Documents) or to safety precautions or programs incident thereto. The review and approval of a separate item as such will not indicate approval of the assembly in which the item functions. Contractor shall make corrections required by Engineer and shall return the required number of corrected copies of Shop Drawings and submit as required new Samples for review and approval. Contractor shall direct specific attention in writing to revisions other than the corrections called for by Engineer on previous submittals. SECTION III Page 18 of 49 SECTION III—General Conditions Engineer's review and approval of Shop Drawings or Samples shall not relieve Contractor from responsibility for any variation from the requirements of the Contract Documents unless Contractar has in writing called Engineer's attention to each such variation at the time of submission and Engineer has given written approval of each such variation by specific written notation thereof incorporated in or accompanying the Shop Drawing or Sample approval; nor will any approval by the Engineer relieve the Contractor from responsibility for complying with the requirements of paragraph above discussing field measurements by the Contractor. Contractor shall furnish required submittals with complete information and accuracy in order to achieve required approval of an item within two (2) submittals. Owner's Representative reserves the right to backcharge Contractor, for Engineer's costs for resubmittals that account for a number greater than twenty percent (20%) of the total number of first time submittals, per the approved initial submittal log. Owner's Representative reserves the right to backcharge Contractor for all third submittals. The number of first-time submittals shall be equal to the number of submittals agreed to by Engineer and Contractor. All costs to Engineer involved with subsequent submittal of Shop Drawings, Samples or other items requiring approval will be backcharged to Contractor at the rate of 3.0 times direct technical labor cost by deducting such costs from payments due Contractor for Work completed. In the event that Contractor requests a substitution for a previously approved item, all of Engineer's costs in the reviewing and approval of the substitution will be backcharged to Contractor, unless the need for such substitution is beyond the control of Contractor. 6.11.2. AS-BUILT DRAWINGS The Contractor shall keep and maintain one set of blueprints, As-Built Drawings, in good order and legible condition to be continuously marked-up at the job site. The Contractor shall mark and annotate neatly and clearly all project conditions, locations, configurations and any other changes or deviations which may vary from the details represented on the original Contract Plans, including revisions made necessary by Addenda, Shop Drawings, and Change Orders during the construction process. The Contractor shall record the horizontal and vertical locations, in the plan and profile, of all buried utilities that differ from the locations indicated or which were not indicated on the Contract Plans and buried (or concealed), construction and utility features which are revealed during the construction period. The As-Built Drawings shall be available for inspection by the Engineer, Engineer's Consultant, and the Owner's Representative at all times during the progress of the Project. The As-Built Drawings shall be reviewed by the Owner's Representative, or his designee, for accuracy and compliance with the requirements of "As-Built Drawings" prior to submittal of the monthly pay requests. The pay requests shall be rejected if the marked-up redline prints do not conform to the "As-Built Drawings" requirements. As-Built Drawings shall be submitted to the Owner Inspector for approval upon completion of the project and prior to acceptance of iinal pay request. Final pay request shall not be processed until As-Built Drawings have been reviewed by the Engineer or the Engineer's Consultant far accuracy and completeness. Prior to placing new potable water mains in service, the Contractor shall provide the Engineer intersection drawings, as specified for the water mains. The Owner's acceptance of the "As-Built Drawings" does not relieve the Contractor of the sole responsibiliry for the accuracy and completeness of the As-Built Drawings. SECTION III Page 19 of 49 SECTION III—General Conditions 6.11.2.1. General The Contractor shall prepare an "AS-BUILT SURVEY" per chapter SJ-17.052, Florida Administrative Code (see definition below), signed and sealed by a Florida registered land surveyor. The contractor will deliver to the Owner two hard copies of signed and sealed As-Built Drawings and an AutoCAD file. SJ-17.050 Definitiorc: (10)(a) As-Built Survey: a survey performed to obtain horizontal and/or vertical dimensional data so that constructed improvements may be located and delineated: also known as Record Survey. This survey shall be clearly titled "As-Built Survey" and shall be signed and sealed by a Florida registered land surveyor. The survey must be delivered to the Owner of Clearwater Construction Division upon substantial completion of the project. If this condition is not met, the Owner will procure the services of a Professional Surveyor and Mapper registered in the State of Florida and will back charge the contractor a fee of $1,800 per day or any portion thereof to provide the Owner with the required As-Built Survey. 6.11.2.2. Sanitary and Storm Sewer Piping Systems Manholes and inlets shall be located by survey coordinates (northing, easting and elevation) based on the approved horizontal and vertical datum or utilize the stationing supplied on the construction plans. New and replaced service connections shall be dimensioned to the nearest downstream manhole. All manholes, cleanouts and catch basin invert and rim elevations, manhole and catch basin dimensions, pipe sizes, and pipe material shall also be noted on the plan view and also on the profile if one exists. The terminal ends of all subdrains, inverts of all pipe in structures, and the flow line of inlets shall also be noted on the plan view and also on the profile if one exists. 2. Pipe materials and areas of special construction shall be noted. 6.11.2.3. Pressure Pipe construction (Water, Reclaimed Water, Forcemain) All pipes shall be located by survey coordinates (northing, easting and elevation) based on the approved horizontal and vertical datum or utilize the stationing supplied on the construction plans. Coordinates shall be at all pipe bends, tees, valves, reducers, and deflections. Also, all new and replaced service connections for potable and reclaimed water will be located as described above. Additionally, there must be survey coardinates no further than 100 feet apart on linear type construction and shall denote top of pipe elevation at those points. 6.11.2.4. Electrical and Control Wiring The as-built drawings shall include all changes to the original Contract Plans. The as-built drawings shall also include the size, color, and number of wires and conduit. For projects where this information is too voluminous to be contained on the blueline prints, the Contractor shall prepare supplemental drawings, on same size sheets as the blueline prints, showing the additional conduit runs, 1-line diagrams, ladder diagrams, and other information. The wiring schematic diagrams shall show termination location and wiring identification at each point on the ladder diagram. SECTION III Page 20 of 49 SECTION III — General Conditions 6.11.2.5. Horizontal and Vertical Control The As-Built survey shall be based on the original datum used for the construction design plans or if required by the Owner the datum shall be referenced to the North American Datum of 1983/90 (horizontal) and the North American Vertical Datum of 1988. The unit of ineasurement shall be the United States Foot. Any deviation or use of any other datum, (horizontal and or vertical), must be approved by the Owner of Clearwater Engineering Department. 6.11.2.6. Standards The As-Built survey shall meet the Minimum Technical Standards per Chapter SJ-17 and the Clearwater CAD STANDARDS set forth below. In addition to locating all improvements that pertain to the as-built survey it is the requirement of the Owner to have minimum location points at every change in direction and no more than 100 feet apart on all pressure pipes. 6.11.2.7. Other The As-Built drawings shall reflect any differences from the original Contract Plans, in the same level of detail and units of dimensions as the Plans. 6.11.3. CAD STANDARDS 6.11.3.1. Layer Naming 6.11.3.1.1. Prefixes and Suffixes 6.� DI prefix denotes digitized or scanned entities EP prefix denotes existing points - field collected EX prefix denotes existing entities - line work and symbols PR prefix denotes proposed entities - line work and symbols FU prefix denotes future entities (proposed but not part of this contract) - line work and symbols TX suffix denotes text — use for all text, no matter the prefix 11.3.1.2. La er Namin Definitions: GAS gas lines and appurtenances ELEC power lines and appurtenances PHONE telephone lines and appurtenances CABLE cable TV lines and appurtenances BOC curbs WALK sidewalk WATER water lines and appurtenances, sprinklers STORM storm lines and appurtenances TREES trees, bushes, planters SECTION III Page 21 of 49 SECTION ill — General Conditions SANITARY sanitary lines and appurtenances FENCE all fences BLDG buildings, sheds, finished floor elevation DRIVE driveways EOP edge of pavement without curbs TRAFFIC signal poles, control boxes TOPBANK top of bank TOESLOPE toe of slope TOPBERM top of berm TOEBERM toe of berm SEAWALL seawall CONCSLAB concrete slabs WALL walls, except seawall SHORE shoreline, water elevation CL centerline of road CLD centerline of ditch CLS centerline of swale CORNER properiy corners, monumentation BENCH benchmark, temporary benchmarks Other layers may be created as required, using above format. 6.11.3.2. Layer Properties All layers will use standard AutoCAD linetypes, bylayer. All layers will use standard AutoCAD colors, bylayer. All text will use standard AutoCAD fonts. 6.11.3.3. Text Styles Text style for EX layers will use the simplex font, oblique angle of 0°, and a text height of .008 times the plot scale. Text style for PR and FU layers will use the simplex font, oblique angle of 22.5°, and a text height of .O 10 times the plot scale. 6.11.4. DELIVERABLES The as-built survey shall be produced on bond material, 24" x 36" at a scale of 1"=20' unless approved otherwise. The consultant shall deliver two hard copies and one digital copy of all drawings. Requested file formats are: Autodesk DWG and Adobe PDF files. SECTION III Page 22 of 49 SECTION III — General Conditions Please address any questions regarding format to Mr. Tom Mahony, at (727) 562-4762 or e-mail address Thomas.Mahonv(cLmvClearwater.com. 6.12. CONTRACTOR'S GENERAL WARRANTY AND GUARANTEE Contractar warrants and guarantees to Owner, Engineer and Engineer's Consultants that all Wark will be in accordance with the Contract Documents and will not be defective. Contractor's warranty and guarantee hereunder includes defects or damage caused by abuse, vandalism, modification or operation by persons other than Contractor, Subcontractors or Suppliers. Until the acceptance of the Work by the Owner, the Work shall be under the charge and care of the Contractor, and he shall take every necessary precaution against injury or damage to any part thereof by action of the elements, or from any other cause whatsoever, arising from the execution or non-execution of the Work. The Contractor shall rebuild, repair and make good, at his own expense, all injuries or damages to any portion of the Work occasioned by any cause before its completion and final acceptance by the Owner. In addition, "the Contractor shall remedy any defects in the work at his own expense and pay for any damage to other work resulting therefrom which appear within a period of one year from the date of final acceptance". Contractor's warranty and guarantee hereunder excludes improper maintenance and operation by Owner's employees and normal wear and tear under normal usage for any portion of the Work, which has been partially accepted by the Owner for operation prior to final acceptance by the Owner. Contractor's obligation to perform and complete the Work in accordance with the Contract Documents shall be absolute. None of the following will constitute an acceptance of Work that is not in accordance with the Contract Documents or a release of Contractor's obligation to perform the Work in accardance with the Contract Documents: (i) observations by Owner's Representative, (ii) recommendation of any progress or final payment by Owner's Representative, (iii) the issuance of a certificate of Substantial Completion or any payment by the Owner to contractor under the Contract Documents, (iv) use or occupancy of the Work or any part thereof by Owner, (v) any acceptance by Owner or any failure to do so, (vi) any review and approval of a Shop Drawing ar Sample submittal or the issuance of a notice of Acceptance by the Engineer. 6.13. CONTINUING THE WORK Contractor shall carry on the work and adhere to the progress schedule during all disputes ar disagreements with the Owner. No work shall be delayed or postponed pending resolution of any disputes or disagreements, except as the Owner or Contractor may otherwise agree in writing. 6.14. INDEMNIFICATION To the fullest extent permitted by law, Contractor agrees to defend, indemnify, and hold the City, its officers, agents (excluding any design professionals), and employees, harmless from and against any and all liabilities, demands, claims, suits, losses, damages, causes of action, fines or judgments, including costs, attorneys', witnesses', and expert witnesses' fees, and expenses incident thereto, relating to, arising out of, or resulting from: (i) the services provided by Contractor personnel under this Agreement; (ii) any negligent acts, errors, mistakes ar omissions by Contractor or Contractor personnel; and (iii) Contractor or Contractor personnel's failure to comply with or fulfill the obligations established by this Agreement. SECTION III Page 23 of 49 SECTION Iil — General Conditions Contractor will update the City during the course of the litigation to timely notify the City of any issues that may involve the independent negligence of the City that is not covered by this indemnification. The City assumes no liability for actions of Contractor and will not indemnify or hold Contractor or any third party harmless for claims based on this Agreement or use of Contractor-provided supplies ar services. Notwithstanding anything contained herein to the contrary, this indemnification provision shall not be construed as a waiver of any immunity to which Owner is entitled or the extent of any limitation of liability pursuant to § 768.28, Florida Statutes. Furthermore, this provision is not intended to nor shall be interpreted as limiting or in any way affecting any defense Owner may have under § 768.28, Florida Statutes or as consent to be sued by third parties. 6.15. CHANGES IN COMPANY CONTACT INFORMATION Contractor shall notify Owner by US mail addressed to the City Engineer of any changes in company contact information. This includes contact phone, address, project manager, email addresses, etc. 6.16. PUBLIC RECORDS The ENGINEER will be required to comply with Section 119.0701, Florida Statutes (2014), specifically to: a) Keep and maintain public records required by the city of Clearwater (hereinafter "public agency") to perform the service being provided by the contractor hereunder. b) Upon request from the public agency's custodian of public records, provide the public agency with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided for in Chapter 119, Florida Statutes, as many be amended from time to time, ar as otherwise provided by law. c) Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the contractor does not transfer the records to the public agency. d) Upon completion of the contract, transfer, at no cost, to the public agency all public records in possession of the contractor or keep and maintain public records required by the public agency to perform the service. If the contractor transfers all public records to the public agency upon completion of the contract, the contractar shall destroy any public records that are exempt or confidential and exempt from public records disclosure requirements. If the contractor keeps and maintains public records upon completion of the contract, the contractor shall meet all applicable requirements for the retaining public records. All records stored electronically must be provided to the public agency, upon request from the public agency's custodian of public records in a format that is compatible with the information technology systems of the public agency. e) A request to inspect or copy public records relating to a public agency's contract for services must be made directly to the public agency. If the public agency does not possess the requested records, the public agency shall immediately notify the contractor of the request and the contractor must provide the records to the public agency or allow the records to be inspected or copied within a reasonable time. SECTION III Page 24 of 49 SECTION III — General Conditions � The Contractor hereby acknowledges and agrees that if the contractor does not comply with the public agency's request for records, the public agency shall enforce the contract provisions in accordance with the contract. g) A Contractor who fails to provide the public records to the public agency within a reasonable time may be subject to penalties under Section ll9.10, Florida Statutes. h) If a civil action is filed against a contractor to compel production of public records relating to a public agency's contract far services, the court shall assess and award against the contractor the reasonable costs of enforcement, including reasonable attorney fees, if: 1. The court determines that the contractor unlawfully refused to comply with the public recards request within a reasonable time; and 2. At least 8 business days before filing the action, the plaintiff provided written notice of the public request, including a statement that the contractor has not complied with the request, to the public agency and to the contractor. i) A notice complies with subparagraph (h)2. if it is sent to the public agency's custodian of public records and to the contractor at the contractor's address listed on its contract with the public agency ar to the contractor's registered agent. Global Express Guaranteed, or certified mail, with postage or shipping paid by the sender and with evidence of delivery, which may be in an electronic format. j) A contractor who complies with a public records request within 8 business days after the notice is sent is not liable for the reasonable costs of enforcement. 7. OTHER WORK 7.1. RELATED WORK AT SITE The City reserves the right to have its own forces enter the construction site at any time and perform work as necessary in order to perform infrastructure repair or maintenance, whether related to the project or not. The Contractor will allow complete access to all utility owners for these purposes. The City may have its own forces perform new work related to the project, however, this work will be identified in the Contract Scope of Work and coordination will be such that this activity is denoted in the Contractor's CPM Schedule so as not to cause any delays or interference with the Contractor's work or schedule. 7.2. COORDINATION If the Owner contracts with others for the performance of other work on the Project at the site, the following will be set forth in the Scope of Work: (i) the person who will have authority and responsibility for coordination of the activities among the various prime contractors will be identified; (ii) the specific matters to be covered by such authority and responsibility will be itemized; and (iii) the extent of such authority and responsibilities will be provided. Unless otherwise provided in the Supplementary Conditions, the Owner shall have sole authority and responsibility in respect of such coordination. 8. OWNERS RESPONSIBILITY Except as otherwise provided in these General Conditions, the Owner shall issue all communications from the Owner to the Contractor through Owner's Representative. SECTION III Page 25 of 49 SECTION III — General Conditions The Owner shall furnish the data required of the Owner under the Contract Documents promptly and shall make payments to Contractor promptly when they are due as provided in these General Conditions. The Owner is obligated to execute Change Orders as indicated in the Article on Changes In The Work. The Owner's responsibility in respect of certain inspections, tests, and approvals is set forth in the Article on Tests and Inspections. In connection with the Owner's right to stop work or suspend work, see the Article an Engineer may Stop the Work. The Article on Suspension of Work and Termination deals with the Owner's right to terminate services of Contractor under certain circumstances. Owner shall not supervise, direct or have control or authority over, nor be responsible for, Contractar's means, methods, techniques, sequences or procedures of construction or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the furnishing or performance of the Work. The Owner will not be responsible for Contractor's failure to perform or furnish the Work in accordance with the Contract Documents. 9. OWNER REPRESENTATIVE'S STATUS DURING CONSTRUCTION 9.1. OWNERS REPRESENTATIVE Dependent of the project type, the Owner's Representative during the construction period will either be the Construction Manager, the Engineer, or a designee of the Project's Owner. The duties, responsibilities and the limitations of authority of Owner's Representative during construction are set forth in the Contract Documents and shall not be extended without written consent of Owner and Engineer. 9.2. CLARIFICATIONS AND INTERPRETATIONS Engineer will issue with reasonable promptness such written clarifications or interpretations of the requirements of the Contract Documents regarding design issues only, in the form of Submittal responses, RFI responses, Drawings or otherwise, as Engineer may determine necessary, which shall be consistent with the intent of and reasonably inferable from Contract Documents. All other clarifications and interpretations of the Contract Documents shall be issued form the Owner's Representative. Such written clarifications and interpretations will be binding on the Owner and Contractor. If Contractor believes that a written clarification or interpretation justifies an adjustment in the Contract Price or the Contract Time and the parties are unable to agree to the amount or extent thereof, if any, Contractor may make a written claim therefore as provided in the Articles for Change of Work and Change of Contract Time. 9.3. REJECTING OF DEFECTIVE WORK The Owner's Representative or the Engineer will have authority to disapprove or reject Work which Owner's Representative or the Engineer believes to be defective, or that Owner's Representative or the Engineer believes will not produce a completed Project that conforms to the Contract Documents or that will prejudice the integrity of the design concept of the completed SECTION III Page 26 of 49 SECTION III —General Conditions Project as a functioning whole as indicated by the Contract Documents. The Owner's Representative ar the Engineer will also have authority to require special inspection or testing of the Work whether or not the Work is fabricated, installed or completed. 9.4. SHOP DRAWINGS, CHANGE ORDERS, AND PAYMENTS In connection with Engineer's autharity as to Shop Drawings and Samples, see articles on Shop Drawings and Samples. In connection with Owner's Representative autharity as to Change Orders, see the articles on Changes of Work, Contract Price and Contract Time. In connection with Owner's Representative authority as to Applications for Payment, see the articles on Payments to Contractor and Completion. 9.5. DECISIONS ON DISPUTES The Owner's Representative will be the initial interpreter of the requirements of the Contract Documents and judge of the acceptability of the work thereunder. Claims, disputes and other matters relating to the acceptability of the work or the interpretation of the requirements of the Contract Documents pertaining to the performance and furnishing of the wark and Claims under the Articles for Changes of Work, Changes of Contract Time and Changes of Contract Price will be referred initially to Owner's Representative in writing with a request for a formal decision in accordance with this paragraph. Written notice of each such claim, dispute or other matter will be delivered by the claimant to Owner's Representative and the other party to the Agreement promptly, but in no event later than thirty (30) days, after the start of the occurrence or event giving rise thereto, and written supporting data will be submitted to Owner's Representative and the other party within sixry (60) days after the start of such occurrence or event unless Owner's Representative allows an additional period of time for the submission of additional or more accurate data in support of such claim, dispute or other matter. The opposing party shall submit any response to Owner's Representative and the claimant within thirty (30) days after receipt of the claimant's last submittal, unless Owner's Representative allows additional time. Owner's Representative will render a formal decision in writing within thirty (30) days after receipt of the opposing party's submittal, if any, in accordance with this paragraph. Owner Representative's written decision on such claim, dispute or other matter will be final and binding upon the Owner and Contractor unless (i) an appeal from Owner Representative's decision is taken within thirty (30) days of the Owner Representative's decision, or the appeal time which may be stated in a Dispute Resolution Agreement between Owner and Contractor for the settlement of disputes or (ii) if no such Dispute Resolution Agreement has been entered into, a written notice of intention to appeal from Owner Representative's written decision is delivered by the Owner ar Contractor to the other and to Owner's Representative within thirty (30) days after the date of such decision and a formal proceeding is instituted by the appealing party in a forum of competent jurisdiction to exercise such rights or remedies as the appealing pariy may have with respect to such claim, dispute or other matter in accordance with applicable Laws and Regulations within sixty (60) days of the date of such decision, unless otherwise agreed in writing by the Owner and Contractar. When functioning as interpreter and judge, Owner's Representative will not show partiality to the Owner or Contractor and will not be liable in connection with any interpretation or decision rendered in good faith in such capacity. The rendering of a decision by Owner's Representative with respect to any such claim, dispute or other matter will be a condition precedent to any exercise by the Owner or Contractor of such rights or remedies as either may otherwise have under the Contract Documents or by Laws or Regulations in respect of any such claim, dispute or other matter pursuant the Article on Dispute Resolution. SECTION III Page 27 of 49 SECTION III—General Conditions 9.6. LIMITATIONS ON OWNER REPRESENTATIVE'S RESPONSIBILITIES Neither Owner Representative's authority or responsibility under this paragraph or under any other provision of the Contract Documents nor any decision made by Owner's Representative in good faith either to exercise or not exercise such authority or responsibility or the undertaking, exercise or performance of any authority or responsibility by Owner's Representative shall create, impose or give rise to any duty owed by Owner's Representative to Contractor, any Subcontractar, any Supplier, any other person or organization or to any surety for or employee or agent of any of them. Owner's Representative will not supervise, direct, control or have authority over or be responsible for Contractor's means, methods, techniques, sequences or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the furnishing or performance of the work. Owner's Representative will not be responsible for Contractor's failure to perform or furnish the work in accordance with the Contract Documents. Owner's Representative will not be responsible for the acts or omissions of Contractor or of any Subcontractor, any Supplier, or of any other person or organization performing or furnishing any of the work. Owner Representative's review of the final Application for Payment and accompanying documentation and all maintenance and operating instructions, schedules, guarantees, bonds and certificates of inspection, tests and approvals and other documentation required to be delivered by the Contractor will only be to determine generally that their content complies with the requirements of the Contract Documents and, in the case of certificates of inspections, tests and approvals that the results certified indicate compliance with the Contract Documents. The limitations upon authority and responsibility set forth in this paragraph shall also apply to Owner Representative's CEI, the Engineer's Consultants, and assistants. 10. CHANGES IN THE WORK Without invalidating the Agreement and without notice to any surety, the Owner may, at any time or from time to time, order additions, deletions or revisions in the Work. Such additions, deletions or revisions will be authorized by a Written Amendment, a Change Order, or a Work Change Directive. Upon receipt of any such document, Contractor shall promptly proceed with the Work involved which will be performed under the applicable conditions of the Contract Documents (except as may otherwise be specifically provided). If the Owner and Contractor are unable to agree as to the extent, if any, of an adjustment in the Contract Price or an adjustment of the Contract Time that should be allowed as a result of a Work Change Directive, a claim may be made therefore as provided in these General Conditions. Contractor shall not be entitled to an increase in the Contract Price or an extension of the Contract Time with respect to any Wark performed that is not required by the Contract Documents as amended, modified and supplemented as provided in these General Conditions except in the case of an emergency as provided or in the case of uncovering work as provided in article far Uncovering Work. The Owner and Contractor shall execute appropriate Change Orders or Written Amendments recommended by Owner's Representative covering: SECTION III Page 28 of 49 SECTION III — General Conditions • changes in the work which are (i) ordered by the Owner (ii) required because of acceptance of defective work under the article for Acceptance of Defective Work ar correcting defective Work under the article for Owner May Correct Defective Work or (iii) agreed to by the parties; • changes in the Contract Price or Contract Time which are agreed to by the parties; and • changes in the Contract Price or Contract Time which embody the substance of any written decision rendered by Owner's Representative pursuant to the article for Decisions on Disputes; • provided that, in lieu of executing any such Change Order, an appeal may be taken from any such decision in accordance with the provisions of the Contract Documents and applicable Laws and Regulations, but during any such appeal, Contractor shall carry on the Work and adhere to the progress schedule as provided in the article for Continuing the Work. If notice of any change affecting the general scope of the work or the provisions of the Contract Documents (including, but not limited to, Contract Price or Contract Time) is required by the provisions of any Bond to be given to a surety, the giving of any such notice will be Contractar's responsibility, and the amount of each applicable Bond will be adjusted accordingly. 11. CHANGES IN THE CONTRACT PRICE 11.1. CHANGES IN THE CONTRACT PRICE The Contract Price constitutes the total compensation (subject to authorized adjustments) payable to Contractor for performing the Work. All duties, responsibilities and obligations assigned to or undertaken by Contractor shall be at Contractor's expense without change in the Contract Price. The Contract Price may only be adjusted by a Change Order or by a Written Amendment. Any claim for an adjustment in the Contract Price shall be based on a written notice of claim stating the general nature of the claim, to be delivered by the party making the claim to the other party and to Owner's Representative or promptly (but in no event later than thirty days) after the start of the occurrence or event giving rise to the claim. Notice of the amount of the claim with supporting data shall be delivered within sixty (60) days after the start of such occurrence or event, unless Owner's Representative allows additional time for claimant to submit additional or more accurate data in support of the claim, and shall be accompanied by claimant's written statement that the claimed adjustment covers all known amounts to which the claimant is entitled as a result of said occurrence or event. No claim for an adjustment in the Contract Price will be valid if not submitted in accordance with this paragraph. The value of any Work covered by a Change Order or of any claim for an adjustment in the Contract Price will be determined as follows: (i) where the Work involved is covered by unit prices contained in the Contract Documents, by application of such unit prices to the quantities of the items involved (ii) where the Work involved is not covered by unit prices contained in the Contract Documents, by a mutually agreed lump sum (which may include an allowance for overhead and profit), (iii) where the Work is not covered by unit prices contained in the Contract Documents and agreement is reached to establish unit prices for the Work. Where the work involved is not covered by unit prices contained in the Contract Documents and where the Owner's Representative, the Owner, the Engineer, the Engineer's Consultant, and Contractor cannot mutually agree on a lump sum price, the City of Clearwater shall pay for directed changes in the Work, on "COST REIMBURSEMENT" basis. The Contractar shall apply for SECTION III Page 29 of 49 SECTION ill — General Conditions compensation, detailing Contractors forces, materials, equipment, subcontractars, and other items of direct costs required for the directed work. The application for Cost Reimbursement shall be limited to the following items: Labor, including foremen, for those hours associated with the direct work (actual payroll cost, including wages, fringe benefits, labor insurance and labor taxes established by law). Expressly excluded from this item are all costs associated with negotiating the subject change. Materials associated with the change, including sales tax. The costs of materials shall be substantiated through vendars' invoices. Rental or equivalent rental costs of equipment, including necessary transportation costs if specifically used for the Work. The rental rates shall not exceed the current rental rates prevailing in the locality or as defined in the rental Rate Blue Book for Construction Equipment (a.k.a. DataQuest Blue Book). The rental rate is defned as the full-unadjusted base rental rate for the appropriate item of construction equipment and shall cover the costs of all fuel, supplies, repairs, insurance, and other costs associated with supplying the equipment for work ordered. Contractor-owned equipment will be paid for the duration of time required to complete the work. Utilize lowest cost combination of hourly, daily, weekly, or monthly rates. Do not exceed estimated operating costs given in Blue Book. Operating costs will not be allowed for equipment on stand-by. 4. Additional costs for Bonds, Insurance if required by the City of Clearwater. The following fixed fees shall be added to the costs of the directed work performed by the Contractor or Subcontractor. A. A fixed fee of fifteen percent (15%) shall be added to the costs of Item 1 above. If work is performed by a subcontractor, the Contractor's fee shall not exceed five percent (5%), and the subcontractor's fee shall not exceed ten percent (10%). B. A fixed fee of ten percent (10%) shall be added to the costs of Item 2 above. C. No markup shall be added to the costs of Items 3 and 4 The fixed fees shall be considered the full compensation for all cost of general supervision, overhead, profit, and other general expense. 11.2. ALLOWANCES AND FINAL CONTRACT PRICE ADJUSTMENT It is understood that Contractor has included in the Contract Price all allowances so named in the Contract Documents and shall cause the Work so covered to be furnished and performed for such sums as may be acceptable to Owner and Engineer. Contractor agrees that: (i) the allowances include the cost to Contractor (less any applicable trade discounts) of materials and equipment required by the allowances to be delivered at the Site, and all applicable taxes; and (ii) Contractor's costs for unloading and handling on the site, labor, installation costs, overhead, profit and other expenses contemplated for the allowances have been included in the Contract Price and not in the allowances and no demand for additional payment on account of any of the foregoing will be valid. Prior to final payment, an appropriate Change Order will be issued as recommended by Owner's Representative to reflect actual amounts due Contractor on account of Work covered by SECTION III Page 30 of 49 SECTION III—General Conditions allowances and all the Work actually performed by the Contractor, and the Contract Price shall be correspondingly adjusted. 11.3. UNIT PRICE WORK Where the Contract Documents provide that all or part of the Work is to be Unit Price Work, initially the Contract Price will be deemed to include for all Unit Price Work an amount equal to the sum of the established unit price for each separately identified item of unit price work times the estimated quantity of each item as indicated in the Agreement. The estimated quantities of items of Unit Price Wark are not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Determinations of the actual quantities and classifications of Unit Price Work performed by Contractor will be made by Owner's Representative. Each unit price will be deemed to include an amount considered by Contractor to be adequate to cover Contractar's overhead and profit for each separately identified item. The Owner or Contractor may make a claim for an adjustment in the Contract Price i£ (i) the quantity of any item of Unit Price Work performed by Contractor differs materially and significantly from the estimated quantity of such item indicated in the Contract Documents; and (ii) there is no corresponding adjustment with respect to any other item of Work; and (iii) if Contractor believes that Contractor is entitled to an increase in Contract Price as a result of having incurred additional expense or the Owner believes that the Owner is entitled to a decrease in Contract Price and the parties are unable to agree as to the amount of any such increase or decrease. On unit price contracts, Owner endeavors to provide adequate unit quantities to satisfactorily complete the construction of the project. It is expected that in the normal course of project construction and completion that not all unit quantities will be used in their entirety and that a finalizing change order which adjusts contract unit quantities to those unit quantities actually used in the construction of the project will result in a net decrease from the original Contract Price. Such reasonable deduction of final Contract Price should be anticipated by the Contractor in his original bid. 12. CHANGES IN THE CONTRACT TIME The Contract Time (or Milestones) may only be changed by a Change Order or a Written Amendment. Any claim for an adjustment of the Contract Time (or Milestones) shall be based on written notice delivered by the party making the claim to the other party and to Owner's Representative promptly, but in no event later than thirty (30) days, after the occurrence of the event giving rise to the claim and stating the general nature of the claim. Notice of the extent of the claim with supporting data shall be delivered within sixty (60) days after such occurrence, unless Owner's Representative allows an additional period of time to ascertain more accurate data in support of the claim, and shall be accompanied by the claimant's written statement that the adjustment claimed is the entire adjustment to which the claimant has reason to believe it is entitled as a result of the occurrence of said event. All claims for adjustment in the Contract Time (or Milestones) shall be determined by Owner's Representative. No claim for an adjustment in the Contract Time (or Milestones) will be valid if not submitted in accordance with the requirements of this paragraph. All time limits stated in the Contract Documents are of the essence of the Agreement. Where Contractor is prevented from completing any part of the work within the Contract Time (or Milestones) due to delay beyond the control of Contractor, the Contract Time (or Milestones) may be extended in an amount equal to the time lost due to such delay if a claim is made therefore as provided in the article for Changes in the SECTION III Page 31 of 49 SECTION III—General Conditions Work. Delays beyond the control of Contractor shall include, but not be limited to, acts by the Owner, acts of utility owners or other contractors performing other work as contemplated by the article for Other Work, fires, floods, epidemics, abnormal weather conditions or acts of God. Delays attributable to and within the control of a Subcontractor or Supplier shall be deemed to be delays within the control of Contractor. Where Contractor is prevented from completing any part of the Wark within the Contract Times (or Milestones) due to delay beyond the control of both the Owner and Contractar, an extension of the Contract Time (or Milestones) in an amount equal to the time lost due to such delay shall be Contractor's sole and exclusive remedy for such delay. In no event shall the Owner be liable to Contractor, any Subcontractor, any Supplier, any other person, or to any surety for or employee or agent of any of them, for damages arising out of or resulting from (i) delays caused by or within the control of Contractor, or (ii) delays beyond the control of both parties including but not limited to fires, floods, epidemics, abnormal weather conditions, acts of God or acts by utility owners or other contractors performing other work as contemplated by paragraph for Other Work. 13. TESTS AND INSPECTIONS, CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK 13.1. TESTS AND INSPECTION Contractor shall give Owner's Representative and Engineer timely notice of readiness of the Work for all required inspections, tests or approvals, and shall cooperate with inspection and testing personnel to facilitate required inspections ar tests. Contractor shall employ and pay for the services of an independent testing laboratory to perform all inspections, tests, or approvals required by the Contract Documents. The costs for these inspections, tests or approvals shall be borne by the Contractar except as otherwise provided in the Contract Documents. If Laws or Regulations of any public body having jurisdiction require any Work (or part thereo� specifically to be inspected, tested or approved by an employee or other representative of such public body including all Owner Building Departments and Owner Utility Departments, Contractor shall assume full responsibility for arranging and obtaining such inspections, tests or approvals, pay all costs in connection therewith, and furnish Owner's Representative the required certificates of inspection or approval. Unless otherwise stated in the Contract Documents, Owner permit and impact fees will be waived. Contractor shall also be responsible for arranging and obtaining and shall pay all costs in connection with any inspections, tests or approvals required for Owner's and Engineer's acceptance of materials or equipment to be incorporated in the Work, or of materials, mix designs, or equipment submitted for approval prior to Contractor's purchase thereof for incorporation of the Work. If any Work (or the work of others) that is to be inspected tested or approved is covered by Contractor without written concurrence of Owner's Representative, it must, if requested by Owner's Representative, be uncovered for observation. Uncovering Work as provided in this paragraph shall be at Contractor's expense unless Contractor has given Owner's Representative and Engineer timely notice of Contractor's intention to cover the same and Owner's Representative has not acted with reasonable promptness in response to such notice. SECTION III Page 32 of 49 SECTION III—General Conditions 13.2. UNCOVERING THE WORK If any Wark is covered contrary to the written request of Owner's Representative, it must, if requested by Owner's Representative, be uncovered for Owner Representative's observation and replaced at Contractor's expense. If Owner's Representative considers it necessary or advisable that covered Work be observed by Owner's Representative or inspected or tested by others, Contractar, at Owner Representative's request, shall uncover, expose or otherwise make available for observation, inspection or testing as Engineer or Owner's Representative may require, that portion of the Work in question, furnishing all necessary labor, material and equipment. If it is found that such Work is defective, Contractor shall pay all claims, costs, losses and damages caused by, arising out of or resulting from such uncovering, exposure, observation, inspection and testing and of satisfactory replacement or reconstruction (including but not limited to all costs of repair or replacement of work of others); and the Owner shall be entitled to an appropriate decrease in the Contract Price for the costs of the investigation, and, if the parties are unable to agree as to the amount thereof, may make a claim therefore as provided in the article for Change in Contract Price. If, however, such Work is not found to be defective, Contractor shall be allowed an increase in the Contract Price or an extension of the Contract Time (or Milestones), or both, directly attributable to such uncovering, exposure, observation, inspection, testing, replacement and reconstruction; and, if the parties are unable to agree as to the amount or extent thereof, Contractor may make a claim therefare as provided the article for Change in Contract Price and Change of Contract Time. 13.3. OWNER'S REPRESENTATIVE MAY STOP THE WORK If the Work is defective, or Contractor fails to supply sufficient skilled workers or suitable materials or equipment, or fails to furnish or perform the Work in such a way that the completed Work will conform to the Contract Documents, Engineer or Owner's Representative may order Contractor to stop the Work, or any portion thereof, until the cause far such order has been eliminated; however, this right of Owner's Representative to stop the Work shall not give rise to any duty on the part of Owner's Representative or Owner to exercise this right for the benefit of Contractor or any surety or other party. If the Owner's Representative stops Work under this paragraph, Contractor shall be entitled to no extension of Contract Time or increase in Contract Price. 13.4. CORRECTION OR REMOVAL OF DEFECTIVE WORK If required by Engineer or Owner's Representative, Contractor shall promptly, as directed, either correct all defective Work, whether or not fabricated, installed or completed, or, if the Work has been rejected by Engineer or Owner's Representative, remove it from the site and replace it with Work that is not defective. Contractor shall pay all claims, costs, losses and damages caused by or resulting from such correction or removal (including but not limited to all costs of repair or replacement of work of others). 13.5. WARRANTY/CORRECTION PERIOD If within one year after the date of Substantial Completion or such longer period of time as may be prescribed by Laws or Regulations or by the terms of any applicable special guarantee required by the Contract Documents or by any specific provision of the Contract Documents, any Work is found to be defective, Contractor shall promptly, without cost to the Owner and in accordance with the Owner's written instructions; (i) correct such defective Work, or, if it has been rejected by the SECTION III Page 33 of 49 SECTION III — General Conditions Owner, remove it from the site and replace it with Work that is not defective and (ii) satisfactorily correct or remove and replace any damage to other Work or the work of others resulting therefrom. If Contractar does not promptly comply with the terms of such instructions, or in an emergency where delay would cause serious risk of loss or damage, the Owner may have the defective Work corrected or the rejected. Work removed and replaced, and all claims, costs, losses and damages caused by or resulting from such removal and replacement (including but not limited to all costs of repair or replacement of work of others) will be paid by Contractor. In special circumstances where a particular item of equipment is placed in continuous service before Final Completion of all the Wark, the correction period far that item may start to run from an earlier date if specifically, and expressly so provided in the Specifications or by Written Amendment. Where defective Work (and damage to other Work resulting therefrom) has been corrected, removed or replaced under this paragraph the correction period hereunder with respect to such Work will be extended for an additional period of one year after such correction or removal and replacement has been satisfactorily completed. 13.6. ACCEPTANCE OF DEFECTIVE WORK If, instead of requiring correction or removal and replacement of defective Work, the Owner prefers to accept it, the Owner may do so. Contractor shall pay all claims, costs, losses and damages attributable to the Owner's evaluation of and determination to accept such defective Work such costs to be approved by Owner's Representative as to reasonableness. If any such acceptance occurs prior to Owner Representative's recommendation of final payment, a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Wark; and the Owner shall be entitled to an appropriate decrease in the Contract Price, and, if the parties are unable to agree as to the amount thereof, the Owner may make a claim therefore as provided in article for Change of Contract Price. If the acceptance occurs after the Owner Representative's recommendation for final payment an appropriate amount will be paid by Contractor to the Owner. 13.7. OWNER MAY CORRECT DEFECTIVE WORK If Contractor fails within a reasonable time after written notice from Owner's Representative to correct defective Work or to remove and replace rejected Work as required by Owner's Representative in accordance with the article for Correction and Removal of Defective Work ar if Contractor fails to perform the Work in accardance with the Contract Documents, or if Contractor fails to comply with any other provision of the Contract Documents, the Owner may, after seven days' written notice to Contractor, correct and remedy any such deficiency. In exercising the rights and remedies under this paragraph the Owner shall proceed expeditiously. In connection with such corrective and remedial action, the Owner may exclude Contractor from all or part of the site, take possession of all or part of the Work, and suspend Contractor's services related thereto, and incorporate in the Work all materials and equipment stored at the site or for which the Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Owner's Representatives, Agents and employees, the Owner's other contractors, and Owner's Representative, Engineer, and Engineer's Consultants access to the site to enable the Owner to exercise the rights and remedies under this paragraph. All claims, costs, losses and damages incurred or sustained by the Owner in exercising such rights and remedies will be charged against Contractor and a Change Order will be issued incorporating the necessary revisions in the Contract SECTION Iii Page 34 of 49 SECTION III — General Conditions Documents with respect to the Work; and the Owner shall be entitled to an appropriate decrease in the Contract Price, and, if the parties are unable to agree as to the amount thereof, the Owner may make a claim therefore as provided in the article for Change of Contract Price. Such claims, costs, losses and damages will include but not be limited to all costs of repair or replacement of work of others destroyed or damaged by correction, removal or replacement of Contractor's defective Work. Contractor shall not be allowed an extension of the Contract Time (or Milestones) because of any delay in the performance of the Wark attributable to the exercise by the Owner of the Owner's rights and remedies hereunder. 14. PAYMENTS TO CONTRACTOR AND COMPLETION Requests for payment shall be processed in accordance with F.S. 218.735 and as described herein. Progress payments on account of Unit Price Work will be based on the number of units completed. 14.1. APPLICATION FOR PROGRESS PAYMENT Contractor shall submit (not mare often than once a month) to Owner's Representative for review an Application for Payment iilled out and signed by Contractor covering the Work completed once each month and accompanied by such supporting documentation as is required by the Owner's Representative and the Contract Documents. Unless otherwise stated in the Contract Documents or pre-approved by Owner, payment will not be made for materials and equipment not incorporated in the Work. Payment will only be made for that portion of the Work, which is fully installed including all materials, labor and equipment. A retainage of not less than five (5%) of the amount of each Application for Payment for the total of all Work, including as-built survey and Inspector overtime reimbursement, completed to date will be held until final completion and acceptance of the Work covered in the Contract Documents. No progress payment shall be construed to be acceptance of any portion of the Work under contract. The Contractor shall review with the Engineer or the Construction Inspectar all quantities and work for which payment is being applied for and reach agreement prior to submittal of an Official Pay Request. The Engineer or the Construction Inspector will verify that the on-site marked up as- built drawings are up to date with the work and are in compliance with the Contract Documents. In addition to all other payment provisions set out in this contract, the Owner's Representative may require the Contractor to produce for Owner, within fifteen (15) days of the approval of any progress payment, evidence and/or payment affidavit that all subcontractors and suppliers have been paid any sum or sums then due. A failure on the part of the contractor to provide the report as required herein shall result in further progress ar partial payments being withheld until the report is provided. 14.2. CONTRACTOR'S WARRANTY OF TITLE Contractor warrants and guarantees that title to all Wark, materials and equipment covered by any Application for Payment, whether incorporated in the Project or not, will pass to the Owner no later than the time of payment, free and clear of liens. No materials or supplies far the Wark shall be purchased by Contractor or Subcontractor subject to any chattel mortgage or under a conditional sale contact or other agreement by which an interest is retained by the seller. Contractor warrants that he has good title to all materials and supplies used by him in the Work, free from all liens, claims or encumbrances. Contractor shall indemnify and save the Owner harmless from all claims growing out of the lawful demands of Subcontractors, laborers, workmen, mechanics, materialmen, and furnishers of machinery and parts thereof, equipment, power tools, and all SECTION III Page 35 of 49 SECTION III — General Conditions supplies incurred in the furtherance of the performance of this Contract. Contractor shall at the Owner's request, furnish satisfactory evidence that all obligations of nature hereinabove designated have been paid, discharged, or waived. If Contractor fails to do so, then the Owner may, after having served written notice on said Contractor either pay unpaid bills, of which the Owner has written notice, or withhold from the Contractor's unpaid compensation a sum of money deemed reasonably sufficient to pay any and all such lawful claims until satisfactory evidence is furnished that all liabilities have been fully discharged, whereupon payment to Contractar shall be resumed in accordance with the terms of this Contract, but in no event shall the provisions of this sentence be construed to impose any obligations upon the Owner to the Contractar or the Surety. In paying any unpaid bills of the Contractor, the Owner shall be deemed the agent of Contractor and any payment so made by the Owner shall be considered as payment made under the Contract by the Owner to Contractor, and the Owner shall not be liable to Contractor for any such payment made in good faith. 14.3. REVIEW OF APPLICATIONS FOR PROGRESS PAYMENTS The Owner's Representative will within twenty (20) business days after receipt autharize and process payment by the Owner a properly submitted and documented Application for payment, unless the application requires review by an Agent. If the Application for payment requires review and approval by an Agent, properly submitted and documented Applications for payment will be paid by the Owner within twenty-five (25) business days. If an Application for payment is rejected, notice shall be given within twenty (20) business days of receipt indicating the reasons for refusing payment. The reasons for rejecting an Application will be submitted in writing, specifying deficiencies and identifying actions that would make the Application proper. In the latter case, Contractar may make the necessary corrections and resubmit the Application. The Owner's Representative or Agent may refuse to recommend the whole or any part of any payment to Owner. Owner's Representative or Agent may also refuse to recommend any such payment, or, because of subsequently discovered evidence or the results of subsequent inspections ar test, nullify any such payment previously recommended, to such extent as may be necessary in Owner Representative's or Agent's opinion to protect the Owner from loss because: (i) the Work is defective, or completed Work has been damaged requiring correction or replacement, (ii) the Contract Price has been reduced by amendment or Change Order, (iii) the Owner has been required to correct defective Work or complete Work, ar(iv) Owner's Representative or Agent has actual knowledge of the occurrence of any of the events enumerated in the article on Suspension of Work and Termination. The Owner may refuse to make payment of the full amount recommended by the Owner's Representative or Agent because: (i) claims have been made against the Owner on account of Contractar's performance or furnishing of the Work, (ii) Liens have been filed in connection with the Wark, except where Contractor has delivered a specific Bond satisfactory to the Owner to secure the satisfaction and discharge of such Liens, (iii) there are other items entitling the Owner to a set-off against the amount recommended, or (iv) the Owner has actual knowledge of any of the events described in this paragraph. The Owner shall give Contractor notice of refusal to pay in accordance with the time constraints of this section with a copy to the Owner's Representative or Agent, stating the reasons for such actions, and Owner shall promptly pay Contractor the amount so withheld, or any adjustment thereto agreed to by the Owner and Contractor, when Contractor corrects to the Owner's satisfaction the reasons for such action. SECTION III Page 36 of 49 SECTION III—General Conditions 14.4. PARTIAL UTILIZATION Use by the Owner at the Owner's option of any substantially completed part of the Work which (i) has specifically been identified in the Contract Documents, or (ii) Owner, Engineer, Owner's Representative, and Contractor agree constitutes a separately functioning and usable part of the Work that can be used by the Owner for its intended purpose without significant interference with Contractor's performance of the remainder of the Work, may be accomplished prior to Final Completion of all the Work subject to the following: The Owner at any time may request Contractor in writing to permit the Owner to use any such part of the Work which the Owner believes to be ready for its intended use and substantially complete. If Contractor agrees that such part of the Work is substantially complete, Contractor will certify to Owner, Owner's Representative, and Engineer that such part of the Work is substantially complete and request Owner's Representative to issue a certificate of Substantial Completion for that part of the Work. Contractor at any time may notify Owner, Owner's Representative, and Engineer in writing that Contractor considers any such part of the Work ready for its intended use and substantially complete and request Owner's Representative to issue a certificate of Substantial Completion for that part of the Work. Within a reasonable time after either such request, Owner, Contractor, Owner's Representative, and Engineer shall make an inspection of that part of the Work to determine its status of completion. If Engineer does not consider that part of the Work to be substantially complete, Engineer will notify Owner, Owner's Representative, and Contractor in writing giving the reasons therefore. If Engineer considers that part of the Work to be substantially complete, the provisions of the articles for Substantial Completion and Partial Utilization will apply with respect to certification of Substantial Completion of that part of the Work and the division of responsibility in respect thereof and access thereto. 14.5. FINAL INSPECTION Upon written notice from Contractor that the entire Work or an agreed portion thereof is complete, Owner's Representative will make a final inspection with Engineer, Owner and Contractor and will within thiriy (30) days notify Contractor in writing of particulars in which this inspection reveals that the Work is incomplete or defective. The Owner's Representative will produce a final punch list, deliver it to the Contractar within five (5) days of completion and assign a date for this work to be completed not less than thirty (30) days from delivery of the list. Failure to include any corrective work or pending items does not alter the responsibility of the contractor to complete all the construction services purchased pursuant to the contract. Contractor shall immediately take such measures as are necessary to complete such Work or remedy such deficiencies. 14.6. FINAL APPLICATION FOR PAYMENT After Contractor has completed all such corrections to the satisfaction of Owner's Representative and has delivered in accardance with the Contract Documents all maintenance and operating instructions, As-built/Record Drawings, schedules, guarantees, Bonds, certificates or other evidence of insurance required by the paragraph for Bonds and Insurance, certificates of inspection, Inspector overtime reimbursement as required in the Contract Documents and other documents, Contractar may make application for final payment following the procedure for progress payments. The final Application for Payment shall be accompanied (except as previously delivered) by: (i) all documentation called for in the Contract Documents, including but not limited to the evidence of insurance required by paragraph for Bonds and Insurance, and (ii) executed SECTION III Page 37 of 49 SECTION III — General Conditions consent of the surety to final payment using the form contained in Section V of the Contract Documents. Prior to application far final payment, Contractor shall clean and remove from the premises all surplus and discarded materials, rubbish, and temporary structures, and shall restore in an acceptable manner all property, both public and private, which has been damaged during the prosecution of the Work and shall leave the Work in a neat and presentable condition. 14.7. FINAL PAYMENT AND ACCEPTANCE If through no fault of Contractor, final completion of the Work is significantly delayed and if Owner's Representative so confirms, the Owner shall, upon receipt of Contractor's final Application for payment and recommendation of Owner's Representative, and without terminating the Agreement, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance to be held by the Owner for Work not fully completed or corrected is less than the retainage stipulated in the Agreement, and if Bonds have been furnished as required in paragraph for Bonds and Insurance, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by Contractor to Owner's Representative with the Application for such payment. Such payment shall be made under the terms and conditions governing final payment, except that such payment shall not constitute a waiver of claims. If on the basis of Owner Representative's observation of the Work during construction and final inspection, and Owner Representative's review of the final Application for Payment and accompanying documentation, all as required by the Contract Documents, Owner's Representative is satisfied that the Work has been completed and Contractor's other obligations under the Contract Documents have been fulfilled, Owner's Representative will indicate in writing his recommendation of payment and present the Application to Owner for payment. Thereupon, Owner's Representative will give written notice to Owner and Contractor that the Work is acceptable subject to the provisions of this article. Otherwise, Owner's Representative will return the Application to Contractor, indicating in writing the reasons for refusing to recommend final payment, in which case Contractor shall make the necessary corrections and resubmit the Application. If the Application and accompanying documentation are appropriate as to form and substance, the Owner shall, within twenty (20) days after receipt thereof pay contractor the amount recommended by Owner's Representative. 14.8. WAIVER OF CLAIMS The making and acceptance of final payment will constitute: a waiver of all claims by the Owner against Contractor, except claims arising from unsettled Liens, from defective Work appearing after final inspection, from failure to comply with the Contract Documents or the terms of any special guarantees specified therein, or from Contractor's continuing obligations under the Contract Documents; and a waiver of all claims by Contractor against the Owner other than those previously made in writing and still unsettled. 15. SUSPENSION OF WORK AND TERMINATION 15.1. OWNER MAY SUSPEND THE WORK At any time and without cause, Owner's Representative may suspend the Work or any portion thereof for a period of not more than ninety (90) days by notice in writing to Contractor, which SECTION III Page 38 of 49 SECTION III — General Conditions will fix the date on which Wark will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be allowed an adjustment in the Contract Price or an extension of the Contract Times, or both, directly attributable to any such suspension if Contractor makes an approved claim therefore as provided in the articles for Change of Contract Price and Change of Contract Time. 15.2. OWNER MAY TERMINATE Upon the occurrence of any one or more of the following events; if Contractor persistently fails to perform the work in accordance with the Contract Documents (including, but not limited to, failure to supply sufficient skilled workers or suitable materials or equipment or failure to adhere to the progress schedule as adjusted from time to time); if Contractor disregards Laws and Regulations of any public body having jurisdiction; if Contractar disregards the autharity of Owner's Representative; if Contractor otherwise violates in any substantial way any provisions of the Contract Documents; or if the Work to be done under this Contract is abandoned, ar if this Contract or any part thereof is sublet, without the previous written consent of the Owner, or if the Contract or any claim thereunder is assigned by Contractor otherwise than as herein specified, or at any time Owner's Representative certifies in writing to the Owner that the rate of progress of the Work or any part thereof is unsatisfactory or that the wark ar any part thereof is unnecessarily or unreasonably delayed. The Owner may, after giving Contractor (and the surety, if any), seven days' written notice and, to the extent permitted by Laws and Regulations, terminate the services of Contractor, exclude Contractor from the site and take possession of the Work and of all Contractor's tools, appliances, construction equipment and machinery at the site and use the same to the full extent they could be used by Contractar (without liability to Contractor for trespass or conversion), incorporate in the Work all materials and equipment stored at the site or for which the Owner has paid Contractor but which are stored elsewhere, and finish the Work as the Owner may deem expedient. In such case Contractor shall not be entitled to receive any further payment until the Work is finished. If the unpaid balance of the Contract Price exceeds all claims, costs, losses and damages sustained by the Owner arising out of or resulting from completing the Work such excess will be paid to Contractor. If such claims, costs, losses and damages exceed such unpaid balance, Contractor shall pay the difference to the Owner. Such claims, costs, losses and damages incurred by the Owner will be reviewed by Owner's Representative as to their reasonableness and when so approved by Owner's Representative incorporated in a Change Order, provided that when exercising any rights ar remedies under this paragraph the Owner shall not be required to obtain the lowest price for the Work performed. Where Contractor's services have been so terminated by the Owner, the termination will not affect any rights or remedies of the Owner against Contractor then existing or which may thereafter accrue. Any retention or payment of moneys due Contractor by the Owner will not release Contractor from liability. Upon seven (7) days' written notice to Contractor and Owner's Representative, the Owner may, without cause and without prejudice to any other right or remedy of the Owner, elect to terminate the Agreement. In such case, Contractor shall be paid (without duplication of any items): SECTION III Page 39 of 49 SECTION III—General Conditions for completed and acceptable Wark executed in accordance with the Contract Documents prior to the effective date of termination, including fair and reasonable sums far overhead and profit on such Work; for expenses sustained prior to the effective date of termination in performing services and furnishing labor, materials ar equipment as required by the Contract Documents in connection with uncompleted Work, plus fair and reasonable sums for overhead and profit on such expenses; for all claims, costs, losses and damages incurred in settlement of terminated contracts with Subcontractors, Suppliers and others; and for reasonable expenses directly attributable to termination. Contractor shall not be paid on account of loss of anticipated profits or revenue ar other economic loss arising out of or resulting from such termination. 15.3. CONTRACTOR MAY STOP WORK OR TERMINATE If, through no act or fault of Contractor, the Wark is suspended for a period of more than ninety (90) days by the Owner or under an order of court or other public authority, or the Owner's Representative fails to act on any Application for Payment within thirty (30) days after it is submitted or the Owner fails for thirty (30) days to pay Contractor any sum finally determined to be due, then Contractor may, upon seven (7) days' written notice to the Owner and Owner's Representative, and provided the Owner or Owner's Representative does not remedy such suspension ar failure within that time, terminate the Agreement and recover from the Owner payment on the same terms as provided in the article for the Owner May Terminate. However, if the Work is suspended under an order of court through no fault of Owner, the Contractor shall not be entitled to payment except as the Court may direct. In lieu of terminating the Agreement and without prejudice to any other right or remedy, if Owner's Representative has failed to act on an Application for Payment within thiriy (30) days after it is submitted, or the Owner has failed for thirty (30) days to pay Contractor any sum finally determined to be due, Contractor may upon seven (7) days' written notice to the Owner and Owner's Representative stop the Work until payment of all such amounts due Contractor. The provisions of this article are not intended to preclude Contractor from making claim under paragraphs for Change of Contract Price or Change of Contract Time or otherwise for expenses or damage directly attributable to Contractor's stopping Work as permitted by this article. 16. DISPUTE RESOLUTION If and to the extent that the Owner and Contractor have agreed on the method and procedure for resolving disputes between them that may arise under this Agreement, such dispute resolution method and procedure will proceed. If no such agreement on the method and procedure for resolving such disputes has been reached, subject to the provisions of the article for Decisions on Disputes, the Owner and Contractor may exercise such rights or remedies as either may otherwise have under the Contract Documents or by Laws or Regulations in respect of any dispute provided, however, that nothing herein shall require a dispute to be submitted to binding arbitration. SECTION III Page 40 of 49 SECTION III—General Conditions 17. MISCELLANEOUS 17.1. SUBMITTAL AND DOCUMENT FORMS The form of all submittals, notices, change orders, pay applications, logs, schedules and other documents permitted or required to be used or transmitted under the Contract Documents shall be determined by the Owner's Representative subject to the approval of Owner. 17.2. GIVING NOTICE Whenever any provision of the Contract Documents requires the giving of written notice, notice will be deemed to have been validly given if delivered in person to the individual ar to a member of the firm or to an officer of the corparation for whom it is intended, or if delivered or sent by registered ar certified mail, postage prepaid, to the last business address known to the giver of the notice. 17.3. NOTICE OF CLAIM Should the Owner ar Contractar suffer injury ar damage to person ar property because of any error, omission or any act of the other party or of any of the other party's officers, employees or agents or others for whose acts the other party is legally liable, claim will be made in writing to the other party within a reasonable time of the first observance of such injury or damage. The provisions of this paragraph shall not be construed as a substitute for ar a waiver of.the provisions of any applicable statute of limitations or repose. 17.4. PROFESSIONAL FEES AND COURT COSTS INCLUDED Whenever reference is made to "claims, costs, losses and damages," the phrase shall include in each case, but not be limited to, all fees and charges of engineers, architects, attorneys and other professionals and all court or other dispute resolution costs. 17.5. ASSIGNMENT OF CONTRACT The Contractor shall not assign this contract or any part thereof or any rights thereunder without the approval of Owner, nor without the consent of surety unless the surety has waived its rights to notice of assignment. 17.6. RENEWAL OPTION Annual Contracts issued through the Engineering Department may be renewed for up to three (3) years, upon mutual consent of both the Owner and the Contractor/Vendor. All terms, conditions and unit prices shall remain constant unless otherwise specified in the contract specifications or in the Invitation to bid. Renewals shall be made at the sole discretion of the Owner and must be agreed to in writing by both parties. All renewals are contingent upon the availability of funds, and the satisfactory performance of the Contractor as determined by the Construction Department. 17.7. ROLL-OFF CONTAINERS AND/OR DUMPSTERS All City construction projects shall utilize City of Clearwater Solid Waste roll-off containers and/or dumpsters for their disposal and hauling needs. For availability or pricing contact William SECTION III Page 41 of 49 SECTION III—General Conditions Buzzell, at the City of Clearwater, Solid Waste Department, by phone: (727) 562-4929 or email: W illiam.Buzzell(a�myClearwater. com. 18. ORDER AND LOCATION OF THE WORK The City reserves the right to accept and use any portion of the work whenever it is considered to the public interest to do so. The Engineer shall have the power to direct on what line or street the Contractor shall work and order thereof. 19. MATERIAL USED All material incorporated into the iinal work shall be new material unless otherwise approved by the Engineer. If requested by the Engineer, the Contractor shall furnish purchase receipts of all materials. 20. CONFLICT BETWEEN PLANS AND SPECIFICATIONS The various Contract Documents shall be given precedence, in case of conflict, error or discrepancy, as follows: Modifications, Contract Agreement, Addenda, Supplementary General Conditions, General Conditions, Supplementary Technical Specifications and Technical Specifications. In a series of Modifications or Addenda the latest will govern. In the case of an inconsistency between Drawings and Specifications or within either pocument not clarified by addendum, the better quality, more stringent or greater quantity of Work shall be provided in accordance with the Engineer/Architect's interpretation. 21. OWNER DIRECT PURCHASE (ODP) 21.1. SALES TAX SAVINGS The Owner reserves the right to purchase certain portions of the materials or equipment for the Project directly in order to save applicable sales tax in compliance with Florida Law since owner is exempt from the payment of sales tax. The contract price includes Florida sales and other applicable taxes for materials, supplies, and equipment which will be a part of the Contractor's Work. Owner-purchasing of construction materials or equipment, if selected, will be administered on a deductive Change Order basis. The contract price shall be reduced by the actual cost of the materials or equipment purchased by owner plus the normally applicable sales tax, even if the actual cost is in excess of the cost for the materials or equipment as-bid by the Contractor. For purposes of calculating engineering fees, contractor fees, architects' fees, and any other amounts that are based on the contract amount, however, the ariginal, as-bid contract amount shall be used. Direct purchase shall be considered for single items or materials that exceed $10,000 in value and/or items identified in Section V, Bidders Proposal. The Contractor shall provide the Owner an ODP Summary of all intended suppliers, vendors, equipment and materials for consideration as ODP materials or equipment (refer to ODP Instructions in Contract Appendix). 21.2. TITLE AND OWNER RISK Owner will issue Purchase Orders and provide a copy of Owner's Florida Consumer Certification of Tax Exemption and Certificate of Entitlement directly to the Vendor for ODP materials or SECTION III Page 42 of 49 SECTION III — General Conditions equipment. Invoices for ODP materials or equipment shall be issued to the Owner, and a copy sent to the Contractor. Notwithstanding the transfer of ODP materials or equipment by the Owner to the Contractor's possession, the Owner shall retain legal and equitable title to any and all ODP materials or equipment; therefore, the owner assumes the risk of damage or loss at the time of purchase or delivery of items, unless material is damaged as the result of negligence by the Contractor. 21.3. CONTRACTOR'S RECEIPT OF MATERIALS The Contractor shall be fully responsible for all matters relating to the receipt of materials or equipment furnished to the Owner including, but not limited to, verifying correct quantities, verifying documents of arders in a timely manner, coardinating purchases, providing and obtaining all warranties and guarantees required by the Contract Documents, and inspection and acceptance of the goods at the time of delivery. The Owner shall coordinate with Contractor and Vendor delivery schedules, sequence of delivery, loading orientation, and other arrangements normally required by the Contractar for the particular materials ar equipment furnished. The Contractar shall provide all services required for the unloading and handling of materials or equipment. The Contractar agrees to indemnify and hold harmless the Owner from any and all claims of whatever nature resulting from non-payment of goods to suppliers arising from the action of the Contractor. As ODP materials or equipment are delivered to the job site, the Contractar shall visually inspect all shipments from the suppliers and approve the vendor's invoice for items delivered. The Contractor shall assure that each delivery of ODP materials or equipment is accompanied by documentation adequate to identify the Purchase Order against which the purchase is made. This documentation may consist of a delivery ticket and/or an invoice from the supplier conforming to the Purchase Order together with such additional information as the Owner may require. The Contractar will then forward an electronic copy of the invoice and supporting documentation to the Owner for payment within fourteen (14) calendar days of receipt of said goods or materials. Such payment shall be directly from public funds, from Owner to Vendor. The Contractor shall insure that ODP materials or equipment conform to the Specifications and determine prior to acceptance of goods at time of delivery if such materials or equipment are patently defective, and whether such materials or equipment are identical to the materials or equipment ordered and match the description on the bill of lading. If the Contractor discovers defective or non-conformities in ODP materials or equipment upon such visual inspection, the Contractor shall not utilize such nonconforming or defective materials or equipment in the Contractor's Work and instead shall properly notify the Owner of the defective or nonconforming condition so that repair or replacement of those materials or equipment can occur without undue delay or interruption to the Project. If the Contractor fails to perform such inspection and otherwise incorporates into the Contractor's Work such defective or nonconforming ODP materials or equipment, the condition of which it either knew or should have known by performance of an inspection, Contractor shall be responsible for all damages to the Owner, resulting from Contractar's incorporation of such materials or equipment into the Project, including liquidated damages. 21.4. ODP RECORDS, WARRANTIES AND INDEMNIFICATION The Contractar shall maintain records of all ODP materials or equipment it incorparates into Contractor's Work from the stock of ODP materials or equipment in its possession. The Contractor shall account monthly to the Owner far any ODP materials ar equipment delivered into the SECTION III Page 43 of 49 SECTION III — General Conditions Contractar's possession, indicating portions of all such materials or equipment which have been incorporated in the Contractor's Wark. The Contractor shall be responsible far obtaining and managing all warranties and guarantees for all materials, equipment and products as required by the Contract Documents. All repair, maintenance, or damage-repair calls shall be forwarded to the Contractor for resolution with the appropriate supplier, vendor, or subcontractor. The Owner shall indemnify and hold Contractor harmless from any sales tax (and interest and penalties incurred in connection therewith) in the event there is a final determination that purchases made by Owner, which Owner treats as being exempt from sales tax, are subject to sales tax. "Final determination" shall mean an assessment by the Department of Revenue that is no longer subject to protest, or a determination of a court having jurisdiction over such matters that is final and not subject to appeal. Contractor agrees to promptly notify owner of any audit, assessment, proposed assessment or notice of deficiency issued with regard to the Project and relating to ODP materials or equipment. ODP Purchase Orders must be closed out prior to closing out the contract/Contractor Purchase Order. If material costs needed far project exceed the ODP Purchase Order amount, the ODP Purchase Order will not be increased. Amounts in excess of the ODP Purchase Order will be paid for by the Contractor. 22. RESIDENT NOTIFICATION OF START OF CONSTRUCTION 22.1. GENERAL The Contractor shall notify all residents along the construction route or within a 500-foot radius, unless stated otherwise in the Contract Documents, with a printed door hanger notice indicating the following information about the proposed construction work and the Contractor performing the work: City seal or logo; the scheduled date for the start of construction; the type of construction; general sequence and scheduling of construction events; possibility of water service disruption and/or colored water due to construction efforts; Contractor's name, the Superintendent's name, Contractar address and telephone number; Contractor's company logo (optional); requirement for residents to remove landscaping and/or other private appurtenances which are in conflict with the proposed construction; and other language as appropriate to the scope of Contract wark. Sample door hanger including proposed language shall be approved by the City prior to the start of construction. Notification shall be printed on brightly colored and durable card stock and shall be a minimum of 4-'/a by 11 inches in size. Notification (door hanger) shall be posted to residences and businesses directly affected by the Contractor's activities no later than seven (7) days prior to the start of construction activity. Directly affected by the Contractor's activities shall mean all Contractor operations including staging areas, equipment and material storage, principal access routes across private property, etc. Contractor cannot start without proper seven (7) day notice period to residents. Contractar is required to maintain sufficient staff to answer citizen inquiries during normal business hours and to maintain appropriate message recording equipment to receive citizen inquires after business hours. Resident notification by the Contractor is a non-specific pay item to be included in the bid items provided in the contract proposal. SECTION III Page 44 of 49 22.2. EXAMPLE SECTION III — General Conditions .� � _ � �� � BRIGHT AND BEAUTIFUL • BAY TO BEACH NOTICE OF CONSTRUCTION TODAY' S DATE: / / PLEASE EXCUSE US FOR ANY INCONVENIENCE We are the construction contractor performing the (state project name) for the City of Clearwater in your area. The wark will be performed in the public right-of-way adjacent to your property. This notice is placed a minimum of seven (7) days in advance of construction to notify property owners of the pending start of construction. (BYief description of the construction process to be expected by the property owners) The construction process may necessitate the removal of certain items from the right-of-way. Typical items such as sprinklers, grass, and postal approved mailboxes will be replaced by the contractor within a reasonably short period of time. The replacement of driveways and sidewalks will be made using standard asphalt or concrete materials. The property owner is responsible for the expense and coordination to replace driveways and sidewalks which have customized colors, textures and/or materials. Small trees, shrubs, landscaping materials, unauthorized mailboxes or structures within the right-of-way which must be removed due to the construction process will not be replaced. The property owner is responsible to relocate any such items which the property owner wishes to save prior to the start of construction. Vehicles parked on the streets ar within the right- of-way may be required to be placed elsewhere. We are available to answer any questions you may have regarding the construction process or any particular item that must be relocated. Please contact our Construction Manager at (727) . We will be more than happy to assist you. Construction is anticipated to begin on: Company Name Company Address Contractor Phone Number 23. PROJECT INFORMATION SIGNS 23.1. SCOPE AND PURPOSE The Owner desires to inform the general public on the Owner's use and expenditure of public funding for general capital improvement and maintenance projects. To help accomplish this purpose, the Contractor is required to prepare and display public project information signs during the full course of the contract period. These signs will be displayed at all location(s) of active work. Payment to Contractor for the preparation, installation and management of project sign(s) shall be SECTION III Page 45 of 49 SECTION III — General Conditions included in the cost of the work. The number of and type of signs will be stated in SECTION IV, SCOPE OF WORK. 23.2. PROJECT SIGN, FIXED OR PORTABLE Sign type shall be "fixed" on stationary projects and "portable" on projects which have extended locations or various locations. The particular wording to be used on the signs will be determined after contract award has been approved. Contractor will be provided the wording to be used on sign at the preconstruction conference. 23.3. FIXED SIGN Fixed sign shall be 4-foot by 6-foot (4'x6') in size and painted on a sheet of exterior grade plywood of the same size and a minimum thickness of 1/2-inches. Sign shall be attached to a minimum of two (2) 4-inch by 4-inch (4"x4") below grade pressure treated (P.T.) wooden posts and braced as necessary for high winds. Posts shall be long enough to provide secure anchoring in the ground. Bottom of sign must be a minimum of 24-inches above the ground. Alternate mounting system or attachment to fencing or other fixed structure can be considered for approval. Sign shall be painted white on both sides with exterior rated paint. 23.4. PORTABLE SIGNS Portable sign shall be a minimum of 24-inches by 30-inches (24"x30") in size and will be attached to a standard sized portable traffic barricade. Sign material shall be aluminum, 0.080-inches or thicker, background of white reflective sheeting, and shall be silkscreen or vinyl lettering. Portable sign shall be two signs located and attached to each side of the traffic barricade. 23.5. SIGN COLORING Background shall be white. Project Descriptive Name shall be in blue lettering. All other lettering shall be black. Basic lettering on sign shall be in all capital letters, of size proportional to the sign itsel£ Each sign shall depict the City's logo. The Project Manager/City Representative shall provide the appropriate electronic logo file(s) to the Contractor. 23.6. SIGN PLACEMENT Signs shall be placed where they are readily visible by the general public which pass by the project site. Signs are not to be placed where they may become a hazard or impediment to either pedestrian or vehicular traffic. For construction projects outside of the Owner's right-of-way, the signs will be placed on the project site. For projects constructed inside of the Owner's right-of-way, the signs will be placed in the right-of-way. Portable signs are to be moved to the locations of active work on the project. Multiple portable signs will be necessary where work is ongoing in several locations at the same time. Fixed signs are to be placed at the start of construction and will remain in place until the request for final payment. 23.7. SIGN MAINTENANCE The Contractor is responsible for preparation, installation, movement, maintenance, replacement, removal and disposal of all project signs during the full course of the contract period. The Contractor will place and secure portable signs from dislocation by wind or other actions. Signs are to be cleaned as necessary to maintain legibility and immediately replaced if defaced. SECTION III Page 46 of 49 SECTION III — General Conditions 23.8. TYPICAL PROJECT SIGN � <PROJECT NAME> <CONTRACT NUMBER> <DEPARTMENT NAME> PROJECT ; N CONTRACTOR: � COMPLETION DATE: a FUNDING: OWNER'S REPRESENTATIVE: � . ��n�_� � ����� �� � :� � ���� BItIGHT AND BEAUTI FUL • BAY TO BEACH � , 3,�1�4,� r � ,c 4"x4"P.L � Post (Typ.) E � �E N ' 1 . . . . . . . . � . .� � f ,. . . . . ' . I �. . 4 � I ' i � 24. AWARD OF CONTRACT, WORK SCHEDULE AND GUARANTEE It will be required that the work will commence not later than five (5) calendar days after the Engineer gives written Notice to Proceed (NTP), which notice shall be given as outlined in Article 2 of these General Conditions. It is further required that all work within this contract be completed within the indicated number of consecutive calendar days as determined in Section IV, Scope of Work. Contract Time to commence at start date noted on the Notice to Proceed. If the Contractor fails to complete the work within the stipulated time, the City will retain the amount stated in the Contract, per calendar day, for each day that the contract remains incomplete. The work shall be discontinued on Saturdays, Sundays, and approved Holidays. If it becomes necessary for the Contractor to perform work on Saturdays, Sundays, and approved City of Clearwater Employee Holidays, that in the opinion of the Engineer, will require the presence of Inspectors, the Contractor shall pay the City of SECTION III Page 47 of 49 SECTION III — General Conditions Clearwater, Florida, the amount of Four Hundred Eighty Dollars ($480.00) per each eight-hour (8) day for each Inspector given such assignment. The Contractor shall remedy any defects in the work at his own expense and pay for any damage to other work resulting therefrom which appear within a period of one (1) year from the date of final acceptance. 25. SCRUTINIZED COMPANIES AND BUSINESS OPERATIONS WITH CUBA AND SYRIA CERTIFICATION FORM AND ISRAEL CERTIFICATION FORM Pursuant to Section 287.135, Florida Statutes, any vendor, company, individual, principal, subsidiary, affiliate, ar owner on the Scrutinized Companies with Activities in Sudan List, the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List, or is engaged in business operations in Cuba or Syria, is ineligible for, and may not bid on, submit a proposal for, or enter into or renew a contract with the City of Clearwater for goods or services for an amount equal to or greater than one million ($1,000,000.00) dollars. Any vendor, company, individual, principal, subsidiary, affiliate, or owner on the Scrutinized Companies that Boycott Israel List, or is engaged in a boycott of Israel, is ineligible for, and may not bid on, submit a proposal for, or enter into or renew a contract with the City of Clearwater for goods or services for ANY amount. Each entity submitting a bid, proposal, or response to a solicitation must certify to the City of Clearwater that it is not on the aforementioned lists, ar engaged in business operations in Cuba or Syria, or engaged in a boycott of Israel at the time of submitting a bid, proposal or response, in accordance with Section 287.135, Florida Statutes. Business Operations means, for purposes speciiically related to Cuba or Syria, engaging in commerce in any form in Cuba or Syria, including, but not limited to, acquiring, developing, maintaining, owning, selling, possessing, leasing ar operating equipment, facilities, personnel, products, services, personal property, real property, military equipment, or any other apparatus of business or commerce. Boycott Israel or boycott of Israel means refusing to deal, terminating business activities, or taking other actions to limit commercial relations with Israel, or persons or entities doing business in Israel or in Israeli- controlled territories, in a discriminatory manner. A statement by a company that it is participating in a boycott of Israel, or that it has initiated a boycott in response to a request for a boycott of Israel or in compliance with, or in furtherance of, calls for a boycott of Israel, may be considered as evidence that a company is participating in a boycott of Israel. The certification forms (the Certiiication) are attached hereto, and must be submitted, along with all other relevant contract documents, at the time of submitting a bid, proposal, or response. Failure to provide the Certification may deem the entity's submittal non-responsive. If the City of Clearwater determines that an entity has submitted a false certification form, been placed on the Scrutinized Companies with Activities in Sudan List or the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List ar the Scrutinized Companies that Boycott Israel List, or engaged in business operations in Cuba or Syria, or engaged in a boycott of Israel, then the contract may be terminated at the option of the City of Clearwater. Other than the submission of a false certification, the City of Clearwater, on a case-by-case basis and in its sole discretion, may allow a company to bid on, submit a proposal for, or enter into or renew a contract for goods or services, if the conditions set forth in Section 287.135, Florida Statutes, apply. The City retains the right to pursue civil penalties and any other applicable rights and remedies as provided by law for the false submission of the attached certification forms. SECTION III Page 48 of 49 SECTION III — General Conditions See Section V of the Contract for Certification Forms to be executed and submitted with the Bid/Proposal Form. SECTION III Page 49 of 49