PUBLIC WORK PERFORMANCE AND PAYMENT BOND FRONT PAGEI #: 2016279605 BK: 19337 PG: 2436, 09/12/2016 at 02:36 PM, RECORDING 4 PAGES
,,$35.59 KEN BURKE, CLERK OF COURT AND COMPTROLLER PINELLAS COUNTY, FL BY
DEPUTY CLERK: CLKDU10
PUBLIC WORK PERFORMANCE AND PAYMENT BOND FRONT PAGE
"This bond is given to comply with Section 255.05 Florida Statutes, and any action
instituted by a claimant under this bond for payment must be in accordance with the
notice and time limitation provisions in Section 255.05(2), Florida Statutes."
BOND NO.:
CONTRACTOR NAME:
CONTRACTOR ADDRESS:
CONTRACTOR PHONE NO.:
SURETY COMPANY:
SURETY COMPANY ADDRESS:
SURETY COMPANY PHONE NO.:
SURETY AGENT:
SURETY AGENT ADDRESS:
SURETY AGENT PHONE NO.:
OWNER NAME:
OWNER ADDRESS:
OWNER PHONE NO:
BOND AMOUNT:
CONTRACT NO.: (If applicable)
DESCRIPTION OF WORK:
PROJECT ADDRESS:
LEGAL DESCRIPTION: (If available)
481811P
Keystone Excavators, Inc.
371 Scarlet Blvd., Oldsmar, FL 34677
(813) 854-2342
Developers Surety and Indemnity Company
17771 Cowan Ave., Suite 100, Irvine, CA 92614
(727) 822 -5610
The Shrum Agency
2227 Pinnacle Circle North, Palm Harbor, FL 34684
(727) 781 -9797
City of Clearwater
100 S. Myrtle Ave., Clearwater, FL 33756
(727) 562 -4747
$ 243,977.80
Park Place Blvd Roadway Repairs
City of Clearwater, Florida
All other Bond page(s) are deemed subsequent to this page regardless of any
page number(s) that may be pre - printed thereon.
PINELLAS COUNTY FL OFF. REC. BK 19337 PG 2437
Bond No. :481811P
PUBLIC CONSTRUCTION BOND
(1)
This bond is given to comply with § 255.05, Florida Statutes, and any action instituted by a claimant under this bond for
payment must be in accordance with the notice and time limitation provisions in subsections (2) and (10).
Pursuant to § 255.05(1)(b), Florida Statutes, "Before commencing the work or before recommencing the work .after a
default or abandonment, the contractor shall provide to the public entity a certified copy of the recorded bond.
Notwithstanding the terms of the contract or any other law governing prompt payment for construction services, the
public entity may not make a payment to the contractor until the contractor has complied with this paragraph."
CONTRACTOR SURETY
Keystone Excavators, Inc.
371 Scarlet Blvd
Oldsmar, FL 34677
813- 854 -2342
Developers Surety & Indemnity Co
17771 Cowan Ave, Suite 100
Irvine, CA 92614
727 - 822 -5610
OWNER
City of Clearwater
Engineering Department
100 S. Myrtle Avenue
Clearwater, FL 33756
(727) 562 -4747
PROJECT NAME: Park Place Blvd Roadway Repairs
PROJECT NO.: TBD
PROJECT DESCRIPTION: Brick Paver Replacement and Roadway Repairs
BY THIS BOND, We, Keystone Excavators, Inc., as Contractor, and Developers Surety & Indemnity Company, a
corporation, as Surety, are bound to the City of Clearwater, Florida, herein called Owner, in the sum of $243,977.80, for
payment of which we bind ourselves, our heirs, personal representatives, successors, and assigns, jointly and severally.
THE CONDITION OF THIS BOND is that if Contractor:
1. Performs the proposal dated August 11, 2016, between Contractor and Owner for construction of
Park Place Blvd Roadway Repairs
, the contract documents being made a part of this bond by reference (which include the Advertisement for Bids, Proposal,
Contract, Surety. Bond, Instructions to Bidders, General Conditions, Plans, Technical Specifications and Appendix, and
such alterations as may be made in said Plans and Specifications as therein provided for), at the times and in the manner
prescribed in the contract; and
2. Promptly, makes payments to all claimants, as defined in Section 255.05(1), Florida Statutes, supplying Contractor
with labor, materials, or supplies, used directly or indirectly by Contractor in the prosecution of the work provided for in
the contract; and
3. Pays Owner all losses, damages, expenses, costs, and attorney's fees, including appellate proceedings, that Owner
sustains because of a default by Contractor under the contract; and
PINELLAS COUNTY FL OFF. REC. BK 19337 PG 2438
Bond No.: 481811P
PUBLIC CONSTRUCTION BOND
(2)
4. To the limits of § 725.06(2), Florida Statutes, shall indemnify and hold harmless Owner, their officers and
employees, from liabilities, damages, losses and costs, including, but not limited to, reasonable attorney's fees, to the
extent caused by the negligence, recklessness, or intentional wrongful misconduct of Contractor and persons employed or
utilized by Contractor in the performance of the construction contract; and
5. Performs the guarantee of all work and materials furnished under the contract for the time specified in the
contract, then this bond is void; otherwise it remains in fiill force.
6. Any action instituted by a claimant under this bond for payment must be in accordance with the notice and time
limitation provisions in Section 255.05(2), Florida Statutes.
7. Any changes in or under the contract documents and compliance or noncompliance with any formalities
connected with the contract or the changes does not affect Surety's obligation under this bond, and Surety does hereby
waive notice of any such change, extension of time, alteration or addition to the terms of the contract or to the work or to
the specifications.
IN TESTIMONY WHEREOF, witness the hands and seals of the parties hereto this 6th day of
September ,2016.
(Ifsole Ownership or Partnership, two (2) Witnesses required).
(IfCorporation, Secretary only will attest and af, x seal).
WITNESS:
Corporate Secretary or Wjiness
Print Name:., 4S% /.D 4.X4,IS
1 ct*xate, Q 1)
-'' `.
a : •„ ._
Keystone Excavators, Inc.
..y ._a
Title: President r.. ;0'. -;)1,-71! 0 .
Print Name: Robert C. Fora' j It ti•.:r `\
WITNES:
Developers S ty and Indemnity Co
By.
.51110..
'1,
ATTORNEY IN -FAC
Print Name: Warren M. Shixim;'•47,.,;i •
•
.. ''4brH+,n n+�5d555 +•
(affix corporate seal)
PINELLAS COUNTY FL OFF. REC. BK 19337 PG 2439
POWER OF ATTORNEY FOR
DEVELOPERS SURETYAND INDEMNITY COMPANY
PO Box 19725, IRVINE, CA 92623 (949) 263 -3300
KNOW ALL BY THESE PRESENTS that except as expressly limited, DEVELOPERS SURETY AND INDEMNITY COMPANY, does hereby make, constitute and appoint:
***Warren M. Shrum Jr.*
asks bue and lawful Attomey(s).in•Fad, to make, execute, deliver and acknowledge, for and on behalf of said corporation, ae surety, bonds, undertakings and contracts of suretyship
giving and granting unto said Attomey(s)-infad full power and authority to do and to perform every act necessary, requisite or proper to be done in connection therewith as each of said
corporation could do, but reserving to each of said corporation full power of substitution and revocation, and all of the acts of said Attomey(s) -in -Fad, pursuant to these presents, are
hereby ratified and confirmed.
This Power of Attorney is granted and is signed by facsimile under and by authority of the following resolution adopted by the Board of Directors of DEVELOPERS SURETYAND
INDEMNITY COMPANY, effective as of January 1st, 2008.
RESOLVED, that a combination of any two of the Chairman of the Board, the President, any Executive Vice - President, Senior Vice - President or Vice - President of the
corporation be, and that each of them hereby is, authorized to execute this Power of Attorney, qualifying the attomey(s) named In the Power of Attorney to execute, on behalf of the
corporation, bonds, undertakings and contracts of suretyship; and that the Secretary or any Assistant Secretary of the corporation be, and each of them hereby is, authorized to attest the
execution of any such Power of Attorney;
RESOLVED, FURTHER, that the signatures of such officers may be affixed to any such Power of Attorney or to any certificate relating thereto by facsimile, and any such
Power of Attorney or certificate ixearing such facsimile signatures shall be valid and binding upon the corporation when so affixed and in the future Mil respect to any bond, undertaking
or contract of suretyship to which it is attached.
IN WITNESS WHEREOF, DEVELOPERS SURETYAND INDEMNITY COMPANY has caused these presents to be signed by Its officers and attested by Its Secretary orAssistant
Secretary this December.1; 2014.
Dagiel Voting, Senlbr.Vioe- Piealilent
-0 •
py',IAerk J. Lansdon, Ytce•Pres4en(
l�tajedfCaliforda••
Cou'ntypf Orange
On December1 ;2014
' Date'
personalty appeared
before me,
Lucile Raymond, Notary Public
Here Insert Name and Title of the Officer
Daniel Young and Mark J. Lansdon
Name(s) of Signer(s)
LUCILLE RAYMOND
Commission # 2051915
Notary Public • California
Orange County
Comm. fx�Iris Oct 19`2015
Place Notary Seal Above
who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) Ware subscribed to
the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized
apacity(les), and that by Ns/her/their signature(s) on the instrument the person(s), or the entity upon behalf of
which the person(e) acted, executed the Instrument.
I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph Is
true and correct,
WITNESS my hand and official seal. e ` /) -
Signature
ca e:(24
/JG 6k/744
a Raymond, Notary Public
`rrr,r„rrrrrrr�ir CERTIFICATE
i
`s �. ; The`uridersPgge?tga Secretary orAssistent Secretary of DEVELOPERS SURETYAND INDEMNITY COMPANY does hereby certify that the foregoing Power of Attorney
?enlelna In f(it)arie a)td Pee po(tseen revoked and, furthermore, that the provisiorf of the resolution of the Board of Directors of said corporation set forth In the Power of Attorney are in
faceds of the debiofthI Certik
• ;• . ThJwCsafiate Is executed In the City of Irvine, California, this 6th day of September , 2018 .
e presto J.,,,, ,¢/iaeicteii(Secrelary
v
ID 1438(Rev.12/14).' ;;,;,•••
STATE OF FLORIUA•PINELLASt ( iUNTV
t nerebvi certify rhat the foregoing isatrue
4.1.iy tits reecroed in the official records of
I 1 nib I
hrSl
, 20
BUR
lark of Q`ircuitbourt 8 Comptroller
OeontvClerk