JOE DIMAGGIO SPORTS COMPLEX - PRESS BOX AND STORAGE FACILITY - 07-0035-PR-F - PUBLIC CONSTRUCTION BONDBond No.:
PUBLIC CONSTRUCTION BOND
(1)
This bond is given to comply with § 255.05, Florida Statutes, and any action instituted by a claimant
under this bond for payment must be in accordance with the notice and time limitation provisions in
subsections (2) and (10).
Pursuant to § 255.05(1)(b), Florida Statutes, "Before commencing the work or before recommencing
the work after a default or abandonment, the contractor shall provide to the public entity a certified
copy of the recorded bond. Notwithstanding the terms of the contract or any other law governing
prompt payment for construction services, the public entity may not make a payment to the contractor
until the contractor has complied with this paragraph."
CONTRACTOR SURETY
Certus Builders, Inc.
301 S. Westland Ave.
Tampa, FL 33606
813 -443 -4990
[name]
[principal business address]
[phone number]
OWNER
City of Clearwater
Parks & Recreation Dept.
100 S. Myrtle Avenue
Clearwater, FL 33756
(727) 562-4856
PROJECT NAME: Joe DiMaggio Sport Complex — Press Box & Storage Facility
PROJECT NO.: 07- 0035 -PR -F
PROJECT DESCRIPTION: Joe DiMaggio Sports Complex Press Box 2450 Drew Street, Clearwater,
Florida 33765 - The work consist of constructing Press Box and Storage Facility, methane mitigation system,
concrete, masonry, plumbing, electrical, HVAC system, stucco, flooring system, roofmg system, drywall, ceiling
grid, doors & hardware, millwork, painting, flooring, & restoration of contractor's staging area and all disturbed
sodding. The General Contractor shall coordinate with the site contractor and other contractors also performing
other work on site. General Contractor shall construct the drawing according to the permitted drawing with no
deviations during construction of the facility unless approved by the architect and the Owner.
BY THIS BOND, We Certus Builders, Inc., as Contractor, and [surety], a corporation, as Surety, are
bound to the City of Clearwater, Florida, herein called Owner, in the sum of $399,788.00, for payment
of which we bind ourselves, our heirs, personal representatives, successors, and assigns, jointly and
severally.
THE CONDITION OF THIS BOND is that if Contractor:
1. Performs the contract dated [execution date], between Contractor and Owner for construction of
Joe DiMaggio Sport Complex — Press Box & Storage Facility the contract documents being made a part
of this bond by reference (which include the Advertisement for Bids, Proposal, Contract, Surety Bond,
Instructions to Bidders, General Conditions, Plans, Technical Specifications and Appendix, and such
alterations as may be made in said Plans and Specifications as therein provided for), at the times and in
the manner prescribed in the contract; and
2. Promptly makes payments to all claimants, as defined in Section 255.05(1), Florida Statutes,
supplying Contractor with labor, materials, or supplies, used directly or indirectly by Contractor in the
prosecution of the work provided for in the contract; and
_SectionV (2) Page 1 of 17 11/25/2014
BondNo.:
PUBLIC CONSTRUCTION BOND
(2)
3. Pays Owner all losses, damages, expenses, costs, and attorney's fees, including appellate
proceedings, that Owner sustains because of a default by Contractor under the contract; and
4. To the limits of § 725.06(2), Florida Statutes, shall indemnify and hold harmless Owner, their
officers and employees, from liabilities, damages, losses and costs, including, but not limited to,
reasonable attorney's fees, to the extent caused by the negligence, recklessness, or intentional wrongful
misconduct of Contractor and persons employed or utilized by Contractor in the performance of the
construction contract; and
5. Performs the guarantee of all work and materials furnished under the contract for the time
specified in the contract, then this bond is void; otherwise it remains in full force.
6. Any action instituted by a claimant under this bond for payment must be in accordance with the
notice and time limitation provisions in Section 255.05(2), Florida Statutes.
7. Any changes in or under the contract documents and compliance or noncompliance with any
formalities connected with the contract or the changes does not affect Surety's obligation under this
bond, and Surety does hereby waive notice of any such change, extension of time, alteration or addition
to the terms of the contract or to the work or to the specifications.
IN TESTIMONY WHEREOF, witness the hands and seals of the parties hereto this day
of , 20
(If sole Ownership or Partnership, two (2) Witnesses required). JTY.PE LEGAL NAME OF
C'ON7'RAC7'ORI
(If Corporation, Secretary only will attest and affix seal).
WITNESS:
By:
Title: CEO
Print Name: Dean Summer
WITNESS:
Corporate Secretary or Witness Print Name:
Print Name:
(affix corporate seal) [Leavj blankfor Name Qf CQrporate Suretvl
By:
ATTORNEY -IN -FACT
Print Name:
(affix corporate seal)
(Power of Attorney must be attached)
Joe DiMaggio press box_SectionV.docx Page 2 of 16 11/25/2014