Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
DVA2007-00002
lu 9V11 0 DVA2007-00002 500 MANDALAY AVE THE SANDPEARL RESORT PLANNER OF RECORD: NOT ENTERED ATLAS # 267A ZONING: T LAND USE: RFH RECEIVED: 05/04/2007 INCOMPLETE: COMPLETE: MAPS: PHOTOS: STAFF REPORT: nxc: G -7- 07 CDB: CLWCoverSheet 0 Clearwater Planning Department 100 South Myrtle Avenue > Clearwater, Florida 33756 Telephone: 727-562-4567 U Fax: 727-562-4865 ? SUBMIT ORIGINAL SIGNED AND NOTARIZED APPLICATION ? SUBMIT 12 COPIES OF THE ORIGINAL APPLICATION including folded site plans ? SUBMIT APPLICATION FEE $ . M CASE #: :PV Pr Z-00 7 - 0 d 00 LL DATE RECEIVED: RECEIVED BY (staff initials): ATLAS PAGE #: ZONING DISTRICT: LAND USE CLASSIFICATION: ZONING & LAND USE CLASSIFICATION OF ADJACENT PROPERTIES: NORTH: SOUTH: WEST: EAST: DEVELOPMENT AGREEMENT APPLICATION (Revised 05/22/02) PLEASE TYPE OR PRINT- A. APPLICANT, PROPERTY OWNER AND AGENT INFORMATION: (Section 4-202.A) The Sandppearl Resort, LLC APPLICANT NAME: The Residences at Sahdnearl Resort, LLC MAILINGADDRESS: . 2201 - 4th. Street North, Suite 200, St. Petersburg, FL 33704 PHONE NUMBER: 727-443-6585 FAX NUMBER: 72774433885 CELL NUMBER: PROPERTY OWNER(S): Same as applicants (Must include ALL owners) O AGENT NAME: E. D.. Armstrong ITIi Es?S,uixe. PLANNING DEPARTMENT Jo nson, Pope, Bo or, Ruppel & Burns, LLP MAILINGADDRESS: 911 Chestnut Street, Clearwater, FL 33756 PHONE NUMBER: 727-461-1818 FAX NUMBER: 7277.4620365 B. PROPOSED DEVELOPMENT INFORMATION: STREET ADDRESS: 500 Mandalay Avenue. LEGAL DESCRIPTION: Lot 1, Blk. 1, & Lot 1, Rlk. 2, $andpearl, Plat Book. 129f? Page 89 PARCEL NUMBER: 08/29/15/78657/001/0010 and 08/29/15/78657/002/0010 PARCEL SIZE: (acres, square feet) PROPOSED USE AND SIZE: 253 overnight accommodation units, 119 (number of dwelling units, hotel rooms or square footage of nonresidential use) attached dwellings and 11,000 square feet retail sales and services. DESCRIPTION OF ANY RELATED REQUEST(S): This is a request for an amendment to the existing development (approval of a developmentinclude all requested code deviations; e.g. reduction in required number of parking spaces, specific use, etc.) agreement. as. approved by Resolution 05-04. DOES THIS APPLICATION INVOLVE THE TRANSFER OF DEVELOPMENT RIGHTS (TDR), A PREVIOUSLY APPROVED PLANNED UNIT DEVELOPMENT, OR A PREVIOUSLY APPROVED (CERTIFIED) SITE PLAN? YES _ NO X (if yes, attach a copy of the applicable documents) EMAIL ADDRESS: ORIGINAL RECEIVEL) Page 1 of 5 - Development Agreement Application - City of Clearwater 0 0 B.2 DEVELOPMENT AGREEMENTS SUPPLEMENTAL SUBMITTAL REQUIREMENTS: (Section 4-606.B) An application for approval of a development agreement shall be accompanied by the following (use separate sheets or include in a formal report): ? STATEMENT OF THE REQUESTED DURATION OF THE DEVELOPMENT AGREEMENT,WHICH SHALL NOT EXCEED TEN YEARS ? DESCRIPTION OF ALL EXISTING AND PROPOSED PUBLIC FACILITIES AND SERVICES THAT SERVE OR WILL SERVE THE DEVELOPMENT; ? DESCRIPTION OF THE USES DESIRED TO BE PERMITTED ON THE LAND, INCLUDING POPULATION DENSITIES AND BUILDING INTENSITIES AND HEIGHTS; ? INDENTIFICATION OF ZONING DISTRICT CHANGES, CODE AMENDMENTS THAT WILL BE REQUIRED IF THE PROPOSED DEVELOPME PROPOSAL WERE TO BE APPROVED; ? ZONING AND LAND USE CATEGORIES OF ALL ADJOINING PROPERTIES; ? COMPLETE NAMES AND ADDRESSES OF ALL OWNERS OR PROPERTIES ABUTTING OR LYING WITHIN 200 FEET OF THE SUBJECT PROPERTY AS CURRENTLY LISTED IN THE COUNTY RECORDS AS OF ONE WEEK PRIOR TO THE FILING OF AN APPLICATION. C. PROOF OF OWNERSHIP: (Section 4-202.A) ? SUBMIT A COPY OF THE TITLE OR DEED TO THE PROPERTY OR PROVIDE OWNER SIGNATURE ON PAGE OF THIS APPLICATION D. WRITTEN SUBMITTAL REQUIREMENTS: (Section 4-606.13) ORIGINAL ? Provide the following contents to the development agreement, as follows: RECEIVED Contents. The approved development agreement shall contain, at a minimum, the following information: a. A legal description of the land subject to the development agreement. JUN 18 2007 b. The names of all persons having legal or equitable ownership of the land. PLANNING DEPARTMEPTT c. The duration of the development agreement, which shall not exceed ten years. CITY OF CLEARWATER d. The development uses proposed for the land, including population densities, building intensities and building height. e. A description of the public facilities and services that will serve the development, including who shall provide such public facilities and services; date any new public facilities and services, if needed, will be. constructed; who shall bear the expense of construction of any new public facilities services; and a schedule to assure that the public facilities and services are available concurrent with the impacts of the development. development agreement shall provide for a cashier's check, a payment and performance bond or letter of credit in the amount of 115 percent of estimated cost of the public facilities and services, to be deposited with the city to secure construction of any new public facilities and servi required to be, constructed by the development agreement. The development agreement shall provide that such construction shall be comple prior to the issuance of any certificate of occupancy. f. A description of any reservation or dedication of land for public purposes. g. A description of all local development approvals approved or needed to be approved for the development. h. A finding that the development approvals as proposed is consistent with the comprehensive plan and the community development co Additionally, a finding that the requirements for concurrency as set forth in Article 4 Division 10 of these regulations have been satisfied. I. A description of any conditions, terms, restrictions or other requirements determined to be necessary by the city commission for the public hea safety or welfare of the citizens of the City of Clearwater. Such conditions, terms, restrictions or other requirements may be supplemental requirements in existing codes or ordinances of the city. j. A statement indicating that the failure of the development agreement to address a particular permit, condition, term or restriction shall not relic the developer of the necessity of complying with the law governing said permitting requirements, conditions, terms or restrictions. k. The development agreement may provide, in the discretion of the City Commission, that the entire development or any phase thereof commenced or be completed within a specific period of time. The development agreement may provide for liquidated damages, the denial of fut development approvals, the termination of the development agreement, or the withholding of certificates of occupancy for the failure of developer to comply with any such deadline. 1. A statement that the burdens of the development agreement shall be binding upon, and the benefits of the development agreement shall inure all successors in interest to the parties to the development agreement. m. All development agreements shall specifically state that subsequently adopted ordinances and codes of the city which are of general application not governing the development of land shall be applicable to the lands subject to the development agreement, and that such modifications specifically anticipated in the development agreement. Page 2 of 5 - Development Agreement Application - City of Clearwater 0 0 E. SUPPLEMENTAL SUBMITTAL REQUIREMENTS: (Section 4-202.A) ? SIGNED AND SEALED SURVEY (including legal description of property) - One original and 12 copies; ? COPY OF RECORDED PLAT, as applicable; ? PRELIMINARY PLAT, as required; ? LOCATION MAP OF THE PROPERTY. ? TREE SURVEY (including existing trees on site and within 25' of the adjacent site, by species, size (DBH 4" or greater), and location, including drip lines.) ? GRADING PLAN, as applicable; F. SITE PLAN SUBMITTAL REQUIREMENTS: (Section 4-202.A) ? SITE PLAN with the following information (not to exceed 24" x 36"): _ All dimensions; North arrow; Engineering bar scale (minimum scale one inch equals 50 feet), and date prepared; Location map; Index sheet referencing individual sheets included in package; Footprint and size of all buildings and structures; All required setbacks; All existing and proposed points of access; All required sight triangles; Identification of environmentally unique areas, such as watercourses, wetlands, tree masses, and specimen trees, including description and location of understory, ground cover vegetation and wildlife habitats, etc; Location of all public and private easements; Location of all street rights-of-way within and adjacent to the site; Location of existing public and private utilities, including fire hydrants, storm and sanitary sewer lines, manholes and lift stations, gas and water lines; All parking spaces, driveways, loading areas and vehicular use areas; Depiction by shading or crosshatching of all required parking lot interior landscaped areas; Location of all refuse collection facilities and all required screening (min. 10'x12' clear space); Location of all landscape material; Location of all onsite and offsite storm-water management facilities; Location of all outdoor lighting fixtures; and Location of all existing and proposed sidewalks. ? SITE DATA TABLE for existing, required, and proposed development, in written/tabular form: _ Land area in square feet and acres; _ Number of dwelling units proposed; _ Gross floor area devoted to each use; Parking spaces: total number, presented in tabular form with the number of required spaces; Total paved area, including all paved parking spaces and driveways, expressed in square feet and percentage of the paved vehicular area; Size and species of all landscape material; _ Official records book and page numbers of all existing utility easement; Building and structure heights - Impermeable surface ratio (I.S.R.); and - Floor area ratio (F.A.R.) for all nonresidential uses. ORIGINAL ? REDUCED SITE PLAN to scale (8'/2 X 11) and color rendering if possible; RECEIVED ? FOR DEVELOPMENTS OVER ONE ACRE, provide the following additional information on site -plan: JI i? 1 2OO7 One-foot contours or spot elevations on site; 1 Offsite elevations if required to evaluate the proposed stormwater management for the parcel; All open space areas; PLANNING DEPARTMENT Location of all earth or water retaining walls and earth berms; CITY OF CLEARWATER _ Lot lines and building lines (dimensioned); Streets and drives (dimensioned); _ Building and structural setbacks (dimensioned); Structural overhangs; _ Tree Inventory; prepared by a "certified arborist", of all trees 8" DBH or greater, reflecting size, canopy (drip lines) and condition of such trees. Page 3 of 5 - Development Agreement Application - City of Clearwater 0 • G. LANDSCAPING PLAN SUBMITTAL REQUIREMENTS: (Section 4-1102.A) ? LANDSCAPE PLAN: All existing and proposed structures; _ Names of abutting streets; Drainage and retention areas including swales, side slopes and bottom elevations; Delineation and dimensions of all required perimeter landscape buffers; Sight visibility triangles; Delineation and dimensions of all parking areas including landscaping islands and curbing; Proposed and required parking spaces; Existing trees on-site and immediately adjacent to the site, by species, size and locations, including dripline; Location, size, description, specifications and quantities of all existing and proposed landscape materials, including botanical and common names; Typical planting details for trees, palms, shrubs and ground cover plants including instructions, soil mixes, backfilling, mulching and protective measures; Interior landscaping areas hatched and/or shaded and labeled and interior landscape coverage, expressing in both square feet and percentage covered; Conditions of a previous development approval (e.g. conditions imposed by the Community Development Board); Irrigation notes. ? REDUCED LANDSCAPE PLAN to scale (8'/z X 11) (color rendering if possible); ? IRRIGATION PLAN (required for level two and three approval); ? COMPREHENSIVE LANDSCAPE PROGRAM application, as applicable. H. BUILDING ELEVATION PLAN SUBMITTAL REQUIREMENTS: (Section 4-202.A.23) Required in the event the application includes a development where design standards are in issue (e.g. Tourist and Downtown Districts) or as part of a Comprehensive Infill Redevelopment Project or a Residential Infill Project. ? BUILDING ELEVATION DRAWINGS - all sides of all buildings including height dimensions, colors and materials; ? REDUCED BUILDING ELEVATIONS - four sides of building with colors and materials to scale (8 X 11) (black and white and color rendering, if possible) as required. 1. SIGNAGE: (Division 19. SIGNS / Section 3-1806) ? Comprehensive Sign Program application, as applicable (separate application and fee required). ? Reduced signage proposal (8'/S X 11) (color), if submitting Comprehensive Sign Program application. PLANNING ICE J. TRAFFIC IMPACT STUDY: (Section 4-801.C) ? Include as required if proposed development will degrade the acceptable level of service for any roadway as adopted in the Comprehensive Plan. Trip generation shall be based on the most recent edition of the Institute of Transportation Engineer's Trip General Manual. Refer to Section 4-801 C of the Community Development Code for exceptions to this requirement. K. SIGNATURE: I, the undersigned, acknowledge that all representations made in this application are true and accurate to the best of my knowledge and authorize City representatives to visit and photograph the property described in this application. Signature of property owner or representative E. D. Armstrong III STATE OF FLORIDA, COUNTY OF PINELLAS Sworn to and subscribed before ine this 3o n-- day of April. APT 20 0 to me and/or by • truhg I who is personally known has produced as identification. otaryblic, My commission expires: Jayne E. Sears Commission # DD449633 Expires September 2, 2009 Page 4 of 5 - Development Agreement Application - City of Clearwater E L. AFFIDAVIT TO At.ITHC3;"tB E AGENT: a't. GiarfdpE>.«r.'l, R(?sr):r.-t: F ;L?F?C y ,f'.''or-.m(!.r i'y kriowr.L i:.: ?'iK );C:?:c;:.j.!:3):%iii?::il'•:: :t?.'....:.:?.C. N;:Mes of ail property 1. That (: arrYwe are' ,he otvnertst and record tine hoidens; of the following described pr-•,frerty {address or garer3l::rration; ----------------------------------------------------- L. That this property c isRutes the property',-'which a request f_r: a. idescribe request) slmendnni^nt of an. E3£istinJ dievelopynent c"gr.:?tFtvE?n't.. zx t-L rE; ZTIr :>G):33.Et:, jti_-insorzr 3. That tF:F Undersigned (haslhave) appointed and. (doesldo) appoirit. -:p as (h >itheir) agents) to ex?3cute, any petitiens or other documents necessary to a::ect such p-tit on; 4. That this affidavit has been executed to induce the City of Gleanvater, Florida to consider and act on the above described properry; 5. 'that Safe visits to the propeily are necessary by City representatives in order to Process this application and the, o:ener authorizes .^,i?y representatives to visit and phowgrapn the prope-Ay, dde-scribed in this application; E 6. That (ltwf3). fhcsttnd nr,' ra tbs.: ,he fore. cinc is tr:rr and . c. rr 'Me. Fes1 f noes a,t Sandpearl rsign authority, heby certify 7, 0 BCA. Res 7• ' By:CBR Coma:-z i 'e j .11girig Mr--tuber V1, Tn:_ . Gert.. properly i.)iV'IE`.r? ?. \ ?.'. 'ST:C .... 'c3.T .. pp tltl?? A? 7Pprt>p?iep.?plyyg±.g?-SyYnpkax,3A\RDA2r .1o?in. £; A11ff la, Ofi f', 'J r3 it COUNTY OF PINEt-I-AS E fore me the undersigned, air o:9icer duly commissioned by the laves of the State of Florida, on this -2 ? clay of j 2007 pFrsonally appeared .Tob-3 P. flbdci ` v:t?C? r?3Yrf %? 1?4°t 3? flrJt ttLl a MO.`n Ge ?sWr- ar?d _eys tt:at he-15he fully uMerstands the coriter?is :;f tt:e af`•.davit tt3at t?eIs be signed. Notary Public l ty ::otnrrrissior? •?xpires. *ac FYF,< 3_rst i f ?+ tj 3 :.i.t? t?~ E a € M ....... Y'? MARLENE K. WEBER E w Y ?... iiD 344534•-. ..: ray J c?HtII I' I, d c Pr Lr2 r .i.:'.``, fe :.,C's.E' ...c: ??; r 2(l? EXPIRES: June 13, Bonded Thru Notary Public Undalliters S"Ir'%annin,J i:ep2+tmgnftkpphc%;ben FrrmsL:flvtdop+>!enr re.Vlew!dev,:Wopfr;ent %agreem%i l app/icali[r»3.?CC ORIGINAL RECEIVED ?1?°?? ? 2€17 PLANNING DEPARTMENT CITY OF CLEARWATER Page 5 of 5 - Development Agreement Application -- City of Clearwater L. AFFIDAVIT TO AUTHORIZE AGENT. :.'tl.£? y.,e.::•C£t:3Aa.:... }?E?:it>Y.'t - ?.?1, e ,.'•f)..:tii .`.'.?.? E'..E ow,.;t ais CDR ue veYorxften t 1, L LC ................................................................:........................ ................:. ....:...;.......... ;Fames o. a:: property cwrtem) i ?tat ii ant, rr a e; the r,Wr:::t{si a Zd r5r it:i titx hrsltSerfsj of tile fOE3a',vin? cGctihcfi prap2t y i9±l:lt.>s or a8;t21c i E..^..a. t3atj: # np 12 ";; 73 6 5 7 /001 j %)01 , .. ......................................... -°----- -------------------------------------------- . ---------- ------ -- ------------.... Thai i. its property cmAitu e's the F.-Opcr`, tar which a reque s: ar ;deacrihe requ sij <^:... me.mr.nt of l;''. L 1FC ?t:'F:^. ^_.F E^•{. <SCf: E3E;3?if;: ... D. Axrlllstllma III, ESq`-!ir'e, 3. -twat t to ct xteesi.ttted ihaOiave; a:ppcrited ar.i 'do6s.do' app Y.tt: __ .... ... v of nso t , Pope, Boko3, RuIppe:. & Burns, LL P as ihisi"Ie4) a :e n4;s; to exec:.;c a;Ty petikvofts or outer dao rnertts rier;essaty to affe'4 such peMitrn: i. That thi;> .affidavit ey..i culed to Ertd+,ce tf c City of Clearmater; 's lor:ti? ti, oc. lsider an:1 art on fhe a one. d<^"s.aib•od p:,t)perty. z. -hat siib u:sit_ to fia itn'Opefty are ntacessorv by +:;iiy represerrtati?tes in, order tc.• roc ss tt..s applica5or% and the owner au.thoriz_,^ +:;ity !eprssentatives to 'As., a _--Id phctccraph tta property described in ibis app catiar:; 3: ?it8f ;l..^xei, it?e fff'e1g:5;rsnt?.t :tethC iaf" her ;y o@.'t ty t i it r : J r g "'h( e n.-I}:ie-- Z. ?eSG t , L LC .^.2 to t?f> o! T ., Er_ia and CCCreCi. ;:3zi + y Coam"anit.ies I, ° T f ' , Ala-na, ,c£ £t ;1-c)r7TT, nit .: a of Clearwater "-v , lac, art: , Pr?;tantsGvfre>::Cri. .. t::i: `:?G i,' ,>vvy .Ei~Tl":' STATE OF FI,ORIDA, COUNTY OF PINELLAS 'xtt the >hc t,r uafxicntcd• ;, of tcer duiy O;,nrnnission°d by t?;e laws of the S.aty of Ficrida. on this p? day of ° t 1 persona (y 3 F e <ed h n t' G•bac i ' vF.c F.aV be.£.: r.:. J:y sworn .. .. ?J..>LK cis:; ;3na .3 ..<.M -. M3 f:,I:Y cr.c:£K5 .ands :he ront?rt, ci fhc ,fidavil that ft 'she. sippd /;,3 /Og Rio;a Public fbiip cOr!1!ff1SS1UlT E;4jJtr`•5: (y / *a s PreSiet?n-L of iv14C Cm:frrtuniities MARLENE K. WEBER MY COMMISSION DD 384834 ... .... ....................... .p. ... p? , Bonded Thru Notary Public Underwrlt m :'?3.na-C1iinc •'i.<'.ItL, -r ^.: ?rrr. _ -_ . The Sanrapearl _-,R?so?rt, IUD- ...ii>rY:flrA?:it^;JB•r••.PA':"f:7Rir,.'.tsill i?C,"AY.iiyAy.e;>02?;;J?^(,'rl?it:'.7?.Cts: ^i:7 <^P»:.B,:fYPA;q.':P?(ii;?i,:... .;::?.CPC ORIGINAL RECEIVED vv',? ? 2007 t e£: Ot e - L?e,ve3aF:met::.;gr?at??ar::.;p;Tai ?ysc:::?.. ity of cyst :?t pLANNING DENARTMENT CITY OF CLEARWATER AMENDMENT TO DEVELOPMENT AGREEMENT FOR PROPERTY IN THE CITY OF CLEARWATER This is an amendment ("Amendment") to the Development Agreement for Property in the City of Clearwater dated January 26, 2005 ("Agreement") between THE CITY OF CLEARWATER, FLORIDA, a Florida municipal corporation (the "City") and The Sandpearl Resort, LLC, a Florida limited liability company, formerly known as CBR Development I, LLC and The Residences at Sandpearl Resort, LLC, a Florida limited liability company, formerly known as CBR Development II, LLC (collectively the "Developer"). The Agreement is recorded in Official Records book 14089, at Pages 314 through 451, of the Public Records, of Pinellas County, Florida. WITNESSETH: WHEREAS, the City and Developer entered into the Agreement which include Section 5.03(10) provisions as to development of shared Boat Docking Facilities in the Boat Basin (as described in the Agreement); WHEREAS, subsequent to the execution of the Agreement it was determined that the submerged land in the Boat Basin was owned in fee simple by the City; WHEREAS, as a result of this change in circumstances, the parties have agreed to certain revisions to the agreement between the City and the Developer attached to the Agreement as Exhibit N-1 ("Boat Dock Agreement") and to the Agreement; WHEREAS, the City has conducted such hearings as are required by and in accordance with Chapter 163.3220 et seg. Fla Stat. and applicable law; WHEREAS, the City has determined that as of the Effective Date of this Amendment the proposed development is consistent with the City's Comprehensive Plan and Land Development Regulations; WHEREAS, at a duly called public meeting on , 2007, the City Council approved this Amendment, and authorized and directed its execution by the appropriate officials of the City; and WHEREAS, the members of Developer have approved this Amendment and have authorized the undersigned individuals to execute this Amendment on its behalf; NOW, THEREFORE, in consideration of the mutual promises and covenants contained herein, the parties hereby agree as follows: 1. Capitalized Terms. Capitalized terms used herein that are not defined shall have the same meanings given to such terms in the Agreement. 2. Amendment to Agreement. The Agreement is amended as follows: a. Section 5.03(10) is deleted in its entirety and replaced with the following subsection: Amendment to Development Agreement Page 1 ADOPTED • • 10. Boat Docking Facilities. The City owns certain real property including submerged lands within a boat basin immediately to the North of the Belle Harbor Condominium project ("Boat Basin"). The City agrees to grant to Developer the right to construct shared boat docking facilities ("Boat Docking Facilities") in the Boat Basin. Developer agrees to pursue, at Developer's expense, all required Permits for construction of boat slips (the "Boat Slips") in the Boat Basin as conceptually depicted on the attached Revised Exhibit N. In the event Developer is able to obtain the Permits for the Boat Slips, the City and Developer shall enter into an agreement in the form attached as Revised Exhibit N-1 ("Boat Dock Agreement") that will authorize the Developer to construct the new Boat Slips, at Developer's sole expense, and provide for Developer and its designated successors and assigns to have the right to utilize 27 of such Boat Slips during the term of the Boat Dock Agreement. The remaining 15 Boat Slips are to be utilized by the City pursuant to the terms of the Boat Dock Agreement. The Boat Dock Agreement will provide (i) for Developer to pay all maintenance and repair costs for the Boat Slips, (ii) for use of the Boat Slips to be limited to owners, tenants and guests (including Beach Club members) of the Project and other owners and tenants that own or lease residences within the geographical area bordered on the West by the Gulf of Mexico, on the East by Clearwater Bay, on the North by Rockaway Street and on the South by Papaya Street; and (iii) for Developer to provide a shuttle service to the Boat Slips from the Project. Any sublease or assignment by Developer of rights to utilize the Developer Boat Slips shall be limited to such owners, tenants and guests as provided above and all subleases or assignments shall expressly prohibit parking on the City Property during use of the Developer Boat Slips. b. Exhibit N to the Agreement is deleted and replaced with the "Revised Exhibit N" attached to this Amendment. C. Exhibit N-1 to the Agreement is deleted and replace with the "Revised Exhibit N-1" attached to this Amendment. 3. Ratification. Except as modified herein, the terms and conditions of the Agreement remain in full force and effect and are ratified by the parties. 4. Effective Date. As provided in §163.3239, Florida Statutes (2006), this Amendment will become effective after being recorded in the public records in the county and 30 days after having been received by the state land planning agency. Amendment to Development Agreement Page 2 ADOPTED 0 • IN WITNESS WHEREOF, the parties hereto have set their hands and their respective seals affixed as of this _ day of , 2007. THE CITY OF CLEARWATER Attest By: By: City Clerk Mayor Approved as to form and correctness , Esquire City Attorney STATE OF FLORIDA COUNTY OF PINELLAS The foregoing instrument was acknowledged before me this _ day of , 2007; by and , Mayor and City Clerk, respectively, for the City of Clearwater, Florida, on behalf of the City, ? who are personally known to me or ? who produced as identification. r. NOTARY PUBLIC Printed Name: Commission No. My Commission expires: 7/2-4-)0-7 Amendment to Development Agreement Page 3 ADOPTED 0 0 THE SANDPEARL RESORT, LLC, a Florida limited liability company By: CBR Communities I, Ltd., a Florida limited partnership, Managing Member By: JMC Communities of Clearwater V, Inc. a Florida corporation, General Partner By: Name: J. Michael Cheezem Title: CEO STATE OF FLORIDA COUNTY OF PINELLAS The foregoing instrument was acknowledged before me this day of , 2007, by J. Michael Cheezem, as CEO of JMC Communities of Clearwater V, Inc., a Florida corporation, the General Partner of CBR Communities I, Ltd., a Florida limited partnership, the Managing Member of The Sandpearl Resort, LLC, a Florida limited liability company, on behalf of the company, ? who are personally known to me or ? who produced as identification. NOTARY PUBLIC Printed Name: Commission No. My Commission expires: Amendment to Development Agreement Page 4 ADOPTED C THE RESIDENCES AT SANDPEARL RESORT, LLC, a Florida limited liability company By: CBR Communities II, Ltd., a Florida limited partnership, Managing Member By: JMC Communities of Clearwater VI, Inc. a Florida corporation, General Partner By:_ Name Title: J. Michael Cheezem CEO STATE OF FLORIDA COUNTY OF PINELLAS The foregoing instrument was acknowledged before me this _ day of , 2007, by J. Michael Cheezem, as CEO of JMC Communities of Clearwater VI, Inc., a Florida corporation, the General Partner of CBR Communities II, Ltd., a Florida limited partnership, the Managing Member of The Residences at Sandpearl Resort, LLC, a Florida limited liability company, on behalf of the company, ? who are personally known to me or ? who produced as identification. NOTARY PUBLIC Printed Name: Commission No. My Commission expires: Amendment to Development Agreement Page 5 ADOPTED Z H X W W W P36POSE0 (BY SIBS: E WET SIBS FOR BOATS IN88 TRAM 91' 1 UMT LIM FUR BOATS 18EE THEN 80' a ww 9IIPa Fm BOATS mas mm Be, 4 MAT LII713 FUR BOATS IR135 THAN 813' 11 YET ffiM9 PAR BOATS UM THAN 40' 9 DAY SUPS TOM 42 MIPS { MANATEE SIGNS NOTR= NO POIIINa. PAI@-130! OR 579H CLEANMG P6CUMIS ARC PEOPOBEO MR THIS PFJMLr -- sEAGaaee METING ;...? MANGBDYES iool G ? STAW Ty If? I ll APr M OF TM iF iATEEWiT LM APPROUME NON-CORALLOM SEA CRASS mm-\ LTM BDTIDII sup fig II '? F °al'- BANLRAR12'-b' ?' s1aP ?1>t . _ I I BLIP sa.s : / - SIP 'FIB 101 -tr MIL3 :E. 818 Ole at>P rte; (IVaj _ ,t HAINHEXRAIL- -•• '{T" ''7' .. .. NO 8 rx, 13DON -r APPROMMTE LIMITS OF NAVIGABLE PATER ?L7Q5TING OUCH ?j 8 A3M LINE / II ' I'f 11.r:?.R;i13 11ATEMM OONSMUCTION CIi4 _t00 , 'No lREUBay,P4 CLAP •` RAW ?r? oan Mhl??117 FILE9NPMME bNaTtl1-gm M14 WATERLINE ? 4408 Grady Avg. N Tampa . PL 88814 GYe xaater Raerqatr CClttGil' or m7 C 7 .: 1 ry =V, rV . 7 Syyygtyc+:gpr r ¢r ranem QWP FLE cx?sTRUCn?v, !N 618-896-1977 S Q? 1,04 R tS FM 1 49F s Nsm C 4) E a) a) Q C O) E Q- 0 Q) N 0 O C Q O W _0 (D m p, O Q d Q • i 4 ?. I CUFULL- 4 41 R ,, .... ;i l? yl tit AIPAMAN UNE +/- aa, n n SUP #10 BI.B ?l14 ?..? a[.m pis me ? Ixa '#2a 15' B' EL7 pap p p9L 1 711EtEM CMAM TO HE n(STALLAD AMR= AR@A DTAMG CMET1iQLTRaN APPROXmtATE LIMITS OF NAVIGABLE WATER f 7N, ?ccRSa Y ? ? ?' { ., ."t tiAa a _M MASS RIMS SL'A GRASS ®.9 - - - - - - s? #i 1 SLIP p2 BLIP go SUP #113 SLIP 4e BLP ?? 99'-B. sur jl11 ZUGMUS HIM 811P p14 NO ENTRY SIGN r' Slip #4 BLIP 15 slip Ala ADDTTMNAL TCHBMTPT C13TTUM TO BE METAWZD 15 8' Bur to BLIP 15, G1C 18-8' sLtP pis SUP #15 AB4 5 13699 ?. iYC1M-G CONSTRUCTION ?-----iG' ?---2e' ' 4s^,?•-zip=-i APPRONDUTE 259 OF TM WATERWAY IM 144' OF I%.. p.1C ` u L{ 71:5 WATERIM CON3IRUCTI9N t!#I i C F2 ') i 0M, NC ont ol/ia?Om i1IG YYiF]M1ME OEFItIRIL'71EIQ N4 1 am 4408 Grady Ave. N C i TA rewar ru eee cwy FLE V?A7ERLINE Tampa FL 98814 p?rwafor Racy-mvfrorr CCI]f? rF f : ?p WNSTRUCT10N, IK, 818-896-1977 _ - _ - S d4 J 25! A i5 PAW F QF 7 wyw C (D E N O V) Q C m E 0- 0 al a) 0 O c 0 O w E W a, O E cu Q d Q REVISED EXHIBIT N-1 AGREEMENT • This Agreement (the "Agreement") is made as of this day of , 2007, by and between THE CITY OF CLEARWATER, FLORIDA, a Florida municipal corporation (the "City") and THE SANDPEARL RESORT, LLC, a Florida limited liability company (the "Developer"). WITNESSETH: WHEREAS, the City of Clearwater and Developer have entered into a Development Agreement for Property in the City of Clearwater dated January 26, 2005 and Amendment to Development Agreement for Property in the City of Clearwater dated 2007 (collectively the "Development Agreement"); WHEREAS, Section 5.03.10 of the Development Agreement provides for the City and Developer to enter into an agreement providing for the construction of shared boat docking facilities ("Boat Dock Facilities") within a boat basin ("Boat Basin') adjoining City owned upland property ("City Property"), which Boat Basin and Boat Docking Facilities are conceptually depicted on the attached Exhibit "A" ("Site Plan"); WHEREAS, the construction and use of the Boat Docking Facilities will further the objectives of the City and facilitate the development by Developer of the mixed use resort Project, as provided in the Development Agreement; WHEREAS, at a duly called public meeting on , 2007, the City Council approved this Agreement, and authorized and directed its execution by the appropriate officials of the City; and WHEREAS, the members of Developer have approved this Agreement and have authorized the undersigned individual to execute this Agreement on its behalf. NOW, THEREFORE, in consideration of the mutual promises and covenants contained herein, the parties hereby agree as follows: ARTICLE 1. DEFINITIONS. 1.01. Definitions. The capitalized terms used in this Agreement that are not defined shall have the meanings given to such terms in the Development Agreement. 1.02. Use of Words and Phrases. Words of the masculine gender shall be deemed and construed to include correlative words of the feminine and neuter genders. Unless the context shall otherwise indicate, the singular shall include the plural as well as the singular number, and the word "person" shall include corporations and associations, limited liability corporations and partnerships, including public bodies, as well as natural persons. "Herein," "hereby," "hereunder," "hereof," "hereinbefore," "hereinafter" and Amendment to Development Agreement Page 8 ADOPTED 9 0 other equivalent words refer to this Agreement and not solely to the particular portion thereof in which any such word is used. 1.03. Florida Statutes. All references herein to Florida Statutes are to Florida Statutes (2005), as amended from time to time. ARTICLE 2. PURPOSE AND DESCRIPTION OF BOAT DOCKING FACILITIES. 2.01. Finding of Public Purpose and Benefit. The proposed Boat Docking Facilities, including the design, construction, completion and use of the Boat Docking Facilities, is hereby found by the parties hereto: (1) to be consistent with and in furtherance of the objectives of the Comprehensive Plan of the City of Clearwater, (2) to conform to the provisions of Florida law, (3) to be in the best interests of the citizens of the City, (4) to further the purposes and objectives of the City, (5) to further the public interest on Clearwater Beach, and (6) to implement Beach by Design, including the creation of the new quality hotel resort to be constructed as a part of the Project. 2.02. Purpose of Agreement. The purpose of this Agreement is to further the implementation of Beach by Design by providing for the development of the Boat Docking Facilities, all to enhance the quality of life, increase employment and improve the aesthetic and useful enjoyment of Clearwater Beach and the City, all in accordance with and in furtherance of the Comprehensive Plan of the City of Clearwater and as authorized by and in accordance with the provisions of Florida law. 2.03. Scope of the Project. The Boat Docking Facilities are contemplated to include a central pier, finger piers and associated pilings as conceptually depicted on the attached Exhibit "A", which will accommodate a maximum of 42 boat slips ("Boat Slips"). The Developer and its designated successors and assigns shall have the right to utilize exclusively 27 of the Boat Slips which are identified on the Site Plan ("Developer Slips") and the finger piers containing the Developer Slips ("Developer Piers"). The City shall have the right to control the use of the central pier, the 15 remaining Boat Slips ("City Slips") and the finger piers containing the City Slips. The City shall have the right to utilize the City Slips during the term of this Agreement for day docking or for any other purpose. Boats shall not be permitted to occupy the City Slips and no access shall be permitted to the City Slips during the period each night between midnight and 5:00 a.m., except in an emergency or as authorized by the City Harbor Master. The foregoing restriction on overnight use of the City Slips shall not be applicable to a fireboat or other boats operated by the City or other municipal or governmental entities for public purposes ("Governmental Vessels"). 2. The Developer shall have the right to install gates or other access control improvements on the finger piers containing the Developer Slips and the right to install boat lifts in the Developer Slips ("Slip Improvements"). Developer shall also install gates on the finger piers containing the City Slips or on the central pier as directed by the City. Developer shall have the right to obtain at Developer's expense required access devices for 24/7 access to Developer Slips. The Boat Docking Facilities including Slip Improvements are subject to the following additional requirements and limitations: Amendment to Development Agreement Page 9 ADOPTED • 0 (a) Only low profile pilings and/or tie poles shall be used in the Boat Docking Facilities. As used in this Agreement, the term "low profile" means having a height of four (4) feet or less above the height of the decking of the dock. (b) No covered Boat Slips are allowed. (c) No boat lifts are permitted on 40 foot or larger slips. (d) Boat lifts shall not be installed in more than 13 of the 27 Developer Slips or in more than 50% of the total Developer Slips if the number of Developer Slips is reduced from 27. (e) No fuel containers shall be transported across the central pier or finger piers, nor any refueling of any vessels be done at this facility. 3. The Developer shall have the right, at its expense, to install water and electric lines serving the Developer Slips and the City shall cooperate as to extension and connection of such utilities. All utilities provided to the Developer Boat Slips shall be separately metered and Developer shall pay all utility connection and usage charges. Developer shall also provide lighting for the Boat Docking Facilities and pay all electric expenses as to such lighting. Utilities shall not be provided by Developer to the' City Slips, provided, that at the request of the City, utilities (water and electric) shall be provided to City Slips to be used by Governmental Vessels and City shall reimburse Developer for additional expenses incurred by Developer as to such utilities. 4. Developer shall provide and pay for all maintenance and repair costs for the Boat Docking Facilities. Developer shall also provide, at its expense, for all required trash removal from the Boat Docking Facilities. All normal operating expenses incurred by Developer as to the Boat Docking Facilities including maintenance, repairs, insurance premiums and cost of trash removal excluding utilities provided to Developer Slips are collectively referred to as the Common Expenses. Developer shall comply with the minimum maintenance standards as provided in the attached Exhibit "C". 5. Developer agrees that use of the Developer Boat Slips shall be limited to owners, tenants and guests (including Beach Club members) of the Project and other owners and tenants that own or lease residences within the geographical area bordered on the West by the Gulf of Mexico, on the East by Clearwater Bay, on the North by Rockaway Street and on the South by Papaya Street. Any sublease or assignment by Developer of rights to utilize Developer Boat Slips shall be limited to such owners, tenants and guests and all subleases or assignments shall expressly prohibit parking on the City Property during use of the Developer Boat Slips. 6. During the term of this Agreement, Developer shall provide a shuttle service to the Boat Docking Facilities from the Project. Developer shall also provide at the Project an employee assigned to respond to problems at the Boat Docking Facilities on a 24 hour/ 7 day per week basis. Neither the City nor Developer shall have any obligation to provide on-site security at the Boat Docking Facilities. Amendment to Development Agreement Page 10 ADOPTED 2.04. Cooperation of the Parties. The City and the Developer recognize that the successful development of the Boat Docking Facilities and each component thereof is dependent upon the continued cooperation of the City and the Developer, and each agrees that it shall act in a reasonable manner hereunder, provide the other party with complete and updated information from time to time, with respect to the conditions such party is responsible for satisfying hereunder and make its good faith reasonable efforts to. ensure that such cooperation is continuous, the purposes of this Agreement are carried out to the full extent contemplated hereby and the Boat Docking Facilities are designed, constructed, completed and used as provided herein. ARTICLE 3. REGULATORY PROCESS. 3.01 Development Approvals and Permits. Applications for Development Approval. The Developer shall prepare and submit to the appropriate governmental authorities, including the City, applications for approval of all required permits ("Permits"), and all plans and specifications ("Plans and Specifications") necessary for the Boat Docking Facilities, and shall bear all costs of preparing such applications, applying for and obtaining such approvals and permits, including payment of any and all applicable application, inspection, and regulatory fees or charges. The City shall, to the extent possible, expedite review of all applications. The failure of this Agreement to address a particular permit, condition, or term of restriction shall not relieve the Developer of the necessity of complying with the law governing said permitting requirements, conditions, terms or restrictions. 2. City Cooperation and Assistance. The City shall cooperate with the Developer in obtaining all necessary Permits required for the constructibn, completion and use of the Boat Docking Facilities. If requested by the Developer and authorized by law, the City will join file or in the filing of any application for any Permit, or, alternatively, recommend to and urge any governmental authority that such Permit be issued or approved. . 3. City Authority Preserved. The City's duties, obligations, or responsibilities under any section of this Agreement, specifically including, but not limited to, this Section 3.02, shall not affect the City's right, duty, obligation, authority and power to act in its governmental or regulatory capacity in accordance with applicable laws, ordinances, codes or other building regulations. Notwithstanding any other provision of this Agreement, any required permitting, licensing or other regulatory approvals by the City shall be subject to the established procedures and substantive requirements of the City with respect to review and permitting of a project of a similar or comparable nature, size and scope. In no event shall the City, due to any provision of this Agreement, be obligated to take any action concerning regulatory approvals except through its established procedures and in accordance with applicable provisions of law. Amendment to Development Agreement Page 11 ADOPTED 0 0 ARTICLE 4. PLANS AND SPECIFICATIONS. 4.01. Plans and Specifications. Responsibility for Preparation of Plans and Specifications. The Developer shall be solely responsible for and shall pay the cost of preparing, submitting and obtaining approval of the Plans and Specifications for the Boat Docking Facilities. 2. Use of Qualified Professionals. The Developer shall retain qualified professionals to prepare the Plans and Specifications and shall cause such professionals to prepare the Plans and Specifications. ARTICLE 5. DEVELOPMENT OF BOAT DOCKING FACILITIES. 5.01. Ownership of City Property. The City is the owner the City Property which is more particularly described in Exhibit "B" to this Agreement. 5.02. Boat Basin. The Boat Basin in which the Boat Docking Facilities are to be constructed adjoins the City Property, is located on submerged lands owned by the City of Clearwater, and is depicted on the Site Plan attached as Exhibit "A". 5.03. Obligations of the City. 1. Lease of Boat Basin. This Agreement shall constitute a lease to Developer of the portion of the Boat Basin on which the Developer Slips and associated finger piers will be located (the "Leased Premises") together with the non-exclusive right to utilize the central pier and City Property for access to the Developer Slips. Developer shall pay City as rental for the Leased Premises, annual rental in the initial amount of $5,435.83 commencing on the date that the Boat Docking Facilities are completed and authorized for occupancy by the City ("Lease Commencement Date"). The annual rental shall be payable in arrears within ten (10) days after the first anniversary of the Lease Commencement Date and annually thereafter on or before each anniversary of the Lease Commencement Date. The annual rental shall be adjusted on the first day of each lease year in accordance with the annual increase in the consumer price index for urban wage earners and clerical wages for clerical workers for all items- U.S. City Average (cpi) published by the Bureau of Labor Statistics, United States Department of Labor (BLS), 1982-84-100. In the event the BLS shall cease to publish the CPI the City shall designate a comparable index for calculating increases in annual rental. The term of the lease shall be for the term of this Agreement as provided in Section 18.18 below. 2. Permits. The City will cooperate and coordinate with the Developer with regard to all Permit applications, including those to state agencies, and will facilitate or expedite, to the greatest extent possible, the permit approval process. 4. City Share of Common Expenses. City shall pay to the Developer its proportionate share of Common Expenses relating to the Boat Docking Facilities based on a percentage determined by dividing the number of City Slips by the total number of Boat Slips in the Boat Docking Facilities ("City's Share"). Amendment to Development Agreement Page 12 ADOPTED • • Developer shall invoice the City annually at the end of each lease year for City's Share of Common Expenses, such invoice to include an itemized statement of Common Expenses. Notwithstanding the foregoing, in no event shall City's Share of Common Expenses for any lease year exceed the amount of annual rental due from Developer to City. Developer shall bear the full amount of City's Share of Common Expenses in excess of the annual rental amount due to City. ARTICLE 6. PROJECT FINANCING. 6.01. Assignment of Rights Under Agreement To Project Lender. Developer may assign to the Project Lender all its right, title and interest under this Agreement as security for any indebtedness of Developer. The execution of any assignment, security agreement, or other instrument, or the foreclosure of the instruction or any sale under the instrument, either by judicial proceedings or by virtue of any power reserved in the mortgage or deed of trust, or conveyance in lieu of foreclosure by Developer to the holder of such indebtedness, or the existence of any right, power, or privilege reserved in any instrument, shall not be held as a violation of any of the terms or conditions of this Agreement, or as an assumption by the holder of such indebtedness personally of the obligations of this Agreement. No such assignment, foreclosure, conveyance or exercise of right shall relieve Developer from its liability under this Agreement. 6.02. Cooperation. The City and the Developer shall cooperate as to reasonable requests for assurances any proposed Project Lender for the purpose of implementing the mortgagee protection provisions contained in this Agreement and allowing the Project Lender reasonable means to protect or preserve the liens of such Project Lender upon the occurrence of a default under the terms of this Agreement. ARTICLE 7. CONSTRUCTION OF PROJECT. 7.01. Site. The Developer shall be responsible for all site investigation and environmental testing. 7.02. Construction of Boat Docking Facilities. a. Commencement. Developer shall construct the Boat Docking Facilities substantially in accordance with the Plans and Specifications therefore approved by the City. The Boat Docking Facilities include certain improvements to the City Property/Boat Basin consisting of approximately 100 - 200 feet of new seawall cap as determined to be required by Rube Clarson, P.E.. Developer shall commence construction of the Boat Docking Facilities ("Construction Commencement Date") on or before one (1) year after receipt of all Permits, and expiration or resolution of all appeal/challenges thereto ("Approval Effective Date"). b. For purposes of this Section 7.02, "commence construction" means commencement of meaningful physical development of the Boat Docking Facilities as authorized by the Permits therefor which is continued and diligently prosecuted toward completion of the Boat Docking Facilities. Amendment to Development Agreement Page 13 ADOPTED 9 0 C. All obligations of Developer (including deadlines in the Construction Commencement Date) with respect to commencement and continuation of construction shall be subject to delays and extensions from time to time for Unavoidable Delay (see Article 15). Developer shall not be deemed to be in default of this Agreement to the extent construction of the Boat Docking Facilities, or a part thereof, is not complete by reason of Unavoidable Delay. 2. Pursuit of Construction. After the Construction Commencement Date, Developer shall continue, pursue and prosecute the construction of the Boat Docking Facilities with due diligence to completion, and shall not at any time actually or effectively have abandoned (or its Contractor having actually or effectively abandoned) the Boat Docking Facilities. For purposes of this subsection 7.02.2, "abandoned" means to have ceased any construction work which effectively advances the construction of the Boat Docking Facilities toward completion, including removing all or substantially all of the construction work force from the site of the Boat Docking Facilities for a period of not less than sixty (60) days. 3. Maintenance of Construction Site. During the construction of the Boat Docking Facilities, Developer shall, at its own expense, keep the Boat Docking Facilities and all adjoining City Property in reasonably good order and condition. 4. Construction Completion. Developer agrees to complete the Boat Docking Facilities on or before one (1) year after the Construction Commencement Date. 7.03. City Not in Privity. The City shall not be deemed to be in privity of contract with any Contractor or provider of services with respect to the construction of any part of the Boat Docking Facilities not constituting all or any part of public improvements. 7.04. Construction Sequencing and Staging Area. The Developer shall construct the Boat Docking Facilities in a manner and fashion which will minimize the inconvenience of the construction on the property owners of Clearwater Beach and the residents of the City and the use of the City Property. The City agrees to allow Developer to use portions of the City Property as designated by the City for construction staging during construction of the Boat Docking Facilities, without charge to the Developer, provided that such staging area does not unreasonably affect the continued use of the City Property. ARTICLE 8. INDEMNIFICATION. 8.01. Indemnification by the Developer. The Developer agrees to indemnify, defend and hold harmless, the City, its respective agents, officers, or employees from any and all liabilities, damages, penalties, judgments, claims, demands, costs, losses, expenses or attorneys' fees through appellate proceedings, for personal injury, bodily injury, death or property damage arising out of, or by reason of any act or omission of the Developer, its agents, employees or contractors arising out of, in connection with or by reason of, the performance of any and all services covered by this Agreement, or which are alleged to have arisen out of, in connection with or by reason of, the performance of any and all services covered by this Agreement. Amendment to Development Agreement Page 14 ADOPTED 0 0 2. The Developer shall indemnify, defend and hold harmless the City, its officers and employees from any and all liabilities, damages, costs, penalties, judgments, claims, demands, losses, or expenses (including, but not limited to, actual attorneys' fees and engineering fees) arising from or attributable to any breach by the Developer, as the case may be, of any representations or warranties contained in Section 9.01, or covenants contained in Section 9.02. 3. The Developer's indemnity obligations under subsections (1) and (2) of this Section shall survive the earlier of the Termination Date or the Expiration Date, but shall apply only to occurrences, acts, or omissions that arise on or before the earlier of the Termination Date or the Expiration Date. 4. The Developer's indemnity hereunder is in addition to and not limited by any insurance policy and is not and shall not be interpreted as an insuring agreement between or among the parties to this Agreement, nor as a waiver of sovereign immunity for any party entitled to assert the defense of sovereign immunity. 8.02. Indemnification by the City. To the extent permitted by law, the City agrees to indemnify, defend and hold harmless, the Developer, its respective officers, and employees from any and all liabilities, damages, penalties, judgments, claims, demands, costs, losses, expenses or attorneys' fees through appellate proceedings, for personal injury, bodily injury, death or property damage arising out of, or by reason of, any act or omission of the City, its respective agents or employees arising out of, in connection with or by reason of, the performance of any and all services covered by this Agreement, or which are alleged to have arisen out of, in connection with or by reason of, the performance of any and all services covered by this Agreement. 2. The City shall indemnify, defend and hold harmless the Developer, its officers and employees from any and all liabilities, damages, costs, penalties, judgments, claims, demands, losses, or expenses (including, but not limited to, actual attorneys' fees and engineering fees) arising from or attributable to any breach by the City, as the case may be, of any representations or warranties contained in Section 10.01, or covenants contained in Section 10.02. 3. The City's indemnity obligations under this Section 8.02 shall survive the earlier of the Termination Date or the Expiration Date, but shall only apply to occurrences, acts or omissions that arise on or before the earlier of the Termination Date or the Expiration Date. The City's indemnity hereunder is not and shall not be interpreted as an insuring agreement between or among the parties to this Agreement, but is in addition to and not limited by any insurance policy provided that said obligation shall not be greater than that permitted and shall be limited by the provisions of Section 768.28, Florida Statutes, or any successor statute thereto. 8.03. Limitation of Indemnification. Notwithstanding anything to the contrary contained herein, with respect to the indemnification obligations of the Developer (as set forth in Section 8.01) and the City (as set forth in Section 8.02), the following shall apply: Amendment to Development Agreement Page 15 ADOPTED 0 0 The indemnifying party shall not be responsible for damages that could have been, but were not, mitigated by the indemnified party; 2. The indemnifying party shall not be responsible for that portion of any damages caused by the negligent or willful acts or omissions of the indemnified party; and 3. There shall be no obligation to indemnify hereunder in the event that the indemnified party (1) shall have effected a settlement of any claim without the prior written consent of the indemnifying party, or (2) shall not have subrogated the indemnifying party to the indemnified party's rights against any third party by an assignment to the indemnifying party of any cause or action against such third party. ARTICLE 9. REPRESENTATIONS, WARRANTIES AND COVENANTS OF THE DEVELOPER. 9.01. Representations and Warranties. The Developer represents and warrants to the City that each of the following statements is currently true and accurate and agrees the City may rely upon each of the following statements: The Developer is a Florida Limited Liability Company duly organized and validly existing under the laws of the State of Florida, has all requisite power and authority to carry on its business as now conducted, to own or hold its properties and to enter into and perform its obligations hereunder and under each document or instrument contemplated by this Agreement to which it is or will be a party, is qualified to do business in the State of Florida, and has consented to service of process upon a designated agent for service of process in the State of Florida. 2. This Agreement and, to the extent such documents presently exist in a form accepted by the City and the Developer, each document contemplated or required by this Agreement to which the Developer is or will be a party have been duly authorized by all necessary action on the part of, and have been or will be duly executed and delivered by, the Developer, and neither the execution and delivery thereof, nor compliance with the terms and provisions thereof or hereof: (i) requires the approval and consent of any other party, except such as have been duly obtained or as are specifically noted herein, (ii) contravenes any existing law, judgment, governmental rule, regulation or order applicable to or binding on the Developer, (iii) contravenes or results in any breach of, default under or, other than as contemplated by this Agreement, results in the creation of any lien or encumbrance upon any property of the Developer under any indenture, mortgage, deed of trust, bank loan or credit agreement, the Developer's Articles of Organization, or, any other agreement or instrument to which the Developer is a party or by which the Developer may be bound. 3. This Agreement and, to the extent such documents presently exist in a form accepted by the City and the Developer, each document contemplated or required by this Agreement to which the Developer is or will be a party constitutes, or when entered into will constitute, a legal, valid and binding obligation of the Developer enforceable against the Developer in accordance with the terms thereof, except as such enforceability may be limited by applicable bankruptcy, insolvency or similar laws from time to time in effect which affect Amendment to Development Agreement Page 16 ADOPTED 0 0 creditors' rights generally and subject to usual equitable principles in the event that equitable remedies are involved. 4. There are no pending or, to the knowledge of the Developer threatened actions or proceedings before any court or administrative agency against the Developer, or against any controlling shareholder, officer, employee or agent of the Developer. which question the validity of this Agreement or any document contemplated hereunder, or which are likely in any case, or in the aggregate, to materially adversely affect the consummation of the transactions contemplated hereunder or the financial condition of the Developer. 5. The Developer has filed or caused to be filed all federal, state, local and foreign tax returns, if any, which were required to be filed by the Developer and has paid, or caused to be paid, all taxes shown to be due and payable on such returns or on any assessments levied against the Developer. 6. All documentation, including that pertaining to the Boat Docking Facilities or the Developer, delivered by the Developer to the City was, on the date of delivery thereof, true and correct. 7. The principal place of business and principal executive offices of the Developer is in St. Petersburg, Florida, and the Developer will keep records concerning the Boat Docking Facilities (such as construction contracts, financing documents and corporate documents) and all contracts, licenses and similar rights relating thereto at an office in Pinellas County. 8. As of the Effective Date, the Developer will have the financial capability to carry out its obligations and responsibilities in connection with the development of the Boat Docking Facilities as contemplated by this Agreement. 9. The Developer has the experience, expertise, and capability to develop, cause the construction, and complete the Boat Docking Facilities and, oversee and manage the design, planning, construction, completion and use of the Boat Docking Facilities. 9.02. Covenants. The Developer covenants with the City that until the earlier of the Termination Date or the Expiration Date: The Developer shall timely perform or cause to be performed all of the obligations contained herein which are the responsibility of the Developer to perform. 2. During each year that this Agreement and the obligations of the Developer under this Agreement shall be in effect, the Developer shall cause to be executed and to continue to be in effect those instruments, documents, certificates, permits, licenses and approvals and shall cause to occur those events contemplated by this Agreement that are applicable to, and that are the responsibility of, the Developer. 3. The Developer shall assist and cooperate with the City to accomplish the development of the Boat Docking Facilities by the Developer in accordance with Amendment to Development Agreement Page 17 ADOPTED 0 0 the Plans and Specifications, and this Agreement, and will not violate any laws, ordinances, rules, regulations, orders, contracts or agreements that.are or will be applicable thereto. 4. Subsequent to the Effective Date, the Developer shall maintain its financial capability to develop, construct and complete the Boat Docking Facilities and shall promptly notify the City of any event, condition, occurrence, or change in its financial condition which adversely affects, or with the passage of time is likely to adversely affect, the Developer's financial capability to successfully and completely develop, construct and complete the Boat Docking Facilities as contemplated hereby. 5. The Developer shall promptly cause to be filed when due all federal, state, local and foreign tax returns required to be filed by it, and shall promptly pay when due any tax required thereby. 6. Subject to Section 18.01, the Developer shall maintain its existence, will not dissolve or substantially dissolve all of its assets and will not consolidate with or merge into another corporation, limited partnership, or other entity or permit one or more other corporations or other entity to consolidate with or merge into it without the prior approval of the City unless the Developer or an entity under common control.with Developer, retains a controlling interest in the consolidated or merged entity, and will promptly notify the City of any changes to the existence or form of the entity or any change in the control of the Developer. 7. The Developer shall not permit, commit, or suffer any waste of the City Property, the Boat Basin or the Boat Docking Facilities. 8. Provided all conditions precedent thereto have been satisfied or waived as provided herein, the Developer shall design, construct and complete the Boat Docking Facilities such that it is substantially complete as provided in this Agreement no later than the Completion Date. ARTICLE 10. REPRESENTATIONS, WARRANTIES AND COVENANTS OF THE CITY. 10.01. Representations and Warranties. The City represents and warrants to the Developer that each of the following statements is currently true and accurate and agrees that the Developer may rely on each of the following statements: The City is a validly existing body corporate and politic of the State of Florida, has all requisite corporate power and authority to carry on its business as now conducted and to perform its obligations hereunder and under each document or instrument contemplated by this Agreement to which it is or will be a party. 2. This Agreement and, to the extent such documents presently exist in a form accepted by the City and the Developer, each document contemplated or required by this Agreement to which the City is or will be a party have been duly authorized by all necessary action on the part of, and have been or will be duly executed and delivered by, the City, and neither the execution and delivery thereof, nor compliance with the terms and provisions thereof or hereof (i) requires the approval and consent of any other party, except such as have been Amendment to Development Agreement Page 18 ADOPTED • duly obtained or as are specifically noted herein, (ii) contravenes any existing law, judgment, governmental rule, regulation or order applicable to or binding on the City, (iii) contravenes or results in any breach of, or default under or, other than as contemplated by this Agreement, results in the creation of any lien or encumbrance upon any property of the City under any indenture, mortgage, deed of trust, bank loan or credit agreement, applicable ordinances, resolutions or, on the date of this Agreement, any other agreement or instrument to which the City is a party, specifically including any covenants of any bonds, notes, or other forms of indebtedness of the City outstanding on the Effective Date. 3. This Agreement and, to the extent such documents presently exist in a form accepted by the City and the Developer, each document contemplated or required by this Agreement to which the City is or will be a party constitute, or when entered into will constitute, legal, valid and binding obligations of the City enforceable against the City in accordance with the terms thereof, except as such enforceability may be limited by public policy or applicable bankruptcy, insolvency or similar laws from time to time in effect which affect creditors' rights generally and subject to usual equitable principles in the event that equitable remedies are involved. 10.02. Covenants. The City covenants with the Developer that until the earlier of the Termination Date or the Expiration Date: The City shall timely perform, or cause to be performed, all of the obligations contained herein which are the responsibility of the City to perform. 2. During each year that this Agreement and the obligations of the City under this Agreement shall be in effect, the City shall cause to be executed and to continue to be in effect those instruments, documents, certificates, permits, licenses and approvals, and shall cause to occur those events contemplated by this Agreement that are applicable to and are the responsibility of the City. 3. The City shall assist and cooperate with the Developer to accomplish the development of the Boat Docking Facilities in accordance with this Agreement and the Plans and Specifications, will carry out its duties and responsibilities contemplated by this Agreement, and will not violate any laws, ordinances, rules, regulations, orders, contracts, or agreements that are or will be applicable thereto, and, to the extent permitted by law, the City will not enact or adopt or urge or encourage the adoption of any ordinances, resolutions, rules regulations or orders or approve or enter into any contracts or agreements, including issuing any bonds, notes, or other forms of indebtedness, that will result in any provision of this Agreement to be in violation thereof. 4. The City shall not permit, commit, or suffer any waste or impairment to the Boat Docking Facilities, nor shall the City alter the City Property, or any part thereof, so as to prevent or adversely affect the development and use of the Boat Docking Facilities. ARTICLE 11. CONDITIONS PRECEDENT. Amendment to Development Agreement Page 19 ADOPTED 0 0 11.01. Developer Obligations. Unless this Agreement has been terminated pursuant to Article 12 hereof, the obligation of the Developer to construct the Boat Docking Facilities is subject to the fulfillment to the satisfaction of, or waiver in writing by, the Developer of each of the following conditions precedent: All conditions precedent under Article 11 of the Development Agreement have been satisfied or waived by Developer. 2. The Plans and Specifications required to commence construction of the Boat Docking Facilities shall have been approved by the City in accordance with applicable ordinances, land use regulations, building codes and other regulations of the City. 3. All Permits necessary for construction of the Boat Docking Facilities to commence shall have been issued and have become final and non-appealable. 11.02. Responsibilities of the Parties for Conditions Precedent. The parties hereto shall not, individually or collectively, knowingly, intentionally or negligently prevent any condition precedent from occurring; provided, however, nothing in this Section is intended or shall be deemed to deny any party the right to reasonably exercise its discretion to the extent permitted by law or this Agreement. ARTICLE 12. DEFAULT; TERMINATION. 12.01. Project Default by the Developer. There shall be an "event of default" by the Developer under this Agreement upon the occurrence of any one or more of the following: a. The Developer shall fail to perform or comply with any material provision of this Agreement applicable to it within the time prescribed therefor, after receipt of a notice from the City pursuant to Subsection 12.01.2.a.; or b. The Developer shall make a general assignment for the benefit of its creditors, or shall admit in writing its inability to pay. its debts as they become due or shall file a petition in bankruptcy, or shall be adjudicated a bankrupt or insolvent, or shall file a petition seeking any reorganization, arrangement, composition, readjustment, liquidation, dissolution or similar relief under any present or future statute, law or regulation or shall file an answer admitting, or shall fail reasonably to contest, the material allegations of a petition filed against it in any such proceeding, or shall seek or consent to or acquiesce in the appointment of any trustee, receiver or liquidator of the Developer or any material part of such entity's properties; or c. Within sixty (60) days after the commencement of any proceeding by or against the Developer seeking any reorganization, arrangement, composition, readjustment, liquidation, dissolution or similar relief under any present or future statute, law or regulation, such proceeding shall not have been dismissed or otherwise terminated, or if, within sixty (60) days after the appointment without the consent or acquiescence of the Amendment to Development Agreement Page 20 ADOPTED 0 0 Developer of any trustee, receiver or liquidator of any of such entities or of any material part of any of such entity's properties, such appointment shall not have been vacated; or 2. a. If an event of default by the Developer described in subsection 1 above shall occur, the City shall provide written notice thereof to the Developer, and, if such event of default shall not be cured by the Developer within thirty (30) days after receipt of the written notice from the City specifying in reasonable detail the event of default by the Developer, or if such event of default is of such nature that it cannot be completely cured within such time period, then if the Developer shall not have commenced to cure such default within such thirty (30) day period and shall not diligently prosecute such cure to completion within such reasonable longer period of time as may be necessary (provided, however, if the Developer is proceeding diligently and in good faith, the curative period shall be extended for a period of not exceeding six (6) months without any approval or consent of the City being required, but such approval will be required if the curative period is to be extended beyond six (6) months) then, in addition to any remedy available under Section 12.05, the City may terminate this Agreement or pursue any and all legal or equitable remedies to which the City is entitled, provided, however, if the Developer shall fail to cure such event of default within said thirty (30) day or longer period or ceases to proceed diligently to timely cure such event of default, then the City may proceed to enforce other available remedies without providing any additional notice to the Developer. b. Any attempt by the City to pursue any of the above referenced remedies will not be deemed an exclusive election of remedy or waiver of the City's right to pursue any other remedy to which either may be entitled. C. Any time periods or deadlines provided in this Agreement shall be tolled or extended by the amount of time to cure any event of default hereunder if such event affects the Developer's or City's ability to perform by such deadline or the expiration of such period. 3. Subject to the rights of the Project Lender, if the City elects to cure a default under Subsection 12.01.1. by the Developer, construction contracts, contract documents, building permits, development permits, management agreements, and financial commitments (all only to the extent assignable) with respect to the Project shall, if such default has not been previously cured, on the day following receipt by the Developer of notice from the City of its election to cure, be deemed then assigned to the City making said election, without necessity of any other action being taken or not taken by any party hereto. The Developer shall transfer and deliver to the City upon making said election, all assignable Plans and Specifications, working drawings, construction contracts, contract documents and all Permits, and, at the direction of the City, the Developer shall vacate the Leased Premises. Amendment to Development Agreement Page 21 ADOPTED 0 0 12.02. Default by the City. Provided the Developer is not then in default under Section 12.01, there shall be an "event of default" by the City under this Agreement in the event the City shall fail to perform or comply with any material provision of this Agreement applicable to it; provided, however, that suspension of or delay in performance by the City during any period in which the Developer is in default of this Agreement as provided in Section 12.01 hereof will not constitute an event of default by the City under this Subsection 12.02. 2. a. If an event of default by the City described in Subsection 12.02.1. shall occur, the Developer shall provide written notice thereof to the City, and, after expiration of the curative period described in paragraph (b) below, may terminate this Agreement, institute an action to compel specific performance of the terms hereof by the City or pursue any and all legal or equitable remedies to which the Developer is entitled; provided, however, if the event of default by the City occurs, any monetary recovery by the Developer in any such action shall be limited to bona fide third-party out of-pocket costs and expenses, including reasonable attorneys' fees, incurred by the Developer in connection with this Agreement and the transactions contemplated hereby, unless any such default by the City was willful and committed in bad faith with reckless disregard for the rights of the Developer. b. The Developer may not terminate this Agreement or institute an action described in paragraph (2a) above if the City cures such event of default within thirty (30) days after receipt by the City of written notice from the Developer specifying in reasonable detail the event of default by the City, or if any such event of default is of such nature that it cannot be completely cured within such period, then within such reasonably longer period of time as may be necessary to cure such default, provided however, if the City is proceeding diligently and in good faith, the curative period shall be extended for a period of not exceeding six (6) months without any approval or consent of the Developer being required, but such approval will be required if the curative period is to be extended beyond six (6) months after the notice of default has been given by the Developer to the City if the City has commenced to cure such default within such thirty (30) day period and is diligently prosecuting such curative action to completion. The City shall within said thirty (30) day period or such longer period promptly, diligently and in good faith proceed to cure such event of default after receipt of the notice from the Developer and shall succeed in curing such event of default within said period of time, provided, however, if the City shall fail to cure such event of default within said thirty (30) day or longer period or ceases to proceed diligently to timely cure such event of default, then the Developer may proceed with its available remedies without providing any additional notice to the City. C. Any attempt by the Developer to pursue any of the remedies referred to in paragraphs a. and b. above will not be deemed an exclusive election of Amendment to Development Agreement Page 22 ADOPTED 0 • remedy or waiver of the Developer's right to pursue any other remedy to which it might be entitled. d. Any time periods or deadlines provided in this Agreement shall be tolled or extended by the amount of time to cure any event of default hereunder if such event affects the Developer's or City's ability to perform by such deadline or the expiration of such period. 12.03. Obligations, Rights and Remedies Cumulative. Unless specifically stated herein to the contrary, the specified rights and remedies to which either the City or the Developer are entitled under this Agreement are not exclusive and are intended to be in addition to any other remedies or means of redress to which the City or the Developer may lawfully be entitled and are not specifically prohibited by this Agreement. The suspension of, or delay in, the performance of its obligations by the Developer while the City shall at such time be in default of their obligations hereunder shall not be deemed to be an "event of default." The suspension of, or delay in, the performance of the obligations by the City while the Developer shall at such time be in default of its obligations hereunder shall not be deemed to be an "event of default" by the City. 12.04. Non-Action on Failure to Observe Provisions of this Agreement. The failure of the City or the Developer to promptly or continually insist upon strict performance of any term, covenant, condition or provision of this Agreement, or any Exhibit hereto, or any other agreement, instrument or document of whatever form or nature contemplated hereby shall not be deemed a waiver of any right or remedy that the City or the Developer may have, and shall not be deemed a waiver of a subsequent default or nonperformance of such term, covenant, condition or provision. Amendment to Development Agreement Page 23 ADOPTED 0 0 12.05. Termination Prior to Commencement of Project. The Developer and the City acknowledge and agree that as of the Effective Date certain matters mutually agreed by the parties hereto to be essential to the successful development of the Boat Docking Facilities have not been satisfied or are subject to certain conditions, legal requirements or approvals beyond the control of any of the parties hereto or which cannot be definitely resolved under this Agreement, including, but not limited to, failure of a governmental authority to grant an approval required for development of the Boat Docking Facilities. In recognition of these events or conditions, the parties hereto mutually agree that, provided the appropriate or responsible party therefor diligently and in good faith seeks to the fullest extent of its capabilities to cause such event or condition to occur or be satisfied, the failure of the events or conditions listed in subsection 2. below to occur or be satisfied shall not constitute an event of default by any party under this Article 12, but may, upon the election of any party hereto, be the basis for a termination of this Agreement in accordance with this Section. 2. In addition to any other rights of termination provided elsewhere in this Agreement, prior to commencement of the Boat Docking Facilities, this Agreement may be terminated as provided in subsection 3. of this section by the City or the Developer after the occurrence of any of the following events or conditions (except for subsection b. , in which event only the Developer may terminate this Agreement pursuant to this subsection 2.): a. The appropriate governmental authority (including the City in exercise of its governmental and regulatory authority and responsibility), upon petition by the Developer denies or fails to: issue the Permits, or issue any other approval necessary to commence construction of the Boat Docking Facilities, provided the Developer has proceeded diligently, expeditiously and in good faith to obtain such Permits or other necessary actions; b. A previously unknown site condition is subsequently discovered and that condition prevents successful development of the Boat Docking Facilities. 3. Upon the occurrence of an event described in subsection 2. or in the event that the Developer or the City, after diligently and in good faith to the fullest extent its capabilities, is unable to cause a condition precedent to its respective obligations to occur or be satisfied, then the Developer or the City may elect to terminate this Agreement by giving a notice to the other party hereto within thirty (30) days of the occurrence of such event or the determination of inability to cause a condition precedent to occur or be satisfied, stating its election to terminate this Agreement as a result thereof, in which case this Agreement shall then terminate. 4. In the event of a termination pursuant to this Section 12.05, neither the Developer nor the City shall be obligated or liable one to the other in any way, financially or otherwise, for any claim or matter arising from or as a result of this Agreement or any actions taken by the Developer and the City, or any of them, hereunder or contemplated hereby, and each party shall be responsible for its Amendment to Development Agreement Page 24 ADOPTED 0 0 own costs, however, the provisions of Sections 9.01 and 10.01 shall apply and shall survive termination of this Agreement, the provisions of this Subsection 12.05.4 to the contrary notwithstanding. 12.06. Termination Certificate. In the event of a termination of this Agreement for any reason prior to the Expiration Date, each of the parties hereto do covenant and agree with each other to promptly execute a certificate prepared by the party electing to terminate this Agreement, which certificate shall expressly state that this Agreement has been terminated in accordance with its terms, is no longer of any force and effect except for those provisions hereof which expressly survive termination, that the rights, duties and obligations of the parties hereto have been terminated and released (subject to those surviving provisions hereof) and that the Boat Basin is no longer subject to any restrictions, limitations or encumbrances imposed by this Agreement. 2. The certificate described in Subsection 1. shall be prepared in a form suitable for recording and promptly after execution by all of the parties hereto shall be recorded in the public records of Pinellas County, Florida. ARTICLE 13. RIGHT TO CONTEST. 13.01. Right to Contest. Subject to the conditions set forth in Section 13.02 below, the City or the Developer each may, at its sole discretion and expense, after prior written notice to the other parties hereto, contest by appropriate action or proceeding conducted in good faith and with due diligence, the amount or validity or application, in whole or in part, of any lien, any payment of any taxes, assessments, impact fees or other public charges of a similar nature that may from time to time be levied upon or assessed by any appropriate governmental authority against the City, the Developer, the Boat Docking Facilities (or any part thereof), the Boat Basin or personal property thereon, and the revenues generated from the use or operation of any or all of the above, any other payment specifically identified in this Agreement, or compliance with any law, rule, regulation, or other such legal requirement. 13.02. Conditions. The right to contest any charge, payment or requirement pursuant to Section 13.01 is subject to the following: Such proceeding shall suspend the execution or enforcement of such charge, payment or requirement; 2. Such proceeding will not create any risk of impairment of the construction, completion, operation or use of the Boat Docking Facilities or any part thereof, in any material respect, and no portion of the Boat Docking Facilities would be subject to any risk of being involuntarily sold, forfeited or lost or the construction, equipping, or completion of the Boat Docking Facilities or any part thereof be delayed or prohibited; 3. Such proceeding will not subject any other party to criminal liability or risk of material civil liability for failure to comply therewith, or involve risk of any material claim against such party; and Amendment to Development Agreement Page 25 ADOPTED 0 . 0 4. The party seeking the benefit of this Article shall have furnished to the other parties such security, if any, as may be required in such proceeding or as may be reasonably requested by the others, to protect the Boat Docking Facilities and any part thereof, and any interest of such parties hereunder. ARTICLE 14. ARBITRATION 14.01. Agreement to Arbitrate. Only as specifically provided in this Agreement and only if any judicial or administrative action or proceeding has not been commenced with regard to the same matter and, if so, the party hereto commencing such action has not dismissed it, any disagreement or dispute between the parties may be arbitrated in the manner set forth in this Article 14. All parties hereby agree such arbitration, once commenced, shall be the exclusive procedure for resolving such disagreement or dispute and agree to be bound by the result of any such arbitration proceeding unless all parties mutually agree to terminate such proceeding prior to decision. If any arbitration proceeding under this part adversely affects the performance of any party hereunder, then any time periods provided herein for such performance by that party shall be tolled during the pendency of the arbitration proceeding affecting such performance. 14.02. Appointment of Arbitrators. a. Unless accelerated arbitration as provided in Section 14.08 hereof is invoked, any party invoking arbitration herewith shall, within five (5) days after giving notice of impasse in the dispute resolution process or upon following the expiration of the time period for such dispute resolution occurrence of the event permitting arbitration to be invoked, give written notice to that effect to the other parties, and shall in such notice appoint a disinterested person who is on the list of qualified arbitrators maintained by the American Arbitration Association or a disinterested person not on such list to whom an objection is not made by any other party hereto within five (5) days of receipt of the notice of such appointment as.the arbitrator or, if more than one (1) arbitrator is to be appointed, as one of the arbitrators. b. Within ten (10) days after receipt of the notice described in paragraph (1), the other parties shall by written notice to the original party acknowledge that arbitration has been invoked as permitted by this Agreement, and shall either accept and approve the appointment of such individual set forth in the original notice as a sole arbitrator or shall appoint one (1) disinterested person per party of recognized competence in such field as an arbitrator. 2. a. If two (2) arbitrators are appointed pursuant to subsection a. above, the arbitrators thus appointed shall appoint a third disinterested person who is on the list of qualified arbitrators maintained by the American Arbitration Association, and such three (3) arbitrators shall as promptly as possible determine such matter. Amendment to Development Agreement Page 26 ADOPTED 0 0 b. If the second arbitrator shall not have been appointed as provided in subsection a., the first arbitrator shall; after ten (10) days notice to the parties, proceed to determine such matter. C. If the two (2) arbitrators appointed by the parties pursuant to subsection a. shall be unable to agree within fifteen (15) days after the appointment of the second arbitrator upon the appointment of a third arbitrator, they shall give written notice of such failure to agree to the parties, and, if the parties then fail to agree upon the selection of such third arbitrator within fifteen (15) days thereafter, then within ten (1.0) days thereafter each of the parties upon written notice to the other parties hereto may request the appointment of a third arbitrator by the office in or for the State of Florida (or if more than one office, the office located closest to the City) of the American Arbitration Association (or any successor organization thereto), or, in its absence, refusal, failure or inability to act, request such appointment of such arbitrator by the United States District Court for the Middle District of Florida (which request shall be filed in the division of that court responsible for the geographic area including the City), or as otherwise provided in Chapter 682, Florida Statutes, known and referred to as the Florida Arbitration Act, as amended. 14.03. General Procedures. In any arbitration proceeding under this part, those parties appointing arbitrators shall each be fully entitled to present evidence and argument to the sole arbitrator or panel of arbitrators. The arbitrator or panel of arbitrators shall only interpret and apply the terms of this Agreement and may not change any such terms, or deprive any party to this Agreement of any right or remedy expressed or implied in this Agreement, or award any damages or other compensation to any party hereto. The arbitration proceedings shall follow the rules and procedures of the American Arbitration Association (or any successor organization thereto) unless specifically modified by this Agreement, or as then agreed to by the parties hereto. 14.04. Majority Rule. In any arbitration proceeding under this part, the determination of the majority of the panel of arbitrators, or of the sole arbitrator. if only one (1) arbitrator is used, shall be conclusive upon the parties and judgment upon the same may be entered in any court having jurisdiction thereof. The arbitrator or panel of arbitrators shall give written notice to the parties stating his or their determination within thirty (30) days after the conclusion of the hearing or final submission of all evidence or argument. 14.05. Replacement of Arbitrator. In the event of the failure, refusal or inability of any arbitrator to serve as such, promptly upon such determination being made by the affected arbitrator, the affected arbitrator shall give notice to the other two (2) arbitrators (if applicable) and to the parties hereto, and then a new arbitrator shall be promptly appointed as a replacement, which appointment shall be made by the party or the arbitrators who appointed the affected arbitrator in the same manner as provided for in the original appointment of the affected arbitrator in Section 14.02 hereof. 14.06. Decision of Arbitrators. If any decision reached by arbitration as provided in this part requires performance by the Developer, the Developer covenants and agrees to comply with any decision of the arbitrator(s) promptly after the date of receipt by the Amendment to Development Agreement Page 27 ADOPTED Developer of such decision, and to continue such performance to completion with due diligence and in good faith. 2. If any such decision requires performance by the City, the City covenants and agrees to comply promptly with any decision reached by arbitrators) promptly after the date of receipt by the City of such decision, and to continue such performance to completion with due diligence and in good faith. 3. Nothing in this part, nor in any arbitration decision rendered under this part, shall be construed to require any payment by the City to the Developer not otherwise provided for herein. 14.07. Expense of Arbitration. The expenses of any arbitration proceeding pursuant to this part shall be borne equally by the parties to such proceeding, provided, however, for the purpose of this Section 14.07, "expenses" shall include the fees and expenses of the arbitrators and the American Arbitration Association with respect to such proceeding, but shall not include attorneys' fees or expert witness fees, or any costs incurred by attorneys or expert witnesses, unless (and to the extent) agreed to by the parties to such proceeding, which in the absence of such Agreement shall be the responsibility of the party incurring such fees or costs. 14.08. Accelerated Arbitration. a. If any of the parties to any arbitration proceeding under this part determines the matter for arbitration should be decided on an expedited basis, then after an initial election to invoke arbitration pursuant to Section 14.02 hereof has been made, either party to such proceeding may invoke accelerated arbitration by giving notice thereof to the other parties no later than three (3) days after arbitration has been initially invoked and the other parties do not object within three (3) days thereafter. b. Accelerated arbitration, for purposes of this Section 14.08, shall be accomplished by either party notifying the American Arbitration Association (or any successor organization thereto) that the parties have agreed to a single arbitrator, qualified to decide the matter for arbitration, to be appointed by the American Arbitration Association (or any successor organization thereto) with the consent of the parties to such proceeding within three (3) days after receipt of the request and to decide such matter within five (5) days after such appointment. C. If an arbitrator is not so appointed with consent of the parties to the proceeding within three (3) days after the notice referred to in paragraph (2) is received by the American Arbitration Association, the accelerated proceeding under this Section 14.08 shall terminate and the procedures otherwise set forth in this Article 14 shall apply, unless the parties mutually agree to an extension of such time period. 2. The Developer and the City hereby agree to use such accelerated procedure only when reasonably necessary, to not contest the appointment of the arbitrator or his or her decision except as may be permitted by law, and that all other Amendment to Development Agreement Page 28 ADOPTED provisions of this part, except as are in conflict with this Section 14.08, remain in effect and applicable to an accelerated arbitration proceeding. 14.09. Applicable Law. To the extent not inconsistent with this article, any arbitration proceeding under this article shall be governed by the provisions of Chapter 682, Florida Statutes, as amended, known and referred to as the Florida Arbitration Code. 14.10. Arbitration Proceedings and Records. Any arbitration hearing under this article shall be considered a meeting subject to Section 286.011, Florida Statutes, and shall be open to any member of the public. Unless otherwise rendered confidential pursuant to or by the operation of any applicable law or order (other than an order by a sole arbitrator or panel of arbitrators acting under this part), the record of such proceedings shall be a public record under Chapter 119, Florida Statutes. ARTICLE 15. UNAVOIDABLE DELAY. 15.01. Unavoidable Delay. 1. Any delay in performance of or inability to perform any obligation under this Agreement (other than an obligation to pay money) due to any event or condition described in paragraph (b) as an event of "Unavoidable Delay" shall be excused in the manner provided in this Section 15.01. 2. "Unavoidable Delay" means any of the following events or conditions or any combination thereof: acts of God, litigation which has the effect of precluding reasonable satisfaction of the obligations of this Agreement, acts of the public enemy, riot, insurrection, war, pestilence, archaeological excavations required by law, unavailability of materials after timely ordering of same, epidemics, quarantine restrictions, freight embargoes, fire, lightning, hurricanes, earthquakes, tornadoes, floods, extremely abnormal and excessively inclement weather (as indicated by the records of the local weather bureau for a five-year period preceding the Effective Date), strikes or labor disturbances, delays due to proceedings under Chapters 73 and 74, Florida Statutes, restoration in connection with any of the foregoing or any other cause beyond the reasonable control of the party performing the obligation in question, including, without limitation, such causes as may arise from the act of the other party to this Agreement, or acts of any governmental authority (except that acts of the City shall not constitute an Unavoidable Delay with respect to performance by the City). 3. An application by any party hereto (referred to in this paragraph (c) and in paragraph (d) as the "Applicant") for an extension of time pursuant to this subsection must be in writing, must set forth in detail the reasons and causes of delay, and must be filed with the other party to this Agreement within seven (7) days following the occurrence of the event or condition causing the Unavoidable Delay or seven (7) days following the Applicant becoming aware (or with the exercise of reasonable diligence should have become aware) of such occurrence. 4. The Applicant shall be entitled to an extension of time for an Unavoidable Delay only for the number of days of delay due solely to the occurrence of the event or Amendment to Development Agreement Page 29 ADOPTED • • condition causing such Unavoidable Delay and only to the extent that any such occurrence actually delays that party from proceeding with its rights, duties and obligations under this Agreement affected by such occurrence. ARTICLE 16. INTENTIONALLY DELETED. Amendment to Development Agreement Page 30 ADOPTED 0 0 ARTICLE 17. FIRE OR OTHER CASUALTY; CONDEMNATION. 17.01. Loss or Damage to Project. Until the Termination Date or the Expiration Date, and without regard to the extent or availability of any insurance proceeds, however, subject to any condition or limitations as set forth in the Permits, the Developer shall have the right to commence and complete the reconstruction or repair of any loss or damage caused by fire or other casualty or by eminent domain (provided the City is not the condemning authority) to each and every part of the Boat Docking Facilities substantially the same condition as existed prior to the occurrence of such loss or damage, promptly after the City approves the Plans and Specifications for such reconstruction or repairs. 2. The City shall review the Plans and Specifications for such reconstruction or repairs as soon as possible after filing thereof by the Developer. The City agrees to approve the Plans and Specifications for such reconstruction or repairs if the reconstruction or repairs contemplated by such Plans and Specifications will restore the Boat Docking Facilities, or the damaged portion thereof, to substantially the same condition as existed prior to the occurrence of such loss or damage and if such Plans and Specifications conform to the applicable laws, ordinances, codes, and regulations in effect at the time of filing with the City of the plans and specifications for such reconstruction or repairs. 3. If Developer elects not to reconstruct or repair the Boat Docking Facilities as provided herein, Developer shall promptly remove all improvements constituting the Boat Docking Facilities in compliance with the requirements of the City and the Permits. 17.02. Partial Loss or Damage to Project. Until the Termination Date or the Expiration Date, any loss or damage by fire or other casualty or exercise of eminent domain to the Boat Docking Facilities, or any portion thereof, which does not render the Boat Docking Facilities unusable for the use contemplated by Section 2.03 of this Agreement, shall not operate to terminate this Agreement or to relieve or discharge the Developer from the timely performance and fulfillment of the Developer's obligations pursuant to this Agreement, subject to an extension of time for an Unavoidable Delay. 17.03. Insurance Proceeds. Whenever the Boat Docking Facilities, or any part thereof, shall have been damaged or destroyed, the Developer shall promptly make proof of loss and shall proceed promptly to collect, or cause to be collected, all valid claims which may have arisen against insurers or others based upon such damage or destruction. Notwithstanding the foregoing, Developer shall not be obligated to obtain or provide casualty insurance as to the Boat Docking Facilities. 2. Subject to the rights of a Project Lender, the Developer agrees that all proceeds of property or casualty insurance received by the Developer as a result of such loss or damage shall be available and shall be used for payment of the costs of Amendment to Development Agreement Page 31 ADOPTED • • the reconstruction or repair of the Boat Docking Facilities to the extent necessary to repair or reconstruct the Boat Docking Facilities. 17.04. Notice of Loss or Damage to Boat Docking Facilities. The Developer shall promptly give the City written notice of any significant damage or destruction to the Boat Docking Facilities stating the date on which such damage or destruction occurred, the expectations of the Developer as to the effect of such damage or destruction on the use of the Boat Docking Facilities, and the proposed schedule, if any, for repair or reconstruction of the Boat Docking Facilities. 17.05. Condemnation of Boat Docking Facilities; Application of Proceeds. In the event that part, but not all, of the Boat Docking Facilities shall be taken by the exercise of the power of eminent domain at any time before the Expiration Date, subject to the rights of a Project Lender, the compensation awarded to and received by the Developer shall be applied first to the restoration of the Boat Docking Facilities, provided the Boat Docking Facilities can be restored and be commercially feasible for its intended use as contemplated by Section 2.03.1. of this Agreement after the taking, and, if not, can be retained by the Developer. ARTICLE 18. MISCELLANEOUS 18.01. Assignments. By the Developer. a. The Developer may sell, convey, assign or otherwise dispose of any or all of its right, title, interest and obligations in and to the Boat Docking Facilities, or any part thereof, only with the prior written consent of the City, which consent is hereby granted for assignment to a party to which Developer's rights are assigned pursuant to the Development Agreement, provided that such party (hereinafter referred to as the "assignee"), to the extent of the sale, conveyance, assignment or other disposition by the Developer to the assignee, shall be bound by the terms of this Agreement the same as the Developer for such part of the Boat Docking Facilities as is subject to such sale, conveyance, assignment or other disposition. b. If the assignee of the Developer's right, title, interest and obligations in and to the Boat Docking Facilities, or any part thereof assumes all of the Developer's obligations hereunder, then the Developer shall be released from all such obligations hereunder which have been so assumed by the assignee, and the City agrees to execute an instrument evidencing such release, which shall be in recordable form. C. An assignment of the Boat Docking Facilities, any part thereof, by the Developer to any corporation, limited partnership, limited liability company, general partnership, or joint venture, in which the Developer (or an entity under common control with Developer) has either the controlling interest or through a joint venture or other arrangement shares equal management rights and maintains such controlling interest or equal management rights shall not be deemed an assignment or transfer subject to any restriction on or approvals of assignments or transfers Amendment to Development Agreement Page 32 ADOPTED 0 0 imposed by this Section 18.01, provided, however, that notice of such assignment shall be given by the Developer to the City not less than thirty (30) days prior to such assignment being effective and the assignee shall be bound by the terms of this Agreement to the same extent as would the Developer in the absence of such assignment. d. Notwithstanding the foregoing, so long as this Agreement is in effect, Developer shall have the right to sublease or license the use of individual Developer Boat Slips to owners, tenants and guests in accordance with Subsection 2.03.05 above without City's consent. 18.02. Successors and Assigns. The terms herein contained shall bind and inure to the benefit of the City, and its successors and assigns, and the Developer and its successors and assigns, except as may otherwise be specifically provided herein. 18.03. Notices. All notices, demands, requests for approvals or other communications given by either party to another shall be in writing, and shall be sent by registered or certified mail, postage prepaid, return receipt requested or by courier service, or by hand delivery to the office for each party indicated below and addressed as follows: To the Developer: THE SANDPEARL RESORT, LLC 2201-4 th Street North Suite 200 St. Petersburg, FL 33704 Attn: J. Michael Cheezem with copies to: E.D. (Ed) Armstrong, III P.O. Box 1368 Clearwater, FL 33757 and Greene & Schermer 1301-6 th Avenue West Suite 400 Bradenton, FL 34205 Attn: Robert F. Greene, Esquire 2. Notices given by courier delivery and notices given person to accept delivery indicated above (or as it effective delivery as prov notices are to be sent rr To the City: City of Clearwater 112 S. Osceola Avenue Clearwater, FL 33756 with copies to: Pam Akin, Esquire Clearwater City Attorney 112S. Osceola Avenue Clearwater, FL 33756 service or by hand delivery shall be effective upon by mail shall be effective upon receipt. Refusal by any of any notice delivered to the office at the address nay be changed) shall be deemed to have been an ded in this Section 18.03. The addresses to which ay be changed from time to time by written notice Amendment to Development Agreement Page 33 ADOPTED 0 .0 delivered to the other parties and such notices shall be effective upon receipt. Until notice of change of address is received as to any particular party hereto, all other parties may rely upon the last address given. 18.04. Applicable Law and Construction. The laws of the State of Florida shall govern the validity, performance and enforcement of this Agreement. This Agreement has been negotiated by the City and the Developer and the Agreement, including, without limitation, the Exhibits, shall not be deemed to have been prepared by the City or the Developer, but by all equally. 18.05. Venue; Submission to Jurisdiction. For purposes of any suit action, or other proceeding arising out of or relating to this Agreement, the parties hereto do acknowledge, consent, and agree that venue thereof is Pinellas County, Florida. 2. Each party to this Agreement hereby submits to the jurisdiction of the State of Florida, Pinellas County and the courts thereof and to the jurisdiction of the United States District Court for the Middle District of Florida, for the purposes of any suit, action, or other proceeding arising out of or relating to this Agreement and hereby agrees not to assert by way of a motion as a defense or otherwise that such action is brought in an inconvenient forum or that the venue of such action is improper or that the subject matter thereof may not be enforced in or by such courts. 3. If at any time during the term of this Agreement the Developer is not a resident of the State of Florida or has no office, employee, City or general partner thereof available for service of process as a resident of the State of Florida, or if any permitted assignee thereof shall be a foreign corporation, partnership or other entity or shall have no officer, employee, agent, or general partner available for service of process in the State of Florida, the Developer hereby designates the Secretary of State, State of Florida, its agent for the service of process in any court action between it and the City, or both, arising out of or relating to this Agreement and such service shall be made as provided by the laws of the State of Florida for service upon a non-resident; provided, however, that at the time of service on the Florida Secretary of State, a copy of such service shall be delivered to the Developer at the address for notices as provided in 18.03. 18.06. Estoppel Certificates. The Developer and the City shall at any time and from time to time, upon not less than ten (10) days prior notice by another party hereto, execute, acknowledge and deliver to the other parties a statement in recordable form certifying that this Agreement has not been modified and is in full force and effect (or if there have been modifications that the said Agreement as modified is in full force and effect and setting forth a notation of such modifications), and that to the knowledge of such party, neither it nor any other party is then in default hereof (or if another party is then in default hereof, stating the nature and details of such default), it being intended that any such statement delivered pursuant to this Section 18.06 may be relied upon by any prospective purchaser, mortgagee, successor, assignee of any mortgage or assignee of the respective interest in the Boat Docking Facilities, if any, of any party made in accordance with the provisions of this Agreement. Amendment to Development Agreement Page 34 ADOPTED 10 0 18.07. Complete Agreement; Amendments. This Agreement, and all the terms and provisions contained herein, including without limitation the Exhibits hereto, constitute the full and complete agreement between the parties hereto to the date hereof, and supersedes and controls over any and all prior agreements, understandings, representations, correspondence and statements, whether written or oral. 2. Any provision of this Agreement shall be read and applied in pars materia with all other provisions hereof. 3. This Agreement cannot be changed or revised except by written amendment signed by all parties hereto. 18.08. Captions. The article and section headings and captions of this Agreement and the table of contents preceding this Agreement are for convenience and reference only and in no way define, limit, describe the scope or intent of this Agreement or any part thereof, or in any way affect this Agreement or construe any article, section, subsection, paragraph or provision hereof. 18.09. Holidays. It is hereby agreed and declared that whenever a notice or performance under the terms of this Agreement is to be made or given on a Saturday or Sunday or on a legal holiday observed in the City, it shall be postponed to the next following business day. 18.10. Exhibits. Each Exhibit referred to and attached to this Agreement is an essential part of this Agreement. The Exhibits and any amendments or revisions thereto, even if not physically attached hereto shall be treated as if they are part of this Agreement. 18.11. No Brokers. The City and the Developer hereby represent, agree and acknowledge that no real estate broker or other person is entitled to claim or to be paid a commission as a result of the execution and delivery of this Agreement, including any of the Exhibits. 18.12. Not an Agent of City. During the term of this Agreement, the Developer hereunder shall not be an agent of the City with respect to any and all services to be performed by the Developer (and any of its agents, assigns, or successors) with respect to the Boat Docking Facilities. 18.13. Memorandum of Agreement. The City and the Developer agree to execute, in recordable form, at the request of either party, a short form "Memorandum of Agreement" and agree, authorize and hereby direct such Memorandum to be recorded in the public records of Pinellas County, Florida, as soon as possible after execution thereof. The Developer shall pay the cost of such recording. 18.14. Public Purpose. The parties acknowledge and agree that this Agreement satisfies, fulfills and is pursuant to and for a public purpose and municipal purpose and is in the public interest, and is a proper exercise of the City's power and authority. 18.15. No General Obligation. In no event shall any obligation of the City under this Agreement be or constitute a general obligation or indebtedness of the City, a pledge of the ad valorem taxing power of the City or a general obligation or indebtedness of the Amendment to Development Agreement Page 35 ADOPTED 0 0 City within the meaning of the Constitution of the State of Florida or any other applicable laws, but shall be payable solely from legally available revenues and funds. Neither the Developer nor any other party under or beneficiary of this Agreement shall ever have the right to compel the exercise of the ad valorem taxing power of the City or any other governmental entity or taxation in any form on any real or personal property to pay the City's obligations or undertakings hereunder. 18.16. Other Requirements of State Law. Nothing in this Agreement shall be deemed to relieve either party from full compliance with any provision of State law which is applicable to any of the obligations or undertakings provided for in this Agreement. In the event that this Agreement omits an obligation to comply with any provision of State law in regard to any of the obligations or undertakings provided for in this Agreement, it is the intention of the parties that such applicable State law shall be deemed incorporated into this Agreement and made a part thereof. In the event that there is any conflict between the provisions of this Agreement and applicable State law, it is the intention of the parties that the Agreement shall be construed to incorporate such provisions of State law and that such provisions shall control. 18.17. Technical Amendments; Survey Corrections. In the event that due to minor inaccuracies contained herein or any Exhibit attached hereto or any other agreement contemplated hereby, or due to changes resulting from technical matters arising during the term of this Agreement, the parties agree that amendments to this Agreement required due to such inaccuracies, unforeseen events or circumstances which do not change the substance of this Agreement may be made and incorporated herein. The City Manager is authorized to approve such technical amendments on behalf of the City, respectively, and is authorized to execute any required instruments, to make and incorporate such amendment to this Agreement or any Exhibit attached hereto or any other agreement contemplated hereby. 18.18. Term; Expiration; Certificate. If not earlier terminated as provided in Section 12.05, this Agreement shall expire and no longer be of any force and effect on the fifth (5th) anniversary of the Lease Commencement Date. The City shall have the unilateral option to renew this Agreement for five (5) successive renewal terms of five (5) years each by written notice to Developer. The date of expiration of this Agreement is the "Expiration Date". 2. If the City exercises all five (5) renewal options this Agreement shall expire on the date that is thirty (30) years after the Lease Commencement Date ("Final Expiration Date") and exclusive possession of the Boat Docking Facilities shall be relinquished by Developer to City together with ownership of all improvements within the Boat Docking Facilities (excluding the Slip Improvements) ("Improvements"). At the request of the City, Developer shall execute and deliver to City a Bill of Sale as to all Improvements. In the event the City does not exercise one of the renewal options so that this Agreement expires prior to the Final Expiration Date, City agrees to pay to Developer an amount equal to the unamortized cost on the Expiration Date incurred by Developer in connection with the design, permitting and construction of all Improvements ("Project Costs") such unamortized Project Costs to be determined by amortizing the Project Costs on a straight line basis over the thirty (30) year period commencing on the Amendment to Development Agreement Page 36 ADOPTED Lease Commencement Date. Upon expiration or termination of this Agreement, Developer may at its option and at its sole expense remove the Slip Improvements. Costs relating to the Slip Improvements shall not be considered part of the Project Costs. The total Project Costs to be amortized as provided above shall not exceed $1,000,000.00. 3. Upon completion of the term of this Agreement including all renewal terms exercised by City, all parties hereto shall execute the Agreement Expiration Certificate. The Agreement Expiration Certificate shall constitute (and it shall be so provided in the certificate) a conclusive determination of satisfactory completion of all obligations hereunder and the expiration of this Agreement. 4. In the event of any dispute as to. whether any party is required to execute the Agreement Expiration Certificate, the dispute shall be resolved by arbitration as provided in Article 14. 5. The Agreement Expiration Certificate shall be in such form as will enable it to be recorded in the public records of Pinellas County, Florida. Following execution by all of the parties hereto, the Agreement Expiration Certificate shall promptly be recorded by the Developer in the public records of Pinellas County, Florida and the Developer shall pay the cost of such recording. 18.19. Approvals Not Unreasonably Withheld. The parties hereto represent that it is their respective intent as of the Effective Date and do covenant and agree in the future that all approvals, consents, and reviews will be undertaken and completed as expeditiously as possible, in good faith, and will not be arbitrarily or unreasonably withheld, unless otherwise expressly authorized by the terms of this Agreement. 18.20 Severability. If any term, provision or condition contained in this Agreement shall, to any extent, be held invalid or unenforceable, the remainder of this Agreement, or the application of such term, provision or condition to persons or circumstances other than those in respect of which it is invalid or unenforceable, -shall not be affected thereby, and each term, provision and condition of this Agreement shall be valid and enforceable to the fullest extent permitted by law. 18.21. Effective Date. The Effective Date shall be the date of the last signature to this Agreement. BALANCE OF PAGE INTENTIONALLY LEFT BLANK SIGNATURE PAGES FOLLOW Amendment to Development Agreement Page 37 ADOPTED 0 0 IN WITNESS WHEREOF, the parties hereto have set their hands and their respective seals affixed as of this day of , 2007. THE CITY OF CLEARWATER, FLORIDA Attest: By: _ By: City Clerk Mayor Approved as to form and correctness: City Attorney STATE OF FLORIDA COUNTY OF PINELLAS Esquire The foregoing instrument was acknowledged before me this day of 2007, by and , Mayor and City Clerk, respectively, for the City of Clearwater, Florida, on behalf of the City, who is ? personally known to me or ? has produced a Florida driver's license or ? as identification. NOTARY PUBLIC Printed Name: Commission No. My Commission expires: Amendment to Development Agreement Page 38 ADOPTED • THE SANDPEARL RESORT, LLC, a Florida limited liability company By: CBR Communities I, Ltd., a Florida limited partnership Managing Member By: JMC Communities of Clearwater V, Inc. a Florida corporation, General Partner By: Name: J. Michael Cheezem Title: CEO STATE OF FLORIDA COUNTY OF PINELLAS The foregoing instrument was acknowledged before me this day of 2007, J. Michael Cheezem, as CEO of JMC Communities of Clearwater V, Inc., a Florida corporation, the General Partner of CBR Communities I, Ltd., a Florida limited partnership, the Managing Member of The Sandpearl Resort, LLC, a Florida limited liability company, who is ? personally known to me or ? has produced a Florida driver's license or ? as identification. NOTARY PUBLIC Printed Name: Commission No. My Commission expires: #404229 v2 - Sandpearl/Amendment to Dev Agt Amendment to Development Agreement Page 39 ADOPTED E 0 Q ? .a W PROPGBID NEW SLIPS: 8 ALT BLIPS PM BOATS 1899 MAN 29' B BOAS LI TH FOR HQATS 1885 THAN 80' s A6f SLIPS FOR BOATO lags mm Be, 4 BOAT LUTH FTm MATH 1888 THAN 88' 19 WET ffi88 TER BOATS IESSI THAN 40• 9 BAY SLIPS TOTAL 48 MIPSI f MANATEE 91GNs NOTR: NO 1'Q 06• PilMP-MUT OA Mil CLEANING FACQ.R•IFS ARC PEIOPOM rCR THS FROJEC1' F SEAGHARB r• • < j M3NGRDVffi ?? seaxnu? I? APPRG11 MATE Nun I'D _ •Fr WA R84F-COBiLi1NR CR6e8 9? LiTe HOT'HBI sup PD: , r ..? ? f l ; #fi HANDFUL SLAP X11 II SUP 06 - - mm 61s r ffiD 17 SUP #1 4. L 1 O1 -8' . SUP a ; HEMP -TIM) IIV In" 44 9e1aBAHa Hen -, . NO RN1'RY SI M 75'-7" APPROKIMM LIMITS i B. ?I gAPI'MO ATTe OF NAVIGABLE PATER VATEMT LINE L]QSTING OUCH f I RIPARIAN UNE + f - - P.f'.'N U.j01,1a *1'1' 1'' O0N3t'RUCTION 6i libt:dN CLRF ":7di! t"+sy$art TIIN[3, INC fi',tM y ooc 0i M2`110M R1E UU MIME OOhli7RM- 09 Nt , 4409 Grady Ave. 14 4, °FS'L° rww¢r raaieu ClDP F7E E-? ? VVATERLINE " Tampa FL 88614 CYe?P-rvafa, Recrwofi Center 4lEY=Sd' coNSlls€ niel, irle 618-806-1977 S dA )r 24 R Ar of 7 w9w c a? a? N Cn Q c (1) E Q- .2 m 0 0 c 0 EoW C a q? C, 0 < < • 4-161 h¢ cop LIP A SUP SUP ps SLIP SLIP a94. 16 9' TUKa1D1TT CHAIN TO 11E IN3TALIAD Aa%3LWn ARRA MMMG COMTRUC= S PAM" IM 1Y? I? fl 44 on99 - v SAY 8 ' ti?2 a M& MAM RIMS _ SrA 6BA99 F= - - - - - - -' ' xs' SUP Ra our #s ffiP #10, J? me ." ? 49 sup #7 99'-B' 69 ffill' 411 NU ENTRY BIGN SUP #4 Bur to ' Jl18 812 ;14 _ a - ADDrMNa Tll.Sk3IiM 1b' E" Bur #6 BLIP 15)l 11 15_8• SLIP 013 Sup X15 CURI'AM TO BE DOTA'LMD ?- aOM MlkM;VM ENDS DII'RWG CON ET.RDCTIDN 40 kµ-26 1 - 49. --' is- APPRMM(ATL' 95R CP TM VATEWAT LNS APPROKKATE LIMITS OF NAVIGABLE WATER 144' DF ? S. ttlotQN, f. N,. ?i61;. WATERLINE OON&MCTION 7Yld Y '' i l ' 1i?7P meE1f1l?]LU7 rew? ruiene FILE-!T1M1ME wamwnoµ w. WATERLINE 4409 Grady Ave. If Tampa FL 88614 LYCYNxoler Recr?aofion CtnlEY Ft 4''v 0.i .. „- ,?yg? t=,# aw9 FlE cCN5TR TlCN, INC, 013-506-1977 S t?'.s f", R tS eME r OF 7 w9.. C N E O N 0) Q c m E CL O m a) 0 O c 0 E w E Mo Q CL Q 0 0 EXHIBIT "B" CITY PROPERTY LEGAL DESCRIPTION Upland Property PI D# 05/29/15/00000/330/0100 BEG AT NW COR LOT 9 YACHT BASIN SUB RUN N'LY ALONG E RIW MANDALAY AVE 400 FT(S) TH FLY ALONG S R/W CLEARWATER ST 915 FT(S) TH S'LY ALONG SEAWALL 195 FT(S) TH W'LY MEANDERING SHORELINE 700 FT(S) TH S'LY 100 FT(S) TH SW'LY ALONG SEAWALL 245 FT(S) TH S'LY 60 FT(S) TH W'LY 27 FT(S) TO POB CONT 4.13 AC(C) Amendment to Development Agreement Page 42 ADOPTED 0 1 0 EXHIBIT "C" MAINTENANCE STANDARDS DAILY: • Inspect Boat Docking Facilities • Enforce use restrictions • Respond to emergency conditions WEEKLY: • Trash removal (or more frequently as needed) • Lighting inspection and light bulb replacement • General maintenance inspection. Docking Facilities to be maintained in good condition and repair with all deteriorated or damaged materials and loose screws/nails replaced as needed. All repairs to be completed within ten (10) working days, however any repairs required for safe use of facilities shall be completed as soon as possible under the circumstances. QUARTERLY: • Thorough inspection of Docking Facilities with the City Harbor Master. All required repairs identified in quarterly inspection to be documented by written report and signed by a representative of Developer and City Harbor Master. All repairs to be completed in the time frame to be stated in the inspection report and Developer shall provide written certification upon completion. #404229 v2 - Sandpearl/Amendment to Dev Agt Amendment to Development Agreement Page 43 ADOPTED LIST OF SURROUNDING OWNERS WITHIN 200' OF SANDPEARL PROJECT [PARCEL #S 08/29/15/78657/001/0010 AND 08/29/15/78657/002/0010] ?i ??? ? 4 Zp01 ENO cm PINELLO JIM COUNTY SMITH PROPERTY APPRAISER 03-May-2007 PAGEa 1 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 06449 / 000 / 0001 BELLE HARBOR OWNERS ASSN INC BELLE HARBOR CONDO 501 MANDALAY AVE COMMON ELEMENTS CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1703 PROPERTY ADDR; --------------_..------------....--------------------_...-_..------.._..------------- 05 / 29 / 15 / 06449 / 001 / 0011 BELLE HARBOR CONDO PHASE I UNIT 11 & BOAT SLIP 51 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 525 MANDALAY AVE --------------------------------- FULLBACH INVESTMENTS LLC 2201 4TH ST N # 200 ST PETERSBURG FL 33704 4300 05 / 29 / 15 / 06449 / 001 / 0012 WANDACHOWICZ7 BOGDAN BELLE HARBOR CONDO 18175 MASON SMITH RD PHASE I BROOKSVILLE FL UNIT 12 34604 9028 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 525 MANDALAY AVE ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 001 / 0013 ELIAS, SCOTT D BELLE HARBOR CONDO 1435 N CLEVELAND # E PHASE I CHICAGO IL UNIT 13 60610 1135 (LYING IN SEC'S 5 & 8) PROPERTY ADDR4 525 MANDALAY AVE -----------------------------------_.-------------...--_..........---------------- 05 / 29 / 15 / 06449 / 001 / 0014 GIANFILIPPO, JOHN F BELLE HARBOR CONDO GIANFILIPPO, LAURA L PHASE I 162 DEVON DR UNIT 14 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 2438 PROPERTY ADDR; 525 MANDALAY AVE ------------------------------------------------------------ ------- 05 / 29 / 15 / 06449 / 001 / 0021 BELLE HARBOR CONDO PHASE I UNIT 21 & BOAT SLIP 53 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 525 MANDALAY AVE ----------------------------------- ORISSA PROPERTIES LTD 31 BROAD ST ST HELIER JERSEY JE4 CXW CHANNEL ISLANDS PINELLO JIM COUNTY SMITH PROPERTY APPRAISER 03-May-2007 PAGE; 2 PARCEL */BRIEF LEGAL DESC 05 / 29 / 15 / 06449 / 001 BELLE HARBOR CONDO PHASE I UNIT 22 & BOAT SLIP 12 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 525 MANDALAY --------------------------- OWNER'S NAME AND ADDRESS / 0022 SADYLO: INNA I WA2I0: RAFAL 740 S GULFVIEW BLVD CLEARWATER FL 33767 AVE 05 / 29 / 15 / 06449 / 001 / 0023 BELLE HARBOR CONDO PHASE I UNIT 23 8 BOAT SLIP 58 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 525 MANDALAY AVE ------------------------------------ MATZKIN: STEVEN R 1 SOUTH SCHOOL AVE # 1000 SARASOTA FL 34237 6046 05 / 29 / 15 / 06449 / 001 / 0024 THOMAS-KIRSCHKE: HEIDI BELLE HARBOR CONDO 525 MANDALAY AVE # 24 PHASE I CLEARWATER FL UNIT 24 & BOAT SLIP 56 33767 1798 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 525 MANDALAY AVE ---------------------_.-------------_...----------------------_----__------ 05 / 29 / 15 / 06449 / 001 / 0025 FLOTO9 RONALD J BELLE HARBOR CONDO FLOT0 NANCY C PHASE I 6019 BEACON SHORES ST UNIT 25 & BOAT SLIP 57 TAMPA FL (LYING IN SEC'S 5 & 8) 33616 PROPERTY ADDR; 525 MANDALAY AVE ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 001 / 0031 HORTON, RODNEY 0 BELLE HARBOR CONDO HORTON, JANE A PHASE I 2557 LAKESIDE CT UNIT 31 & BOAT SLIP 23 PALM HARBOR FL (LYING IN SEC'S 5 & 8) 34684 1718 PROPERTY ADDR; 525 MANDALAY AVE --------------------------_..------_------------------------------------- 05 / 29 / 15 / 06449 / 004 / 0032 HARTMAN: JEFFREY E BELLE HARBOR CONDO HARTMAN, MARISA A PHASE I 5 CORD GRASS LN UNIT 32 & BOAT SLIP 8 OLD LYME CT (LYING IN SEC'S 5 & 8) 06371 2080 PROPERTY ADDR; 525 MANDALAY AVE ----------------------------------------------------------------------- PINELLO JIM COUNTY SMITH PROPERTY APPRAISER 03--May-2007 PACE: 3 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 06449 / 001 / 0033 WITHERS, SUSAN BELLE HARBOR CONDO WITHERSr WARREN CLAY PHASE I PO BOX 3636 UNIT 33 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 8636 PROPERTY ADDR; 525 MANDALAY AVE .---------------..------------------_---_..-.....---------_..--------------------- 05 / 29 / 15 / 06449 / 001 / 0034 BELLE HARBOR CONDO PHASE I UNIT 34 & BOAT SLIP 40 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 525 MANDALAY AVE --.--..-......-..-------------------------.-...--- CAMBAS, NICHOLAS A 2939 ELYSIUM WAY CLEARWATER FL 33759 1414 05 / 29 / 15 / 06449 / 001 / 0035 BELLE HARBOR CONDO PHASE I UNIT 35 & BOAT SLIP 47 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 525 MANDALAY AVE ---------------------------------- 0 5 / 29 / 15 / 06449 / 001 / 0036 BELLE HARBOR CONDO PHASE I UNIT 36 & BOAT SLIP 45 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 525 MANDALAY AVE ------------------------------------- 05 / 29 / 15 / 06449 / 001 / 0301 BELLE HARBOR CONDO PHASE I UNIT 301 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY AVE -------------------------------.-- 05 / 29 / 15 / 06449 / 001 / 0302 BELLE HARBOR CONDO PHASE I UNIT 302 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY AVE ---------------------------------- HESS, STEPHEN 525 MANDALAY AVE # 35 CLEARWATER FL 33767 1798 MATTOX, JEFFREY A MATTOX, LORI A 2830 COBBLSTONE DR PALM HARBOR FL 34684 1620 STOJAA, JAMES L STOJAK, ROBIN L 3964 MULLENHURST DR PALM HARBOR FL 34685 3665 ROBULAK, KENNETH J ROBULAK, PATRICIA J 521 MANDALAY AVE # 302 CLEARWATER FL 33767 1793 PINELLO JIM COUNTY SMITH PROPERTY APPRAISER 03-May-2007 PAGE: 4 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 06449 / 001 / 0303 BODUCHr RAYMOND T BELLE HARBOR CONDO BODUCH: LINDA C PHASE I 521 MANDALAY AVE # 303 UNIT 303 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1793 PROPERTY ADDR= 521 MANDALAY AVE ----------------------------------------------------------------------- 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 304 (LYING IN SEi PROPERTY ADDR< -------------- 06449 / 001 / 0304 CONDO C'S 5 & 8) 521 MANDALAY AVE ------------------- 05 / 29 / 15 / 06449 / 001 / 0305 BELLE HARBOR CONDO PHASE I UNIT 305 (LYING IN SEC'S 5 & 8) PROPERTY ADDR= 521 MANDALAY AVE --------------------------------- 05 / 29 / 15 / 06449 / 001 / 0307 BELLE HARBOR CONDO PHASE I UNIT 307 (LYING IN SEC'S 5 & 8) PROPERTY ADDR= 521 MANDALAY AVE --------------------------------- 05 / 29 / 15 / 06449 / 001 / 0309 BELLE HARBOR CONDO PHASE I UNIT 309 & BOAT SLIP 63 (LYING IN SEC'S 5 & 8) PROPERTY ADDR= 521 MANDALAY AVE --------------------------------- 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 310 (LYING IN SE! PROPERTY ADDR? -------------- 06449 / 001 / 0310 CONDO C'S 5 & 8) 521 MANDALAY ------------------- FARRELL, BRIAN M FARRELL, CYNTHIA B 5116 WESTSHORE DR NEW PORT RICHEY FL 34652 8007 RAMIREZ, EDGAR D RAMIREZ4 JENNIFER 4916 W MELROSE AVE S TAMPA FL 33629 5420 VISOS07 ROBERTO VISOSO: GRACIELA 521 MANDALAY AVE # 307 CLEARWATER FL 33767 1793 ENGEBRETSEN: ARDEN B EST C/O ENGEBRETSENY ELEANORE A 10 PAPAYA ST # 1404 CLEARWATER FL 33767 2058 MA2.AS LAND TRUST MAZAS: BILL W THE 1600 GULF BLVD # 7117 CLEARWATER FL 33767 2973 AVE JIM SMITH PINELLOCOUNTY PROPERTY APPRAISER 03-May-2007 PAGE: 5 PARCEL #/BRIEF LEGAL DESC 05 / 29 / 15 / 06449 / 001 / 0401 BELLE HARBOR CONDO PHASE I UNIT 401 (LYING IN SEC'S 5 & 8) PROPERTY ADDRQ 521 MANDALAY AVE ---------------------------.........-_---- OWNER'S NAME AND ADDRESS JACOBSEN, GLENN C JACOBSEN, BARBARA D 6 FERRAND WOODS SAINT LOUIS MO 63124 1244 05 / 29 / 15 / 06449 / 001 / 0402 TADROSY HANI S BELLE HARBOR CONDO YASSAOUI, SUZANNE PHASE I 2184 LAURENCE DR UNIT 402 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33764 6466 PROPERTY ADDR; 521 MANDALAY AVE ----------------------------------------------------------------------- 0 5 / 29 / 15 / 06449 / 001 I BELLE HARBOR CONDO PHASE I UNIT 403 (LYING IN SEC'S 5 & 8) PROPERTY ADDR= 521 MANDALAY ---------------------------- 05 / 29 / 15 / 06449 / 001 / BELLE HARBOR CONDO PHASE I UNIT 404 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY ---------------------------- 0403 BOND, GEORGE L JR BOND: YVONNE N 1215 CAMINO CAPISTRANO ROSEVILLE CA 95747 6727 AVE 0404 PFAFF, ROBERT PFAFF, BETTY 521 MANDALAY AVE # 404 CLEARWATER FL 33767 1793 AVE ------------------------------------------- 05 / 29 / 15 / 06449 / 001 / 0405 VANWORP, JUDSON BELLE HARBOR CONDO VANWORPY DEBORAH PHASE I 1907 MUIRFIELD WAY UNIT 405 OLDSMAR FL (LYING IN SEC'S 5 & 8) 34677 1936 PROPERTY ADDRi 521 MANDALAY AVE ---------------------_.----------------....__------------------__--_-.._.----- 05 / 29 / 15 / 06449 / 001 / 0406 COLTON, JAMES A BELLE HARBOR CONDO COLTON, LORI B PHASE I 421 HAMPTON GREEN UNIT 406 PEACHTREE CITY GA (LYING IN SEC'S 5 & 8) 30269 2712 PROPERTY ADDR; 521 MANDALAY AVE ----------------------------------------------------------------------- PINELLO JIM COUNTY SMITH PROPERTY APPRAISER 03-May-2007 PAGE 4 6 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 06449 / 001 / 0407 VON STADENY JOHN JR BELLE HARBOR CONDO 521 MANDALAY AVE # 407 PHASE I CLEARWATER FL UNIT 407 33767 1793 (LYING IN SEC'S 5 & 8) PROPERTY ADDR. 521 MANDALAY AVE ------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 001 / 0408 BARBO2Ar SILVIA BELLE HARBOR CONDO BARBO?A: VITELIO E PHASE I 521 MANDALAY AVE # 408 UNIT 408 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1793 PROPERTY ADDR: 521 MANDALAY AVE ------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 001 / 0409 MOMESSO, SERGIO F BELLE HARBOR CONDO MOMESSO. NOELLA NOORY PHASE I 10 JONQUILLE UNIT 409 KIRKLAND OC H9H 3C4 (LYING IN SEC'S 5 R 8) CANADA PROPERTY ADDR: 521 MANDALAY AVE ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 001 / 0410 FALLON, JOSEPH BELLE HARBOR CONDO FALLON, SHEILA PHASE I 521 MANDALAY AVE # 410 UNIT 410 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1793 PROPERTY ADDR. 521 MANDALAY AVE ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 001 / 0501 BELLE HARBOR CONDO PHASE I UNIT 501 (LYING IN SEC'S 5 & 8) PROPERTY ADDR= 521 MANDALAY AVE ------------------------------------- 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 502 (LYING IN SE PROPERTY ADDR: -------------- 06449 / 001 / 0502 CONDO C'S 5 & 8) 521 MANDALAY AVE ------------------- KIEFFERY ALAN L KIEFFER, NELLI L 521 MANDALAY AVE # 501 CLEARWATER FL 33767 1793 JENNINGS, MARK K JENNINGS, VICKI B 14345 FOX CREEK CT COOKSVILLE MD 21723 9616 PINELA JIM COUNTY SMITH PROPERTY APPRAISER 03-May-2007 PAGE; 7 PARCEL #/BRIEF LEGAL DESC 05 / 29 / 15 / 06449 / 001 / 0503 BELLE HARBOR CONDO PHASE I UNIT 503 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY AVE ------------------------------------ 05 / 29 / 15 / 06449 / 001 BELLE HARBOR CONDO PHASE I UNIT 504 & BOAT SLIP 55 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 521 MANDALAY --------------------------- 05 / 29 / 15 / 06449 / 001 BELLE HARBOR CONDO PHASE I UNIT 505 (LYING IN SEC'S 5 & 8) PROPERTY ADDR= 521 MANDALAY --------------------------- OWNER'S NAME AND ADDRESS KAROUNOS, THEODORE P KAROUNOS, LORRAINE J 444 PINE HILL RD LEONIA NJ 017605 1420 / 0504 CLARK, ROBERT B CLARK, SANDRA H 521 MANDALAY AVE # 504 CLEARWATER FL 33767 1793 AVE / 0505 COOK, JAMES C COOK, SHARI H 865 WADDINGTON CT DUNWOODY GA 30350 4459 AVE -------------------------------------------- 05 / 29 / 15 / 06449 / 001 / 0506 BADIE, BADIE A BELLE HARBOR CONDO 32 BRAELOCH WAY PHASE I MONROE CT UNIT 506 06468 3013 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY AVE --__---------------------------------------------------------- 05 / 29 / 15 / 06449 / 001 / 0507 BELLE HARBOR CONDO PHASE I UNIT 507 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY AVE --------------------------------- TOUCHTON, JOANN TOUCHTON, WALTER W 10 PAPAYA # 702 CLEARWATER FL 33767 2054 05 / 29 / 15 / 06449 / 001 / 0508 NAGALE, VISHWANATH T BELLE HARBOR CONDO NAGALE, PUSHPAMALA V PHASE I 521 MANDALAY AVE # 508 UNIT 508 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1793 PROPERTY ADDR: 521 MANDALAY AVE ----------------------------------------------------------------------- JIM SMITH PINELLO COUNTY PROPERTY APPRAISER 03-May-2007 PAGE; 8 PARCEL #/BRIEF LEGAL DESC 05 / 29 / 15 / 06449 / 001 / 0509 BELLE HARBOR CONDO PHASE I UNIT 509 & BOAT SLIP 61 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY AVE -----------------.....-__-----__------ 05 / 29 / 15 / 06449 / 001 / 0510 BELLE HARBOR CONDO PHASE I UNIT 510 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY AVE ----------------------------------- OWNER'S NAME AND ADDRESS DIGIANNANTONIO, GILBERT DIGIANNANTONIO> PAULETTE 3717 WOODRIDGE PL PALM HARBOR FL 34684 2449 HEIDI INVESTMENT TRUST BENJAMIN BUILDERS REALTY TRUST C/O LORDEN, HEIDI M THE PO BOX 651 TOWNSEND MA 01469 0651 05 / 29 / 15 / 06449 / 001 / 0601 BOMERGER, DAVID RICHARD BELLE HARBOR CONDO 990 W OAK ST PHASE I ZIONSVILLE IN UNIT 601 46077 1209 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY AVE ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 001 / 0602 JOYCE, JILL E BELLE HARBOR CONDO 521 MANDALAY AVE # 602 PHASE I CLEARWATER FL UNIT 602 & BOAT SLIP 49 33767 1794 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY AVE --------------------------------------------------_.-_------- 05 / 29 / 15 / 06449 / 001 / 0603 BELLE HARBOR CONDO PHASE I UNIT 603 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY AVE ------------------------------------- 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 604 (LYING IN SE' PROPERTY ADDR; -------------- 06449 / 001 / 0604 CONDO C'S 5 & 8) 521 MANDALAY AVE ------------------- BOTWICK. ANDREW L BOTWICK. DIANNE S 6608 PISANO DR LAKE WORTH FL 33467 5928 DENISCO, DANIEL L 7617 LAKE CYPRESS DR ODESSA FL 33556 1804 PINELL)O JIM COUNTY SMITH PROPERTY APPRAISER 03-May-2007 PAGE: 9 PARCEL #/BRIEF LEGAL DESC 05 / 29 / 15 / 06449 / 001 / BELLE HARBOR CONDO PHASE I UNIT 605 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 521 MANDALAY --------.....-....__....-..._.__---__ ---- 05 / 29 / 15 / 06449 / 001 / BELLE HARBOR CONDO PHASE I UNIT 606 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 521 MANDALAY ---------------------------- OWNER'S NAME AND ADDRESS 0605 SANDD2, DAVID C SANDO2: ANN L 523 N OKLAHOMA AVE MORTON IL 61550 2373 AVE ------------------------------ 0606 ISHAK: REDA H BISHAY, MANAR 12 PINEWOOD HILLS LONGMEADOW MA 01106 1663 AVE ------------------------------------------- 05 / 29 / 15 / 06449 / 001 / 0607 GREEN, RONALD D TRUST BELLE HARBOR CONDO GREEN: RONALD D THE PHASE I 521 MANDALAY AVE # 6;.77 UNIT 607 CLEARWATER FL. (LYING IN SEC'S 5 & 8) 33767 1794 PROPERTY ADDR: 521 MANDALAY AVE ------------------------------------_..--------------.......---__------------- 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 608 (LYING IN SEi PROPERTY ADDR= -------------- 06449 / 001 / 0608 CONDO C'S 5 & 8) 521 MANDALAY AVE ------------------- CIOCIA: JAMES CIOCIA, TRACY 187-•11 PEPPER PIKE L.UTZ FL 33558 5315 05 / 29 / 15 / 06449 / 001 / 0609 ORMOND, BRIAN E BELLE HARBOR CONDO 1451 LINDHURST DR PHASE I CENTERVILLE OH UNIT 609 & BOAT SLIP 15 -45459 3328 (LYING IN SEC'S 5 & 8) PROPERTY ADDR= 521 MANDALAY AVE -------------.---------__-__------............... -----------------------_...._.....................-.... - 05 / 29 / 15 / 06449 / 001 / 0610 BELLE HARBOR CONDO PHASE I UNIT 610 & BOAT SLIP 21 (LYING IN SEC'S 5 & 8) PROPERTY ADDR 521 MANDALAY AVE --------------------------------- GIBSON, PAUL F 521 MANDALAY AVE # 610 CLEARWATER FL 33767 1794 PINELA JIM COUNTY SMITH PROPERTY APPRAISER 03-May-2007 PAGE; 10 PARCEL #/BRIEF LEGAL DESC 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 701 (LYING IN SE PROPERTY ADDR: --------------- ?6449 / 001 / 0701 CONDO :'S 5 & 8) 521 MANDALAY AVE ------------------- 06449 / 001 / 0704 CONDO :'S 5 & 8) ,.5,21 MANDALAY AVE -------------------- 05 / 29 / 15 / 06449 / 001 / 0702 REEVE, DIANE B BELLE HARBOR CONDO 521 MANDALAY AVE # 702 PHASE I CLEARWATER FL UNIT 702 33767 1794 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 521 MANDALAY AVE -------------- -----------.__--_...._______------- ------------------- 05 / 29 / 15 / 06449 / 001 / 0703 SWIDEREK, TIMOTHY J BELLE HARBOR CONDO SWIDEREK, JOSEPH A PHASE I 4,.540 WEATHERVANE DR .UNIT 703 ALPHARETTA GA (LYING IN SEC'S 5 & 8) 30022 3759 PROPERTY ADDR* 521 MANDALAY AVE --------------------------------------------------------------------------- 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 704 (LYING IN SE, PROPERTY ADDR: --------------- 05 / 29 / 15 / 06449 / 001 BELLE HARBOR CONDO PHASE I UNIT 705 & BOAT SLIP 54 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 521 MANDALAY --------------------------- 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 706 (LYING IN SE PROPERTY ADDR: --------------- OWNER'S NAME AND ADDRESS LEVINE, RICHARD LEVINE, BARBARA 5047 OTIS AVE TART ANA CA 91356 4207 AVERY, JOSEPHINE ULINE, BRADLEY R 521 MANDALAY AVE ## 704 CLEARWATER FL 33767 1794 / 0705 TEJEDA, RAFAEL E TEJEDA, IDELFIA A 3516 WOODRIDGE PL PALM HARBOR FL 34684 2434 AVE 06449 / 001 / 0706 DEFERRARI, DIANA CONDO 110 HARBOR DR PALM HARBOR FL 34683 5403 'S 5 & 8) 521 MANDALAY AVE ----------------------------------------- JIM SMITH PINELLO COUNTY PROPERTY APPRAISER 03-May-2007 PAGES 11 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 06449 / 001 / 0707 GRIECO, DANIEL J II BELLE HARBOR CONDO GRIECO, DIANE Y PHASE I 521 MANDALAY AVE # 707 UNIT 707 CLEARWATER FL. (LYING IN SEC'S 5 & 8) 33767 1794 PROPERTY ADDR: 521 MANDALAY AVE --------------------------------------------------------------- 05 / 29 / 15 / 06449 / 001 / 0708 PERRY. GREGORY G BELLE HARBOR CONDO PERRY; GERALD N PHASE I 1574 SHINING ORE DR UNIT 708 BRENTWOOD TN (LYING IN SEC'S 5 & 8) 37027 2218 PROPERTY ADDR: 521 MANDALAY AVE --------------------------------------------------------- 05 / 29 / 15 / 06449 / 001 / 0709 EQUITABLE HOLDING CO LLC BELLE HARBOR CONDO 7667 EQUITABLE DR # 201 PHASE I EDEN PRAIRIE MN UNIT 709 55344 4626 (LYING IN SEC'S 5 & 8) PROPERTY ADDR= 521 MANDALAY AVE ----------------------------.,. ------.....--------------------------- 0 5 / 29 / 15 / 06449 / 001 BELLE HARBOR CONDO PHASE I UNIT 710 (LYING IN SEC'S 5 & 8) PROPERTY ADDR? 521 MANDALAY _---------_..----------------- 05 / 29 / 15 / 06449 / 001 / 0801 BELLE HARBOR CONDO PHASE I UNIT 801 & BOAT SLIP 59 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 521 MANDALAY AVE ---------------------_.-._.._--------- / 0710 EQUITABLE HOLDING CO LLC 7667 EQUITABLE DR ## 201 EDEN PRAIRIE MN 55344 4626 AVE _-----------------------------_._---- 05 / 29 / 15 / 06449 / 001 / BELLE HARBOR CONDO PHASE I UNIT 802 (LYING IN SEC'S 5 & 8) PROPERTY ADDR 521 MANDALAY ---------------------------- ABOOD, ROBERT G ABOOD, CATHERINE C 2256 MACKENZIE CT CLEARWATER FL 33765 2241 0802 BICZ, DANIEL S BIC2.. MARGARET C 521 MANDALAY AVE # 802 CLEARWATER FL 33767 1795 AVE PINELLO JIM COUNTY SMITH PROPERTY APPRAISER 03-May-2007 PAGE; 12 PARCEL #/BRIEF LEGAL DESC 05 / 29 / 15 / 06449 / 001 BELLE HARBOR CONDO PHASE I UNIT 803 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY --------------------------- 05 / 29 / 15 / 06449 / 001 BELLE HARBOR CONDO PHASE I UNIT 804 & BOAT SLIP 52 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY --------------------------- 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 805 (LYING IN SE' PROPERTY ADDR; -------------- 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 806 (LYING IN SEi PROPERTY ADDR; -------------- 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 807 (LYING IN SEi PROPERTY ADDR; -------------- OWNER'S NAME AND ADDRESS / 0803 HALL, ROGER W HALL, SYLVIA M 20938 SUNSWEET CT LAND 0 LAKES FL 34637 7422 AVE -------------------------------------------- ! 0804 ECKALL INVESTMENTS LLC 8155 ELBOW LN N ST PETERSBURG FL 33710 432., AVE 06449 / 001 / 0805 CONDO C'S 5 & 8) 521 MANDALAY AVE ------------------- GALBO, LORETO GALBO, ANGELO M 1 CRYSTAL CIR WESTPORT CT 06880 5067 / 0806 GIBSON, PAUL F 521 MANDALAY AVE CLEARWATER FL 33767 1700 AVE 06449 ! 001 CONDO C'S 5 8) 521 MANDALAY ------------- 06449 ! 001 / 0807 CONDO C'S 5 8) 521 MANDALAY AVE _------------------ DIA2., JACQUELINE B 10 PAPAYA ST # 1202 CLEARWATER FL 33967 2056 05 / 29 / 15 / 06449 / 001 / 0808 MILLER, DONALD R BELLE HARBOR CONDO MILLER, MARTHA S PHASE I 521 MANDALAY AVE # 808 UNIT 808 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1795 PROPERTY ADDR; 521 MANDALAY AVE -----_.--------.....--..,.------------------------_..--------... ------------------- JIM SMITH PINELLOCOUNTY PROPERTY APPRAISER* 03-May-2007 PAGE; 13 PARCEL #/BR?EF LEGAL DESC 05 / 29 / 15 / 06449 / 001 BELLE HARBOR COMO PHASE I UNIT 809 & BOAT SLIP 13 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY --------------------------- OWNER'S NAME AND ADDRESS / 0809 EGAN, JOHN M 10 PAPAYA ST # 1604 CLEARWATER FL 33767 2057 AVE ------------------------------ 05 / 29 / 15 / 06449 / 001 / 0810 BELLE HARBOR CONDO PHASE I UNIT 810 & BOAT SLIP 17 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY AVE ---------------------------_..-....--- 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 901 (LYING IN SEi PROPERTY ADDR; -------------- 06449 / 001 / 0901 CONDO :'S 5 & 8) 521 MANDALAY AVE ------------------- MEEHAN, THOMAS P 521 MANDALAY AVE ## 810 CLEARWATER FL 33767 1795 GAHERTY, JOHN B SR GAHERTY, CECILIA G 5527 S PARK AVE H I NSDALE IL 60521 5061 05 / 29 / 15 / 06449 / 001 / 0902 ENTEL: ROBERT J BELLE HARBOR CONDO 521 MANDALAY AVE # 902 PHASE I CLEARWATER FL UNIT 902 8 BOAT SLIP 5 33767 1795 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY AVE ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 001 BELLE HARBOR CONDO PHASE I UNIT 903 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY --------------------------- O5 / 29 / 15 / 06449 / 001 BELLE HARBOR CONDO PHASE I UNIT 904 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY _.--------------_.------_---- / 0903 KAHRS, CAROLYN J KAHRS7 HENRY G 4834 QUILL CT PALM HARBOR FL 34685 3699 AVE -------------------------------------- / 0904 ZURAVLE. JOE 2URAVLE, DOREEN A 2922 HAMPTON PLACE CT PLANT CITY FL 33566 9321 AVE ------------------------------------------- JIM SMITH PINELLOCOUNTY PROPERTY APPRAISER* 03-May-2007 PAGE; 14 PARCEL #/BRIEF LEGAL DESC 05 / 29 / 15 / 06449 / 001 / 0905 BELLE HARBOR CONDO PHASE I UNIT 905 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 521 MANDALAY AVE --------------------------------- 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 906 (LYING IN SEi PROPERTY ADDR; -------------- 06449 / 001 / 0906 CONDO C'S 5 & 8) 521 MANDALAY AVE ------------------- 05 / 29 / 15 / 06449 / 001 / 0907 BELLE HARBOR CONDO PHASE I UNIT 907 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY AVE --------------------------------- 05 / 29 / 15 / 06449 / 001 / 0908 BELLE HARBOR CONDO PHASE I UNIT 908 (LYING IN SEC'S 5 & 8) PROPERTY ADDR= ,.5.,21 MANDALAY AVE --------------------------------- OWNER'S NAME AND ADDRESS WARSTLER FAMILY TRUST WARSTLER: ARTHUR K THE 521 MANDALAY AVE # 905 CLEARWATER FL 33767 1795 HORVATH, KLARA 10 PAPAYA ST # 502 CLEARWATER FL 33767 CLARK, TERRY M CLARK, JANE H 16756 WHITES STORE RD BOYDS MD 20841 9673 --------_,.--..,..,..--.. -----_.....---- ACHARYA. RAVINDRA P ACHARYA. KALPANA R PO BOX 338 DUDLEY MA 01571 5849 05 / 29 / 15 / 06449 / 001 / 0909 M B C PROPERTIES II LLC BELLE HARBOR CONDO 4500 NORTHWOODS LN PHASE I BLOOMINGTON IN UNIT 909 47404 9420 (LYING IN SEC'S 5 & 8) PROPERTY ADDR* 521 MANDALAY AVE ----------------------....------------_.----_.......--.._--.._... --.._... --__--------------- 05 / 29 / 15 / 06449 / 001 / 0910 SLONE, RICHARD BELLE HARBOR CONDO 521 MANDALAY AVE # 910 PHASE I CLEARWATER FL UNIT 910 33767 (LYING IN SEC'S 5 & 8) PROPERTY ADDR= 521 MANDALAY AVE ----------------------------------------------------------------------- JIM SMITH PINELLAOUNTY PROPERTY APPRAISER 16 03-May-2007 PAGE: 15 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 06449 / 001 / 1001 WILKENS, GILBERT H BELLE HARBOR CONDO WILKENS, MAUREEN E PHASE I 36 BAKER ST UNIT 1001 & BOAT SLIP 29 DARTMOUTH NS BZW 6L1 (LYING IN SEC'S 5 & 8) CANADA PROPERTY ADDR* 521 MANDALAY AVE ------------------------------------------------------------...---------- 05 / 29 / 15 / 06449 / 001 / 1002 BELLE HARBOR CONDO PHASE I UNIT 1002 & BOAT SLIP 3 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 521 MANDALAY AVE ------------------------------------- J M C FAMILY INVESTMENTS LTD 2201 4TH ST N STE 200 ST PETERSBURG FL 33704 4300 05 / 29 / 15 / 06449 / 001 / 1003 MC SWIGGIN7 CHERYL A LIVING TRUS BELLE HARBOR CONDO C/O MC SWIGGIN, CHERYL A THE PHASE I 12 SAXONY ST UNIT 1003 CLIFTON PARK NY (LYING IN SEC'S 5 & 8) 12065 1655 PROPERTY ADDR* 521 MANDALAY AVE ---------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 001 / 1004 POOLE, WILLIAM L III BELLE HARBOR CONDO ROBINSON7 JOHN CONNIE JR PHASE I 135 WHITLEY MILL LN UNIT 1004 NEW LONDON NC (LYING IN SEC'S 5 & 8) 28127 9303 PROPERTY ADDR: 521 MANDALAY AVE ----------------------------------------------------------------------- 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 1005 (LYING IN SE PROPERTY ADDR: -------------- 06449 / 001 / CONDO I'S 5 & 8) 521 MANDALAY -------------- 1005 GIANFILIPPO. JOHN BURKETT, FRANKLIN S 1775 CEDAR WAXWING CT PALM HARBOR FL 34683 6676 AVE 05 / 29 / 15 / 06449 / 001 / 1006 KROLL, WOLFGANG BELLE HARBOR CONDO KROLL, LILLI PHASE I 521 MANDALAY AVE # 1006 UNIT 1006 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1795 PROPERTY ADDR: 521 MANDALAY AVE ------------------------------------------- JIM SMITH PINELLA&OUNTY PROPERTY APPRAISER 03-May-2007 PAGE; 16 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 06449 / 001 / 1007 POMS, ALAN M BELLE HARBOR CONDO 521 MANDALAY PHASE I CLEARWATER FL UNIT 1007 33767 1795 (LYING IN SEC'S 5 & 8) PROPERTY ADDR ; 521 MANDALAY AVE --------------------------------------------------- O5 / 29 / 15 / BELLE HARBOR PHASE I UNIT 1008 (LYING IN SE PROPERTY ADDR; -------------- 06449 / 001 f CONDO C'S 5 & 8) 521 MANDALAY -------------- AVE # 1007 1008 ROWLAND, CLARENCE E 16132 ARMSTEAD LN ODESSA FL 33556 3303 AVE ----------------------------- 05 / 29 / 15 / 06449 / 001 / 1009 J N E BEACH CONDOS LLC BELLE HARBOR CONDO 6326 MACLAURIN DR PHASE I TAMPA FL UNIT 1009 & BOAT SLIP 39 33647 1163 (LYING IN SE C'S 5 & 8) PROPERTY ADDR; -------------- 521 MANDALAY AVE ---------------------- ------- ---------------------------- 05 / 29 / 15 / 06449 / 001 / 1010 BELLE HARBOR 1010 LLC BELLE HARBOR CONDO 965 G REEN STREET CIR PHASE I GAINE SVILLE GA UNIT 1010 & BOAT SLIP 27 30501 2280 (LYING IN SE C'S 5 & 8) PROPERTY ADDR; -------------- 521 MANDALAY AVE ----------_.----------- ----_.-- ---------------------------- 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 1101 (LYING IN SEi PROPERTY ADDR; -------------- 06449 / 001 / 1101 CONDO C'S 5 & 8) 521 MANDALAY AVE ------------------- O5 / 29 / 15 / 06449 / 001 / 1102 BELLE HARBOR CONDO PHASE I UNIT 1102 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 521 MANDALAY AVE ---------------------_.-__----__--- COLTER, GEORGE L COLTER, HELEN T 521 MANDALAY AVE # 1101 CLEARWATER FL 33767 1797 SANON, ASHISH SANON, RITU 521 MANDALAY AVE # 1102 CLEARWATER BEACH FL 33767 1797 JIM SMITH PINELLAOCOUNTY PROPERTY APPRAISER. 03-May-2007 PAGE; 17 PARCEL #/BRIEF LEGAL DESC 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 1103 (LYING IN SEC PROPERTY ADDR= -------------- 06449 / 001 / 1103 CONDO S 5 & 8) 521 MANDALAY AVE ------------------- 05 / 29 / 15 / 06449 / 001 / 1104 BELLE HARBOR CONDO PHASE I UNIT 1104 (LYING IN SEC'S 5 & 8) PROPERTY! ADDR: 521 MANDALAY AVE --------------------------------- 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 1105 (LYING IN SE PROPERTY ADDR -------------- 06449 / 001 / 1105 CONDO C'S 5 8) 521 MANDALAY AVE ------------------- OWNER'S NAME AND ADDRESS FERRO, MICHAEL P 3003 SOUTH WELLS CHICAGO IL 60616 2739 FONTANA, ERIC M 2519 MCMULLEN BOOTH RD # 510--314 CLEARWATER FL 33761 4173 --....--------------------------------- REHKEMPER, BARBARA A 521 MANDALAY AVE # 1105 CLEARWATER FL 33767 1797 ------------------------------------ 05 / 29 / 15 / 06449 / 001 / 1106 CASO, RONALD BELLE HARBOR CONDO CASO, BERNADETTE PHASE I 3 SUTPHIN AVE UNIT 1106 MATAWAN NJ (LYING IN SEC'S 5 & 8) 07747 3315 PROPERTY ADDR: 521 MANDALAY AVE -.. --------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 001 / BELLE HARBOR CONDO PHASE I UNIT 1107 (LYING IN SEC'S 5 8 8) PROPERTY ADDR 521 MANDALAY ---------------------------- 1107 COOK, JAMES C COOK, SHARI H 865 WADDINGTON CT PUNWOODY GA 30350 4459 AVE 05 / 29 / 15 / 06449 / 001 / 1108 MESTAS, DONALD M JR BELLE HARBOR CONDO MESTAS, CAROL S PHASE I 521 MANDALAY AVE # 1108 UNIT 1108 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1797 PROPERTY ADDR= 521 MANDALAY AVE ------------------------------------------------------------- JIM SMITH PINELLAOUNTY PROPERTY APPRAISER 03-May-2007 PAGE; 18 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 06449 / 001 / 1109 AVA MINA II LLC BELLE HARBOR CONDO 808 SMSKERISE BLVD PHASE I PORT ORANGE FL UNIT 1109 32127 7783 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 521 MANDALAY AVE ------------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 001 / BELLE HARBOR CONDO PHASE I UNIT 1110 & BOAT SLIP 7 (LYING IN SEC'S 5 & 8) PROPERTY ADDR 521 MANDALAY .....----.........----------------... _...-- 05 / 29 / 15 / BELLE HARBOR PHASE I UNIT 1201 (LYING IN SE PROPERTY ADDR -------------- 1110 MACK, DAVID A REVOCABLE TRUST MACK, DAVID A THE 30 JELLIFF LN SOUTHPORT CT 06890 1482 AVE - --------------------- Ub449 / 001 / 1201 HOERNIG, OTTO W CONDO HOERNIG, JUANITA S 521 MANDALAY AVE # CLEARWATER FL n-'S 5 & 8) 33767 1797 521 MANDALAY AVE ------------------------------------------- -------------- 1201 -------------- 05 / 29 / 15 / 06449 / 001 / 1202 WILLIAMS, BERNABE REVOCABLE TRUS BELLE HARBOR CONDO WILLIAMS, BERNABE THE PHASE I C/O RINGER, BILL UNIT 1202 & BOAT SLIP 9 PO BOX 8540 (LYING IN SEC'S 5 & 8) STOCKTON CA 95208 0 540 PROPERTY ADDR= 521 MANDALAY AVE ---------------------.....-------_..., -------_-_-------_.---------------------- 05 / 29 / 15 / 06449 / 001 / 1209 BELLE HARBOR CONDO PHASE I UNIT 1209 & BOAT SLIP 44 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 521 MANDALAY AVE --------------------------------..._-..._ FALLER, JANET L PERSONAL RESIDEN FALLER, JANET L THE 521 MANDALAY AVE # 1209 CLEARWATER FL 33767 1797 05 / 29 / 15 / 06449 / 001 / 1210 OLIVER, ROBERT BELLE HARBOR CONDO OLIVER, CHARLOTTE B PHASE I 521 MANDALAY AVE # 1210 UNIT 1210 & BOAT SLIP 11 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1797 PROPERTY ADDR: 521 MANDALAY AVE --------....----------------------.....---..,.--------...... -----------__-------- JIM SMITH PINELL*COUNTY PROPERTY APPRAISER. 03-May-2007 PAGE: 19 PARCEL #/BRIEF LEGAL DESC 05 / 29 / 15 / 06449 / 001 / 1401 BELLE HARBOR CONDO PHASE I UNIT 1401 (LYING IN SEC'S 5 & 8) PROPERTY ADDR• 521 MANDALAY AVE ------------------------------------- OWNER'S NAME AND ADDRESS PLANES, REGINA M STE 200 32801 US HIGHWAY 19 N PALM HARBOR FL 34684 3105 05 / 29 / 15 / 06449 / 001 / 1402 HEAL, RALPH C BELLE HARBOR CONDO NEAL, JULIE A PHASE I 4622 OSAGE CT UNIT 1402 R BOAT SLIP 42 GREEN BAY WI (LYING IN SEC'S 5 & 8) 54313 9531 PROPERTY ADDR: 521 MANDALAY AVE ------------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 001 / 1409 BELLE HARBOR CONDO PHASE I UNIT 1409 & .BOAT SLIP 33 (LYING IN SEC'S 5 & 8) PROPERTY ADDR= 521 MANDALAY AVE --------------...------------------- BERG, ANNA JACOBSEN 521 MANDALAY AVE # 1409 CLEARWATER FL 33767 1797 05 / 29 / 15 / 06449 / 001 / 1410 BELLE HARBOR CONDO PHASE I UNIT 1410 & BOAT SLIP 35 (LYING IN SEC'S 5 & 8) PROPERTY ADDR. 521 MANDALAY AVE ---------------------------------- DAHM, ERHARD M 5250 ELMGATE ORCHARD LAKE MI 48324 05 / 29 / 15 / 06449 / 002 / 0041 GONZALEZ, EDWARD A BELLE HARBOR CONDO GON2.ALE2. , MAR I T2.A PHASE II 8856 DARLENE DR UNIT 4 1 & BOAT SLIP 48 ORLANDO FL (LYING IN SEC'S 5 & 8) 32836 5826 PROPERTY -------- ADDR= ------ 505 MANDALAY -------------- AVE #F41 --------- ----------------------- 05 / 29 / 15 / 06449 / 002 / 0042 WEBER, JED P BELLE HARBOR CONDO WEBER, JILL E PHASE II PO BOX 560 UNIT 4 2 CRYSTAL BEACH FL (LYING IN SEC'S 5 R 8) 34681 03560 PROPERTY -------- ADDR* ------ 505 MANDALAY -------------- AVE #42 ----------- -------------------- JIM SMITH PINELLADCOUNTY PROPERTY APPRAISER. 03-May--2007 PAGE; MCA PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 06449 / 002 / 0043 BEAVER, MICHAEL BELLE HARBOR CONDO BEAVER, LINDA PHASE II 1311 SCOTTSLAND DR UNIT 43 LAKELAND FL (LYING IN SEC'S 5 & 8) 33813 3796 PROPERTY ADDR= 505 MANDALAY AVE #43 ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0044 CHRISTOPHER, TODD BELLE HARBOR CONDO CHRISTOPHER, WANDA PHASE II 3743 PRESIDENTIAL DR UNIT 44 & BOAT SLIP 22 PALM HARBOR FL (LYING IN SEC'S 5 & 8) 34685 1075 PROPERTY ADDR: 505 MANDALAY AVE #44 ---------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0045 COULTER, WAYNE R BELLE HARBOR CONDO COULTER, PAMELA W PHASE II 4407 W DALE ST UNIT 45 & BOAT SLIP 60 TAMPA FL (LYING IN SEC'S 5 & 8) 33609 3706 PROPERTY ADDR; 505 MANDALAY AVE #F45 ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0051 BELLE HARBOR CONDO PHASE II UNIT 51 (LYING IN SEC'S 5 & 8) PROPERTY ADDR* 505 MANDALAY AVE 051 -----------------------------------_ GILMORE, DAVID C GILMORE, KATHLEEN A 2715 ST ANDREWS BLVD TARPON SPRINGS FL 34688 6312 05 / 29 / 15 / 06449 / 002 / 0052 MENKE, RICHARD F JR BELLE HARBOR CONDO 1215 WAREHAM DR PHASE II CINCINNATI OH UNIT 52 45202 1523 (LYING IN SEC'S 5 & 8) PROPERTY ADDR= 505 MANDALAY AVE #52 ----------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0053 HESS, DONALD E BELLE HARBOR CONDO HESS, PAULINE D PHASE II 819 HARBOR ISL UNIT 53 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1807 PROPERTY ADDR : 50,.5, MANDALAY AVE #53 -----------------------....-------_---_.-_....,---_..---_..---------__. -----__------ JIM SMITH PINELLOCOUNTY PROPERTY APPRAISER* 03-May-2007 PAGE; 21 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 06449 / 002 / 0054 MENKE, RICHARD F JR BELLE HARBOR CONDO 1053 SAINT GEORGE ST PHASE II CINCINNATI OH UNIT 54 45202 1733 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 505 MANDALAY AVE #54 ----------------------...-----.....--_---------_-----.,...--------__..-------_.----- 05 / 29 / 15 / 06449 / 002 / 0055 YOFAN: JACQUELINE BELLE HARBOR CONDO YOFAN7 AVI PHASE II 10 PAPAYA ST # 1202 UNIT 55 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 2056 PROPERTY ADDR; 505 MANDALAY AVE #55 _-----_..------------------...._...-_.....---_----------------_--_-_------___------ 05 / 29 / 15 / 06449 / 002 / 0056 MC CULLOUGH> JAMES & MARLENE LIV BELLE HARBOR CONDO C/O MC CULLOUGH, JAMES THE PHASE II 21 IDLEWILD ST UNIT 56 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1517 PROPERTY ADDR< 505 MANDALAY AVE #56 ---_..------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0061 WASHINK07 SHAWN BELLE HARBOR CONDO PO BOX 260995 PHASE II TAMPA FL UNIT 61 33685 0995 (LYING IN SEC'S 5 & 8) PROPERTY ADDR* 505 MANDALAY AVE #61 -------------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0062 BELLE HARBOR CONDO PHASE II UNIT 62 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 505 MANDALAY AVE #62 -------------------------------- ------ O'SHAUGHNESSY. BETTY JEAN 505 MANDALAY AVE # 62 CLEARWATER FL 33767 1718 05 / 29 / 15 / 06449 / 002 / 0063 CRESPO: LUIS E BELLE HARBOR CONDO CRESPO, VIRGINIA M PHASE II 995 BAY ESPLANADE UNIT 63 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1004 PROPERTY ADDR> 505 MANDALAY AVE #63 ----------------------------------------------------------------------- JIM SMITH PINELL*COUNTY PROPERTY APPRAISER. 03-May-2007 PAGE; 22 PARCEL #/BRIEF LEGAL DESC 05 / 29 / 15 / BELLE HARBOR PHASE II UNIT 64 (LYING IN SE PROPERTY ADDR; -------------- 06449 / 002 / 0064 CONDO -_'S 5 & 8) 505 MANDALAY AVE #64 ------------------------- OWNER'S NAME AND ADDRESS BIELER, RONALD 505 MANDALAY AVE # C64 CLEARWATER FL 33767 1716 05 / 29 / 15 / 06449 / 002 / 0065 CHEN, CHUNG J BELLE HARBOR CONDO 505 MANDALAY AVE # 65 PHASE II CLEARWATER FL UNIT 65 33767 1718 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 505 MANDALAY AVE #65 ------------------------------------------------------------------------ 05 / 29 / 15 / 06449 / 002 / 0066 J K B BEACH-HOLDINGS LLC BELLE HARBOR CONDO 1825 REGAL MIST LOOP PHASE II TRINITY FL UNIT 66 34655 4976 (LYING IN SEC'S 5 & 8) PROPERTY ADDR. 505 MANDALAY AVE #66 -----------------------------------------------.,.------------------------ 05 / 29 / 15 / 06449 / 002 / 0067 BELLE HARBOR CONDO PHASE II UNIT 67 (LYING IN SEC'S 5 & 8) PROPERTY ADDR. 505 MANDALAY AVE #67 -----------------------.....____----__--- 05 / 29 / 15 / 06449 / 002 / 0071 BELLE HARBOR CONDO PHASE II UNIT 71 (LYING IN SEC'S 5 & 8) PROPERTY ADDR+ 505 MANDALAY AVE #71 ------------------------------------ 05 / 29 / 15 / 06449 / 002 / 0072 BELLE HARBOR CONDO PHASE II UNIT 72 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 505 MANDALAY AVE #72 ------------------------------------- ALUISY7 ROMAN G ALUISY7 CHRISTINE 505 MANDALAY AVE # 67 CLEARWATER FL. 33767 1718 CHASE, WALTER 11 SAN MARCO # 1405 CLEARWATER FL 33767 2075 HYCY PETER HYC, ANDY 505 MANDALAY AVE # 72 CLEARWATER FL 33767 1718 JIM SMITH PINELLAWCOUNTY PROPERTY APPRAISER 16 03-May-2007 PAGEa 23 PARCEL #/BRIEF LEGAL DESC 05 / 29 / 15 / 06449 / 002 / 0073 BELLE HARBOR CONDO PHASE II UNIT 73 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 505 MANDALAY AVE ..-.-----------........-------------------- OWNER'S NAME AND ADDRESS CLASSONY STEPHEN J CLASSON, KAREN L 801 HERITAGE RD STE A DEPERE WI 54115 3292 #73 ------------------.,-.------------------- 05 / 29 / 15 / 06449 / 002 / 0074 RENDELY JEROLD S TRUST BELLE HARBOR CONDO C/O RENDEL. JEROLD S THE PHASE II 660 SNUG ISL UNIT 74 CLEARWATER Fl- (LYING IN SEC'S 5 t 8) 33767 1829 PROPERTY ADDR= 505 MANDALAY AVE #74 --- ------------------------------------------------------------ 05 / 29 / 15 / 06449 / 002 / 0075 BELLE HARBOR CONDO PHASE II UNIT 75 (LYING IN SEC'S 5 & 8) PROPERTY ADDR 505 MANDALAY AVE #75 ------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0301 BELLE HARBOR CONDO PHASE II UNIT 301 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 501 MANDALAY AVE #301 ------------------------------------- 05 / 29 / 15 / BELLE HARBOR PHASE II UNIT 302 (LYING IN SEi PROPERTY ADDR -------------- 06449 / 002 / 0302 CONDO :'S 5 & 8) 501 MANDALAY AVE ------------------- 05 / 29 / 15 / 06449 / 002 / 0303 BELLE HARBOR CONDO PHASE II UNIT 303 (LYING IN SEC'S 5 & 8) PROPERTY ADDR= 501 MANDALAY AVE -------------------------.--------- MACRE, DANIEL M MACRE, ANNETTE 505 MANDALAY AVE # 75 CLEARWATER FL. 33767 1718 GALASSO9 MICHAEL GALASSO. DAWN 1631 SAND KEY ESTATES CT CLEARWATER FL 33767 2959 CORDEIRO, JACK CORDEIROY ALDA 501 MANDALAY AVE # 302 CLEARWATER FL 33767 1707 #302 ------------- :......-------... ---------------- PENN COMMONS LP PO BOX 308 DU BOIS PA 15801 0308 #303 --------------------------------------- JIM SMITH PINELLAWCOUNTY PROPERTY APPRAISER 03-May-2007 PAGE: 24 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS ray / 29 / 15 / 06449 / 002 / 0304 MANION, JOSEPH M BELLE HARBOR CONDO MANION, JANINE M PHASE II 10118 BENNINGTON DR UNIT 304 TAMPA FL (LYING IN SEC'S 5 & 8) 33626 2406 PROPERTY ADDR: 501 MANDALAY AVE #304 ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0306 BARRETT, WILLIAM T BELLE HARBOR CONDO BARRETT, SHEILA M PHASE II 11 SAN MARCO ST # 408 UNIT 306 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 2060 PROPERTY ADDR: 501 MANDALAY AVE #306 -----_.-.-----------.....----------------_.----------...---...... ----....--..------------ 05 / 29 / 15 / 06449 / 002 / 0308 YOFANY AVI BELLE HARBOR CONDO YOFANv JACKIE PHASE II 10 PAPAYA ST # 1202 UNIT 308 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 2056 PROPERTY ADDR: 501 MANDALAY AVE #308 ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0309 BELLE HARBOR CONDO PHASE II UNIT 309 & BOAT SLIP 64 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 501 MANDALAY AVE #309 ---------------------.----_-.---_------ STANISLAWEK, DANIEL STANISLAWEK, GRE:TA 501 MANDALAY AVE # 309 CLEARWATER FL 33767 1707 05 / 29 / 15 / 06449 / 002 / 0310 INVESTMENT BUILDING GROUP II INC BELLE HARBOR CONDO 9460 125TH ST PHASE II SEMINOLE FL UNIT 310 33772 2043 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 501 MANDALAY AVE #310 ----------_.------.....--.....-_..... ---------------.....--------_-- -------------------- 05 / 29 / 15 / 06449 / 002 / 0401 HAYNES, ALVIN S BELLE HARBOR CONDO HAYNES, BITA P PHASE II 501 MANDALAY AVE # 401 UNIT 401 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1708 PROPERTY ADDR: 501 MANDALAY AVE #401 ---------------------_..------------_.,---------------------.,.... -_------------ JIM SMITH PINELL*COUNTY PROPERTY APPRAISER. 03-May-2007 PAGE; 25 PARCEL #/BRIEF LEGAL DESC 05 / 29 / 15 / 06449 / 002 / 04032 BELLE HARBOR CONDO PHASE II UNIT 402 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 501 MANDALAY AVE #4032 ---------------------------_..---------- OWNER'S NAME AND ADDRESS KOPANAKIS: WILLIAM A 501 MANDALAY AVE # 402 CLEARWATER FL 33767 1708 05 / 29 / 15 / 06449 / 00,7 / 0403 COOKE FAMILY REV TRUST BELLE HARBOR CONDO C/O COOKE: RUSSELL D THE PHASE II 14 CLARK ISLAND RD UNIT 403 AMHERST NH (LYING IN SEC'S 5 & 8) 03031 1766 PROPERTY ADDR; 501 MANDALAY AVE #403 -.__-------.-------.....--.e.--......,......,...--.....-----.....--------------,_. ---_---.... -----------.. - 05 / 29 / 15 / 06449 / 002 / 0404 LEBRON, GEORGE BELLE HARBOR CONDO LEBRON, SONIA DUDZIAK PHASE II 506 TAMARACK DR UNIT 404 BARTLETT IL (LYING IN SEC'S 5 & 8) 60103 1515 PROPERTY ADDR= 501 MANDALAY AVE #404 -------------------------------------.....------_----------_-_.--- 05 / 29 / 15 / 06449 / 002 / 0405 BELLE HARBOR CONDO PHASE II UNIT 405 (LYING IN SEC'S 5 & 8) PROPERTY ADDR 501 MANDALAY AVE #405 ------------------------------------- YOURTH, BRADLEY J YOURTHY VALERIE R 501 MANDALAY AVE # 405 CLEARWATER FL 33767 1708 05 / 29 / 15 / 06449 / 002 / 0406 BELLE HARBOR CONDO PHASE II UNIT 406 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 501 MANDALAY AVE #406 ------------------------------------- SALTZMAN, MURRAY SALTZMAN7 BARBARA 1170 GULF BLVD # 306 CLEARWATER FL 33767 2780 05 / 29 / 15 / 06449 / 002 / 0407 SUCHARSKI7 FRANK J BELLE HARBOR CONDO SUCHARSKI7 CATHERINE J PHASE II 3263 MORRELL AVE # I UNIT 407 PHILADELPHIA PA (LYING IN SEC'S 5 & 8) 19114 1117 PROPERTY ADDR= 501 MANDALAY AVE #407 --------------------------------------------------------------- JTM S? ITTH PINELL* COUNTY PROPERTY APPRAISE 03-May-2007 PAGE: 26 PARCEL #/BRIEF LEGAL DESC 05 / 29 / 15 / BELLE HARBOR PHASE II UNIT 408 (LYING IN SE? PROPERTY ADDR: --------------- 06449 / 002 / 0408 CONDO :'S 5 8) 501 MANDALAY AVE #408 ------------ ------ OWNER'S NAME AND ADDRESS ANDERSEN LARRY E 102 DICKINSON ST PHILADELPHIA PA 19147 6108 05 / 29 / 15 / 06449 / 002 / 0409 PARAMOUNT LLC BELLE HARBOR CONDO 1803 BRIAR CREEK BLVD PHASE II SAFETY HARBOR FL UNIT 409 & BOAT SLIP 62 34695 4696 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 501 MANDALAY AVE #409 -------------------------------------------------------------- x.15 / 29 / 15 / 06449 / 002 BELLE HARBOR CONDO PHASE II UNIT 410 & BOAT SLIP 28 (LYING IN SEC'S 5 & 8) PROPERTY ADDR= 501 MANDALAY --------------------------- 05 / 29 / 15 / 06449 / 002 BELLE HARBOR CONDO PHASE II UNIT 501 (LYING IN SEC'S 5 $ 8) PROPERTY ADDR: 501 MANDALAY --------------------------- / 0410 K02.MINSKI, JACEK KOZMINSKI, GRAZYNA 4758 S PULASKI RD CHICAGO IL 60632 4114 AVE #410 ------------------------------ / 0501 BURKETT, THOMAS J BURKETT, DEBORAH L 14744 SAN MARSALA CT TAMPA FL 33626 3316 AVE #501 ----------------------------------- 05 / 29 / 15 / 06449 / 002 / 0502 BELLE HARBOR CONDO PHASE II UNIT 502 & BOAT SLIP 65 (LYING IN SEC'S 5 & 8) PROPERTY ADDR. 501 MANDALAY AVE #502 ---------------------.,...__..------------- MORRIS, MICHELLE V 29 GAYLORD GLEN WATERBURY CT 06708 2100 05 / 29 / 15 / 06449 / 002 / 0503 KAHLER, PERRY E BELLE HARBOR CONDO KAHLER, VICKI LEE PHASE II 501 MANDALAY AVE: # 503 UNIT 503 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1709 PROPERTY ADDR= 501 MANDALAY AVE #503 --------------------------------------------------------------- JIM SMITH PINELLAIWOUNTY PROPERTY APPRAISER • 03-May-2007 PAGE: 27 PARCEL #/BRIEF LEGAL DESC 05 / 29 / 15 / 06449 / 002 / 0504 BELLE HARBOR CONDO PHASE II UNIT 504 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 501 MANDALAY AVE #504 ------------------------------------- OWNER'S NAME AND ADDRESS LAMBRINIDES FAMILY IRREV TRUST C/O LAMBRINIDES. A C THE 2175 VALLEY VIEW DR ROCKY RIVER OH 44116 2860 05 / 29 / 15 / 06449 / 002 / 0505 MIHOLICS, JOHN C BELLE HARBOR CONDO MIHOLICS: MARIA T PHASE 11 18 WINGATE PL UNIT 505 YONKERS NY (LYING IN SEC'S 5 & 8) 10705 1533 PROPERTY ADDR* 501 MANDALAY AVE #505 -----------------------------_.--------....--_ ---------__..--__.. ------_------ 05 / 29 / 15 / 06449 / 002 / 0506 LOWE, JEFF BELLE HARBOR CONDO LOWE, KATHY PHASE II 700 DEER VUE LN UNIT 506 FENTON MO (LYING IN SEC'S 5 & 8) 63026 3562 PROPERTY ADDR: 501 MANDALAY AVE #506 ------------------------------.... ----....--------_------....-----_..- 05 / 29 / 15 / 06449 / 002 / 0507 ALTNER: MARTIN L BELLE HARBOR CONDO ALTNER. JANIS C PHASE II ,.5,01 MANDALAY AVE # 507 UNIT 507 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1709 PROPERTY ADDR: 501 MANDALAY AVE #507 ----------------....------------__--.----------------_.,-_.--...... --.._._...----------- 05 / 29 / 15 / 06449 / 002 / 0508 BEHESHTI: TARANEH BELLE HARBOR CONDO 501 MANDALAY AVE # ,.5,08 PHASE II CLEARWATER. FL UNIT 508 33767 1709 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 501 MANDALAY AVE #508 ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0509 BELLE HARBOR CONDO PHASE II UNIT 509 & BOAT SLIP 16 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 501 MANDALAY AVE #509 ------------------------------------- ISHAM, MARK W ISHAM, DONNA H 1880 CENTURY PARK E # 1600 LOS ANGELES CA 90067 1661 IM SMITH PINEL.LO COUNTYJ PROPERTY APPRAISE 03-May-2007 PAGE; 28 PARCEL */BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 06449 / 002 / 0510 LIEBERMAN, LAWRENCE T BELLE HARBOR CONDO LIEBERMAN, DEBORAH S PHASE II 10 WILLOWOOD LN UNIT 510 & BOAT SLIP 26 OLDSMAR FL (LYING IN SEC'S 5 & 8) 34677 2058 PROPERTY ADDR; 501 MANDALAY AVE #510 ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0601 BELLE HARBOR CONDO PHASE II UNIT 601 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 501 MANDALAY AVE #601 ------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0602 BELLE HARBOR CONDO PHASE II UNIT 602 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 501 MANDALAY AVE --------------------------------- COLTER, GEORGE COLTER, HELEN 501 MANDALAY AVE # 601 CLEARWATER FL 33767 1710 SCHECHTER, JANIS ILENE 501 MANDALAY AVE # 602 CLEARWATER FL 33767 1710 #602 -------------------- 05 / 29 / 15 / 06449 / 002 / 0603 HALLERAN, EDWARD M BELLE HARBOR CONDO SIKA, STEPHEN PHASE II 1005 VICTORIA DR UNIT 603 DUNEDIN FL (LYING IN SEC'S 5 & 8) 34698 5749 PROPERTY ADDR; 501 MANDALAY AVE #603 ---------------------.....---_..---------_.------------_- ------ 05 / 29 / 15 / BELLE HARBOR PHASE II UNIT 604 (LYING IN SE' PROPERTY ADDR; -------------- 05 / 29 / 15 / BELLE HARBOR PHASE II UNIT 605 (LYING IN SE PROPERTY ADDR -------------- 06449 / 002 / 0604 CONDO C'S 5 & 8) 501 MANDALAY AVE #604 ----------------------- 06449 / 002 CONDO :'S 5 & 8) 501 MANDALAY ------------- ESPOSITO, TONY 501 MANDALAY AVE # 604 CLEARWATER FL 33767 1710 0605 RAGHAVAN, CHAKRAVARTHY RAGHAVANs VASANTHY 8918 SOUTHERN BREEZE DR ORLANDO FL 32836 5012 AVE #605 ---------------------------------- JIM SMITH PINELLASOUNTY PROPERTY APPRAISER 03-May-2007 PAGE; 29 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 06449 / 002 / 0606 CHACONAS: ANGELINE BELLE HARBOR CONDO 501 MANDALAY AVE # 606 PHASE II CLEARWATER FL UNIT 606 33767 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 501 MANDALAY AVE #606 -----....--------.... -----------------_...---------------...--------.---_----------- 05 / 29 / 15 / 06449 / 002 / 0607 LEVY, BELLE HARBOR CONDO LEVY, PHASE II 10005 UNIT 607 TAMPA (LYING IN SEC'S 5 & 8) 33626 PROPERTY ADDR= 501 MANDALAY AVE #607 ------------------------------------------- MARK S DEBORAH T RADELIFFE DR FL 2511 ------------ 05 / 29 / 15 / 06449 / 002 / 0608 MC CARTHY, LORETTA E TRUST BELLE HARBOR CONDO C/O MC CARTHY, EUGENE J PHASE II 2505 ENTERPRISE RD UNIT 608 CLEARWATER FL (LYING IN SEC'S 5 8 8) 33763 1100 PROPERTY ADDR* 501 MANDALAY AVE #608 ----------------------------------- -.-.....--------------.-_------------------ 05 / 29 / 15 / 06449 / 002 / 0609 PEARLMAN, LOUIS J BELLE HARBOR CONDO 12488 PARK AVE PHASE II WINDERMERE FL UNIT 609 & BOAT SLIP 2 34786 7712 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 501 MANDALAY AVE #609 ----------•--------------------------.-----------------------_----...-_------ 0 5 / 29 / 15 / 06449 / 002 BELLE HARBOR CONDO PHASE II UNIT 601 & BOAT SLIP 4 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 501 MANDALAY --------------------------...- / 0610 CHASE, WALTER W CHASE, JUDITH A 11 SAN MARCO ST CLEARWATER FL 33767 2066 AVE #610 --------------------------- 05 / 29 / 15 / 06449 / 002 / 0701 BELLE HARBOR CONDO PHASE II UNIT 701 (LYING IN SEC'S 5 & 8) PROPERTY ADDR= 501 MANDALAY AVE #701 --------------------------------------- NOLL, STEPHEN A NOLL, DEBORAH V 501 MANDALA`< AVE # 701 CLEARWATER FL 33767 1711 JIM TH PINELLAIWOUNTY SM0"PERTY APPRAISER 03-May-2007 PAGE; 30 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 f 06449 / 002 / 0702 MC DERMOTT, JAMES T BELLE HARBOR CONDO DRAPP, SHANNON M PHASE II 001 MANDALAY AVE # 702 UNIT 702 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1711 PROPERTY ADDR= 501 MANDALAY AVE #702 --------------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / BELLE HARBOR CONDO PHASE II UNIT 703 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 501 MANDALAY ---------------------------- 05 / 29 / 15 / BELLE HARBOR PHASE II UNIT 704 (LYING IN SE, PROPERTY ADDR= -------------- 0703 BAKER, BARRY J BAKER ANN F 1435 STEVENSON DR LIBERTYVILLE IL 60048 2572 AVE #703 --------------------------- 06449 / 002 / 0704 CONDO :'S 5 & 8) 501 MANDALAY AVE #704 ----------------------- 05 / 29 / 15 / 06449 / 002 BELLE HARBOR CONDO PHASE II UNIT 705 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 501 MANDALAY --------------------------- 05 / 29 / 15 / BELLE HARBOR PHASE II UNIT 706 (LYING IN SE PROPERTY ADDR= -_. ------__--__.. COSTELLO, JAMES COSTELL07 JENNY L 19103 MANDARIN GROVE PL TAMPA FL 33647 3095 f 0705 BERGER, RALPH F LIVING TRUST C/O BERGER, RALPH F THE 7131 ASHVILLE PARK DR COLUMBUS OH 43235 5013 AVE #705 -------------------------------------------- 06449 / 002 / CONDO --'S 5 & 8) 501 MANDALAY -------------- 0706 MARRULLIER, ALAN H 501 MANDALAY AVE # 706 CLEARWATER FL 33767 1711 AVE #706 --------------------- 05 f 29 / 15 / 06449 / 002 / 0707 CASCIOLA, GENE M BELLE HARBOR CONDO CASCIOLA, SHEILA PHASE II 7000 WEDDINGTON BROOK DR UNIT 707 WEDDINGTON NC (LYING IN SEC'S 5 & 8) 28104 7274 PROPERTY ADDR= 501 MANDALAY AVE #707 ----------------------------------------------------------------- JIM TH PINELLA OUNTY SRMIOPERTY APPRAISER • 03-May-2007 PAGE; 31 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 06449 / 002 / 0708 HOERNIG, LAURA BELLE HARBOR CONDO 337 RIVER BEND RD PHASE II GREAT FALLS VA UNIT 7 08 22066 4138 (LYING IN SEC'S 5 & 8) PROPERTY -------- ADDR; ------ 501 MANDALAY AVE #708 ---------.----------_..---- --------------------------------- 05 / 29 / 15 / 06449 / 002 / 0709 LOWRY: RICHARD M BELLE HARBOR CONDO LOWRY, ALEXIS PHASE II 1648 RIPARIAN DR UNIT 709 NAPERVILLE IL (LYING IN SEC'S 5 & 8) 60565 4173 PROPERTY ADDR; 501 MANDALAY AVE #709 ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0710 BELLE HARBOR CONDO PHASE II UNIT 710 & BOAT SLIP 6 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 501 MANDALAY AVE #710 --------------------------_....--------- 05 / 29 / 15 / 06449 / 002 ! BELLE HARBOR CONDO PHASE II UNIT 801 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 501 MANDALAY ---------------------------- 05 / 29 / 15 / 06449 / 002 f BELLE HARBOR CONDO PHASE II UNIT 802 & BOAT SLIP 38 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 501 MANDALAY ---------------------------- OLIVER, BRIAN C OLIVER, JEANINE H 3739 MULLENHURST DR PALM HARBOR FL 34685 3661 0801 KUNIS, SABINA KUNIS, NAUM 501 MANDALAY AVE # 801 CLEARWATER FL 33767 1712 AVE #801 -------------------------------- 0802 KNUTSON, WILLIAM R II KNUTSON, CAROLE M 501 MANDALAY AVE # 802 CLEARWATER FL 33767 1712 AVE #802 ------------------------------------------- 05 / 29 f 15 / 06449 / 002 / 0803 BELLE HARBOR CONDO PHASE II UNIT 803 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 501 MANDALAY AVE 4803 ------------------------------------- ATKINS, J MICHAEL ATKINS, TERESA K 1613 ELM SHORE DR PORT BYRON IL 61275 9092 SMITH PINELLAOOUNTYIM J PROPERTY APPRAISER 03-May-2007 PAGE; 32 PARCEL ##/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 06449 / 002 / 0804 MIKHAIL, MAGUED N BELLE HARBOR CONDO MAR2.OUK. CHRISTIANE G PHASE II 591 BELTED KINGFISHER DR N UNIT 804 PALM HARBOR FL (LYING IN SEC'S 5 & 8) 34683 6149 PROPERTY ADDR; 501 MANDALAY AVE #804 --------------------------------------------------- _-_--__------_--- O5 / 29 / 15 / BELLE HARBOR PHASE II UNIT 805 (LYING IN SE PROPERTY ADDR; -------------- 06449 / 002 / CONDO W'S 5 & 8) 501 MANDALAY -------------- 0805 GINION. WAYNE C GINION: CONSTANCE R 92 PEREGRINE DR VOORHEES NJ 08043 1661 AVE #805 ------------------------------------------- O5 / 29 / 15 / 06449 / 002 / 0806 DEISEF CHARLES M BELLE HARBOR CONDO DEISE7 MARTIN V PHASE II 501 MANDALAY AVE # 806 UNIT 806 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1712 PROPERTY ADDR; 501 MANDALAY AVE #806 --------------.... --------_--_..--------....-----------------___--------_------ 05 / 29 / 15 / 06449 / 002 / 0807 ATKINS, J MICHAEL BELLE HARBOR CONDO ATKINSY TERESA K PHASE II 1613 ELMSHORE DR UNIT 807 PORT BRYAN IL (LYING IN SEC'S 5 & 8) 61275 PROPERTY ADDR; 501 MANDALAY AVE #807 ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0808 808 MANDALAY LLC BELLE HARBOR CONDO 2429 N FAIRFAX DR PHASE II ARLINGTON VA UNIT 808 22201 2712 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 501 MANDALAY AVE #808 ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0809 2.URAVLE, JOE BELLE HARBOR CONDO 2.URAVLE. DOREEN A PHASE II 117 W ALEXANDER ST PMB 340 UNIT 809 PLANT CITY FL (LYING IN SEC'S 5 K 8) 33563 PROPERTY ADDR; 501 MANDALAY AVE #809 ----------------------------------------------------------------------- JIM SMITH PINELLAOOUNTY PROPERTY APPRAISER 0 03-May-2007 PAGE: 33 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS Cry / 29 / 15 / 06449 / 002 / 0810 KOCH, MYRON BELLE HARBOR CONDO KOCH, ELIZABETH PHASE II 501 MANDALAY AVE # 810 UNIT 810 8 BOAT SLIP 30 CLEARWATER FL. (LYING IN SEC'S 5 & 8) 33767 1712 PROPERTY ADDR; 501 MANDALAY AVE #810 ------------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0901 BELLE HARBOR CONDO PHASE II UNIT 901 & BOAT SLIP 14 (LYING IN SEC'S 5 & 8) PROPERTY ADDR: 501 MANDALAY AVE #901 -------------------------------------- 05 / 29 / 15 / 06449 / 002 / BELLE HARBOR CONDO PHASE II UNIT 902 & BOAT SLIP 10 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 501 MANDALAY ---------------------------- SNYDER, CLIFFORD D SNYDER, MARYLIN V 501 MANDALAY AVE # 901 CLEARWATER FL 33767 1713 0902 HURLEY, G JOHN HURLEY, MAUREEN JOYCE 501 MANDALAY AVE # 902 CLEARWATER FL 33767 1713 AVE #902 ------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0909 FIRST LIVING TRUST BELLE HARBOR CONDO ST JOHN, DENNIS THE PHASE II 501 MANDALAY AVE # 909 UNIT 909 & BOAT SLIP 18 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 PROPERTY ADDR; 501 MANDALAY AVE #909 ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 0910 BELLE HARBOR CONDO PHASE II UNIT 910 & BOAT SLIP 20 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 501 MANDALAY AVE #910 ------------------------------------- 05 / 29 / 15 / 06449 / 002 / 1001 BELLE HARBOR CONDO PHASE II UNIT 1001 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 501 MANDALAY ----------------------------------- ARRINGTON, WILLIAM H 501 MANDALAY AVE # 910 CLEARWATER FL 33767 1713 PLANES, REGINA 854 CYPRESS LAKEVIEW CT TARPON SPRINGS FL 34688 7307 AVE #1001 JIM SMITH PINELLAVOUNTY PROPERTY APPRAISER,jg 03-May-2007 PAGE; 34 PARCEL #/BRIEF LEGAL DESC 05 / 29 / 15 / 06449 / 002 / 1002 BELLE HARBOR CONDO PHASE II UNIT 1002 & BOAT SLIP 41 (LYING IN SEC'S 5 & 8) PROPERTY ADDR; 501 MANDALAY AVE #1002 -------------------------------------- OWNER'S NAME AND ADDRESS J N E BEACH CONDOS LLC 8875 HIDDEN RIVER PKWY STE 115 TAMPA FL 33637 2012 05 / 29 / 15 / 06449 / 002 / 1009 DAVIS: DEXTER C BELLE HARBOR CONDO DAVIS: LISA ALEXANDER PHASE II 501 MANDALAY AVE # 1009 UNIT 1009 & BOAT SLIP 36 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1714 PROPERTY ADDR; 501 MANDALAY AVE #1009 ----------------------------------------------------------------------- 05 / 29 / 15 / 06449 / 002 / 1010 RADKE, BRAD BELLE HARBOR CONDO RADKE, HEATHER PHASE II 501 MANDALAY AVE # UNIT 1010 & BOAT SLIP 24 CLEARWATER FL (LYING IN SEC'S 5 & 8) 33767 1714 PROPERTY ADDR; 501 MANDALAY AVE #1010 --------------------------------------------------------- 05 / 29 / 15 / 16362 / 000 / 0160 CLEARWATER BEACH REV CLEARWATER CITY PARK 1010 CLEARWATER, CITY OF PO BOX 4748 CLEARWATER FL 33758 4748 PROPERTY ADDR; MANDALAY AVE --------------....___-------_------------ 05 / 29 / 15 / 50308 / 000 / 1010 LA SAL MOTEL CONDO UNIT 101 (OFFICE) LA SAL MOTEL CONDO ASSN PO BOX 1054 DUPED I N FL 34697 1054 PROPERTY ADDR; 530 MANDALAY AVE ----------------------------------------------------------------------- 05 / 29 / 15 / 50308 / 000 / 1020 P S B CREDIT SERVICES INC LA SAL MOTEL CONDO 508 3RD ST UNIT 102 PRINSBURG MN 56281 3700 PROPERTY ADDR; 530 MANDALAY AVE -----------------_.--.....----------------------------------------------- JIM SMITH PINELLOCOUNTY PROPERTY APPRAISER. 03-May-2007 PAGE; 35 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 50308 / 000 / 1030 P S B CREDIT SERV INC LA SAL MOTEL CONDO PO BOX 38 UNIT 103 PRINSBURG MN 56281 0038 PROPERTY ADDR; 530 MANDALAY AVE ------------------------------------------------------------ 05 / 29 / 15 / 50308 / 000 / 1040 LA SAL MOTEL CONDO UNIT 104 P S B CREDIT SERV INC PO BOX 38 PRINSBURG MN 56281 0038 PROPERTY ADDR: 530 MANDALAY AVE ------------------------------- 05 / 29 / 15 / 50308 / 000 / 1050 LA SAL MOTEL CONDO UNIT 105 P S B CREDIT SERVICES INC 508 3RD ST PRINSBURG MN 56281 3700 PROPERTY ADDR: 530 MANDALAY AVE ----------------------------------------------------------------------- 05 / 29 / 15 / 50308 / 000 / 1060 LA SAL MOTEL CONDO UNIT 106 KOENIG, NORBERT KOENIG, BRUNHILDE 44 EILEEN AVE PLAINVIEW NY 11803 5203 PROPERTY ADDR; 530 MANDALAY AVE ------------------------------------- 05 / 29 / 15 / 50308 / 000 / 1070 LA SAL MOTEL CONDO UNIT 107 222 E 13TH STREET CORP 44 EILEEN AVE PLAINVIEW NY 11803 5203 PROPERTY ADDR; 530 MANDALAY AVE --_.--------....-------------------------.-----.....----------__...__-_----_------- 05 / 29 / 15 / 50308 / 000 / 2010 LA SAL MOTEL CONDO UNIT 201 ROTH, ELIZABETH W 8826 NAUTILUS DR TAMPA FL 33635 1339 PROPERTY ADDR; 530 MANDALAY AVE ------------------------------- 05 / 29 / 15 / 50308 / 000 / 2020 LA SAL MOTEL CONDO UNIT 202 MC LAY, DAVID THE PO BOX 7153 CLEARWATER FL 33758 7153 PROPERTY ADDR; 530 MANDALAY AVE ------------------------------------------.....----------.....---__-------.....----- JIM SMITH PINELL*COUNTY PROPERTY APPRAISER 03-May-2007 PAGE; 36 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 50308 / 000 / 2030 P S B CREDIT SERV INC LA SAL MOTEL CONDO PO BOX 38 UNIT 203 PRINSBURG MN 56281 0038 PROPERTY ADDR; 530 MANDALAY AVE ----------------------------------------------------------- 05 / 29 / 15 / 50308 / 000 / 2040 P S B CREDIT SERV INC LA SAL MOTEL CONDO PO BOX 38 UNIT 204 PRINSBURG MN 56281 0038 PROPERTY ADDR: 530 MANDALAY AVE -_--_-_----_---_....--......._..,. --__---............--__----__..__---------.....----------------- 05 / 29 / 15 / 50308 / 000 / 2050 P S B CREDIT SERV INC LA SAL MOTEL CONDO PO BOX 38 UNIT 205 PRINSBURG MN 56281 0038 PROPERTY ADDR; 530 MANDALAY AVE ----------------------------------------------------------------------- 05 / 29 / 15 / 50308 / 000 / 2060 HAYDONv CHARLES R LA SAL MOTEL CONDO 1601 DRUID RD E UNIT 206 CLEARWATER FL 33756 4512 PROPERTY ADDR; 530 MANDALAY AVE ----------------------------------------------------------------------- 05 / 29 / 15 / 57924 / 000 / 0020 MILLER'S REPLAT LOTS 2 & 3 & VAC BEACH DR ON W PROPERTY ADDR; 7 ROCKAWAY ST --------------------------------- PRESTON. MICHAEL G THE 419 E SHORE DR CLEARWATER FL 33767 2028 05 / 29 / 15 / 57924 / 000 / 0040 MILLER'S REPLAT LOT 4 & N 7FT OF LOT 9 PROPERTY ADDR; 19 ROCKAWAY ST BONI, JOAN P 19 ROCKAWAY ST # 4 CLEARWATER FL 33767 1739 05 / 29 / 15 / 57924 / 000 / 0050 KOVACS, VIOLET C MILLER'S REPLAT 23 ROCKAWAY ST LOT 5 CLEARWATER FL 33767 1739 PROPERTY ADDR 23 ROCKAWAY ST ----------------------------------------------------------------------- JIM SMITH PINELLAWOUNTY PROPERTY APPRAISER 03--May-2007 PAGE; 37 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 05 / 29 / 15 / 57924 / 000 / 0070 TEMA INVESTMENTS MILLER'S REPLAT 251 174TH ST # 902 LOT 7 SUNNY ISLES BEACH FL 33160 3356 PROPERTY ADDR; 516 MANDALAY AVE ----------------------------------------------------------------------- 05 / 29 / 15 / 57924 / 000 / 0080 KOVACS, VIOLET K MILLER'S REPLAT 23 ROCKAWAY ST LOT 8 CLEARWATER FL 33767 1739 PROPERTY ADDR* 23 ROCKAWAY ST --------------------------------------------------.....----------.--_...------- 08 / 29 / 15 / 00000 / 220 / 0100 UNPLATTED LAND TO WEST OF LOTS 1 THRU 24 & N 1/2 OF LOT 25 CLEARWATER BEACH PARK (PT BEING VAC BEACH PROPERTY ADDR; CLEARWATER, CITY OF ATTN; CASH & INVESTMENTS MGR P 0 BOX 4748 CLEARWATER FL 33758 4748 --------------------------------------------------------- 08 / 29 / 15 / 16398 / 000 / 0570 MARY G REALTY INC CLEARWATER BEACH PARK 490 MANDALAY AVE LOTS 57,58,59,60,61,62 AND CLEARWATER FL 63 R N 10.25FT OF LOT 64 33767 2007 PROPERTY ADDR+ 490 MANDALAY AVE ---------------------------------........-----__....__...__._--_---- 08 / 29 / 15 / 16398 / 000 / 0720 CLEARWATER BEACH PARK LOTS 72 AND 73 MANDALAY LAND TRUST C/O DERVECH, STEVEN THE 3711 SWANN AVE TAMPA FL 33609 4521 PROPERTY ADDR. 458 MANDALAY AVE -------------------------------- 08 / 29 / 15 / 16398 / 000 / 0740 CLEARWATER BEACH PARK LOTS 74,75,76 AND 77 MANDALAY LAND TRUST C/O DERVECH, STEVEN THE 3711 SWANN AVE TAMPA FL 33609 4521 PROPERTY ADDR; 458 MANDALAY AVE ---------------------------------------------.....---_--------------------- JIM SMITH PINELLARCOUNTY PROPERTY APPRAISER. 03-May-2007 PAGE: 38 PARCEL #/BRIEF LEGAL DESC 08 / 29 / 15 / 16398 / 000 / 0780 CLEARWATER BEACH PARK LOTS 78 AND 79 PROPERTY ADDR; 454 MANDALAY AVE ----------------------------.-_- OWNER'S NAME AND ADDRESS P K & J K INC 5020 CENTRAL AVE ST PETERSBURG FL 33707 1942 08 / 29 / 15 / 16416 / 002 / 0200 HEILMANS RESTAURANTS INC CLEARWATER BEACH PARK 447 MANDALAY AVE 1ST ADD CLEARWATER FL BLK B: LOTS 20 THRU 23 & 33767 2013 VAC ALLEY INCL PROPERTY ADDR+ 457 MANDALAY AVE ----------------------------------------------------------------------- 08 / 29 / 15 / 16416 / 002 / 0240 CLEARWATERY CITY OF CLEARWATER BEACH PARK ATTNZ CASH & INVESTMENTS MGR 1ST ADD P O BOX 4748 BLK B: LOTS 24:25 & S 10 CLEARWATER FL FT OF LOT 26 & 1/2 VAC 33758 4748 PROPERTY ADDR= ------------------------------------------------------------------------- 08 / 29 / 15 / 16416 / 002 CLEARWATER BEACH PARK 1ST ADD BLK By N 15FT OF LOT 26 & ALL OF LOTS 27 THRU 31 & PROPERTY ADDR= 467 MANDALAY --------------------------- / 0270 J E C FUNDING INC C/O EPROPERTY TAX INC - DEPT 123 PO BOX 4900 SCOTT SDALE A2 85261 4900 AVE -------------------------------------------- 08 / 29 / 15 / 16416 / 002 / 0320 CLEARWATER BEACH PARK 1ST ADD BLK B: LOTS 32 THRU 43 LESS E 5FT PROPERTY ADDR= 483 MANDALAY AVE --------------------------------- B J E INC 630 S GULFVIEW BLVD CLEARWATER FL 33767 2642 08 / 29 / 15 / 16416 / 002 / 0440 MANDALAY BUILDING PARTNERSHIP CLEARWATER BEACH PARK 499 MANDALAY AVE 1ST ADD CLEARWATER FL BLK B7 LOTS 44 AND 45 33767 2045 AND 1/2 OF VAC ALLEY ON E PROPERTY ADDR 499 MANDALAY AVE ----------------------------------------------------------------------- IM SMITH PINELLAWOUNTYJ PROPERTY APPRAISER 03-May-2007 PAGE: 39 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 08 / 29 / 15 / 16434 / 001 / 0010 PRESTON, MICHAEL G THE CLEARWATER BEACH PARK 419 E SHORE DR 1ST ADD REPLAT CLEARWATER FL BLK A, LOT 1 AND 1/2 OF 33767 2028 VAC ALLEY ON W PROPERTY ADDR: 41 BAYMONT ST -------------------------------------------------------------------------- 08 / 29 / 15 / 16434 / 001 / 0020 CLEARWATER BEACH PARK 1ST ADD REPLAT BLK A: LOTS 2 THRU 7 & 15 FT VAC ALLEY ON W & LOT 8 PROPERTY ADDR= --------------------------------- L B J LLC 630 S GULFVIEW BLVD CLEARWATER FL 33767 2642 08 / 29 / 15 / 16434 / 001 / 0090 CLEARWATER BEACH PARK 1ST ADD REPLAT BLK A: LOTS 9 AND 10 AND 1/2 VAC ALLEY ON W PROPERTY ADDR= --------------------------- --------- 08 / 29 / 15 / 16434 / 001 / 0110 CLEARWATER BEACH PARK 1ST ADD REPLAT BLK A: LOT 11 PROPERTY ADDR: ----------------------------- J E C FUNDING INC C/O EPROPERTY TAX INC - DEPT 123 PO BOX 4900 SCOTTSDALE A2 85261 4900 ---------------------------------- CLEARWATER: CITY OF ATTN: CASH & INVESTMENTS MGR P 0 BOX 4748 CLEARWATER FL 33758 4748 08 / 29 / 15 / 16434 / 001 / 0120 HEILMANS RESTAURANTS INC CLEARWATER BEACH PARK 447 MANDALAY AVE 1ST ADD REPLAT CLEARWATER FL BLK Ar LOTS 12 THRU 15 33767 2013 INCL PROPERTY ADDR: 454 POINSETTIA ST 08 / 29 / 15 / 54658 / 000 / 0001 MANDALAY BEACH CLUB CONDO ASSN MANDALAY BEACH CLUB CONDO C/O MANDALAY BEACH CLUB LTD (COMMON ELEMENT) COMMON 2201 4TH ST N # 200 AREA ST PETERSBURG FL 33704 4300 PROPERTY ADDR --------------------------------------------------------------------------- JIM SMITH PINELLAMOUNTY PROPERTY APPRAISER 0 03-May-2007 PAGE; 40 PARCEL #/BRIEF LEGAL DESC 08 / 29 / 15 / 54658 / 000 / 0002 MANDALAY BEACH CLUB CONDO 3RD FLOOR. POOL & CLUB HSE OWNER'S NAME AND ADDRESS MANDALAY BEACH CLUB LTD 2201 4TH ST N # 200 ST PETERSBURG FL 33704 4300 PROPERTY ADDR ------------------------------ 08 / 29 / 15 / 54658 / 001 / 0301 MANDALAY BEACH CLUB CONDO PHASE 1: UNIT 301 MURRAY, SUSAN L 902 ANCHORAGE RD TAMPA FL 3360,2 5754 PROPERTY ADDR 11 SAN MARCO ST #301 -----------------------------------.. ---------------.....-----_..- 08 / 29 / 15 / 54658 / 001 / 0302 HARMON: THOMAS S JR MANDALAY BEACH CLUB CONDO HARMON: DEANNE L PHASE 1: UNIT 302 3321 W SEVILLA AVE TAMPA FL 33629 PROPERTY ADDR; 11 SAN ... -----------------....--- MARCO ST #302 .....---_...--_,------- -----------.._.----.....-------------- 08 / 29 / 15 / 54658 / 001 / 0303 HALLERAN, EDWARD M MANDALAY BEACH CLUB CONDO SIKH: STEPHEN PHASE 1, UNIT 303 11 SAN MARCO ST # 303 CLEARWATER FL 33767 2060 PROPERTY ADDR* 11 SAN MARCO ST #303 ---------------------------.....------------------..,.---------.. -------------- 08 / 29 / 15 / 54658 / 001 / 0304 BROMBOZ, JONATHAN MANDALAY BEACH CLUB CONDO BROMB02., VICKI PHASE it UNIT 304 11 SAN MARCO ST # 304 CLEARWATER FL 33767 2060 PROPERTY ADDR 11 SAN MARCO ST #304 ---------------------------------------------------_.---.....s -------------- 08 / 29 / 15 / 54658 / 001 / 0306 BARRETTE WILLIAM T MANDALAY BEACH CLUB CONDO BARRETT, SHEILA M PHASE 1. UNIT 306 11 SAN MARCO ST # 306 CLEARWATER FL 33767 2060 PROPERTY ADDR: 11 SAN MARCO ST #306 ----------------------------------------------------------------------- JIM SMITH PINELLAOUNTY PROPERTY APPRAISER 03-May-2007 PAGE; 41 PARCEL #/BRIEF" LEGAL DESC 08 / 29 / 15 / 54658 / 001 / 0307 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 307 OWNER'S NAME AND ADDRESS DELLATERZA, ROBIN DELLATERZA, JAMES 10 CYPRESS DR CEDAR KNOLLS NJ 07927 1558 PROPERTY ADDR= it SAN MARCO ST #307 ------------------------------------- 08 / 29 / 15 / 54658 / 001 / 0308 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 308 REISS, KENNETH P 11 SAN MARCO ST # 308 CLEARWATER FL 33767 2060 PROPERTY ADDR 11 SAN MARCO ST #308 ---------------.,...----------------------------------... --.....-...--------------- 08 / 29 / 15 / 54658 / 001 / 0401 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 401 KELLY, THOMAS L THE KELLY, KATHLEEN F THE 11 SAN MARCO ST # 401 CLEARWATER FL 33767 2060 PROPERTY ADDR 11 SAN MARCO ST #401 -----------------------------------_- 08 / 29 / 15 / 54658 / 001 / 0402 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 402 LEE, PAUL J LEE, AGNES S 9715 STONECLIFF CT CLARENCE NY 14031 2439 PROPERTY ADDR= 11 SAN MARCO ST #402 --_.--.....-----------.....---------_,-----------------------......_.......... -------._.._.._.....-__.. - 08 / 29 / 15 / 54658 / 001 / 0403 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 403 HIGHPOINTE THOROUGHBRED CENTER L 6280 RUE DU LAC WEST BLOOMFIELD MI 48323 PROPERTY ADDR= 11 SAN MARCO ST #403 ------------------------------------- 08 / 29 / 15 / 54658 / 001 / 0404 MANDALAY BEACH CLUB CONDO PHASE 17 UNIT 404 PROPERTY ADDR= 11 SAN MARCO ST #404 -------------------------------..---- SCHROEDER, STEVEN A 1 ASPEN DR LOVELAND CO 80538 2,.5.:38 ------------------------------ ?w 9r JIM SMITH PINELLJOCOUNTY PROPERTY APPRAISER 03-May-2007 PAGE: 42 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 08 / 29 / 15 / 54658 / 001 / 0405 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 405 HULLING DON C HULLING, TRICE D 14008 SHADY SHORES DR TAMPA FL 33613 1931 PROPERTY ADDR 11 SAN MARCO ST #405 --------------------------------------------------....... --_..,-.... -------------- 08 / 29 / 15 / 54658 / 001 / 0406 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 406 PITTMAN, C CHRISTOPHER PITTMAN, KAREN G 12228 BROADWATER LOOP THONOTOSASSA FL 33592 3953 PROPERTY ADDR: 11 SAN MARCO ST #406 --__ _----------------------.....-__----- 08 / 29 / 15 / 54658 / 001 / 0407 MANDALAY BEACH CLUB CONDO PHASE i, UNIT 407 THWAITE, EDWARD W THWAITE, PATRICIA A 15 LOOK OUT POINTE TRL TOTOWA NJ 07512 1611 PROPERTY ADDR 11 SAN MARCO ST #407 -----------_ ---_.-------------_.-------..s... --------._.....-_..... -----........------------ 08 / 29 / 15 / 54658 / 001 / 0408 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 408 RODWELL, ERIC V RODWELL, DONNA M 11 SAN MARCO ST # 408 CLEARWATER FL 33767 2060 PROPERTY ADDR: 11 SAN MARCO ST 4408 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 0501 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 501 MOHR, GREGORY A MOHR, KATHLEEN L 2873 ROEHAMPTON CLOSE TARPON SPGS FL 34688 8426 PROPERTY ADDR 11 SAN MARCO ST #501 ------------------------------------- 08 / 29 / 15 / 54658 / 001 / 0502 ABRAHAM DAVID MANDALAY BEACH CLUB CONDO 11 SAN MARCO ST # 502 PHASE 1, UNIT 502 CLEARWATER FL 33767 2060 PROPERTY ADDR 11 SAN MARCO ST #502 --------------------------------------------------------------- JIM SMITH PINELLAAUNTY PROPERTY APPRAISER 03-May-2007 PAGE: 43 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 08 / 29 / 15 / 54658 / 001 / 0503 SOBEL, KATHY MANDALAY BEACH CLUB CONDO 11 SAN MARCO ST # 503 PHASE 1, UNIT 503 CLEARWATER FL 33767 2060 PROPERTY ADDR? 11 SAN MARCO ST #503 ----------_..----------------------------------.....--....,----_..---_.----_-_------ 08 / 29 / 15 / 54658 / 001 / 0504 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 504 PODGURSKI, MICHAEL A PODGURSKI, LINDA G 1125 W POWDERHORN RD MECHANICSBURG PA 17050 2007 PROPERTY ADDR* it SAN MARCO ST #504 --------------------------------------------------__------._----__------ 08 / 29 / 15 / 54658 / 001 / 0505 MANDALAY BEACH CLUB CONDO PHASE 17 UNIT 505 MOULIS, SUSAN B MOULIS, JAMES M 11 SAN MARCO ST # 505 CLEARWATER FL 33767 2060 PROPERTY ADDR: 11 SAN MARCO ST #505 --------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 0506 FONTANA, ERIC M MANDALAY BEACH CLUB CONDO SANDOHFF, JEFFREY A PHASE 1, UNIT 506 2519 MCMULLEN BOOTH RD # 510 CLEARWATER FL 33761 4160 PROPERTY ADDR? 11 SAN MARCO ST #506 ----------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 0507 NEUWOLF PARTNERS MANDALAY BEACH CLUB CONDO C/O MASICK, KENNETH PHASE 1, UNIT 507 2100 CLEARWATER DR OAK BROOK IL 60523 1927 PROPERTY ADDR* 11 SAN MARCO ST #507 ---------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 0508 MANDALAY BEACH CLUB CONDO PHASE 17 UNIT 508 MALACHOWSKI, JERRY MALACHOWSKI, DOROTHY 1426 SEMAR CT MOUNT PROSPECT IL 60056 2984 PROPERTY ADDR 11 SAN MARCO ST #508 ----------------.....---.....----------.....--...,.-----------------------__.---_------- JIM SMITH PINELLAAOUNTY PROPERTY APPRAISER 03-May-2007 PAGE; 44 PARCEL #/BRIEF LEGAL DESC 08 / 29 / 15 / 54658 / 001 / 0601 MANDALAY BEACH CLUB CONDO PHASE 17 UNIT 601 OWNER'S NAME AND ADDRESS PERTILET RICHARD K PERTILE, DEBORAH J 2810 PHILLIPPE PKWY SAFETY HARBOR FL 34695 5115 PROPERTY ADDR: 11 SAN MARCO ST #601 ----------------------------.____-___------------- 08 / 29 / 15 / 54658 / 001 / 0602 MANDALAY BEACH CLUB CONDO PHASE 1. UNIT 602 FUREY, MATT FUREY, 2HANG HONG 11 SAN MARCO ST # 602 CLEARWATER FL 33767 2060 PROPERTY ADDR 11 SAN MARCO ST #602 ------------------------------------ 08 / 29 / 15 / 54658 / 001 / 0603 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 603 2AKHARY: ATEF S 11 SAN MARCO ST # 603 CLEARWATER FL 33767 2060 PROPERTY ADDR= 11 SAN MARCO ST #603 ------------------------------------------------------------ 08 / 29 / 15 / 54658 / 001 / 0604 WELLS, DARCY L MANDALAY BEACH CLUB CONDO NALEY: STEVE W PHASE it UNIT 604 705 BAY ESPLANADE AVE CLEARWATER FL 33767 1409 PROPERTY ADDR 11 SAN MARCO ST #604 ---------------------------------------....... -------.........-------_...-----------.....- O8 / 29 / 15 / 54658 / 001 / 0605 MANDALAY BEACH CLUB CONDO PHASE 1y UNIT 605 NORUS31 KEVIN 11816 MARBLEHEAD DR TAMPA FL 33626 2553 PROPERTY ADDR 11 SAN MARCO ST #605 -------------------------.....---..._....M.....-_-- 08 / 29 / 15 / 54658 / 001 / 0606 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 606 YOFAN: ABRAHAM YOFAN: JACQUELINE D 10 PAPAYA # 1202 CLEARWATER FL 33767 2056 PROPERTY ADDR* 11 SAN MARCO ST #606 --------------------------------------------------------------------------- JIM SMITH PINELLO COUNTY PROPERTY APPRAISER 03-May-2007 PAGE; 45 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 08 / 29 / 15 / 54658 / 001 / 0607 D'AMORE: EUGENE R MANDALAY BEACH CLUB CONDO 11 SAN MARCO ST # 607 PHASE 1, UNIT 607 CLEARWATER FL 33767 2061 PROPERTY ADDR; it SAN MARCO ST #607 -------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 0608 BAYER, DAVID L MANDALAY BEACH CLUB CONDO BAYER. PAMELA R PHASE 1. UNIT 608 710 DUNSCORE CT ROSWELL GA 30075 6812 PROPERTY ADDR¢ 11 SAN MARCO ST #608 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 0701 MOMESSO, NOELLA NOORY MANDALAY BEACH CLUB CONDO MOMESS07 SERGIO PHASE 1: UNIT 701 10 JONEKELLE KIRKLAND KIRKLAND QC H9H 5A3 CANADA PROPERTY ADDR; 11 SAN MARCO ST #701 -----------.....--.....----....----------,----------------------------------.....------ 08 / 29 / 15 / 54658 / 001 / 0702 JOPPERT, MARCOS MANDALAY BEACH CLUB CONDO SNODGRASS, SUSAN M PHASE 1: UNIT 702 5010 W THE RIVIERA ST TAMPA FL 33609 3613 PROPERTY ADDR; 11 SAN MARCO ST #702 -------------------------------------------------...---... ---.....-----__------ 08 / 29 / 15 / 54658 / 001 / 0703 LA BELLE ELECTRIC INC MANDALAY BEACH CLUB CONDO 24546 21 MILE RD PHASE if UNIT 703 MACOMB MI 48042 5111 PROPERTY ADDR; 11 SAN MARCO ST 4703 ---------------------------.....------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 0704 MANDALAY BEACH CLUB CONDO PHASE 1? UNIT 704 IYERP VENKIT S IYERP LAKSHMI V 4419 FALLBR0OK BLVD PALM HARBOR FL 34685 PROPERTY ADDR; 11 SAN MARCO ST #704 ------------------------------------ JIM SMITH PINELLASOUNTY PROPERTY APPRAISER • 03-May-2007 PAGE; 46 PARCEL #/BRIEF LEGAL DESC 08 / 29 / 15 / 54658 / 001 / 0705 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 705 OWNER'S NAME AND ADDRESS BROWN, SHERMAN D BROWN, ANDREA D 11 SAN MARCO ST # 705 CLEARWATER FL 33767 2061 PROPERTY ADDR; 11 SAN MARCO ST 4705 ----------------------------_..---_--- 08 / 29 / 15 / 54658 / 001 / 0706 HILDEBRANDT, MARK THE MANDALAY BEACH CLUB CONDO 33 OLD LAKE RD PHASE 1, UNIT 706 HAWTHORN WOODS IL 60047 8018 PROPERTY ADDR= 11 SAN MARCO ST #706 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 0707 MINA, GEORGE I MANDALAY BEACH CLUB CONDO MINA, AMAL A PHASE 1, UNIT 707 4783 EDGE PARK DR OLDSMAR FL 34677 4845 PROPERTY ADDR: 11 SAN MARCO ST #707 -----------_.----------------------------------------..,.__..-- 08 / 29 / 15 / 54658 / 001 / 0708 2ILISCH, BARBARA L THE MANDALAY BEACH CLUB CONDO 11 SAN MARCO ST # 708 PHASE 1, UNIT 708 CLEARWATER FL 33767 2061 PROPERTY ADDR; 11 SAN MARCO ST #708 -------------------------------.-------_..------.,...-_-__-_-------_------- 08 / 29 / 15 / 54658 / 001 / 0801 MAJEWSKI, DENISE M THE MANDALAY BEACH CLUB CONDO SCHNEIDER, CHRISTINE J PHASE 1, UNIT 801 43 LAKE ADALYN DR S SOUTH BARRINGTON 1L 60010 9542 PROPERTY ADDR; 11 SAN MARCO ST #801 -----------.-----.._ ---------... ------------------......... ------_...--_.------------- 08 / 29 / 15 / 54658 / 001 / 0802 MANDALAY 802 MANDALAY BEACH CLUB CONDO PO BOX 120 PHASE 1, UNIT 802 BLOOMINGDALE IL 60108 0120 PROPERTY ADDR; 11 SAN MARCO ST ##802 ----------------------------------------------------------------------- JIM SMITH PINELLO COUNTY PROPERTY APPRAISER 03-May-2007 PAGE: 47 PARCEL #/BRIEF LEGAL DESC 08 / 29 / 15 / 54658 / 001 / 0803 MANDALAY BEACH CLUB CONDO PHASE 1y UNIT 803 OWNER'S NAME AND ADDRESS KER: G CAMERON KER: LISA A 2426 BUTTERNUT CT DUNEDIN FL 34698 2252 PROPERTY ADDR; 11 SAN MARCO ST #803 --------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 0804 GREENBERG: ROBYN B MANDALAY BEACH CLUB CONDO 1306 PRESERVATION WAY PHASE 1, UNIT 804 OLDSMAR FL 34677 4824 PROPERTY ADDR= 11 SAN MARCO ST #804 ------------------------- ------------------------------------------------ 08 / 29 / 15 / 54658 / 001 / 0805 KAIZER: JEFFREY R MANDALAY BEACH CLUB CONDO KAI2.ER: LISA B PHASE 1, UNIT 805 3303 LEGAL CREST DR LONGWOOD FL 32779 PROPERTY ADDR: 11 SAN MARCO ST #805 ---------------------------- ----------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 0806 KOKOMO PROPERTIES LLC MANDALAY BEACH CLUB CONDO 657 SOUNDVIEW DR PHASE 17 UNIT 806 PALM HARBOR FL 34683 4246 PROPERTY ADDR: 11 SAN MARCO ST #806 --------------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 0807 MANDALAY BEACH CLUB CONDO PHASE 1y UNIT 807 ALIDINA, ARIF A ALIDINAY NOORA 11 SAN MARCO ST # 807 CLEARWATER FL 33767 2062 PROPERTY ADDR: 11 SAN MARCO ST #807 -------------------._---._.----_-----_-- 08 / 29 / 15 / 54658 / 001 / 0808 MANDALAY BEACH CLUB CONDO PHASE 1. UNIT 808 FISHER, PAMELA FISHER, NELSON J 817 BUNKERVIEW DR APOLLO BEACH FL 33572 2812 PROPERTY ADDR: 11 SAN MARCO ST #808 ----------------------------------------------------------------------- JIM SMITH PINEL-LASWUNTY PROPERTY APPRAISER • 03-May-2007 PAGE= 48 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 08 / 29 / 15 / 54658 / 001 / 0901 DENTICEr JOSEPH F & ELLEN L JOIN MANDALAY BEACH CLUB CONDO DENTICE, JOSEPH F THE PHASE 1, UNIT 901 11 SAN MARCO ST # 901 CLEARWATER FL 33767 2062 PROPERTY ADDR: 11 SAN MARCO ST #901 -----------------------_,--------...-------.....----------.--_.. --__------___--- 08 / 29 / 15 / 54658 / 001 / 0902 KLEINBERG, MILTON M MANDALAY BEACH CLUB CONDO KLEINBERG, MARSHA A PHASE 1, UNIT 902 6034 COUNTRY CLUB OAKS PL OMAHA NE 68152 2009 PROPERTY ADDR= 11 SAN MARCO ST #902 ------------------------------------------------___-----_----__------ 08 / 29 / 15 / 54658 / 001 / 0903 AXEL7 JONATHAN P THE MANDALAY BEACH CLUB CONDO AXEL, CORAL S THE PHASE 1y UNIT 903 11 SAN MARCO ST APT 903 CLEARWATER FL 33767 2062 PROPERTY ADDR: 11 SAN MARCO ST #903 ------------------------...-------------------------------_----_.. -------- 08 / 29 / 15 / 54658 / 001 / 0904 EPSTEIN, JOEL MANDALAY BEACH CLUB CONDO EPSTEIN, DIANE A PHASE 1: UNIT 904 40 DEERPATH CT OLDSMAR FL 34677 2054 PROPERTY ADDR= it SAN MARCO ST #904 -----------------------------.-----------------------.,..._------_ _.....---_ _--- 08 / 29 / 15 / 54658 / 001 / 0905 MANDALAY BEACH CLUB CONDO PHASE 1r UNIT 905 CRANOR7 DAVID K CRANOR, TOWANA K 12043 HAWTHORN RIDGE FISHERS IN 46037 8822 PROPERTY ADDR= 11 SAN MARCO ST #905 --------------------------------------- 08 / 29 / 15 / 54658 / 001 / 0906 MANDALAY BEACH CLUB CONDO PHASE 1t UNIT 906 PAULL, DENNIS M PAULL, DIANE P 10104 RADCLIFFE DR TAMPA FL 33626 2512 PROPERTY ADDR• 11 SAN MARCO ST #906 .-------------------------_..--------------------------------------------- JIM SMITH PINELLAAOUNTY PROPERTY APPRAISER • 03-May-2007 PAGE: 49 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 08 / 29 / 15 / 54658 / 001 / 0907 CORE, CHRIS W MANDALAY BEACH CLUB CONDO 124 CHARTWELL PHASE 17 UNIT 907 BEACONSFIELD QC H9W iC3 CANADA PROPERTY ADDR: 11 SAN MARCO ST #907 ------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 0908 ALONSO, ARMANDO MANDALAY BEACH CLUB CONDO ALONSO, SHARON PHASE 1, UNIT 908 36007 LAKE UNITY NURSERY RD FRUITLAND PARK FL 34731 5816 PROPERTY ADDR: 11 SAN MARCO ST #908 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 1001 GRANT, ERIC MANDALAY BEACH CLUB CONDO 1004 ROYAL PASS RD PHASE 1, UNIT 1001 TAMPA FL 33602 5708 PROPERTY ADDR> 11 SAN MARCO ST #1001 ________....___.,..__.,...__._.._.______._._._______________._________-____....__...._....w____...__- 08 / 29 / 15 / 54658 / 001 / 1002 BARYLAK, EDWARD J MANDALAY BEACH CLUB CONDO BARYLAK, CHRYSTINA PHASE 17 UNIT 1002 3132 BRANCH RIVER RD MANITOWOC WI 54220 8717 PROPERTY ADDR: 11 SAN MARCO ST #1002 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 1003 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 1003 LOCKETT, THERESA 11 SAN MARCO ST # 1003 CLEARWATER FL 33767 2062 PROPERTY ADDR: 11 SAN MARCO ST #1003 ------------------------------------- 08 / 29 / 15 / 54658 / 001 / 1003 LOCKETT, THERESA MANDALAY BEACH CLUB CONDO 11 SAN MARCO ST # 1003 PHASE 1, UNIT 1003 CLEARWATER FL 33767 2062 PROPERTY ADDR= 11 SAN MARCO ST ##1003 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 1004 TAYLOR, DAVID R MANDALAY BEACH CLUB CONDO WALTERS, JAMES PHASE 1, UNIT 1004 546 RIVIERA DR TAMPA FL 33606 PROPERTY ADDR. 11 SAN MARCO ST #1004 ------------------------------------------------------ JIM SMITH PINELLA10COUNTY PROPERTY APPRAISE 03-May-2007 PAGE: 50 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 08 / 29 / 15 / 54658 / 001 / 1005 BAUER, CHARLES L MANDALAY BEACH CLUB CONDO BAUER, JANET W PHASE 1, UNIT 1005 11 SAN MARCO ST # 1005 CLEARWATER FL 33767 2062 PROPERTY ADDR: 11 SAN MARCO ST #1005 ----------__-----------._..----------._...._...----_-_.----------.. --_..--------------- 08 / 29 / 15 / 54658 / 001 / 1006 MILLINGTON, CHARLES J MANDALAY BEACH CLUB CONDO MILLINGTON, JULIA B PHASE 1, UNIT 1006 11 SAN MARCO ST # 1006 CLEARWATER FL 33767 2062 PROPERTY ADDR: 11 SAN MARCO ST #1006 ----------------------------------_ -------_..--_..---_-... ------------_------ 08 / 29 / 15 / 54658 / 001 / 1007 SAID, NADER MANDALAY BEACH CLUB CONDO SAID, HALA PHASE l y UNIT 1007 11 SAN MARCO ST # 1 007 CLEARWATER FL 33767 2069 PROPERTY ADDR: 11 SAN MARCO ST #1007 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 1008 SOTEREANOS, STELLA MANDALAY BEACH CLUB CONDO SOTEREANOS, STACEY PHASE 1, UNIT 1008 307 S DITHRIDGE # 808 PITTSBURGH PA 15213 3519 PROPERTY ADDR* 11 SAN MARCO ST #1008 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 1101 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 1101 SAMEE, AHMED B 11 SAN MARCO ST # 1101 CLEARWATER BEACH FL 33767 2069 PROPERTY ADDR= 11 SAN MARCO ST #1101 08 / 29 / 15 / 54658 / 001 / 1102 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 1102 PECORARO, ERNEST A PECORARO, NYDIA 11 SAN MARCO ST # 112 CLEARWATER FL 33767 2066 PROPERTY ADDR* 11 SAN MARCO ST 41102 ------------------------------------------------------------------ SMITH PINELLASOUJNTIM Y PROPERTY APPRAISER 03-May-2007 PAGE; 51 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 08 / 29 / 15 / 54658 / 001 / 1103 CRANOR, DAVID K MANDALAY BEACH CLUB CONDO CRANOR, TOWANA K PHASE 1, UNIT 1103 12043 HAWTHORN RIDGE FISHERS IN 46037 8822 PROPERTY ADDR; 11 SAN MARCO ST #1103 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 1104 SOBOTKA, JOSEPH J MANDAL AY BEACH CLUB CONDO SOBOTKA, SYLVIA R PHASE 1, UNIT 1104 52 THOROUGHBRED DR HOLLAND PA 18966 ?570 PROPERTY -------- ADDR; 11 SAN -------------- MARCO ------ ST #1104 --------- ---------------------------------- 08 / 29 / 15 / 54658 / 001 / 1105 SPARKS, SUSAN M MANDAL AY BEACH CLUB CONDO 11 SANMARCO ST N # 1105 PHASE 1, UNIT 1105 CLEARWATER FL 33767 2069 PROPERTY -------- ADDR; 11 SAN -------------- MARCO ------ ST #1105 --------- ---------------------------------- 08 / 29 / 15 / 54658 / 001 / 1106 MILLS PROPERTIES-CLEARWATER LLC MANDALAY BEACH CLUB CONDO 10713 ROCK MOSS CT PHASE 1, UNIT 1106 LOUISVILLE KY 40291 5026 PROPERTY ADDR; 11 SAN MARCO ST #1106 --------------------_.---_-------------------------------------------....._.._ 08 / 29 / 15 / 54658 / 001 / 1107 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 1107 PERNICE, SALVATORE J 11 SAN MARCO ST # 1107 CLEARWATER FL_ 33767 2069 PROPERTY ADDR; 11 SAN MARCO ST #1107 ------------------------------------- 08 / 29 / 15 / 54658 / 001 / 1108 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 1108 HALE, CAROLYN SMITH FIELDS, ELISABETH SMITH 1107 CONCORD ST CHATTANOOGA TN 37405 3101 PROPERTY ADDR; 11 SAN MARCO ST #1108 ----------------------------------------------------------------------- JIM SMITH PINELLOCOUNTY PROPERTY APPRAISER* 03-May-2007 PAGE; 52 PARCEL #/BRIEF LEGAL DESC 08 / 29 / 15 / 54658 / 001 / 1201 MANDALAY BEACH CLUB CONDO PHASE 1 Y UNIT 12031 OWNER'S NAME AND ADDRESS SMITHY MERLE W SMITHY DIANA T 126031 MAST I CLUE BEACH BLVD # 2 FT MYERS FL 33908 PROPERTY ADDR; 11 SAN MARCO ST #1201 --------------------_.-----_-------_-- 08 / 29 / 15 / 54658 / 001 / 1202 MANDALAY BEACH CLUB CONDO PHASE 1Y UNIT 1202 SHILOH INVESTMENTS INC 3133 W 300TH S TIPTON IN 4607'2 8103 PROPERTY -------- ADDR= 11 SAN --------------- MARCO -------- ST #1202 --------- ------------------------ 08 / 29 / 15 / 54658 / 001 / 1203 ANDERSEN: LARRY E MANDAL AY BEACH CLUB CONDO 102 DICKINSON ST PHASE 1Y UNIT 1203 PHILADELPHIA PA 19147 6108 PROPERTY -------- ADDR; 11 SAN -------------- MARCO ------ ST #1203 --------- --------------------- 08 / 29 / 15 / 54658 / 001 / 1204 NOVICKYY STEVEN D MANDAL AY BEACH CLUB CONDO NOVICKYY KIMBERLY M PHASE 1Y UNIT 1204 5850 DEER SPRING RUN CANFIELD OH 44406 7613 PROPERTY ADDR; 11 SAN MARCO ST #1204 --_--------------------------_._ -------......,._. ---_---_-_-_---_..--_..--_..---------- 08 / 29 / 15 / 54658 / 001 / 1205 MANDALAY BEACH CLUB CONDO PHASE 1Y UNIT 1205 CUNNINGHAMY TODD W 9703 RHAPSODY DR VIENNA VA 22181 3240 PROPERTY ADDR; 11 SAN MARCO ST #1205 -------_-_-.......-----_--.....-....._....------._. ----_-----------_._---....._.._------._.._...--..........--- 08 / 29 / 15 / 54658 / 001 / 1206 SERAG MANDALAY BEACH CLUB CONDO C/O SI PHASE lY UNIT 1206 10538 TAMPA 33626 PROPERTY ADDR; 11 SAN MARCO ST #1206 -----------------_..--_...-------------_-------_ TRUST =RAG: SHERIF THE GREENCREST DR FL 5201 ------------------- JIM SMITH PINELLAOUNTY PROPERTY APPRAISER 16 03-May-2007 PAGEZ 53 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 08 / 29 / 15 / 54608 / 001 / 1207 MIKHAIL, MAGUED N MANDAL AY BEACH CLUB CONDO MAR2.OUK, CHRISTIANE G PHASE 1, UNIT 1207 091 BELTED KING FISHER DR PALM HARBOR FL 34683 6149 PROPERTY -------- ADDR: 11 SAN -------------- MARCO ------ ST #1207 --------- -----_...--------.....------.------------- 08 / 29 / 15 / 54658 / 001 / 1208 PAPPAS, PETER C MANDAL AY BEACH CLUB CONDO 930 WOODCOCK RD STE 227 PHASE 1, UNIT 1208 ORLANDO FL 32803 PROPERTY -------- ADDR* 11 SAN -------------- MARCO ------ ST #1208 --------- ---------------------------------- 08 / 29 / 15 / 54658 / 001 / 1401 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 1401 PROPERTY ADDR. 11 SAN MARCO ST #1401 --------------------------------------- NOVOGRAT2, JOSEPH 7667 EQUITABLE DR EDEN PRAIRIE MN 55344 3696 08 / 29 / 15 / 54658 / 001 / 1402 SAMEE, AHMED MANDALAY BEACH CLUB CONDO 11 SAN MARCO ST # 1101 PHASE 1, UNIT 1402 CLEARWATER FL 33767 2069 PROPERTY ADDR= 11 SAN MARCO ST 41402 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 1405 MARCO, SAN TRUST MANDALAY BEACH CLUB CONDO CHASE, WALTER W BNF PHASE 1, UNIT 1405 11 SAN MARCO ST # 1405 CLEARWATER FL 33767 2075 PROPERTY ADDR: 11 SAN --------------------- 08 / 29 / 15 / 04658 MANDALAY BEACH CLUB PHASE 1, UNIT 1406 PROPERTY ADDR> 11 SAN --------------------- MARCO ST #1405 --------------------------------------- / 001 / 1406 KARTES, BOB CONDO KARTES, MARIA 11 SAN MARCO ST # 1406 CLEARWATER FL 33767 2070 MARCO ST #1406 --------------------------------------- JIM SMITH PINELLA0OUNTY PROPERTY APPRAISER 03-May-2007 PAGE; 54 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 08 / 29 / 15 / 54658 / 001 / 1501 GAREL-JONES, PHILIP THE MANDALAY BEACH CLUB CONDO GAREL-JONES: BEATA THE PHASE 1, UNIT 1501 120 LANSDOWNE RD S OTTAWA ON K1M ON4 CANADA PROPERTY ADDR= 11 SAN MARCO ST #1501 ----------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 1502 AGAMI, DAVID MANDALAY BEACH CLUB CONDO ROMANO, IVETTE NANCY PHASE 1, UNIT 1502 11 SAN MARCO # 1502 CLEARWATER FL 33767 2075 PROPERTY ADDR: 11 SAN MARCO ST #1502 -------------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 1505 MANDALAY BEACH CLUB CONDO PHASE l y UNIT 1 505 CHRISTOPHER: TODD C CHRISTOPHER: WANDA 11 SAN MARCO ST # 1505 CLEARWATER FL 33767 2075 PROPERTY ADDR* 11 SAN MARCO ST #61505 ---_---__---- --_-----.._......-------------- 08 / 29 / 15 / 54658 / 001 / 1506 MANDALAY BEACH CLUB CONDO PHASE i, UNIT 1506 SMITH, DONALD F THE SMITH, MARY H THE 11 SAN MARCO ST # 1506 CLEARWATER FL 33767 2075 PROPERTY ADDR: 11 SAN MARCO ST #61506 -------------------------------------------------------------- 08 / 29 / 15 / 54658 / 001 / 1601 VITOLA, JOHN R MANDALAY BEACH CLUB CONDO VITOLA, GEORGINE A PHASE 17 UNIT 1601 218 S BROAD ST BROOKSVILLE FL 34601 2832 PROPERTY ADDR+ 11 SAN MARCO ST #1601 -------------------------------------- 08 / 29 / 15 / 54658 / 001 / 1602 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 1602 ROSCOE, GREGORY J ROSCOE, LINDA L PO BOX 308 DU BOIS PA 15801 0308 PROPERTY ADDR 11 SAN MARCO ST #1602 ----------------------------------_-- JIM SMITH PINELLOCOUNTY PROPERTY APPRAISER. 03-May-2007 PAGE: 5 PARCEL #/BRIEF LEGAL DESC 08 / 29 / 15 / 54658 / 001 / 1605 MANDALAY BEACH CLUB CONDO PHASE 1, UNIT 1605 OWNER'S NAME AND ADDRESS DENTICE, JOSEPH F DENTICE, ELLEN L 11 SAN MARCO ST # 1605 CLEARWATER FL 33767 2076 PROPERTY ADDR; 11 SAN MARCO ST #1605 ---------------------------------------- 08 / 29 / 15 / 54658 / 001 / 1606 TSANGARIS, WILMA B MANDALAY BEACH CLUB CONDO TSANGARIS, NICHOLAS PHASE 1, UNIT 1606 11 SAN MARCO ST # 1606 CLEARWATER FL 3'3767 2076 PROPERTY ADDR: 11 SAN MARCO ST #1606 --------------------------------------------------_.----_-__---__...------....- 08 / 29 / 15 / 54658 / 002 / 0301 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 301 QUAIL RIDGE APARTMENTS LTD PTNSH 3928 AMBASSADOR DR PALM HARBOR FL 34685 1071 PROPERTY ADDR: 10 PAPAYA ST #301 --------------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 0302 CLEARWATER REAL ESTATE HLDGS MANDALAY BEACH CLUB CONDO PO BOX 320491 PHASE 2, UNIT 302 TAMPA FL 33679 2491 PROPERTY ADDR: 10 PAPAYA ST #302 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 0303 KRYGIER, TESSIE MANDALAY BEACH CLUB CONDO 11109 KAREN DR PHASE 2, UNIT 303 ORLAND PARK IL 60467 4481 PROPERTY ADDR= 10 PAPAYA ST #303 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 0305 LATCH TRUST MANDALAY BEACH CLUB CONDO C/O LATCH, LLOYD E THE PHASE 2, UNIT 305 43 CLOUD VIEW RD SAUSALITO CA 94965 2006 PROPERTY ADDR; 10 PAPAYA ST #305 ----------------------------------------------------------------------- JIM SMITH PINELLO COUNTY PROPERTY APPRAISER. 03-May-2007 PAGE: 56 PARCEL #/BRIEF LEGAL DESC 08 / 29 / 15 / 54658 / 002 / 0306 MANDALAY BEACH CLUB CONDO PHASE 27 UNIT 306 OWNER'S NAME AND ADDRESS MAROTTOLI, ANTHONY 10 PAPAYA ST # 306 CLEARWATER FL 33767 2040 PROPERTY ADDR= 10 PAPAYA ST #306 --------------------------------- 08 / 29 / 15 / 54658 / 002 / 0401 MANDALAY BEACH CLUB CONDO PHASE 2r UNIT 401 JOHNSON 2003 LIV TRUST JOHNSON, GEORGE A THE 10 PAPAYA ST # 401 CLEARWATER FL 33767 2040 PROPERTY ADDR: 10 PAPAYA ST #401 ----------------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 0402 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 402 DIORIO, RONALD L DIORIO, SANDRA R 3944 NORTH FIELD DR BELLBROOK OH 45305 8802 PROPERTY ADDR= 10 PAPAYA ST ##402 ------------------------------------ 08 / 29 / 15 / 54658 / 002 / 0403 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 403 BESSADA, ASHRAF R ABADIR, NEVINE 10 PAPAYA ST # 403 CLEARWATER FL 33767 2040 PROPERTY ADDR? 10 PAPAYA ST #403 ----------_._...--........ --.....---------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 0404 MIKHAIL, MAGUED MANDALAY BEACH CLUB CONDO MARZOUK, CHRISTIANS PHASE 2, UNIT 404 591 BELTED KINGFISHER DR N PALM HARBOR FL 34683 6149 PROPERTY ADDR 10 PAPAYA ST #404 ---------------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 0405 DORSCH, DANIEL J MANDALAY BEACH CLUB CONDO DORSCH, CYNTHIA P PHASE 2, UNIT 405 6326 W MACLAURIN DR TAMPA FL 33647 1163 PROPERTY ADDR: 10 PAPAYA ST #405 -----.... ----------------------------------------------------------- JIM SMITH PINELLAkOUNTY PROPERTY APPRAISER 1041 03-May-2007 PAGE; 57 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 08 / 29 / 15 / 54658 / 002 / 0406 MENKE DEV MANDALAY BEACH CLUB CONDO 10 PAPAYA #406 PHASE 2: UNIT 406 CLEARWATER FL 33767 PROPERTY ADDR= 10 PAPAYA ST #406 --------------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 0501 MANDALAY BEACH CLUB CONDO PHASE 2. UNIT 501 HANNA: ASHRAF F HANNA, MIRANDA Z 3509 SHORELINE CIR PALM HARBOR FL 34684 1727 PROPERTY ADDR= 10 PAPAYA ST #501 ------------------------------------ 08 / 29 / 15 / 54658 / 002 / 0502 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 502 HORVATH, KLARA 10 PAPAYA ST # 502 CLEARWATER FL 33767 2040 PROPERTY ADDR: 10 PAPAYA ST #502 ---------------------------------- 08 / 29 / 15 J 54658 / 002 / 0503 MANDALAY BEACH CLUB CONDO PHASE 2: UNIT 503 RUKAVINA, JAMES RUKAVINA: DIANNE 10 PAPAYA ST # 503 CLEARWATER BEACH FL 33767 PROPERTY ADDR- 10 PAPAYA ST #503 ----------------------------------------------------------------------- O8 / 29 / 15 / 54658 / 002 / 0504 RAFIEIAN, SIAMAK MANDALAY BEACH CLUB CONDO 10617 ROCHESTER WAY PHASE 2, UNIT 504 TAMPA FL 33626 1713 PROPERTY ADDR: 10 PAPAYA ST #504 ----------------------------------------------.. ---_.._----_---___..- 08 / 29 / 15 / 54658 / 002 / 0505 MANDALAY BEACH CLUB CONDO PHASE 2v UNIT 505 SHIVERS, EDWARD T SHIVERS, HAZEL E 10 PAPAYA ST # 505 CLEARWATER FL 33767 2040 PROPERTY ADDR: 10 PAPAYA ST #505 -------------------------------------- JIM SMITH PINELA COUNTY PROPERTY APPRAISE* 03-May-2007 PAGE; 58 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 08 / 29 / 15 / 54658 / 002 / 0506 AUGUSTINF_, RICHARD J MANDALAY BEACH CLUB CONDO 10 PAPAYA ST #506 PHASE 2, UNIT 506 CLEARWATER FL 33767 2040 PROPERTY ADDR; 10 PAPAYA ST #506 ----------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 0601 DOWNS, JANE MANDALAY BEACH CLUB CONDO 50 JONATHAN DR PHASE 27 UNIT 601 NEW ULM MN 56073 3343 PROPERTY ADDR. 10 PAPAYA ST #601 --------------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 0602 DOUSE, ROBERT S MANDALAY BEACH CLUB CONDO DOUSE, GWEN A PHASE 2, UNIT 602 1605 CLAUDIA WAY NORTH WALES PA 19454 3679 PROPERTY ADDR; 10 PAPAYA ST #602 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 0603 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 603 SIINO, WILLIAM J SIINO, MICHAEL T 13519 FALCON POINTE DR ORLANDO FL_ 32837 5327 PROPERTY ADDR; 10 PAPAYA ST #603 -----------_.-------------------------- 08 / 29 / 15 / 54658 / 002 / 0604 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 604 WILSON, CHRISTINE DEFERRARI WILSON, MARK A 132 HARBOR DR PALM HARBOR FL 34683 5403 PROPERTY ADDR; 10 PAPAYA ST 4604 ------------------------------------ 08 / 29 / 15 / 54658 / 002 / 0605 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 605 CHRISTOLINI, CHARLES JR CHRISTOLIN17 DARLENE E 10 PAPAYA ST # 605 CLEARWATER FL 33767 2054 PROPERTY ADDR; 10 PAPAYA ST #605 ---------------------------------------------------------- JIM SMITH PINELLIOCOUNTY PROPERTY APPRAISE* 03--May--2007 PAGE Z 59 PARCEL #/BRIEF LEGAL DESC 08 / 29 / 15 / 54658 / 002 / 0606 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 606 OWNER'S NAME AND ADDRESS ANGELOCCI, RANDY F ANGELOCCI, DEMAREE H 2885 KENSINGTON TRCE TARPON SPRINGS FL 34688 8421 PROPERTY ADDR; 10 PAPAYA ST #606 ------------------------------------ 08 / 29 / 15 / 54658 / 002 / 0701 BIENSTOCK, JOSEPH S MANDALAY BEACH CLUB CONDO BIENSTOCK, PHYLLIS PHASE 27 UNIT 701 10 PAPAYA ST # 701 CLEARWATER FL 33767 2054 PROPERTY ADDR> 10 PAP ---------------------- AYA ST #701 --------------- ---._.--------- ------------------------ 08 / 29 / 15 / 54658 / 002 / 0702 TOUCHTON, WALTER W THE MANDALAY BEACH CLUB CONDO TOUCHTON, JO ANN H THE PHASE 2, UNIT 702 10 PAPAYA ST # 702 CLEARWATER FL 33767 2054 PROPERTY ADDR• 10 PAPAYA ST #702 08 / 29 / 15 / 54658 / 002 / 0703 KOTCHMAN, CASEY J THE MANDALAY BEACH CLUB CONDO 8442 125TH CT PHASE 27 UNIT 703 SEMINOLE FL 33776 3200 PROPERTY ADDR; 10 PAPAYA ST #703 --------------- ---------------------- ----------------------- ------------------- 08 / 29 / 15 / 546,,5.,8 / 002 / 0704 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 704 HILL, ANNE M THE 2510 S DUNDEE ST TAMPA FL 33629 6411 PROPERTY ADDR= 10 PAPAYA ST #704 -----------_.--------------------_...- 08 / 29 / 15 / 54658 / 002 / 0705 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 705 GILBERT, DONNA J GILBERT, HAROLD E 10 PAPAYA ST # 705 CLEARWATER FL 33767 2068 PROPERTY ADDR= 10 PAPAYA ST #705 ------------------------------------ JIM SMITH PINELLAMOUNTY PROPERTY APPRAISER 401 03-May-2007 PAGE= 60 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 08 / 29 / 15 / 54658 / 002 / 0706 TOUCHTON: WALTER MANDALAY BEACH CLUB CONDO TOUCHTON, JOANN PHASE 2. UNIT 706 10 PAPAYA ST # 702 CLEARWATER FL 33767 2054 PROPERTY ADDR; 10 PAPAYA ST #706 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 0801 ROWLAND, CLARENCE E III MANDALAY BEACH CLUB CONDO 2112 WATERS AVE PHASE 2y UNIT 801 TAMPA FL 33604 2748 PROPERTY ADDR: 10 PAPAYA ST #801 08 / 29 / 15 / 54658 / 002 / 0802 ROSSDALE MGMT INC MANDALAY BEACH CLUB CONDO 120 LANSDOWNE RD S PHASE 2: UNIT 802 OTTAWA ON KIM ON4 CANADA PROPERTY ADDR: 10 PAPAYA, ST #802 --------------------------------------------------------_..------__------ 08 / 29 / 15 / 54658 / 002 / 0803 CHALAVARYA, GOPAL MANDALAY BEACH CLUB CONDO CHALAVARYA. SADHNA PHASE 2, UNIT 803 1510 JASMINE AVE TARPON SPRINGS FL 34689 5242 PROPERTY ADDR= 10 PAPAYA ST ----------------------------- #803 _ ----- ------------.....----------_------------ 08 / 29 / 15 / 54658 / 002 / 0804 COLLINS7 WALTER W MANDALAY BEACH CLUB CONDO 9813 COMPASS POINT WAY PHASE 2: UNIT 804 TAMPA FL 33615 4218 PROPERTY ADDR 10 PAPAYA ST -------------------------_.._...-- #804 ------ -_-------_..... ----.. ------__----------_..-..... 08 / 29 / 15 / 54658 / 002 / 0805 EKREN TRUST MANDALAY BEACH CLUB CONDO C/O EKREN. YALCIN THE PHASE 2, UNIT 805 3061 DOXBERRY CT CLEARWATER FL 33761 2003 PROPERTY ADDR 10 PAPAYA ST #805 ------------------------------------------ ---------------------------- JIM SMITH PINELLO COUNTY PROPERTY APPRAISE* 03-May-2007 PAGE; 61 PARCEL #/BRIEF LEGAL DESC 08 / 29 / 15 / 54658 / 002 / 0806 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 806 OWNER'S NAME AND ADDRESS COLLETTE, JAMES A VAUSE7 ROBERT W 10 PAPAYA ST # 806 CLEARWATER FL 33767 2068 PROPERTY ADDR* 10 PAPAYA ST #806 --------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 0901 MANDALAY BEACH CLUB CONDO PHASE 2: UNIT 901 WARD, MICHAEL S WARD? GISELLE V 407 S ROYAL PALM WAY TAMPA FL 33609 3728 PROPERTY ADDR; 10 PAPAYA ST ##901 ---------------------------------------- 08 / 29 / 15 / 54658 / 002 / 0902 MANDALAY BEACH CLUB CONDO PHASE 2: UNIT 902 KAESTNER, JOHN T KAESTNER, JOANN M 777 CARMAN MEADOWS DR BALLWIN MO 63021 7174 PROPERTY ADDR= 10 PAPAYA ST #902 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 0903 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 903 PARADES: ANTONIO M 10 PAPAYA ST # 903 CLEARWATER FL 33767 2055 PROPERTY ADDR: 10 PAPAYA ST #903 ----------------------------------- 08 / 29 / 15 / ..5.,4658 / 002 / 0904 MANDALAY BEACH CLUB CONDO PHASE 2: UNIT 904 DAV I S , DEXTER C ALEXANDER-DAVIS, LISA 501 MANDALAY AVE #1009 CLEARWATER BCH FL 33767 1714 PROPERTY ADDR= 10 PAPAYA ST #904 ---------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 0905 REINHARDT, MARK MANDALAY BEACH CLUB CONDO REINHARDT, CONNIE K PHASE 2r UNIT 905 N3080 MEADE ST APPLETON WI 54913 9571 PROPERTY ADDR= 10 PAPAYA ST #905 ------------------------------------------------------------------------ JIM SMITH PINELL)SCOUNTY PROPERTY APPRAISE* 03-May-2007 PAGE= 62 PARCEL ##/BRIEF LEGAL DESC 08 / 29 / 15 / 54658 / 002 / 0906 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 906 OWNER'S NAME AND ADDRESS HANNA, VICTORIA HANNA, ATIF 29W 471 SUNSET RIDGE RD BARTLETT IL 60'103 PROPERTY ADDR= 10 PAPAYA ST #906 --------------_ ------_•----_--.... -------_---------..._.._-----___------------- 08 / 29 / 15 / 54658 / 002 / 1001 WANDACHOWIC2, BOGDAN MANDALAY BEACH CLUB CONDO 10 PAPAYA ST # 1001 PHASE 2, UNIT 1001 CLEARWATER FL 33767 2055 PROPERTY ADDR= 10 PAPAYA ST ##1001 ----------------------------------------------------------------------------- 08 / 29 / 15 / ,.`.x4658 / 002 / 1002 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 1002 KLABISCH, SUSAN M 2007 TRUST C/O KLABISCM, SUSAN M THE 11348 CEDAR WOOD CT FRANKFORT IL 60423 PROPERTY ADDR. 10 PAPAYA ST #1002 ------------------------------------ 08 / 29 / 15 / 54658 / 002 / 1003 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 1003 FERRELL, CLIFFORD N FERRELL, ROSEMARIE A 2328 COLGATE DR FAYETTEVILLE NC 28304 5309 PROPERTY ADDR: 10 PAPAYA ST #1003 -----------------------------------------_.---_..-----------__._.._..____..-_--__ - 08 / 29 / 15 / 54658 / 002 / 1004 FLORIN, WOLFGANG M MANDALAY BEAC H CLUB CONDO FLORIN, SUSAN PHASE 2, UNIT 1004 10342 PONTOFINO CIR TRINITY FL 34655 7056 PROPERTY ADDR: --------------- 10 PAPAYA ST ------------- #1004 -------- ----------------------------------- 08 / 29 / 15 / 54658 / 002 / 1005 HYDUK, RANDY MANDALAY BEAC H CLUB CONDO HYDUK, APRIL PHASE 2, UNIT 1005 20539 COUNTRYSIDE DR MACOMB MI 48044 3589 PROPERTY ADDR: --------------- 10 PAPAYA ST ------------- #1005 -------- ----------------------------------- JIM SMITH PINELLOCOUNTY PROPERTY APPRAISER 03-May-2007 PAGE; 63 PARCEL #/BRIEF LEGAL DESC 08 / 29 / 15 / 54658 / 002 / 1006 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 1006 OWNER'S NAME AND ADDRESS HAIST, SCOTT J HAIST MELISSA KAY 3659 JUSTIN DR PALM HARBOR FL 34685 3603 PROPERTY ADDR 10 PAPAYA ST #1006 ------------------------------------- 08 / 29 / 15 / 54658 / 002 / 1101 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 1101 MUDD, JAMES A MUDD, CECELIA K C/O BURGER, TOM 6919 CHANCELLOR DR CEDAR FALLS IA 50613 6926 PROPERTY ADDR= 10 PAPAYA ST #1101 ---------------__-------....,-_..--------_------------------------------------ 08 / 29 / 15 / 54658 / 002 / 1102 O'HANLEN, PETER MANDALAY BEACH CLUB CONDO O'HANLEN, TERRIE: PHASE 2, UNIT 1102 10 PAPAYA ST #1102 CLEARWATER FL 33767 2056 PROPERTY ADDR 10 PAPAYA ST #1102 ---_-----.....-----------_..----------_..---.. ------_.-------------___-----_------ 08 / 29 / 15 / 54658 / 002 / 1103 BURGESS, PATRICIA M MANDALAY BEACH CLUB CONDO GRIMM, THOMAS L PHASE 2, UNIT 1103 3234 N 7TH ST WAUSAU WI 54403 3007 PROPERTY ADDR; 10 PAPAYA ST #1103 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 1104 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 1104 ALARAKHIA, NASIR ALARAKHIA, OANA 5201 TIMBERVIEW TER ORLANDO FL 32819 3924 PROPERTY ADDR; 10 PAPAYA ST #1104 ---------------.__-------------_--- 08 / 29 / 15 / 54658 / 002 / 1105 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 1105 J & M PROP APOLLO BEACH 907 BUNKER VIEW DR APOLLO BEACH FL 33572 2813 PROPERTY ADDR; 10 PAPAYA ST #1105 -------------------------------------- JIM SMITH PINELLO COUNTY PROPERTY APPRAISE* 03-May-2007 PAGES 64 PARCEL #/BRIEF LEGAL DESC 08 / 29 / 15 / 54658 / 002 / 1106 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 1106 OWNER'S NAME AND ADDRESS CROSSLAND, RICHARD CROSSLAND, SUSAN 2203 MUIRFIELD WAY OLDSMAR FL 34677 1942 PROPERTY ADDR; 10 PAPAYA ST #1106 ---------------------------------- 08 / 29 / 15 / 54658 / 002 / 1201 ELSAKR, ASHRAF MANDALAY BEACH CLUB CONDO ELSAKR, MONA PHASE 2, UNIT 1201 808 SMOKERISE BLVD PORT ORANGE FL 32127 7783 PROPERTY ADDR; 10 PAPAYA ST #1201 --------------------....------------------_..--....----------_---_------------- 08 / 29 / 15 / 54658 / 002 / 1202 YOFAN, ABRAHAM REVOCABLE TRUST MANDALAY BEACH CLUB CONDO C/O YOFAN, ABRAHAM THE PHASE 27 UNIT 1202 APT 1002 11 SAN MARCO ST CLEARWATER FL 3'3767 2062 PROPERTY ADDR* 10 PAPAYA ST #1202 -----------.._._. -----......,._.... ----------------....-----------__---_,... ----_.-----_--- 08 / 29 / 15 / 54658 / 002 / 1203 PAPAYA TRUST MANDALAY BEACH CLUB CONDO 11 SAN MARCO ST # 1405 PHASE 2, UNIT 1203 CLEARWATER FL 33767 2075 PROPERTY ADDR= 10 PAPAYA ST #1203 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 1,204 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 1204 RIGBY, GREGORY S RIGBY, CAROLE J 124 OWASCO ST AUBURN NY 13021 4114 PROPERTY ADDR: 10 PAPAYA ST #1204 ------------------------------------- 08 / 29 / 15 / 54658 / 002 / 1205 MANDALAY BEACH CLUB CONDO PHASE 2, UNIT 1205 SMITH, PAUL GRAYSON III 11292 142ND WAY LARGO FL 33774 PROPERTY ADDR: 10 PAPAYA ST #1205 ----------------------------------------------------------------------- JIM SMITH PINELLA*OUNTY PROPERTY APPRAISER16 03-May-2007 PAGE: 65 PARCEL #/BRIEF LEGAL DESC 08 / 29 / 15 / 54658 / 002 / 1206 MANDALAY BEACH CLUB CONDO PHASE 2. UNIT 1206 OWNER'S NAME AND ADDRESS PETERS MICHAEL L PETERS STEPHANIE S 22 CLYDE GRUVER RD BINGHAMTON NY 13901 6022 PROPERTY ADDR: 10 PAPAYA ST #1206 ---------------------------------- 08 / 29 / 15 / 54658 / 002 / 1401 COMPTON VACATION HOME REVOCABLE MANDALAY BEACH CLUB CONDO COMPTONT VICKI L THE PHASE 2, UNIT 1401 C/O COMPTON, VICKI L THE 14809 HAMPTON CT DALLAS TX 75254 7681 PROPERTY ADDR 10 PAPAYA ST #1401 -------------------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 1404 ENGEBRETSEN, ELEANORE A MANDALAY BEACH CLUB CONDO 10 PAPAYA ST # 1404 PHASE 2f UNIT 1404 CLEARWATER FL 33767 2058 PROPERTY ADDR: 10 PAPAYA ST 01404 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 1501 MOLLER, ANDREW K MANDALAY BEACH CLUB CONDO 9942 DELL RD PHASE 2. UNIT 1501 EDEN PRAIRIE MN 55347 3523 PROPERTY ADDR= 10 PAPAYA ST #1501 ----------------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 1504 TURLEY, STEWART MANDALAY BEACH CLUB CONDO TURLEY, LINDA A PHASE 2: UNIT 1504 10 PAPAYA ST # 1504 CLEARWATER FL. 33767 2057 PROPERTY ADDR= 10 PAPAYA ST #1504 ----------------------------------------------------------------------- 08 / 29 / 15 / 54658 / 002 / 1601 AJAY ENDEAVORS INC MANDALAY BEACH CLUB CONDO 12190 CONTEL BLVD PHASE 2, UNIT 1601 BROOKVILLE FL 34613 PROPERTY ADDR: 10 PAPAYA ST #1601 -------------------------------.,. --_----.._........,---...._-....... -------_---__---__-... - JIM SMITH PINELLA LINTY PROPERTY APPRAISER 03-May-2007 PAGE; 66 PARCEL #/BRIEF LEGAL DESC OWNER'S NAME AND ADDRESS 08 / 29 / 15 / 54658 / 002 / 1604 EGAN, LYNNE A MANDALAY BEACH CLUB CONDO 10 PAPAYA ST # 1604 PHASE 2, UNIT 1604 CLEARWATER FL 33767 2057 PROPERTY ADDR? 10 PAPAYA ST #1604 ----------------------------------------------------------------------- 08 / 29 / 15 / 78657 / 001 / 0010 SANDPEARL RESORT LLC SANDPEARL 2201 4TH ST N STE 200 BLY 1, LOT 1 ST PETERSBURG FL (LYING IN SEC'S 5 & 8) 33704 4300 PROPERTY ADDR: ------------------------------- -------------------------------------------------- 08 / 29 / 15 / 78657 / 002 / 0010 RESIDENCES AT SANDPEARL RESORT L SANDPEARL 2201 4TH ST N STE 200 BLK 2: LOT 1 ST PETERSBURG FL 33704 4300 PROPERTY ADDR ----------------------------------------------------------------------------- TOTAL PARCELS; 396 r Line Items: 5/4/2007 11:40:12AM Receipt #: 1200700000000003911 Date: 05/04/2007 Case No Tran Code Description Revenue Account No Amount Paid DVA2007-00002 Development Agreement Fee 010-341262 500.00 Line Item Total: $500.00 Payments: Method Payer Initials Check No Confirm No How Received Amount Paid Check JMC DESIGN AND DEV INC R_D 44144 In Person Payment Total: • THIS IS NOT A PERMIT. This is a receipt for an application for a permit. This application will be reviewed and you will be notified as to the outcome of the application. 500.00 $500.00 cReceipt.rpt Page 1 of 1 ,. r r 9!rAl CITY OF C LEARWATE R POST OFFICE BOX 4748, CLEARWATER, FLORIDA 33758-4748 MUNICIPAL SERVICES BUILDING, 100 SOUTH MYRTLE AVF,NUE, CLEARWATER, FLORIDA 33756 TELEPHONE(727) 562-4567 FAx(727) 562-4865 PLANNING DEPARTMENT September 13, 2007 E. D. Armstrong III, Esq. Johnson, Pope, Bokor, Ruppel & Burns, LLP P.O. Box 1368 Clearwater, FL 33757 RE: Development Order - DVA2007-00002 470 and 500 Mandalay Avenue and 11 Baymont Street (Sandpearl Resort) Dear Mr. Armstrong: The City Council at their meeting on September 6, 2007, APPROVED the amendment to an adopted Development Agreement between The Sandpearl Resort, LLC (formerly known as CBR Development I, LLC) and The Residences at Sandpearl Resort, LLC (formerly known as CBR Development II, LLC) and the City of Clearwater (previously DVA2004-00005 approved by City Council on January 20, 2005) relating to the provision of a 42-slip marina dock in conjunction with the Sandpearl Resort project (39 wet slips and three day slips, of which 15 slips will be for public usage and 27 slips will be leased to the Sandpearl Resort) in the submerged lands adjacent to the Clearwater Beach Recreation Center (69 Bay Esplanade) for the sites at 470 and 500 Mandalay Avenue and 11 Baymont Street (Sandpearl Resort). If you have any questions, please do not hesitate to call Wayne M. Wells, AICP, Planner III, at 727-562- 4504. You can access zoning information for parcels within the City through our website: www.myclearwater.com. Sincerely, Michael Delk, 1P 7 7 Planning Director. S: (Planning DepartmentlCD BIDevelopment Agreements (DVA)IDVA2007-00002 Mandalay 500 Sandpearl Resort (7) - Approvedwandalay 500 CC Decision Letter 9.13.07.doc FRANK HIBBARD, MAYOR JOHN DORAN, COUNCILMEMBER J.B. JOHNSON, COUNCILMEMBER BILL JONSON, COUNCILMEMBER CAREEN A. PETERSEN, COUNCILMEMBER "EQUAL EMPLOYMENT AND AFFIRMATIVE ACTION EMPLOYER" • • Wells, Wayne From: Wells, Wayne Sent: Thursday, August 23, 2007 11:13 AM To: 'Jayne E. Sears' Subject: RE: Sandpearl Boat Docks - DVA2007-00002 Jayne - Thanks for the Affidavit. I do not need a copy of the signed agreement, as I will get a copy later after it has been signed by everyone from our Clerk records. Wayne -----Original Message----- From: Jayne E. Sears (mailto:JayneS@jpfirm.com] Sent: Thursday, August 23, 2007 10:05 AM To: Wells, Wayne Subject: Sandpearl Boat Docks - DVA2007-00002 Attached is a copy of the sign posting affidavit. Do you need the original for your file or does it go to Gina Dewitt with the development agreement? Do you need a copy of the signed development agreement? Jayne E. Sears Legal Assistant Johnson, Pope, Bokor, Ruppel & Burns, LLP 911 Chestnut Street Clearwater, FL 33756 Phone: (727) 461-1818 Fax: (727) 462-0365 <<SignPosting.PDF>> 1 • Case # DVA2007-00002 • Sign Posting Acknowledgement I hereby acknowledge posting signs on the subject property that is undergoing an amendment to a previously approved Development Agreement so that they are readable from the most significant adjacent road a minimum of 15 days before the City Council Public Hearing. Gail M. Cooper Print Name Sign Name s a Date Posting Date - No Later Than: Public Hearing Date - CDB: 7-17-07 7-2-07 (Done by Wayne Wells) CC: 9-6-07 8-22-07 I { • Wells, Wayne From: Wells, Wayne Sent: Tuesday, August 21, 2007 11:22 AM To: Jayne Sears (E-mail) Subject: FW: Document2 Jayne - Please see comments below. Wayne -----Original Message----- From: Hollander, Gwen Sent: Tuesday, August 21, 2007 10:50 AM To: Wells, Wayne Cc: Dougall-Sides, Leslie; Dewitt, Gina Subject: Document2 Doc2.doc Wayne, Please ask Jane Sears to substitute the attached City signature page for the one in the agreement. Thank you. Gwen Hollander Legal Staff Assistant Clearwater City Attorney's Office (727) 562-4013 Countersigned: CITY OF CLEARWATER, FLORIDA By: Frank V. Hibbard William B. Horne 11 Mayor City Manager Approved as to form: Leslie K. Dougall-Sides Assistant City Attorney STATE OF FLORIDA ) COUNTY OF PINELLAS ) Attest: Cynthia E. Goudeau City Clerk The foregoing instrument was acknowledged before me this day of , 20 , by FRANK V. HIBBARD, Mayor of the City of Clearwater, who is personally known to me. Print/Type Name: Notary Public STATE OF FLORIDA ) COUNTY OF PINELLAS ) The foregoing instrument was acknowledged before me this day of ,20 , by WILLIAM B. HORNE 11, City Manager of the City of Clearwater, who is personally known to me. Print/Type Name: Notary Public sage • ? Page 1 of 2 Wells, Wayne From: Wells, Wayne Sent: Monday, July 30, 2007 1:37 PM To: 'Jayne E. Sears' Cc: Linda Cunningham; Watkins, Sherry; Clayton, Gina; Dewitt, Gina; Goudeau, Cyndie Subject: RE: DVA2007-00002 - Sandpeal Boat Docks - Amendment to Dev Agt Jayne - According to Gina DeWitt in the City Attorney's office, two original paper copies (cleaned up) with the attachments of the Development Agreement signed by the applicant must be submitted to the City Attorney's office no later than 9:00 am on September 4, 2007 (for the workshop session). I am attaching a cleaned up version (accepted the tracked change on Page 10 plus I deleted some extra spaces throughout the document) that I am sending to the City Clerk and City Attorney for their information and use. Should there be any additional changes to this document, please send that version to me, Gina DeWitt and Cyndi Goudeau. This Development Agreement is scheduled for review and adoption by City Council on September 6, 2007. 1 will prepare three new signs with the revised date of City Council on it. If you would like to pick them up tomorrow and replace the existing signs on Mandalay Avenue (one at San Marco St, one on the north side of the retail area under construction next to 490 Mandalay Ave and one at the northwest corner of the intersection of . Mandalay Ave and Baymont St) that would be great. I will also prepare an acknowledgment for sign posting you will need to complete and return to me. The signs need to be posted no later than August 22, 2007 (see attached). Wayne -----Original Message----- From: Jayne E. Sears [mailto:JayneS@jpfirm.com] Sent: Wednesday, July 25, 2007 10:23 AM To: Wells, Wayne Cc: Linda Cunningham Subject: RE:.DVA2007-00002 - Sandpeal Boat Docks - Amendment to Dev Agt Wayne, what do I need to provide as far as copies for City Commission? Also let me know if I need to pick up revised signs for the site. -----Original Message----- From: Wayne.Wells@myClearwater.com [mailto:Wayne.Wells@myClearwater.com] Sent: Wednesday, July 25, 2007 9:44 AM . To: Jayne E. Sears; Pam.Akin@myClearwater.com; Leslie. Dougall-Sides@myClearwater.com Cc: Ed Armstrong; Ryan.Oliver@Delta-Seven.com; johnh@jmcdev.com; gailc@jmcdev.com Subject: DVA2007-00002 - Sandpeal Boat Docks - Amendment to Dev Agt Jayne - The change has been reviewed by Pam Akin, Leslie Dougall-Sides and myself and is acceptable. In my opinion, since the CDB discussed this issue without requiring any change to the Amended Development Agreement, and since it will most likely be brought up during public discussion at the City Council meeting (which is why it was recommended to go ahead and place it now into the Amended Development Agreement), this change will not require Case DVA2007-00002 to be reheard by the CDB. 7/30/2007 essage Page 2 of 2 14 Wayne -----Original Message----- From: Jayne E. Sears [mailto:JayneS@jpfirm.com] Sent: Tuesday, July 24, 2007 3:56 PM To: Akin, Pam; Wells, Wayne; Dougall-Sides, Leslie Cc: Ed Armstrong; Ryan Oliver; John Hobach; Gail Cooper Subject: Sandpeal Boat Docks - Amendment to Dev Agt Please see the proposed revision concerning the definition of "low profile", shown on page 10. 1 will await your response as to whether this language is acceptable before providing revised hard copies. We agree with your suggestion about providing a definition for low profile, but we do not want to make any change that would cause this matter to go back before CDB. Please confirm that the attached revision is acceptable in that regard as well. Thanks. Jayne E. Sears Legal Assistant Johnson, Pope, Bokor, Ruppel & Burns, LLP 911 Chestnut Street Clearwater, FL 33756 Phone: (727) 461-1818 Fax: (727) 462-0365 7/30/2007 Message . • Page 1 of 1 Wells, Wayne From: Wells, Wayne Sent: Wednesday, July 25, 2007 9:44 AM To: 'Jayne E. Sears'; Akin, Pam; Dougall-Sides, Leslie Cc: Ed Armstrong; Ryan Oliver; John Hobach; Gail Cooper Subject: DVA2007-00002 - Sandpeal Boat Docks - Amendment to Dev Agt Jayne - The change has been reviewed by Pam Akin, Leslie Dougall-Sides and myself and is acceptable. In my opinion, since the CDB discussed this issue without requiring any change to the Amended Development Agreement, and since it will most likely be brought up during public discussion at the City Council meeting (which is why it was recommended to go ahead and place it now into the Amended Development Agreement), this change will not require Case DVA2007-00002 to be reheard by the CDB. Wayne -----Original Message----- From: Jayne E. Sears [mailto:JayneS@jpfirm.com] Sent: Tuesday, July 24, 2007 3:56 PM To: Akin, Pam; Wells, Wayne; Dougall-Sides, Leslie Cc: Ed Armstrong; Ryan Oliver; John Hobach; Gail Cooper Subject: Sandpeal Boat Docks - Amendment to Dev Agt Please see the proposed revision concerning the definition of "low profile", shown on page 10. 1 will await your response as to whether this language is acceptable before providing revised hard copies. We agree with your suggestion about providing a definition for low profile, but we do not want to make any change that would cause this matter to go back before CDB. Please confirm that the attached revision is acceptable in that regard as well. Thanks. Jayne E. Sears Legal Assistant Johnson, Pope, Bokor, Ruppel & Burns, LLP 911 Chestnut Street Clearwater, FL 33756 Phone: (727) 461-1818 Fax: (727) 462-0365 7/25/2007 Message • • Page 1 of 1 Wells, Wayne From: Wells, Wayne Sent: Wednesday, July 25, 2007 9:37 AM To: Akin, Pam; Dougall-Sides, Leslie Cc: Delk, Michael Subject: RE: Sand pearl Boat Docks - Amendment to Dev Agt The change to define "low profile" is acceptable. -----Original Message----- From: Akin, Pam Sent: Wednesday, July 25, 2007 9:27 AM To: Dougall-Sides, Leslie; Wells, Wayne Subject: FW: Sand pearl Boat Docks - Amendment to Dev Agt I have not seen responses from you two. It looks good to me Pamela Akin, City Attorney 112 5. Osceola Ave Clearwater, Florida 33758 727 562-4010 -----Original Message----- From: Jayne E. Sears [mailto:JayneS@jpfirm.com] Sent: Tuesday, July 24, 2007 3:56 PM To: Akin, Pam; Wells, Wayne; Dougall-Sides, Leslie Cc: Ed Armstrong; Ryan Oliver; John Hobach; Gail Cooper Subject: Sandpeal Boat Docks - Amendment to Dev Agt Please see the proposed revision concerning the definition of "low profile", shown on page 10. 1 will await your response as to whether this language is acceptable before providing revised hard copies. We agree with your suggestion about providing a definition for low profile, but we do not want to make any change that would cause this matter to go back before CDB. Please confirm that the attached revision is acceptable in that regard as well. Thanks. Jayne E. Sears Legal Assistant Johnson, Pope, Bokor, Ruppel & Burns, LLP 911 Chestnut Street Clearwater, FL 33756 Phone: (727) 461-1818 Fax: (727) 462-0365 7/25/2007 Message • • Page 1 of 1 Wells, Wayne From: Dougall-Sides, Leslie Sent: Wednesday, July 25, 2007 9:32 AM To: Akin, Pam; Wells, Wayne Subject: RE: Sand pearl Boat Docks - Amendment to Dev Agt It looks fine to me. -----Original Message----- From: Akin, Pam Sent: Wednesday, July 25, 2007 9:27 AM 'To: Dougall-Sides, Leslie; Wells, Wayne Subject: FW: Sand pearl Boat Docks - Amendment to Dev Agt I have not seen responses from you two. It looks good to me Pamela Akin, City Attorney 112 5. Osceola Ave Clearwater, Florida 33758 727 562-4010 -----Original Message----- From: Jayne E. Sears [mailto:JayneS@jpfirm.com] Sent: Tuesday, July 24, 2007 3:56 PM To: Akin, Pam; Wells, Wayne; Dougall-Sides, Leslie Cc: Ed Armstrong; Ryan Oliver; John Hobach; Gail Cooper Subject: Sandpeal Boat Docks - Amendment to Dev Agt Please see the proposed revision concerning the definition of "low profile", shown on page 10. 1 will await your response as to whether this language is acceptable before providing revised hard copies. We agree with your suggestion about providing a definition for low profile, but we do not want to make any change that would cause this matter to go back before CDB. Please confirm that the attached revision is acceptable in that regard as well. Thanks. Jayne E. Sears Legal Assistant Johnson, Pope, Bokor, Ruppel & Burns, LLP 911 Chestnut Street Clearwater, FL 33756 Phone: (727) 461-1818 Fax: (727) 462-0365 7/25/2007 'sage Page 1 of 2 Wells, Wayne From: Goudeau, Cyndie Sent: Tuesday, July 24, 2007 4:22 PM To: Akin, Pam; Dougall-Sides, Leslie Cc: Dewitt, Gina; Vaughan, Karen; Wells, Wayne Subject: RE: DVA2007-00002/Sandpearl Development Agt We were able to catch the ad, so we will not have to list this and continue it on the 8/14 agenda. We will move it to the 9/6 meeting on agenda tracking. -----Original Message----- From: Akin, Pam Sent: Tuesday, July 24, 2007 2:25 PM To: Goudeau, Cyndie; Dougall-Sides, Leslie Cc: Dewitt, Gina Subject: FW: DVA2007-00002/Sandpearl Development Agt Pamela Akin, City Attorney 112 S. Osceola Ave Clearwater, Florida 33758 727 562-4010 -----Original Message----- From: Wells, Wayne Sent: Tuesday, July 24, 2007 12:08 PM To: Delk, Michael; Clayton, Gina; Thompson, Neil; Watkins, Sherry; Hollander, Gwen; Akin, Pam Subject: FW: DVA2007-00002/Sandpearl Development Agt FYI -----Original Message----- From: Jayne E. Sears [mailto:JayneS@jpfirm.com] Sent: Tuesday, July 24, 2007 10:07 AM To: Wells, Wayne Cc: Ed Armstrong Subject: DVA2007-00002/Sa nd pearl Development Agt On behalf of the applicant, we request that the referenced case (concerning Sandpearl Development Agreement amendment) be scheduled for the City Commission meeting of September 6, 2007. The reason for the request is that Ed Armstrong will be out-of-town on the upcoming meeting of August 14. Please let me know what needs to be done with regard to the sign posting and by when. We will be providing you with a revised amendment concerning the definition of "low profile" within the next few days. Thank you. 7/25/2007 Itssage 0 0. Page 2 of 2 Jayne E. Sears Legal Assistant Johnson, Pope, Bokor, Ruppel & Burns, LLP 911 Chestnut Street Clearwater, FL 33756 Phone: (727) 461-1818 Fax: (727) 462-0365 7/25/2007 Message 0 • Page 1 of 1 Wells, Wayne From: Jayne E. Sears [JayneS@jpfirm.com] Sent: Tuesday, July 24, 2007 10:07 AM To: Wells, Wayne Cc: Ed Armstrong Subject: DVA2007-00002/San d pearl Development Agt On behalf of the applicant, we request that the referenced case (concerning Sandpearl Development Agreement amendment) be scheduled for the City Commission meeting of September 6, 2007. The reason for the request is that Ed Armstrong will be out-of-town on the upcoming meeting of August 14. Please let me know what needs to be done with regard to the sign posting and by when. We will be providing you with a revised amendment concerning the definition of "low profile" within the next few days. Thank you. Jayne E. Sears Legal Assistant Johnson, Pope, Bokor, Ruppel & Burns, LLP 911 Chestnut Street Clearwater, FL 33756 Phone: (727) 461-1818 Fax: (727) 462-0365 7/25/2007 i"IR Wells, Wayne From: Jayne E. Sears [JayneS@jpfirm.com] Sent: Monday, July 23, 2007 10:58 AM To: Delk, Michael; Morris, William D.; Wells, Wayne Cc: Akin, Pam; Clayton, Gina; Dougall-Sides, Leslie; Ed Armstrong Subject: RE: DVA2007-00002, Sandpearl Development Agreement 4' is acceptable. We are working on making the change to the development agreement. Jayne E. Sears Legal Assistant Johnson, Pope, Bokor, Ruppel & Burns, LLP 911 Chestnut Street Clearwater, FL 33756 Phone: (727) 461-1818 Fax: (727) 462-0365 -----Original Message----- From: michael.delk@MyClearwater.com [mailto:michael.delk@MyClearwater.com) Sent: Monday, July 23, 2007 10:55 AM To: William.Morris@myClearwater.com; Wayne.Wells@myClearwater.com; Jayne E. Sears Cc: Pam.Akin@myClearwater.com; Gina.Clayton@myclearwater.com; Leslie.Dougall-Sides@myClearwater.com Subject: RE: DVA2007-00002, Sandpearl Development Agreement Wayne - I think this is a fair and reasonable compromise on this issue that should allow us to proceed with approval of this item. I trust it will be agreed to. Going forward, this would seem to be a fair standard for "low profile" lift systems. We may consider whether or not it can be incorporated into code when we consider "Code V" next year. michael Michael L. Delk, AICP Planning Director City of Clearwater myclearwater.com > -----Original Message----- > From: Morris, William D. > Sent: Friday, July 20, 2007 1:23 PM > To: Wells, Wayne; 'Jayne Sears (E-mail)' > Cc: Delk, Michael; Akin, Pam; Clayton, Gina; Dougall-Sides, Leslie > Subject: RE: DVA2007-00002, Sandpearl Development Agreement > Wayne, I strongly agree and have worked with Frank Dame who is on the CDB before on boat lift issues when he was on the Marine Advisory board. He has compiled a list of sources, researched them and in his comments strongly suggests the 4 foot height limit as to define "low profile. At the Marine Advisory Board last week, (no minutes yet) we discussed this and I presented the docks for discussion of this issue. At that meeting, mid chest was the consensus which is approximately 4 feet. > There is one company that makes a No Profile lift nut it is expensive > and would not elevate the dock above the dock height. They are 1 Ti > expensive and would not help during storm surges. All the way around, > 4 feet seems to be the best compromise and allows for an 8 foot storm > surge if the dock is 4 feet above mean high water. > Frank Dames message to me with the references docks listed. we would > not be limiting people to one vendor or just a few there are many. > Thanks, Bill M > -----Original Message----- > From: Frank Dame [mailto:fdame@yahoo.com] > Sent: Tuesday, July 17, 2007 6:24 PM > To: Morris, William D. > Subject: Low Profile Boat Lifts > Bill: > Here are 16 links to lift manufacturers that could most likely > accommodate "Low Profile" boat lift specifications not to exceed 48" > in height above the > deck: > http://www.eastcoastboatlifts.com/lift-lpl.htm > http://www.noprofileboatlifts.com/?gclid=COTAyPnFr40CFQ5YgAodbGn-tQ > (this is the manufacturer you had identified) > http://www.decoboatlift.com/concept.html (a local company with low > profile > lifts) > http://www.magnumlift.com/ > http://www.lunmar.com/piling-mount-lift.htm (some of these are not low > profile, but the ones that are only need 48" above the deck). > http://www.boatliftdistributors.com/boat-lifts-c-2l.html (check out > their beamless boat lifts that could be placed on a piling 48" above > the deck) > http://www.goldenboatlifts.com/lowprofile.htm > http://www.boatliftwarehouse.com/boat_lifts/4_piling_lifts/ (note > that any of these lifts could be 48" high and considered "Low > Profile") > http://www.theboatliftcompany.com/faq.htm (Note the comment on this > company's FAQ section that "The size of the slip might limit your > maximum boat size, but almost any size boat can be lifted with a > custom designed low-profile boat lift). > http://www.umlc.com/fo-Paws.html > http://www.sunstreamcorp.com/ssc/sunlift.html > http://www.davitmaster.com/5_cradleLifts/cradleLifts.asp > http://www.boat-lift.com/boat_dock_lift.html > http://www.dolphinboatlifts.com/ > http://www.ablboatlifts.com/vertical-silhouette.html > http://www.aqua-lift.com/boat-lift-photos.htm (interesting concept > with no pilings - May not be practical in salt water) 2 ib > The first company I providee for you (East Coast Boat Lift states > the lift can be mounted on pilings from 36" to 48". Given that a > fixed dock will usually be approximately 41 above mean high tide, if a > "Low Profile" lift is defined as being no more than 48" above the > deck, this would allow a boat owner to lift his boat 4' above the dock > and accommodate an 8' tidal surge> prior to being affected by the > surge. If we are anticipating tidal surges beyond that, the owner > probably will want to take his boat out of the water or anchor it in a > sheltered area to handle the surge. Low profile lifts and would > improve the visual views of the water when the boat was not on the > lift. Over the past few years, I have heard many complaints about > high lifts in Island Estates. Maybe using "low profile" lifts in the > future would be a good thing to mitigate this type of complaint. > I would suggest the city define a "low profile" lift as one that does > not extend higher than 48" above the deck. > Please let me know if you need further assistance. > Best regards, > Frank > Frank L. Dame > -----Original Message----- > From: Wells, Wayne > Sent: Friday, July 20, 2007 12:14 PM > To: Jayne Sears (E-mail) > Cc: Delk, Michael; Akin, Pam; Morris, William D.; Clayton, Gina; Dougall-Sides, Leslie > Subject: DVA2007-00002, Sandpearl Development Agreement > Jayne - > Based on the questions and "non-answers" at the CDB meeting regarding > the definition of "low profile pilings and/or tie poles" to be used in > the Boat Docking Facilities, I would strongly suggest that such a > definition be incorporated into the amended Development Agreement > before it goes to City Council. Additionally, based on the testimony > at the CDB meeting, the Planning Department suggests that such > definition be limited to four feet (rather than five feet). I believe > this question will arise again at the City Council meeting, so we > ought to deal with it now proactively (now that we know there is a > question) rather than at the meeting on August 14th. > Wayne 3 C ITY OF C LEARWATER POST OFFICE BOX 4748, CLEARWATER, FLORIDA 33758-4748 MUNICIPAL SERVICES BUILDING, 100 SOUTH MYRTLE AVENUE, CLEARWATER, FLORIDA 33756 TELEPHONE (727) 562-4567 FAx(727) 562-4865 PLANNING DEPARTMENT ,a E. D. Armstrong III, Esq. Johnson, Pope, Bokor, Ruppel & Burns, LLP P.O. Box 1368 Clearwater, FL 33757 July 23 Febfuai-y 21, 2007 RE: DVA2007-00002, 470 and 500 Mandalay Avenue and 11 Baymont Street (Sandpearl Resort) (Amended to correct date on letter) Dear Mr. Armstrong: The Community Development Board (CDB) at their meeting on July 17, 2007, voted to recommend to the City Council APPROVAL of an amendment to an adopted Development Agreement between The Sandpearl Resort, LLC (formerly known as CBR Development I, LLC) and The Residences at Sandpearl Resort, LLC (formerly known as CBR Development II, LLC) and the City of Clearwater (previously DVA2004-00005 approved by City Council on January 20, 2005) relating to the provision of a 42-slip marina dock in conjunction with the Sandpearl Resort project (39 wet slips and three day slips, of which 15 slips will be for public usage and 27 slips will be leased to the Sandpearl Resort) in the submerged lands adjacent to the Clearwater Beach Recreation Center (69 Bay Esplanade) for the sites at 470 and 500 Mandalay Avenue and 11 Baymont Street (Sandpearl Resort). This amended Development Agreement is scheduled for review and decision by City Council on Tuesday, August 14, 2007. If you have any questions, please do not hesitate to call Wayne M. Wells, Planner III, at 727-562-4504. You can access zoning information for parcels within the City through our website: www.myclearwater.com/ og v/depts/planning. Sincerely, reD , Planning Director S: (Planning Departmen6CD BIFLEX (FLD)Wending cases)Up for the next CDBIDVA2007-00002 Mandalay 500 Sandpearl Resort (T) - 8. /4.07 CC - WWIMandalay 500 CDB Decision Letter 7.23.07.doc FRANK HIBBARD, MAYOR JOHN DORAN, COUNCILMEMBER J.B. JOHNSON, COUNCILMEMBER BILL JONSON, COUNCILMEMBER CARLEN A. PETERSEN, COUNCILMEMBER "EQUAL EMPLOYMENT AND AFFIRMATIVE ACTION EMPLOYER" 0 0 C IrTY OF C LEAK ATER I t mrer?y s e s 'i N o-_Ii, a ; POST OFFICE BOX 4748, CLEARWATER, FLORIDA 33758-4748 s-- " Q MUNICIPAL SERVICES BUILDING, 100 SOUTH MYRTLE AVENUE, CLEARWATER, FLORIDA 33756 TELEPHONE (727) 562-4567 FAx (727) 562-4865 PLANNING DEPARTMENT February 21, 2007 E. D. Armstrong III, Esq. Johnson, Pope, Bokor, Ruppel & Burns, LLP P.O. Box 1368 Clearwater, FL 33757 RE: DVA2007-00002, 470 and 500 Mandalay Avenue and 11 Baymont Street (Sandpearl Resort) Dear Mr. Armstrong: The Community Development Board (CDB) at their meeting on July 17, 2007, voted to recommend to the City Council APPROVAL of an amendment to an adopted Development Agreement between The Sandpearl Resort, LLC (formerly known as CBR Development I, LLC) and The Residences at Sandpearl Resort, LLC (formerly known as CBR Development II, LLC) and the City of Clearwater (previously DVA2004-00005 approved by City Council on January 20, 2005) relating to the provision of a 42-slip marina dock in conjunction with the Sandpearl Resort project (39 wet slips and three day slips, of which 15 slips will be for public usage and 27 slips will be leased to the Sandpearl Resort) in the submerged lands adjacent to the Clearwater Beach Recreation Center (69 Bay Esplanade) for the sites at 470 and 500 Mandalay Avenue and 11 Baymont Street (Sandpearl Resort). This amended Development Agreement is scheduled for review and decision by City Council on Tuesday, August 14, 2007. If you have any questions, please do not hesitate to call Wayne M. Wells, Planner III, at 727-562-4504. You can access zoning information for parcels within the City through our website: www.myclearwater.com/ og v/depts/planning. Sincerely, Michael Delk, AIC Planning Director S:IPlanning DepartmentlCD BIFLEX (FLD)IPending cases)Up for the next CDMDVA2007-00002 Mandalay 500 Sandpearl Resort (T) - 8.14.07 CC - WWIMandalay 500 CDB Decision Letter 7.18.07.doc FRANK HIBBARD, MAYOR JOHN DORAN, COUNCILMEMBER J.B. JOHNSON, COUNCILMEMBER BILL JONSON, COUNCILMEMBER CARLEN A. PETERSEN, COUNCILMEMBER "EQUAL EMPLOYMENT AND AFFIRMAT[VE ACTION EMPLOYER" 0 • Wells, Wayne From: Wells, Wayne Sent: Friday, July 20, 2007 12:14 PM To: Jayne Sears (E-mail) Cc: Delk, Michael; Akin, Pam; Morris, William D.; Clayton, Gina; Dougall-Sides, Leslie Subject: DVA2007-00002, Sandpearl Development Agreement Jayne - Based on the questions and "non-answers" at the CDB meeting regarding the definition of "low profile pilings and/or tie poles" to be used in the Boat Docking Facilities, I would strongly suggest that such a definition be incorporated into the amended Development Agreement before it goes to City Council. Additionally, based on the testimony at the CDB meeting, the Planning Department suggests that such definition be limited to four feet (rather than five feet). I believe this question will arise again at the City Council meeting, so we ought to deal with it now proactively (now that we know there is a question) rather than at the meeting on August 14th. Wayne Message 10 0 Page 1 of 1 Wells, Wayne From: Wells, Wayne Sent: Friday, July 20, 2007 11:44 AM To: 'Jayne E. Sears' Subject: RE: DVA 2007-00002 Sandpearl It is scheduled for the August 14th City Council meeting (the August 16th meeting was cancelled and combined with the workshop meeting on the 14th). There is only one reading of the resolution. -----Original Message----- From: Jayne E. Sears [mailto:JayneS@jpfirm.com] Sent: Thursday, July 19, 2007 3:14 PM To: Wells, Wayne Subject: DVA 2007-00002 Sandpearl Wayne, what are the City Council dates for this amendment? Will there be 2 readings? Jayne E. Sears Legal Assistant Johnson, Pope, Bokor, Ruppel & Burns, LLP 911 Chestnut Street Clearwater, FL 33756 Phone: (727) 461-1818 Fax: (727) 462-0365 7/20/2007 1-1 Wells, Wayne From: Dewitt, Gina Sent: Friday, July 20, 2007 8:18 AM To: 'carl@clearwatergazette.com; Wells, Wayne Cc: Akin, Pam; Castelli, Joelle Wiley Subject: Sandpearl amendment Sandpearl amendment.pdf Attached is the latest version of the 5andpearl amendment. • • Wells, Wayne From: Wells, Wayne Sent: Thursday, July 12, 2007 9:26 AM To: Jayne Sears (E-mail) Subject: FLD2007-02003, 69 Bay Esplanade Jayne - You have been provided a copy of the Staff Report for the above referenced FLD project. Please let me know by 10:00 am on Monday, July 16, 2007, if the conditions of approval are acceptable or not. You have also been provided a copy of the Staff Report for the proposed amended Development Agreement. Wayne • • Wells, Wayne From: Wells, Wayne Sent: Thursday, June 28, 2007 4:05 PM To: Jayne Sears (E-mail) Subject: FLD2007-02003, 69 Bay Esplanade & DVA2007-00002, 470 & 500 Mandalay Avenue & 11 Baymont Street Jayne - Attached are letters regarding the scheduling of the above cases for the CDB. The original letters are being mailed. The DVA is also being scheduled for the August 14, 2007, City Council meeting. We will need to talk about the FLD case and revise some of the application materials. Wayne ?F Bay Esplanade 69 Mandalay 500 CDB CDB Letter.do... Letter.doc C ITY OF C LEARWATE R ,:_ ?. POST OFFICE BOX 4748, CLEARWATER, FLORIDA 33758-4748 MUNICIPAL SERVICES BUILDING, 100 SOUTH MYRTLE AVENUE, CLEARWATER, FLORIDA 33756 TELEPHONE (727) 562-4567 FAx (727) 562-4865 PLANNING DEPARTMENT E. D. Armstrong 111, Esq. Johnson, Pope, Bokor, Ruppel & Burns, LLP P.O. Box 1368 Clearwater, FL 33757 Re: Community Development Board Meeting (Case No. DVA2007-00002) Dear Mr. Armstrong: June 26, 2007 You have filed Case No. DVA2007-00002 for property located at 470 and 500 Mandalay Avenue and 11 Baymont Street for the Review of, and recommendation to the City Council, of an amendment to an adopted Development Agreement between The Sandpearl Resort, LLC (formerly known as CBR Development I, LLC) and The Residences at Sandpearl Resort, LLC (formerly known as CBR Development 11, LLC) and the City of Clearwater (previously DVA2004-00005 approved by City Council on January 20, 2005) relating to the provision of a 42-slip marina dock in conjunction with the Sandpearl Resort project (39 wet slips and three day slips, of which 15 slips will be for public usage and 27 slips will be leased to the Sandpearl Resort) in the submerged lands adjacent to the Clearwater Beach Recreation Center (69 Bay Esplanade). This case has been scheduled to be reviewed by the Community Development Board on July 17, 2007. The meeting will take place at 1:00 p.m. in the City Council Chambers, 3`d floor of City Hall at 112 S. Osceola Avenue, Clearwater. If you have any questions, please do not hesitate to call me at 727-562-4504. Sincerely, Aiab? x 12 / ? • ?/. WayM. Wells, AICP Planner III S:Wlanning DepartmentlC D BIFLEX (FLD)IPending caseslUp for the next CDBIDVA2007-00002 Mandalay 500 Sandpearl Resort (T) - 7.17.07 CDB - WWIMandalay 500 CDB Letter.doc FRANK HIBBARD, MAYOR JOHN DORAN, COUNCILMEMBER J.B. JOHNSON, COUNCILMEMBER BILL JONSON, COUNCILMEMBER CARLEN A. PETERSEN, COUNCILMEMBER "EQUAL EMPLOYMENT AND AFFIRMATIVF. ACTION EMPLOYER" RESPONSES TO COMMENTS DVA2007-00002 500 Mandalay Avenue GENERAL ENGINEERING: No Issues. ENVIRONMENTAL: No Issues. FIRE: No Issues. HARBOR MASTER: is Comment No. 1: 1 have read the subject amendment in its entirety and find it in keeping with intent of the original document with adjustments made out of consideration for neighboring properties. While the requirement to provide (Article 2 section 2.03 Scope, Subparagraph 6) (on page 10 in the copy I reviewed) where it states the Developer shall also provide an employee assigned to respond to problems at the boat docking facilities on a 24/7 per week basis, it does not provide the means by which the public of the city would contact the designated employee. My concern here is that in responding to concerns of citizens both for the City Marina and the airpark, providing a phone number for direct access to a person authorized to act and/or respond as necessary has served the city well and resolved citizen concerns/complaints quickly. The default process would lead the general public to call the police or the city marina and delay response to an incident of perhaps urgent nature. A posted listing of emergency phone numbers for both dock tenants, the general public and local residents would go a long way to head off initial problems as the boating public becomes accustomed to the hours of operation, local resident and community concerns for both public safety and environmental protection. (Bill Morris) Response No. 1: The developer will post signs with telephone numbers as suggested. oftft LEGAL: No Comments. JUN 18 2007 PLANNING MARTWNT CIIYOF CLIMMAIfR A LAND RESOURCES: No Comments. LANDSCAPING: No Issues. PARKS & RECREATION: No Comments. STORMWATER: No Issues. SOLID WASTE: No Comments. TRAFFIC ENGINEERING: No issues with boat dock development agreement. PLANNING: Comment No. 1: First paragraph - My records indicate the Development Agreement was recorded in OR Book 14089, Pages 314-451. Revise Response No. 1: Page 1 of the Amendment to Development Agreement has been revised to correct the recording information. Comment No. 2: Section 2.03.3 - This section does not require lighting on the City Slips. In concert with FLD2007-02003, lighting at the ends of the docks, including the City Slips, is advisable for a night visibility/safety purpose. Adviselrevise as appropriate. Response No. 2: Section 2.03 (3) of the Revised Exhibit N-1 provides "Developer shall also provide lighting for the Boat Docking Facilities and pay all electric expenses as to such lighting." This provision contemplates the safety lighting at the ends of all docks, which Developer agrees to provide as a condition of approval of FLD2007-02003. 6/18/2007 8:50 AM 40900.101407 #407074 v1 - Sandpearl/500 Mandalay/Responses to Comments 2 JUN 181007 ???tur 1EIR 0 • Wells, Wayne From: Wells, Wayne Sent: Monday, June 04, 2007 5:05 PM To: Jayne Sears (E-mail) Cc: Akin, Pam; Dougall-Sides, Leslie Subject: DVA2007-00002, 500 Mandalay Avenue Jayne - Attached is the Draft DRC comments for the above referenced case, to be heard at 1:25 pm on Thursday, June 7, 2007. Wayne draft 6.7.07 dre action agenda... • • Wells, Wayne From: Wells, Wayne Sent: Thursday, May 10, 2007 5:39 PM To: Jayne Sears (E-mail) Subject: Surrounding Property Owners re Sandpearl Jayne - I found the List of Surrounding Owners for the Sandpearl project. It was put in with the dock application material. You don't need to send me the list tomorrow. Thanks. Wayne Wells, Wayne From: Wells, Wayne Sent: Thursday, May 10, 2007 5:05 PM To: Jayne Sears (E-mail) Subject: DVA2007-00002, 500 Mandalay Avenue Jayne - Attached is a Letter of Completeness for the above referenced project. The original letter is being mailed. Wayne OS ?. WIN?i E_J Letter of impleteness 5.10.07 PLANNING DEPARTMENT • C QTY OF C LEARWATER POST OFFICE BOX 4748, CLEARWATER, FLORIDA 33758-4748 MUNICIPAL SERVICES BUILDING, 100 SOUTH MYRTLE AVENUE, CLEARWATER, FLORIDA 33756 TELEPHONE (727) 562-4567 FAx (727) 562-4865 May 14, 2007 Mr. E. D. Armstrong III, Esquire PO Box 1368 Clearwater, FL 33757 RE: DVA2007-00002 - 500 Mandalay Avenue - Letter of Completeness Dear Mr. Armstrong: The Planning Staff has entered your application into the Department's filing system and assigned the case number: DVA2007-00002. After a preliminary review of the submitted documents, staff has determined that the application is complete. The Development Review Committee (DRC) will review the application for sufficiency on June 7, 2007, in the Planning Department conference room - Room 216 - on the second floor of the Municipal Services Building. The building is located at 100 South Myrtle Avenue in downtown Clearwater. The Planning Department's Administrative Analyst will contact you within one week prior to the meeting date for the approximate time that your case will be reviewed. You or your representative (as applicable) must be present to answer any questions that the DRC may have regarding your application. Additional comments may be generated by the DRC at the time of the meeting. If you have any questions, please do not hesitate to contact me at 727-562-4504 or Wayne.Wells@myclearwater.com. Sincerely yours, rV - M . ?A& 6!7e Wells, AICP Planner III S: (Planning Department) C D BIFLEX (FLD)IPending cases) Up for the next DRCIDVA2007-00002 Mandalay 500 Sandpearl Resort (T) - 6. 7.07 DRC - WWILetter of Completeness 5.10.07.doc FRANK HIBBARD, MAYOR JOHN DORAN, COUNCILMEMBER J.B. JOHNSON, COUNCILMEMBER BILL JONSON, COUNCILMEMBER CARLEN A. PETERSEN, COUNCILMEMBER "EQUAL EMPLOYMENT AND AFFIRMATIVE ACTION EMPLOYER" KEN BURKE, CLERK OF COURT PINELLAS COUNTY FLORIDA INST# 2007307280 09/19/2007 at 10:04 AM OFF REC BK: 15983 PG: 1204-1246 DocType:GOV RECORDING: $367.00 AMENDMENT TO DEVELOPMENT AGREEMENT FOR PROPERTY IN THE CITY OF CLEARWATER This is an amendment ("Amendment") to the Development Agreement for Property in the City of Clearwater dated January - 26, 2005 ("Agreement") between THE CITY OF CLEARWATER, FLORIDA, a Florida municipal corporation (the "City") and The Sandpearl Resort, LLC, a Florida limited liability company, formerly known as CBR Development I, LLC and The Residences at Sandpearl Resort, LLC, a Florida limited liability company, formerly known as CBR Development II, LLC (collectively the "Developer"). The Agreement is recorded in Official Records Book 14089, at Pages 314 through 451, of the Public Records of Pinellas County, Florida. WITNESSETH: WHEREAS, the City and Developer entered into the Agreement which include Section 5.03(10) provisions as to development of shared Boat Docking Facilities in the Boat Basin (as described in the Agreement); WHEREAS, subsequent to the execution of the Agreement it was determined that the submerged land in the Boat Basin was owned in fee simple by the City; WHEREAS, as a result of this change in circumstances, the parties have agreed to certain revisions to the agreement between the City and the Developer attached to the Agreement as Exhibit N-1 ("Boat Dock Agreement") and to the Agreement; WHEREAS, the City has conducted such hearings as are required by and in accordance with Chapter 163.3220 et in. Fla Stat. and applicable law; WHEREAS, the City has determined that as of the Effective Date of this Amendment the proposed development is consistent with the City's Comprehensive Plan and Land Development Regulations; WHEREAS, at a duly called public meeting on 2007, the City Council approved this Amendment, and authorized and direct its execution by the appropriate officials of the City; and WHEREAS, the members of Developer have approved this Amendment and have authorized the undersigned individuals to execute this Amendment on its behalf; NOW, THEREFORE, in consideration of the mutual promises and covenants contained herein, the parties hereby agree as follows: 1. Capitalized Terms. Capitalized terms used herein that are not defined shall have the same meanings given to such terms in the Agreement. 2. Amendment to Agreement. The Agreement is amended as follows: a. Section 5.03(10) is deleted in its entirety and replaced with the following subsection: Amendment to Development Agreement Page 1 ADOPTED 10. Boat Docking Facilities. The City owns certain real property including submerged lands within a boat basin immediately to the North of the Belle Harbor Condominium project ("Boat Basin"). The City agrees to grant to Developer the right to construct shared boat docking facilities ("Boat Docking Facilities") in the Boat Basin. Developer agrees to pursue, at Developer's expense, all required Permits for construction of boat slips (the "Boat Slips") in the Boat Basin as conceptually depicted on the attached Revised Exhibit N. In the event Developer is able to obtain the Permits for the Boat Slips, the City and Developer shall enter into an agreement in the form attached as Revised Exhibit N-1 ("Boat Dock Agreemenf) that will authorize the Developer to construct the new Boat Slips, at Developer's sole expense, and provide for Developer and its designated successors and assigns to have the right to utilize 27 of such Boat Slips during the term of the Boat Dock Agreement. The remaining 15 Boat Slips are to be utilized by the City pursuant to the terms of the Boat Dock Agreement. The Boat Dock Agreement will provide (i) for Developer to pay all maintenance and repair costs for the Boat Slips, (ii) for use of the Boat Slips to be limited to owners, tenants and guests (including Beach Club members) of the Project and other owners and tenants that own or lease residences within the geographical area bordered on the West by the Gulf of Mexico, on the East by Clearwater Bay, on the North by Rockaway Street and on the South by Papaya Street; and (iii) for Developer to provide a shuttle service to the Boat Slips from the Project. Any sublease or assignment by Developer of rights to utilize the Developer Boat Slips shall be limited to such owners, tenants and guests as provided above and all subleases or assignments shall expressly prohibit parking on the City Property during use of the Developer Boat Slips. b. Exhibit N to the Agreement is deleted and replaced with the "Revised Exhibit N" attached to this Amendment. C. Exhibit N-1 to the Agreement is deleted and replace with the "Revised Exhibit N-1" attached to this Amendment. 3. Ratification. Except as modified herein, the terms and conditions of the Agreement remain in full force and effect and are ratified by the parties. 4. Effective Date. As provided in §163.3239, Florida Statutes (2006), this Amendment will become effective after being recorded in the public records in the county and 30 days after having been received by the state land planning agency. Amendment to Development Agreement Page 2 ADOPTED IN WITNESS WHEREOF, the parties hereto have set their hands and their respective seals affixed as of this ?2 day of _gsf.,., , 2007. Countersigned: CITY OF CLEARWATER, FLORIDA l/ y: ?IZ&- Hibbard William B. Horne II Mayor City Manager Approved as to fo Leslie K. Dougall- d s Assistant City Atto y STATE OF FLORIDA ) COUNTY OF PINELLAS ) test: S C Ax??? C-1 Cynthia E. Goudeau City Clerk The foregoing instrument was acknowledged before me this /°-za day oft 20?, by FRANK V. HIBBARD, Mayor of the City of Clearwater, who is personally known to me. Print/Type Nam ] /G PL Notary Public STATE OF FLORIDA ) COUNTY OF PINELLAS ) ?.??? DIANE E MANN] p MY COMMISSION # DD526033 ?a gyp!' EXPIRES: Mar. 6, 2DI0 Z(.on 3980153 ftodde Notary Servio8.e0n The foregoing instrument was acknowledged before me this MJ`? day of Sp?g?P.r?nbe r , 20 !, by WILLIAM B. HORNE II, City Manager of the City of Clearwater, who is personally known to me. Sa, Print/Type Name: Notary Public ?J remi't'"•. SANDRA HARRIGER MY COMMISSION p DD 278716 %;•, EXPIRES: January 4,20G8 yd+ B=Wlh-u No" Pibk UrderwMem Amendment to Development Agreement Page 3 ADOPTED • THE SANDPEARL RESORT, LLC, a Florida limited liability company By: CBR Communities I, Ltd., a Florida limited partnership, Managing Member By: JMC Communities of Clearwater V, Inc. a Floriaa-c?orporation, General Partner By: Name: /J/Michael Cheezem Title: EO STATE OF FLORIDA COUNTY OF PINELLAS The foregoing instrument was acknowledged before me this day of 2007, by J. Michael Cheezem, as CEO of JMC Communities of Clearwater V, Inc., a Florida corporation, the General Partner of CBR Communities I, Ltd., a Florida limited partnership, the Managing Member of Thandpearl Resort, LLC, a Florida limited liability company, on behalf of the company, L9 who are personally known to me or ? who produced as identification. /NOTARY PUBLIC M„ ftiry rl N IL M,A l Printed Name: Gail M. Cooper My COWM" #DOW740 Commission NO. t s-b--7q(-P1 ExWRE8'MaY14'2010 My Commission expires: s ova ttn, Hoary ?D tiRd""?"' ? Amendment to Development Agreement Page 4 ADOPTED • • THE RESIDENCES AT SANDPEARL RESORT, LLC, a Florida limited liability company By: CBR Communities II, Ltd., a Florida limited partnership, Managing Member By: JMC Communities of Clearwater VI, Inc. a Florida corporation, General Partner By: Name: ichael Cheezem Title: O STATE OF FLORIDA COUNTY OF PINELLAS The foregoing instrument was acknowledged before me this 15-day of Au-qJ2007., by J: Michael Cheezem, as CEO of JMC Communities of Clearwater VI, inc., a Florida corporation, the General Partner of CBR Communities II, Ltd., a Florida limited partnership, the Managing Member of The Residences at Sandpeari Resort, LLC, a Florida limited liability company, on behalf of the company, d who are personally known to me or D who produced as identification. EIR MY 'M 507469 EXPIRES: may Y? qw,,, e«"" OTARY PUBLIC Printed Name: Gail M. Cooper Commission No. nn sa-7q,,-9 My Commission expires: -jigizio Amendment to Development Agreement Page 5 ADOPTED • • Z H m x W C W N W w ??1• t>I? !11 K ? awr r? rd 31\R7 >s 1r ? Jl iR a>1i77 1? 11? Zi>N 7111 ? ?. ae r? ? 31?M3? 3JN 7?r1 rr a aQ aw » 310r 3a mft ar' s ? atslt Im r =fM astase s 3R3! m >asaa por-roe m >as araas 371Q? a? . ?a ® 3Y1?0 t so tt?a maw w? A i ? ?a aw?a :>ly r -r AFFICOnWE UK= of KuvXMs Wrst mom go= p 31)Ilrlr is +?- p `?e+.=sss??,???cs=s=as???..cssaaa??r?.r??c=.=sxa. ???iss:a RF.umm CLARSON, P- L FL. VX Na1fi31S 7 CLARsbMCaralrL??i6 ••? Ile. •_?? Graft AmN. C0?1 oarA aevaR eve N' WATEI€411 ~?`? 7?Ms !L 114 CYsY?ter Recraobovi Ca?trr:°••a+,,,?,, S?KFJ I'm = Rdp Is ucncw, iwa ??-?Oi-3!!? t'' S GS ,r,? . r w? C N m Q a? E CL 0 a? a? D 0 C Q W a cp d a> QaQ • Via *1 %111 rug to NEW v ?S";? :own AWIDI" 60RM To BE MIMMMD ARUM AMU Main cOllsTllOLTlDx a t ./ m1ep ?w ar w our n - sop a? w 1 r -?" ?' M r 1 14N Or llllv? SOXIMAa LUEM NUMMAM TA's IG?? G a .a.yr al..:r GY?w?riv?er iPecrsofiwr cater aIN pa a r a1: ?...... . ?e w W. 0 Al NMNAL TUROM Y CORrAIl1 TO BE DISTALTAD v Iu ! AROMM IRAIQt11111R MON •. - - cullmo CONS A*raaanrre s0as •a>?t Tas RR1:W.N CLARfON. P_P_ FL ". No.16311 ° 1rY rwrM1 a 1VIEIKt'1N9 w r sE?p+,awc.. .lxlx6 t -JD,. a? N Q c N E a 0 m N 0 0 E W C D 0- 'm Qa¢ 0 0 REVISED EXHIBIT N-1 AGREEMENT This Agreement (the "Agreement") is made as of this 1 day of 2007, by and between THE CITY OF CLEARWATER, FLORIDA, a Florida mun cipal corporation (the "City") and THE SANDPEARL RESORT, LLC, a Florida limited liability company (the "Developer"). WITNESSETH: WHEREAS, the City of Clearwater and Developer have entered into a Development Agreement for Property in the City of Clearwater dated January 26, 2005 and Amendment to 2007 Development Agreement for Property in the City of Clearwater dated 5&6 -2- (collectively the "Development Agreement"); WHEREAS, Section 5.03.10 of the Development Agreement provides for the City and Developer to enter into an agreement providing for the construction of shared boat docking facilities ("Boat Dock Facilities") within a boat basin ("Boat Basin') adjoining City owned upland property ("City Property"), which Boat Basin and Boat Docking Facilities are conceptually depicted on the attached Exhibit "A" ("Site Plan"); WHEREAS, the construction and use of the Boat Docking Facilities will further the objectives of the City and facilitate the development by Developer of the mixed use resort Project, as provided in the Development Agreement; WHEREAS, at a duly called public meeting on , U , 2007, the City Council approved this Agreement, and authorized and directed its execution by the appropriate officials of the City; and WHEREAS, the members of Developer have approved this Agreement and have authorized the undersigned individual to execute this Agreement on its behalf. NOW, THEREFORE, in consideration of the mutual promises and covenants contained herein, the parties hereby agree as follows: ARTICLE 1. DEFINITIONS. 1.01. Definitions. The capitalized terms used in this Agreement that are not defined shall have the meanings given to such terms in the Development Agreement. 1.02. Use of Words and Phrases. Words of the masculine gender shall be deemed and construed to include correlative words of the feminine and neuter genders. Unless the context shall otherwise indicate, the singular shall include the plural as well as the singular number, and the word "person" shall include corporations and associations, limited liability corporations and partnerships, including public bodies, as well as natural persons. "Herein," "hereby," "hereunder," "hereof," "hereinbefore," "hereinafter" and Amendment to Development Agreement Page 8 ADOPTED other equivalent words refer to this Agreement and not solely to the particular portion thereof in which any such word is used. 1.03. Florida Statutes. All references herein to Florida Statutes are to Florida Statutes (2005), as amended from time to time. ARTICLE 2. PURPOSE AND DESCRIPTION OF BOAT DOCKING FACILITIES. 2.01. Finding of Public Purpose and Benefit. The proposed Boat Docking Facilities, including the design, construction, completion and use of the Boat Docking Facilities, is hereby found by the parties hereto: (1) to be consistent with and in furtherance of the objectives of the Comprehensive Plan of the City of Clearwater, (2) to conform to the provisions of Florida law, (3) to be in the best interests of the citizens of the City, (4) to further the purposes and objectives of the City, (5) to further the public interest on Clearwater Beach, and (6) to implement Beach by Design, including the creation of the new quality hotel resort to be constructed as a part of the Project. 2.02. Purpose of Agreement. The purpose of this Agreement is to further the implementation of Beach by Design by providing for the development of the Boat Docking Facilities, all to enhance the quality of life, increase employment and improve the aesthetic and useful enjoyment of Clearwater Beach and the City, all in accordance with and in furtherance of the Comprehensive Plan of the City of Clearwater and as authorized by and in accordance with the provisions of Florida law. 2.03. Scope of the Project. The Boat Docking Facilities are contemplated to include a central pier, finger piers and associated pilings as conceptually depicted on the attached Exhibit "A", which will accommodate a maximum of 42 boat slips ("Boat Slips"). The Developer and its designated successors and assigns shall have the right to utilize exclusively 27 of the Boat Slips which are identified on the Site Plan ("Developer Slips") and the finger piers containing the Developer Slips ("Developer Piers"). The City shall have the right to control the use of the central pier, the 15 remaining Boat Slips ("City Slips") and the finger piers containing the City Slips. The City shall have the right to utilize the City Slips during the term of this Agreement for day docking or for any other purpose. Boats shall not be permitted to occupy the City Slips and no access shall be permitted to the City Slips during the period each night between midnight and 5:00 a.m., except in an emergency or as authorized by the City Harbor Master. The foregoing restriction on overnight use of the City Slips shall not be applicable to a fireboat or other boats operated by the City or other municipal or governmental entities for public purposes ("Governmental Vessels"). 2. The Developer shall have the right to install gates or other access control improvements on the finger piers containing the Developer Slips and the right to install boat lifts in the Developer Slips ("Slip Improvements"). Developer shall also install gates on the finger piers containing the City Slips or on the central pier as directed by the City. Developer shall have the right to obtain at Developer's expense required access devices for 2417 access to Developer Slips. The Boat Docking Facilities including Slip Improvements are subject to the following additional requirements and limitations: Amendment to Development Agreement Page 9 ADOPTED • (a) Only low profile pilings and/or tie poles shall be used in the Boat Docking Facilities. As used in this Agreement, the term "low profile" means having a height of four (4) feet or less above the height of the decking of the dock. (b) No covered Boat Slips are allowed. (c) No boat lifts are permitted on 40 foot or larger slips. (d) Boat lifts shall not be installed in more than 13 of the 27 Developer Slips or in more than 50% _ of the total Developer Slips if the number of Developer Slips is reduced from 27.. (e) No fuel containers shall be transported across the central pier or finger piers, nor any refueling of any vessels be done at this facility. 3. The Developer shall have the right, at its expense, to install water and electric lines serving the Developer Slips and the City shall cooperate as to extension and connection of such utilities. All utilities provided to the Developer Boat Slips shall be separately metered and Developer shall pay all utility connection and usage charges. Developer shall also provide lighting for the Boat Docking Facilities and pay all electric expenses as to such lighting. Utilities shall not be provided by Developer to the City Slips, provided, that at the request of the City, utilities (water and electric) shall be provided to City Slips to be used by Governmental Vessels and City shall reimburse Developer for additional expenses incurred by Developer as to such utilities. 4. Developer shall provide and pay for all maintenance and repair costs for the Boat Docking Facilities. Developer shall also provide, at its expense, for all required trash removal from the Boat Docking Facilities. All normal operating expenses incurred by Developer as to the Boat Docking Facilities including maintenance, repairs, insurance premiums and cost of trash removal excluding utilities provided to Developer Slips are collectively referred to as the Common Expenses. Developer shall comply with the minimum maintenance standards as provided in the attached Exhibit "C". 5. Developer agrees that use of the Developer Boat Slips shall be limited to owners, tenants and guests (including Beach Club members) of the Project and other owners and tenants that own or lease residences within the geographical area bordered on the West by the Gulf of Mexico, on the East by Clearwater Bay, on the North by Rockaway Street and on the South by Papaya Street. Any sublease or assignment by Developer of rights to utilize Developer Boat Slips shall be limited to such owners, tenants and guests and all subleases or assignments shall expressly prohibit parking on the City Property during use of the Developer Boat Slips. 6. During the term of this Agreement, Developer shall provide a shuttle service to the Boat Docking Facilities from the Project. Developer shall also provide at the Project an employee assigned to respond to problems at the Boat Docking Facilities on a 24 hour/ 7 day per week basis. Neither the City nor Developer shall have any obligation to provide on-site security at the Boat Docking Facilities. Amendment to Development Agreement Page 10 ADOPTED 2.04. Cooperation of the Parties. The City and the Developer recognize that the successful development of the Boat Docking Facilities and each component thereof is dependent upon the continued cooperation of the City and the Developer, and each agrees that it shall act in a reasonable manner hereunder, provide the other party with complete and updated information from time to time, with respect to the conditions such party is responsible for satisfying hereunder and make its good faith reasonable efforts to ensure that such cooperation is continuous, the purposes of this Agreement are carried out to the full extent contemplated hereby and the Boat Docking Facilities are designed, constructed, completed and used as provided herein. ARTICLE 3. REGULATORY PROCESS. 3.01 Development Approvals and Permits. Applications for Development Approval. The Developer shall prepare and submit to the appropriate governmental authorities, including the City, applications for approval of all required permits ("Permits"), and all plans and specifications ("Plans and Specifications") necessary for the Boat Docking Facilities, and shall bear all costs of preparing such applications, applying for and obtaining such approvals and permits, including payment of any and all applicable application, inspection, and regulatory fees or charges. The City shall, to the extent possible, expedite review of all applications. The failure of this Agreement to address a particular permit, condition, or term of restriction shall not relieve the Developer of the necessity of complying with the law governing said permitting requirements, conditions, terms or restrictions. 2. City Cooperation and Assistance. The City shall cooperate with the Developer in obtaining all necessary Permits required for the construction, completion and use of the Boat Docking Facilities. If requested by the Developer and authorized by law, the City will join file or in the filing of any application for any Permit, or, alternatively, recommend to and urge any governmental authority that such Permit be issued or approved. 3. City Authority Preserved. The City's duties, obligations, or responsibilities under any section of this Agreement, specifically including, but not limited to, this Section 3.02, shall not affect the City's right, duty, obligation, authority and power to act in its governmental or regulatory capacity in accordance with applicable laws, ordinances, codes or other building regulations. Notwithstanding any other provision of this Agreement, any required permitting, licensing or other regulatory approvals by the City shall be subject to the established procedures and substantive requirements of the City with respect to review and permitting of a project of a similar or comparable nature, size and scope. In no event shall the City, due to any provision of this Agreement, be obligated to take any action concerning regulatory approvals except through its established procedures and in accordance with applicable provisions of law. Amendment to Development Agreement Page 11 ADOPTED ARTICLE 4. PLANS AND SPECIFICATIONS. 4.01. Plans and Specifications. 1. Responsibility for Preparation of Plans and Specifications. The Developer shall be solely responsible for and shall pay the cost of preparing, submitting and obtaining approval of the Plans and Specifications for the Boat Docking Facilities. 2. Use of Qualified Professionals. The Developer shall retain qualified professionals to prepare the Plans and Specifications and shall cause such professionals to prepare the Plans and Specifications. ARTICLE 5. DEVELOPMENT OF BOAT DOCKING FACILITIES. 5.01. Ownership of City Property. The City is the owner the City Property which is more particularly described in Exhibit "B" to this Agreement. 5.02. Boat Basin. The Boat Basin in which the Boat Docking Facilities are to be constructed adjoins the City Property, is located on submerged lands owned by the City of Clearwater, - and is depicted on the Site Plan attached as Exhibit "A". 5.03. Obligations of the City. Lease of Boat Basin. This Agreement shall constitute a lease to Developer of the portion of the Boat Basin on which the Developer Slips and associated finger piers will be located (the "Leased Premises") together with the non-exclusive right to utilize the central pier and City Property for access to the Developer Slips. Developer shall pay City as rental for the Leased Premises, annual rental in the initial amount of $5,435.83 commencing on the date that the Boat Docking Facilities are completed and authorized for occupancy by the City ("Lease Commencement Date"). The annual rental shall be payable in arrears within ten (10) days after the first anniversary of the Lease Commencement Date and annually thereafter on or before each anniversary of the Lease Commencement Date. The annual rental shall be adjusted on the first day of each lease year in accordance with the annual increase in the consumer price index for urban wage earners and clerical wages for clerical workers for all items- U.S. City Average (cpi) published by the Bureau of Labor Statistics, United States Department of Labor (BLS), 1982-84-100. In the event the BLS shall cease to publish the CPI the City shall designate a comparable index for calculating increases in annual rental. The term of the lease shall be for the term of this Agreement as provided in Section 18.18 below. 2. Permits. The City will cooperate and coordinate with the Developer with regard to all Permit applications, including those to state agencies, and will facilitate or expedite, to the greatest extent possible, the permit approval process. 4. City Share of Common Expenses. City shall pay to the Developer its proportionate share of Common Expenses relating to the Boat Docking Facilities based on a percentage determined by dividing the number of City Slips by the total number of Boat Slips in the Boat Docking Facilities ("City's Share"). Amendment to Development Agreement Page 12 ADOPTED • • 2.04. Cooperation of the Parties. The City and the Developer recognize that the successful development of the Boat Docking Facilities and each component thereof is dependent upon the continued cooperation of the City and the Developer, and each agrees that it shall act in a reasonable manner hereunder, provide the other party with complete and updated information from time to time, with respect to the conditions such party is responsible for satisfying hereunder and make its good faith reasonable efforts to ensure that such cooperation is continuous, the purposes of this Agreement are carried out to the full extent contemplated hereby and the Boat Docking Facilities are designed, constructed, completed and used as provided herein. . ARTICLE 3. REGULATORY PROCESS. 3.01 Development Approvals and Permits. Applications for Development Approval. The Developer shall prepare and submit to the appropriate governmental authorities, including the City, applications for approval of all required permits ("Permits"), and all plans and specifications ("Plans and Specifications") necessary for the Boat Docking Facilities, and shall bear all costs of preparing such applications, applying for and obtaining such approvals and permits, including payment of any and all applicable application, inspection, and regulatory fees or charges. The City shall, to the extent possible, expedite review of all applications. The failure of this Agreement to address a particular permit, condition, or term of restriction shall not relieve the Developer of the necessity of complying with the law governing said permitting requirements, conditions, terms or restrictions. 2. City Cooperation and Assistance. The City shall cooperate with the Developer in obtaining all necessary Permits required for the construction, completion and use of the Boat Docking Facilities. If requested by the Developer and authorized by law, the City will join file or in the filing of any application for any Permit, or, alternatively, recommend to and urge any governmental authority that such Permit be issued or approved. 3. City Authority Preserved. The City's duties, obligations, or responsibilities under any section of this Agreement, specifically including, but not limited to, this Section 3.02, shall not affect the City's right, duty, obligation, authority and power to act in its governmental or regulatory capacity in accordance with applicable laws, ordinances, codes or other building regulations. Notwithstanding any other provision of this Agreement, any required permitting, licensing or other regulatory approvals by the City shall be subject to the established procedures and substantive requirements of the City with respect to review and permitting of a project of a similar or comparable nature, size and scope. In no event shall the City, due to any provision of this Agreement, be obligated to take any action concerning regulatory approvals except through its established procedures and in accordance with applicable provisions of law. Amendment to Development Agreement Page 11 ADOPTED ARTICLE 4. PLANS AND SPECIFICATIONS. 4.01. Plans and Specifications. 1. Responsibility for Preparation of Plans and Specifications. The Developer shall be solely responsible for and shall pay the cost of preparing, submitting and obtaining approval of the Plans and Specifications for the Boat Docking Facilities. 2. Use of Qualified Professionals. The Developer shall retain qualified professionals to prepare the Plans and Specifications and shall cause such professionals to prepare the Plans and Specifications. ARTICLE 5. DEVELOPMENT OF BOAT DOCKING FACILITIES. 5.01. Ownership of City Property. The City is the owner the City Property which is more particularly described in Exhibit "B" to this Agreement. 5.02. Boat Basin. The Boat Basin in which the Boat Docking Facilities are to be constructed adjoins the City Property, is located on submerged lands owned by the City of Clearwater, and is depicted on the Site Plan attached as Exhibit "A". 5.03. Obligations of the City. 1. Lease of Boat Basin. This Agreement shall constitute a lease to Developer of the portion of the Boat Basin on which the Developer Slips and associated finger piers will be located (the "Leased Premises") together with the non-exclusive right to utilize the central pier and City Property for access to the Developer Slips. Developer shall pay City as rental for the Leased Premises, annual rental in the initial amount of $5,435.83 commencing on the date that the Boat Docking Facilities are completed and authorized for occupancy by the City ("Lease Commencement Date"). The annual rental shall be payable in arrears within ten (10) days after the first anniversary of the Lease Commencement Date and annually thereafter on or before each anniversary of the Lease Commencement Date. The annual rental shall be adjusted on the first day of each lease year in accordance with the annual increase in the consumer price index for urban wage earners and clerical wages for clerical workers for all items- U.S. City Average (cpi) published by the Bureau of Labor Statistics, United States Department of Labor (BLS), 1982-84-100. In the event the BLS shall cease to publish the CPI the City shall designate a comparable index for calculating increases in annual rental. The term of the lease shall be for the term of this Agreement as provided in Section 18.18 below. 2. Permits. The City will cooperate and coordinate with the Developer with regard to all Permit applications, including those to state agencies, and will facilitate or expedite, to the greatest extent possible, the permit approval process. 4. City Share of Common Expenses. City shall pay to the Developer its proportionate share of Common Expenses relating to the Boat Docking Facilities based on a percentage determined by dividing the number of City Slips by the total number of Boat Slips in the Boat Docking Facilities ("City's Share"). Amendment to Development Agreement Page 12 ADOPTED Developer shall invoice the City annually at the end of each lease year for City's Share of Common Expenses, such invoice to include an itemized statement of Common Expenses. Notwithstanding the foregoing, in no event shall City's Share of Common Expenses for any lease year exceed the amount of annual rental due from Developer to City. Developer shall bear the full amount of City's Share of Common Expenses in excess of the annual rental amount due to City. ARTICLE 6. PROJECT FINANCING. 6.01. Assignment of Rights Under Agreement To Project Lender. Developer may assign to the Project Lender all its right, title and interest under this Agreement as security for any indebtedness of Developer. The execution of any assignment, security agreement, or other instrument, or the foreclosure of the instruction or any sale under the instrument, either by judicial proceedings or by virtue of any power reserved in the mortgage or deed of trust, or conveyance in lieu of foreclosure by Developer to the holder of such indebtedness, or the existence of any right, power, or privilege reserved in any instrument, shall not be held as a violation of any of the terms or conditions of this Agreement, or as an assumption by the holder of such indebtedness personally of the obligations of this Agreement. No such assignment, foreclosure, conveyance or exercise of right shall relieve Developer from its liability under this Agreement. 6.02. Cooperation. The City and the Developer shall cooperate as to reasonable requests for assurances any proposed Project Lender for the purpose of implementing the mortgagee protection provisions contained in this Agreement and allowing the Project Lender reasonable means to protect or preserve the liens of such Project Lender upon the occurrence of a default under the terms of this Agreement. ARTICLE 7. CONSTRUCTION OF PROJECT. 7.01. Site. The Developer shall be responsible for all site investigation and environmental testing. 7.02. Construction of Boat Docking Facilities. a. Commencement. Developer shall construct the Boat Docking Facilities substantially in accordance with the Plans and Specifications therefore approved by the City. The Boat Docking Facilities include certain improvements to the City Property/Boat Basin consisting of approximately 100 - 200 feet of new seawall cap as determined to be required by Rube Clarson, P.E.. Developer shall commence construction of the Boat Docking Facilities ("Construction Commencement Date") on or before one (1) year after receipt of all Permits, and expiration or resolution of all appeal/challenges thereto ("Approval Effective Date"). b. For purposes of this Section 7.02, "commence construction" means commencement of meaningful physical development of the Boat Docking Facilities as authorized by the Permits therefor which is continued and diligently prosecuted toward completion of the Boat Docking Facilities. Amendment to Development Agreement Page 13 ADOPTED C. All obligations of Developer (including deadlines in the Construction Commencement Date) with respect to commencement and continuation of construction shall be subject to delays and extensions from time to time for Unavoidable Delay (see Article 15). Developer shall not be deemed to be in default of this Agreement to the extent construction of the Boat Docking Facilities, or a part thereof, is not complete by reason of Unavoidable Delay. 2. Pursuit of Construction. After the Construction Commencement Date, Developer shall continue, pursue and prosecute the construction of the Boat Docking Facilities with due diligence to completion, and shall not at any time actually or effectively have abandoned (or its Contractor having actually or effectively abandoned) the Boat Docking Facilities. For purposes of this subsection 7.02.2, "abandoned" means to have ceased any construction work which. effectively advances the construction of the Boat Docking Facilities toward completion, including removing all or substantially all of the construction work force from the site of the Boat Docking Facilities for a period of not less than sixty (60) days. 3. Maintenance of Construction Site. During the construction of the Boat Docking Facilities, Developer shall, at its own expense, keep the Boat Docking Facilities and all adjoining City Property in reasonably good order and condition. 4. Construction Completion. Developer agrees to complete the Boat Docking Facilities on or before one (1) year after the Construction Commencement Date. 7.03. City Not in Privity. The City shall not be deemed to be in privity of contract with any Contractor or provider of services with respect to the construction of any part of the Boat Docking Facilities not constituting all or any part of public improvements. 7.04. Construction Sequencing and Staging Area. The Developer shall construct the Boat Docking Facilities in a manner and fashion which will minimize the inconvenience of the construction on the property owners of Clearwater Beach and the residents of the City and the use of the City Property. The City agrees to allow Developer to use portions of the City Property as designated by the City for construction staging during construction of the Boat Docking Facilities, without charge to the Developer, provided that such staging area does not unreasonably affect the continued use of the City Property. ARTICLE 8. INDEMNIFICATION. 8.01. Indemnification by the Developer. The Developer agrees to indemnify, defend and hold harmless, the City, its respective agents, officers, or employees from any and all liabilities, damages, penalties, judgments, claims, demands, costs, losses, expenses or attorneys' fees through appellate proceedings, for personal injury, bodily injury, death or property damage arising out of, or by reason of any act or omission of the Developer, its agents, employees or contractors arising out of, in connection with or by reason of, the performance of any and all services covered by this Agreement, or which are alleged to have arisen out of, in connection with or by reason of, the performance of any and all services covered by this Agreement. Amendment to Development Agreement Page 14 ADOPTED 0 0 2. The Developer shall indemnify, defend and hold harmless the City, its officers and employees from any and all liabilities, damages, costs, penalties, judgments, claims, demands, losses, or expenses (including, but not limited to, actual attomeys' fees and engineering fees) arising from or attributable to any breach by the Developer, as the case may be, of any representations or warranties contained in Section 9.01, or covenants contained in Section 9.02. 3. The Developer's indemnity obligations under subsections (1) and (2) of this Section shall survive the earlier of the Termination Date or the Expiration Date, but shall apply only to occurrences, acts, or omissions that arise on or before the earlier of the Termination Date or the Expiration Date. 4. The Developer's indemnity hereunder is in addition to and not limited by any insurance policy and is not and shall not be interpreted as an insuring agreement between or among the parties to this Agreement, nor as a waiver of sovereign immunity for any party entitled to assert the defense of sovereign immunity. 8.02. Indemnification by the City. To the extent permitted by law, the City agrees to indemnify, defend and hold harmless, the Developer, its respective officers, and employees from any and all liabilities, damages, penalties, judgments, claims, demands, costs, losses, expenses or attorneys' fees through appellate proceedings, for personal injury, bodily injury, death or property damage arising out of, or by reason of, any act or omission of the City, its respective agents or employees arising out of, in connection with or by reason of, the performance of any and all services covered by this Agreement, or which are alleged to have arisen out of, in connection with or by reason of, the performance of any and all services covered by this Agreement. 2. The City shall indemnify, defend and hold harmless the Developer, its officers and employees from any and all liabilities, damages, costs, penalties, judgments, claims, demands, losses, or expenses (including, but not limited to, actual attomeys' fees and engineering fees) arising from or attributable to any breach by the City, as the case may be, of any representations or warranties contained in Section 10.01, or covenants contained in Section 10.02. 3. The City's indemnity obligations under this Section 8.02 shall survive the earlier of the Termination Date or the Expiration Date, but shall only apply to occurrences, acts or omissions that arise on or before the earlier of the Termination Date or the Expiration Date. The City's indemnity hereunder is not and shall not be interpreted as an insuring agreement between or among the parties to this Agreement, but is in addition to and not limited by any insurance policy provided that said obligation shall not be greater than that permitted and shall be limited by the provisions of Section 768.28, Florida Statutes, or any successor statute thereto. 8.03. Limitation of Indemnification. Notwithstanding anything to the contrary contained herein, with respect to the indemnification obligations of the Developer (as set forth in Section 8.01) and the City (as set forth in Section 8.02), the following shall apply: Amendment to Development Agreement Page 15 ADOPTED 0 , 0 1. The indemnifying party shall not be responsible for damages that could have been, but were not, mitigated by the indemnified party; 2. The indemnifying party shall not be responsible for that portion of any damages caused by the negligent or willful acts or omissions of the indemnified party; and 3. There shall be no obligation to indemnify hereunder in the event that the indemnified party (1) shall have effected a settlement of any claim without the prior written consent of the indemnifying party, or (2) shall not have subrogated the indemnifying party to the indemnified party's rights against any third party by an assignment to the indemnifying party of any cause or action against such third party. ARTICLE 9. REPRESENTATIONS, WARRANTIES AND COVENANTS OF THE DEVELOPER. 9.01: Representations and Warranties. The Developer represents and warrants to the City that each of the following statements is currently true and accurate and agrees the City may rely upon each of the following statements: The Developer is a. Florida Limited Liability Company duly organized and validly existing under the laws of the State of Florida, has all requisite power and authority to cant' on its business as now conducted, to own or hold its properties and to enter into and perform its obligations hereunder and under each document or instrument contemplated by this Agreement to which it is or will be a party, is qualified to do business in the State of Florida, and has consented to service of process upon a designated agent for service of process in the State of Florida. 2. This Agreement and, to the extent such documents presently exist in a form accepted by the City and the Developer, each document contemplated or required by this Agreement to which the Developer is or will be a party have been duly authorized by all necessary action on the part of, and have been or will be duly executed and delivered by, the Developer, and neither the execution and delivery thereof, nor compliance with the terms and provisions thereof or hereof: (i) requires the approval and consent of any other party, except such as have been duly obtained or as are specifically noted herein, (ii) contravenes any existing law, judgment, governmental rule, regulation or order applicable to or binding on the Developer, (iii) contravenes or results in any breach of, default under or, other than as contemplated by this Agreement, results in the creation of any lien or encumbrance upon any property of the Developer under any indenture, mortgage, deed of trust, bank loan or credit agreement, the Developer's Articles of Organization, or, any other agreement or instrument to which the Developer is a party or by which the Developer may be bound. 3. This Agreement and, to the extent such documents presently exist in a form accepted by the City and the Developer, each document contemplated or required by this Agreement to which the Developer is or will be a party constitutes, or when entered into will constitute, a legal, valid and binding obligation of the Developer enforceable against the Developer in accordance with the terms thereof, except as such enforceability may be limited by applicable bankruptcy, insolvency or similar laws from time to time in effect which affect Amendment to Development Agreement Page 16 ADOPTED • • creditors' rights generally and subject to usual equitable principles in the event that equitable remedies are involved. 4. Theie are no pending or, to the knowledge of the Developer threatened actions or proceedings before any court or administrative agency against the Developer, . or against any controlling shareholder, officer, employee or agent of the Developer which question the validity of this Agreement or any document contemplated hereunder, or which are likely in any case, or in the aggregate, to materially adversely affect the consummation of the transactions contemplated hereunder or the financial condition of the Developer. 5. The Developer has filed or caused to be filed all federal, state, local and foreign tax returns, if any, which were required to be filed by the Developer and has paid, or caused to be paid, all taxes shown to be due and payable on such returns or on any assessments levied against the Developer. 6. All documentation, including that pertaining to the Boat Docking Facilities or the Developer, delivered by the Developer to the City was, on the date of delivery thereof, true and correct. 7. The principal place of business and principal executive offices of the Developer is in St. Petersburg, Florida, and the Developer will keep records concerning the Boat Docking Facilities (such as construction contracts, financing documents and corporate documents) and all contracts, licenses and similar rights relating thereto at an office in Pinellas County. 8. As of the Effective Date, the Developer will have the financial capability to carry out its obligations and responsibilities in connection with the development of the Boat Docking Facilities as contemplated by this Agreement. 9. The Developer has the experience, expertise, and capability to develop, cause the construction, and complete the Boat Docking Facilities and, oversee and manage the design, planning, construction, completion and use of the Boat Docking Facilities. 9.02. Covenants. The Developer covenants with the City that until the earlier of the Termination Date or the Expiration Date: 1. The Developer shall timely perform or cause to be performed all of the obligations contained herein which are the responsibility of the Developer to perform. 2. During each year that this Agreement and the obligations of the Developer under this Agreement shall be in effect, the Developer shall cause to be executed and to continue to be in effect those instruments, documents, certificates, permits, licenses and approvals and shall cause to occur those events contemplated by this Agreement that are applicable to, and that are the responsibility of, the Developer. 3. The Developer shall assist and cooperate with the City to accomplish the development of the Boat Docking Facilities by the Developer in accordance with Amendment to Development Agreement Page 17 ADOPTED the Plans and Specifications, and this Agreement, and will not violate any laws, ordinances, rules, regulations, orders, contracts or agreements that are or will be applicable thereto. 4. Subsequent to the Effective Date, the Developer shall maintain its financial capability to develop, construct and complete the Boat Docking Facilities and shall promptly notify the City of any event, condition, occurrence, or change in its financial condition which adversely affects, or with the passage of time is likely to adversely affect, the Developer's financial capability to successfully and completely develop, construct and complete the Boat Docking Facilities as contemplated hereby. 5. The Developer shall promptly cause to be filed when due all federal, state, local and foreign tax returns required to be filed by it, and shall promptly pay when due any tax required thereby. 6. Subject to Section 18.01, the Developer shall maintain its existence, will not dissolve or substantially dissolve all of its assets and will not consolidate with or merge into another corporation, limited partnership, or other entity or permit one or more other corporations or other entity to consolidate with or merge into it without the prior approval of the City unless the Developer or an entity under common control with Developer, retains a controlling interest in the consolidated or merged entity, and will promptly notify the City of any changes to the existence or form of the entity or any change in the control of the Developer. 7. The Developer shall not permit, commit, or suffer any waste of the City Property, the Boat Basin or the Boat Docking Facilities. 8. Provided all conditions precedent thereto have been satisfied or waived as provided herein, the Developer shall design, construct and complete the Boat Docking Facilities such that it is substantially complete as provided in this Agreement no later than the Completion Date. ARTICLE 10. REPRESENTATIONS, WARRANTIES AND COVENANTS OF THE CITY. 10.01. Representations and Warranties. The City represents and warrants to the Developer that each of the following statements is currently true and accurate and agrees that the Developer may rely on each of the following statements: The City is a validly existing body corporate and politic of the State of Florida, has all requisite corporate power and authority to carry on its business as now conducted and to perform its obligations hereunder and under each document or instrument contemplated by this Agreement to which it is or will be a party. 2. This Agreement and, to the extent such documents presently exist in a form accepted by the City and the Developer, each document contemplated or required by this Agreement to which the City is or will be a party have been duly authorized by all necessary action on the part of, and have been or will be duly executed and delivered by, the City, and neither the execution and delivery thereof, nor compliance with the terms and provisions thereof or hereof (i) requires the approval and consent of any other party, except such as have been Amendment to Development Agreement Page 18 ADOPTED duly obtained or as are specifically noted herein, (ii) contravenes any existing law, judgment, governmental rule, regulation or order applicable to or binding on the City, (iii) contravenes or results in any breach of, or default under or, other than as contemplated by this Agreement, results in the creation of any lien or encumbrance upon any property of the City under any indenture, mortgage, deed of trust, bank loan or credit agreement, applicable ordinances, resolutions or, on the date of this Agreement, any other agreement or instrument to which the City is a party, specifically including any covenants of any bonds, notes, or other forms of indebtedness of the City outstanding on the Effective Date. 3. This Agreement and, to the extent such documents presently exist in a form accepted by the City and the Developer, each document contemplated or required by this Agreement to which the City is or will be a party constitute, or when entered into will constitute, legal, valid and binding obligations of the City enforceable against the City in accordance with the terms thereof, except as such enforceability may be limited by public policy or applicable bankruptcy, insolvency or similar laws from time to time in effect which affect creditors' rights generally and subject to usual equitable principles in the event that equitable remedies are involved. 10.02. Covenants. The City covenants with the Developer that until the earlier of the Termination Date or the Expiration Date: The City shall timely perform, or cause to be performed, all of the obligations contained herein which are the responsibility of the City to perform. 2. During each year that this Agreement and the obligations of the City under this Agreement shall be in effect, the City shall cause to be executed and to continue to be in effect those instruments, documents, certificates, permits, licenses and approvals, and shall cause to occur those events contemplated by -this Agreement that are applicable to and are the responsibility of the City. 3. The City shall assist and cooperate with the Developer to accomplish the development of the Boat Docking Facilities in accordance with this Agreement and the Plans and Specifications, will carry out its duties and responsibilities contemplated by this Agreement, and will not violate any laws, ordinances, rules, regulations, orders, contracts, or agreements that are or will be applicable thereto, and, to the extent permitted by law, the City will not enact or adopt or urge or encourage the adoption of any ordinances, resolutions, rules regulations or orders or approve or enter into any contracts or agreements, including issuing any bonds, notes, or other forms of indebtedness, that will result in any provision of this Agreement to be in violation thereof. 4. The City shall not permit, commit, or suffer any waste or impairment to the Boat Docking Facilities, nor shall the City alter the City Property, or any part thereof, so as to prevent or adversely affect the development and use of the Boat Docking Facilities. ARTICLE 11. CONDITIONS PRECEDENT. Amendment to Development Agreement Page 19 ADOPTED 0 0 I 1.01. Developer Obligations. Unless this Agreement has been terminated pursuant to Article 12 hereof, the obligation of the Developer to construct the Boat Docking Facilities is subject to the fulfillment to the satisfaction of, or waiver in writing by, the Developer of each of the following conditions precedent: 1. All conditions precedent under Article 11 of the Development Agreement have been satisfied or waived by Developer. 2. The Plans and Specifications required to commence construction of the Boat Docking Facilities shall have been approved by the City in accordance with applicable ordinances, land use regulations, building codes and other regulations of the City. 3. All Permits necessary for construction of the Boat Docking Facilities to commence shall have been issued and have become final and non-appealable. 11.02. Responsibilities of the Parties for Conditions Precedent. The parties hereto shall not, individually or collectively, knowingly, intentionally or negligently prevent any condition precedent from occurring; provided, however, nothing in this Section is intended or shall be deemed to deny any party the right to reasonably exercise its discretion to the extent permitted by law or this Agreement. ARTICLE 12. DEFAULT; TERMINATION. 12.01. Project Default by the Developer. There shall be an "event of default" by the Developer under this Agreement upon the occurrence of any one or more of the following: a. The Developer shall fail to perform or comply with any material provision of this Agreement applicable to it within the time prescribed therefor, after receipt of a notice from the City pursuant to Subsection 12.01.2.a.; or b. The Developer shall make a general assignment for the benefit of its creditors, or.shall admit in writing its inability to pay its debts as they become due or shall file a petition in bankruptcy, or shall be adjudicated a bankrupt or insolvent, or shall file a petition seeking any reorganization, arrangement, composition, readjustment, liquidation, dissolution or similar relief under any present or future statute, law or regulation or shall file an answer admitting, or shall fail reasonably to contest, the material allegations of a petition filed against it in any such proceeding, or shall seek or consent to or acquiesce in the appointment of any trustee, receiver or liquidator of the Developer or any material part of such entity's properties; or c. Within sixty (60) days after the commencement of any proceeding by or against the Developer seeking any reorganization, arrangement, composition, readjustment, liquidation, dissolution or similar relief under any present or future statute, law or regulation, such proceeding shall not have been dismissed or otherwise terminated, or if, within sixty (60) days after the appointment without the consent or acquiescence of the Amendment to Development Agreement Page 20 ADOPTED Developer of any trustee, receiver or liquidator of any of such entities or of any material part of any of such entity's properties, such appointment shall not have been vacated; or 2. a. If an event of default by the Developer described in subsection 1 above shall occur, the City shall provide written notice thereof to the Developer, and, if such event of default shall not be cured by the Developer within thirty (30) days after receipt of the written notice from the City specifying in reasonable detail the event of default by the Developer, or if such event of default is of such nature that it cannot be completely cured within such time period, then if the Developer shall not have commenced to cure such default within such thirty (30) day period and shall not diligently prosecute such cure to completion within such reasonable longer period of time as may be necessary (provided, however, if the Developer is proceeding diligently and in good faith, the curative period shall be extended for a period of not exceeding six (6) months without any approval or consent of the City being required, but such approval will be required if the curative period is to be extended beyond six (6) months) then, in addition to any remedy available under Section 12.05, the City may terminate this Agreement or pursue any and all legal or equitable remedies to which the City is entitled, provided, however, if the Developer shall fail to cure such event of default within said thirty (30) day or longer period or ceases to proceed diligently to timely cure such event of default, then the City may proceed to enforce other available remedies without providing any additional notice to the Developer. b. Any attempt by the City to pursue any of the above referenced remedies will not be deemed an exclusive election of remedy or waiver of the City's right to pursue any other remedy to which either may be entitled. C. Any time periods or deadlines provided in this Agreement shall be tolled or extended by the amount of time to cure any event of default hereunder if such event affects the Developer's or City's ability to perform by such deadline or the expiration of such period. 3. Subject to the rights of the Project Lender, if the City elects to cure a default under Subsection 12.01.1. by the Developer, construction contracts, contract documents, building permits, development permits, management agreements, and financial commitments (all only to the extent assignable) with respect to the Project shall, if such default has not been previously cured, on the day following receipt by the Developer of notice from the City of its election to cure, be deemed then assigned to the City making said election, without necessity of any other action being taken or not taken by any party hereto. The Developer shall transfer and deliver to the City upon making said election, all assignable Plans and Specifications, working drawings, construction contracts, contract documents and all Permits, and, at the direction of the City, the Developer shall vacate the Leased Premises. Amendment to Development Agreement Page 21 ADOPTED 12.02. Default by the City. 1. Provided the Developer is not then in default under Section 12.01, there shall be an "event of default" by the City under this Agreement in the event the City shall fail to perform or comply with any material provision of this Agreement applicable to it; provided, however, that suspension of or delay in performance by the City during any period in which the Developer is in default of this Agreement as provided in Section 12.01 hereof will not constitute an event of default by the City under this Subsection 12.02. 2. a. If an event of default by the City described in Subsection 12.02.1. shall occur, the Developer shall provide written notice thereof to the City, and, after expiration of the curative period described in paragraph (b) below, may terminate this Agreement, institute an action to compel specific performance of the terms hereof by the City or pursue any and all legal or equitable remedies to which the Developer is entitled; provided, however, if the event of default by the City occurs, any monetary recovery by the Developer in any such action shall be limited to bona fide third-party out of-pocket costs and expenses, including reasonable attorneys' fees, incurred by the Developer in connection with this Agreement and the transactions contemplated hereby, unless any such default by the City was willful and committed in bad faith with reckless disregard for the rights of the Developer. b. The Developer may not terminate this Agreement or institute an action described in paragraph (2a) above if the City cures such event of default within thirty (30) days after receipt by the City of written notice from the Developer specifying in reasonable detail the event of default by the City, or if any such event of default is of such nature that it cannot be completely cured within such period, then within such reasonably longer period of time as may be necessary to cure such default, provided however, if the City is proceeding diligently and in good faith, the curative period shall be extended for a period of not exceeding six (6) months without any approval or consent of the Developer being required, but such approval will be required if the curative period is to be extended beyond six (6) months after the notice of default has been given by the Developer to the City if the City has commenced to cure such default within such thirty (30) day period and is diligently prosecuting such curative action to completion. The City shall within said thirty (30) day period or such longer period promptly, diligently and in good faith proceed to cure such event of default after receipt of the notice from the Developer and shall succeed in curing such event of default within said period of time, provided, however, if the City shall fail to cure such event of default within said thirty (30) day or longer period or ceases to proceed diligently to timely cure such event of default, then the Developer may proceed with its available remedies without providing any additional notice to the City. C. Any attempt by the Developer to pursue any of the remedies referred to in paragraphs a. and b. above will not be deemed an exclusive election of Amendment to Development Agreement Page 22 ADOPTED remedy or waiver of the Developer's right to pursue any other remedy to which it might be entitled. d. Any time periods or deadlines provided in this Agreement shall be tolled or extended by the amount of time to cure any event of default hereunder if such event affects the Developer's or City's ability to perform by such deadline or the expiration of such period. 12.03. Obligations, Rights and Remedies Cumulative. Unless specifically stated herein to the contrary, the specked rights and remedies to which either the City or the Developer are entitled under this Agreement are not exclusive and are intended to be in addition to any other remedies or means of redress to which the City or the Developer may lawfully be entitled and are not specifically prohibited by this Agreement. The suspension of, or delay in, the performance of its obligations by the Developer while the City shall at such time be in default of their obligations hereunder shall not be deemed to be an "event of default." The suspension of, or delay in, the performance of the obligations by the City while the Developer shall at such time be in default of its obligations hereunder shall not be deemed to be an "event of default" by the City. 12.04. Non-Action on Failure to Observe Provisions of this Agreement. The failure of the City or the Developer to promptly or continually insist upon strict performance of any term, covenant, condition or provision of this Agreement, or any Exhibit hereto, or any other agreement, instrument or document of whatever form or nature contemplated hereby shall not be deemed a waiver of any right or remedy that the City or the Developer may have, and shall not be deemed a waiver of a subsequent default or nonperformance of such term, covenant, condition or provision. Amendment to Development Agreement Page 23 ADOPTED 0 0 12.05. Termination Prior to Commencement of Project. The Developer and the City acknowledge and agree that as of the Effective Date certain matters mutually agreed by the parties hereto to be essential to the successful development of the Boat Docking Facilities have not been satisfied or are subject to certain conditions, legal requirements or approvals beyond the control of any of the parties hereto or which cannot be definitely resolved under this Agreement, including, but not limited to, failure of a governmental authority to grant an approval required for development of the Boat Docking Facilities. In recognition of these events or conditions, the parties hereto mutually agree that, provided the appropriate or responsible party therefor diligently and in good faith seeks to the fullest extent of its capabilities to cause such event or condition to occur or be satisfied, the failure of the events or conditions listed in subsection 2. below to occur or be satisfied shall not constitute an event of default by any party under this Article 12, but may, upon the election of any party hereto, be the basis for a termination of this Agreement in accordance with this Section. 2. In addition to any other rights of termination provided elsewhere in this Agreement, prior to commencement of the Boat Docking Facilities, this Agreement may be terminated as provided in subsection 3. of this section by the City or the Developer after the occurrence of any of the following. events or conditions (except for subsection b. , in which event only the Developer may terminate this Agreement pursuant to this subsection 2.): a. The appropriate governmental authority (including the City in exercise of its governmental and regulatory authority and responsibility), upon petition by the Developer denies or fails to: issue the Permits, or issue any other approval necessary to commence construction of the Boat Docking Facilities, provided the Developer has proceeded diligently, expeditiously and in good faith to obtain such Permits or other necessary actions; b. A previously unknown site condition is subsequently discovered and that condition prevents successful development of the Boat Docking Facilities. 3. Upon the occurrence of an event described in subsection 2. or in the event that the Developer or the City, after diligently and in good faith to the fullest extent its capabilities, is unable to cause a condition precedent to its respective obligations to occur or be satisfied, then the Developer or the City may elect to terminate this Agreement by giving a notice to the other party hereto within thirty (30) days of the occurrence of such event or the determination of inability to cause a condition precedent to occur or be satisfied, stating its election to terminate this Agreement as a result thereof, in which case this Agreement shall then terminate. 4. In the event of a termination pursuant to this Section 12.05, neither the Developer nor the City shall be obligated or liable one to the other in any way, financially or otherwise, for any claim or matter arising from or as a result of this Agreement or any actions taken by the Developer and the City, or any of them, hereunder or contemplated hereby, and each party shall be responsible for its Amendment to Development Agreement Page 24 ADOPTED own costs, however, the provisions of Sections 9.01 and 10.01 shall apply and shall survive termination of this Agreement, the provisions of this Subsection 12.05.4 to the contrary notwithstanding. 12.06. Termination Certificate. In the event of a termination of this Agreement for any reason prior to the Expiration Date, each of the parties hereto do covenant and agree with each other to promptly execute a certificate prepared by the party electing to terminate this Agreement, which certificate shall expressly state that this Agreement has been terminated in accordance with its terms, is no longer of any force and effect except for those provisions hereof which expressly survive termination, that the rights, duties and obligations of the parties hereto have been terminated and released (subject to those surviving provisions hereof) and that the Boat Basin is no longer subject to any restrictions, limitations or encumbrances imposed by this Agreement. 2. The certificate described in Subsection 1. shall be prepared in a form suitable for recording and promptly after execution by all of the parties hereto shall be recorded in the public records of Pinellas County, Florida. ARTICLE 13. RIGHT TO CONTEST. 13.01. Right to Contest. Subject to the conditions set forth in Section 13.02 below, the City or the Developer each may, at its sole discretion and expense, after prior written notice to the other parties hereto, contest by appropriate action or proceeding conducted in good faith and with due diligence; the amount or validity or application, in whole or in part, of any lien, any payment of any taxes, assessments, impact fees or other public charges of a similar nature that may from time to time be levied upon or assessed by any appropriate governmental authority against the City, the Developer, the Boat Docking Facilities (or any part thereof), the Boat Basin or personal property thereon, and the revenues generated from the use or operation of any or all of the above, any other payment specifically identified in this Agreement, or compliance with any law, rule, regulation, or other such legal requirement. 13.02. Conditions. The right to contest any charge, payment or requirement pursuant to Section 13.01 is subject to the following: 1. Such proceeding shall suspend the execution or enforcement of such charge, payment or requirement; 2. Such proceeding will not create any risk of impairment of the construction, completion, operation or use of the Boat Docking Facilities or any part thereof, in any material respect, and no portion of the Boat Docking Facilities would be subject to any risk of being involuntarily sold, forfeited or lost or the construction, equipping, or completion of the Boat Docking Facilities or any part thereof be delayed or prohibited; 3. Such proceeding will not subject any other party to criminal liability or risk of material civil liability for failure to comply therewith, or involve risk of any material claim against such party; and Amendment to Development Agreement Page 25 ADOPTED 0 0 4. The party seeking the benefit of this Article shall have furnished to the other parties such security, if any, as may be required in such proceeding or as may be reasonably requested by the others, to protect the Boat Docking Facilities and any part thereof, and any interest of such parties hereunder. ARTICLE 14. ARBITRATION 14.01. Agreement to Arbitrate. Only as specifically provided in this Agreement and only if any judicial or administrative action or proceeding has not been commenced with regard to the same matter and, if so, the party hereto commencing such action has not dismissed it, any disagreement or dispute between the parties may be arbitrated in the manner set forth in this Article 14. All parties hereby agree such arbitration, once commenced, shall be the exclusive procedure for resolving such disagreement or dispute and agree to be bound by the result of any such arbitration proceeding unless all parties mutually agree to terminate such proceeding prior to decision. If any arbitration proceeding under this part adversely affects the performance of any party hereunder, then any time periods provided herein for such performance by that party shall be tolled during the pendency of the arbitration proceeding affecting such performance. 14.02. Appointment of Arbitrators. 1. a. Unless accelerated arbitration as provided in Section 14.08 hereof is invoked, any party invoking arbitration herewith shall, within five (5) days after giving notice of impasse in the dispute resolution process or upon following the expiration of the time period for such dispute resolution occurrence of the event permitting arbitration to be invoked, give written notice to that effect to the other parties, and shall in such notice appoint a disinterested person who is on the list of qualified arbitrators maintained by the American Arbitration Association or a disinterested person not on such list to whom an objection is not made by any other party hereto within five (5) days of receipt of the notice of such appointment as the arbitrator or, if more than one (1) arbitrator is to be appointed, as one of the arbitrators. b. Within ten (10) days after receipt of the notice described in paragraph (1), the other parties shall by written notice to the original party acknowledge that arbitration has been invoked as permitted by this Agreement, and shall either accept and approve the appointment of such individual set forth in the original notice as a sole arbitrator or shall appoint one (1) disinterested person per party of recognized competence in such field as an arbitrator. 2. a. If two (2) arbitrators are appointed pursuant to subsection a. above, the arbitrators thus appointed shall appoint a third disinterested person who is on the list of qualified arbitrators maintained by the American Arbitration Association, and such three (3) arbitrators shall as promptly as possible determine such matter. Amendment to Development Agreement Page 26 ADOPTED b. If the second arbitrator shall not have been appointed as provided in subsection a., the first arbitrator shall, after ten (10) days notice to the parties, proceed to determine such matter. C. If the two (2) arbitrators appointed by the parties pursuant to subsection a. shall be unable to agree within fifteen (15) days after the appointment of the second arbitrator upon the appointment of a third arbitrator, they shall give written notice of such failure to agree to the parties, and, if the parties then fail to agree upon the selection of such third arbitrator within fifteen (15) days thereafter, then within ten (10) days thereafter each of the parties upon written notice to the other parties hereto may request the appointment of a third arbitrator by the office in or for the State of Florida (or if more than one office, the office located closest to the City) of the American Arbitration Association (or any successor organization thereto), or, in its absence, refusal, failure or inability to act, request such appointment of such arbitrator by the United States District Court for the Middle District of Florida (which request shall be filed in the division of that court responsible for the geographic area including the City), or as otherwise provided in Chapter 682, Florida Statutes, known and referred to as the Florida Arbitration Act, as amended. 14.03. General Procedures. In any arbitration proceeding under this part, those parties appointing arbitrators shall each be fully entitled to present evidence and argument to the sole arbitrator or panel of arbitrators. The arbitrator or panel of arbitrators shall only interpret and apply the terms of this Agreement and may not change any such terms, or deprive any party to this Agreement of any right or remedy expressed or implied in this Agreement, or award any damages or other compensation to any party hereto. The arbitration proceedings shall follow the rules and procedures of the American Arbitration Association (or any successor organization thereto) unless specifically modified by this Agreement, or as then agreed to by the parties hereto. 14.04. Majority Rule. In any arbitration proceeding under this part, the determination of the majority of the panel of arbitrators, or of the sole arbitrator if only one (1) arbitrator is used, shall be conclusive upon the parties and judgment upon the same may be entered in any court having jurisdiction thereof. The arbitrator or panel. of arbitrators shall give written notice to the parties stating his or their determination within thirty (30) days after the conclusion of the hearing or final submission of all evidence or argument. 14.05. Replacement of Arbitrator. In the event of the failure, refusal or inability of any arbitrator to serve as such, promptly upon such determination being made by the affected arbitrator, the affected arbitrator shall give notice to the other two (2) arbitrators (if applicable) and to the parties hereto, and then a new arbitrator shall be promptly appointed as a replacement, which appointment shall be made by the party or the arbitrators who appointed the affected arbitrator in the same manner as provided for in the original appointment of the affected arbitrator in Section 14.02 hereof. 14.06. Decision of Arbitrators. If any decision reached by arbitration as provided in this part requires performance by the Developer, the Developer covenants and agrees to comply with any decision of the arbitrator(s) promptly after the date of receipt by the Amendment to Development Agreement Page 27 ADOPTED Developer of such decision, and to continue such performance to completion with due diligence and in good faith. 2. If any such decision requires performance by the City, the City covenants and agrees to comply promptly with any decision reached by arbitrators) promptly after the date of receipt by the City of such decision, and to continue such performance to completion with due diligence and in good faith. 3. Nothing in this part, nor in any arbitration decision rendered under this part, shall be construed to require any payment by the City to the Developer not otherwise provided for herein. 14.07. Expense of Arbitration. The expenses of any arbitration proceeding pursuant to this part shall be bome equally by the parties to such proceeding, provided, however, for the purpose of this Section 14.07, "expenses" shall include the fees and expenses of the arbitrators and the American Arbitration Association with respect to such proceeding, but shall not include attorneys' fees or expert witness fees, or any costs incurred by attorneys or expert witnesses, unless (and to the extent) agreed to by the parties to such proceeding, which in the absence of such Agreement shall be the responsibility of the party incurring such fees or costs. 14.08. Accelerated Arbitration. 1. a. If any of the parties to any arbitration proceeding under this part determines the matter for arbitration should be decided on an expedited basis, then after an initial election to invoke arbitration pursuant to Section 14.02 hereof has been made, either party to such proceeding may invoke accelerated arbitration by giving notice thereof to the other parties no later than three (3) days after arbitration has been initially invoked and the other parties do not object within three (3) days thereafter. b. Accelerated arbitration, for purposes of this Section 14.08, shall be accomplished by either party notifying the American Arbitration Association (or any successor organization thereto) that the parties have agreed to a single arbitrator, qualified to decide the matter for arbitration, to be appointed by the American Arbitration Association (or - any successor organization thereto) with the consent of the parties to such proceeding within three (3) days after receipt of the request and to decide such matter within five (5) days after such appointment. C. If an arbitrator is not so appointed with consent of the parties to the proceeding within three (3) days after the notice referred to in paragraph (2) is received by the American Arbitration Association, the accelerated proceeding under this Section 14.08 shall terminate and the procedures otherwise set forth in this Article 14 shall apply, unless the parties mutually agree to an extension of such time period. 2. The Developer and the City hereby agree to use such accelerated procedure only when reasonably necessary, to not contest the appointment of the arbitrator or his or her decision except as may be permitted by law, and that all other Amendment to Development Agreement Page 28 ADOPTED 0 0 provisions of this part, except as are in conflict with this Section 14.08, remain in effect and applicable to an accelerated arbitration proceeding. 14.09. Applicable Law. To the extent not inconsistent with this article, any arbitration proceeding under this article shall be governed by the provisions of Chapter 682, Florida Statutes, as amended, known and referred to as the Florida Arbitration Code. 14.10. Arbitration Proceedings and Records. Any arbitration hearing under this article shall be considered a meeting subject to Section 286.011, Florida Statutes, and shall be open to any member of the public. Unless otherwise rendered confidential pursuant to or by the operation of any applicable law or order (other than an order by a sole arbitrator or panel of arbitrators acting under this part), the record of such proceedings shall be a public record under Chapter 119, Florida Statutes. ARTICLE 15. UNAVOIDABLE DELAY. 15.01. Unavoidable Delay. 1. Any delay in performance of or inability to perform any obligation under this Agreement (other than an obligation to pay money) due to any event or condition described in paragraph (b) as an event of "Unavoidable Delay" shall be excused in the manner provided in this Section 15.01. 2. "Unavoidable Delay" means any of the following events or conditions or any combination thereof: acts of God, litigation which has the effect of precluding reasonable satisfaction of the obligations of this Agreement, acts of the public enemy, riot, insurrection, war, pestilence, archaeological excavations required by law, unavailability of materials after timely ordering of same, epidemics, quarantine restrictions, freight embargoes, fire, lightning, hurricanes, earthquakes, tornadoes, floods, extremely abnormal and excessively inclement weather (as indicated by the records of the local weather bureau for a five-year period preceding the Effective Date), strikes or labor disturbances, delays due to proceedings under Chapters 73 and 74, Florida Statutes, restoration in connection with any of the foregoing or any other cause beyond the reasonable control of the party performing the obligation in question, including, without limitation, such causes as may arise from the act of the other party to this Agreement, or acts of any governmental authority (except that acts of the City shall not constitute an Unavoidable Delay with respect to performance by the City). 3. An application by any party hereto (referred to in this paragraph (c) and in paragraph (d) as the "Applicant") for an extension of time pursuant to. this subsection must be in writing, must set forth in detail the reasons and causes of delay, and must be filed with the other party to this Agreement within seven (7) days following the occurrence of the event or condition causing the Unavoidable Delay or seven (7) days following the Applicant becoming aware (or with the exercise of reasonable diligence should have become aware) of such occurrence. 4. The Applicant shall be entitled to an extension of time for an Unavoidable Delay only for the number of days of delay due solely to the occurrence of the event or Amendment to Development Agreement Page 29 ADOPTED condition causing such Unavoidable Delay and only to the extent that any such occurrence actually delays that parry from proceeding with its rights, duties and obligations under this Agreement affected by such occurrence. ARTICLE 16. INTENTIONALLY DELETED. Amendment to Development Agreement Page 30 ADOPTED ARTICLE 17. FIRE OR OTHER CASUALTY; CONDEMNATION. 17.01. Loss or Damage to Project. Until the Termination Date or the Expiration Date, and without regard to the extent or availability of any insurance proceeds, however, subject to any condition or limitations as set forth in the Permits, the Developer shall have the right to commence and complete the reconstruction or repair of any loss or damage caused by fire or other casualty or by eminent domain (provided the City is not the condemning authority) to each and every part of the Boat Docking Facilities substantially the same condition as existed prior to the occurrence of such loss or damage, promptly after the City approves the Plans and Specifications for such reconstruction or repairs. 2. The City shall review the Plans and Specifications for such reconstruction or repairs as soon as possible after filing thereof by the Developer. The City agrees to approve the Plans and Specifications for such reconstruction or repairs if the reconstruction or repairs contemplated by such Plans and Specifications will restore the Boat Docking Facilities, or the damaged portion thereof, to substantially the same condition as existed prior to the occurrence of such loss or damage and if such Plans and Specifications conform to the applicable laws, ordinances, codes, and regulations in effect at the time of filing with the City of the plans and specifications for such reconstruction or repairs. 3. If Developer elects not to reconstruct or repair the Boat Docking Facilities as provided herein, Developer shall promptly remove all improvements constituting the Boat Docking Facilities in compliance with the requirements of the City and the Permits. 17.02. Partial Loss or Damage to Project. Until the Termination Date or the Expiration Date, any loss or damage by fire or other casualty or exercise of eminent domain to the Boat Docking Facilities, or any portion thereof, which does not render the Boat Docking Facilities unusable for the use contemplated by Section 2.03 of this Agreement, shall not operate to terminate this Agreement or to relieve or discharge the Developer from. the timely performance and fulfillment of the Developer's obligations pursuant to this Agreement, subject to an extension of time for an Unavoidable Delay. 17.03. Insurance Proceeds. Whenever the Boat Docking Facilities, or any part thereof, shall have been damaged or destroyed, the Developer shall promptly make proof of loss and shall proceed promptly to collect, or cause to be collected, all valid claims which may have arisen against insurers or others based upon such damage or destruction. Notwithstanding the foregoing, Developer shall not be obligated to obtain or provide casualty insurance as to the Boat Docking Facilities. 2. Subject to the rights of a Project Lender, the Developer agrees that all proceeds of property or casualty insurance received by the Developer as a result of such loss or damage shall be available and shall be used for payment of the costs of Amendment to Development Agreement Page 31 ADOPTED • C the reconstruction or repair of the Boat Docking Facilities to the extent necessary to repair or reconstruct the Boat Docking Facilities. 17.04. Notice of Loss or Damage to Boat Docking Facilities. The Developer shall promptly give the City written notice of any significant damage or destruction to the Boat Docking Facilities stating the date on which such damage or destruction occurred, the expectations of the Developer as to the effect of such damage or destruction on the use of the Boat Docking Facilities, and the proposed schedule, if any, for repair or reconstruction of the Boat Docking Facilities. 17.05. Condemnation of Boat Docking Facilities; Application of Proceeds. In the event that part, but not all, of the Boat Docking Facilities shall be taken by the exercise of the power of eminent domain at any time before the Expiration Date, subject to the rights of a Project Lender, the compensation awarded to and received by the Developer shall be applied first to the restoration of the Boat Docking Facilities, provided the Boat Docking Facilities can be restored and be commercially feasible for its intended use as contemplated by Section 2.03.1. of this Agreement after the taking, and, if not, can be retained by the Developer. ARTICLE 18. MISCELLANEOUS 18.01. Assignments. By the Developer. a. The Developer may sell, convey, assign or otherwise dispose of any or all of its right, title, interest and obligations in and to the Boat Docking Facilities, or any part thereof, only with the prior written consent of the City, which consent is hereby granted for assignment to a party to which Developer's rights are assigned pursuant to the Development Agreement, provided that such party (hereinafter referred to as the "assignee"), to the extent of the sale, conveyance, assignment or other disposition by the Developer to the assignee, shall be bound by the terms of this Agreement the-same as the Developer for such part of the Boat Docking Facilities as is subject to such sale, conveyance, assignment or other disposition. b. If the assignee of the Developer's right, title, interest and obligations in and to the Boat Docking Facilities, or any part thereof assumes all of the Developer's obligations hereunder, then the Developer shall be released from all such obligations hereunder which have been so assumed by the assignee, and the City agrees to execute an instrument evidencing such release, which shall be in recordable form. C. An assignment of the Boat Docking Facilities, any part thereof, by the Developer to any corporation, limited partnership, limited liability company, general partnership, or joint venture, in which the Developer (or an entity under common control with Developer) has either the controlling interest or through a joint venture or other arrangement shares equal management rights and maintains such controlling interest or equal management rights shall not be deemed an assignment or transfer subject to any restriction on or approvals of assignments or transfers Amendment to Development Agreement Page 32 ADOPTED • s. imposed by this Section 18.01, provided, however, that notice of such assignment shall be given by the Developer to the City not less than thirty (30) days prior to such assignment being effective and the assignee shall be bound by the terms of this Agreement to the same extent as would the Developer in the absence of such assignment. d. Notwithstanding the foregoing, so long as this Agreement is in effect, Developer shall have the right to sublease or license the use of individual Developer Boat Slips to owners, tenants and guests in accordance with Subsection 2.03.05 above without City's consent. 18.02. Successors and Assigns. The terms herein contained shall bind and inure to the benefit of the City, and its successors and assigns, and the Developer and its successors and assigns, except as may otherwise be specifically provided herein. 18.03. Notices. All notices, demands, requests for approvals or other communications given by either party to another shall be in writing, and shall be sent by registered or certified mail, postage prepaid, return receipt requested or by courier service, or by hand delivery to the office for each party indicated below and addressed as follows: To the Developer: THE SANDPEARL RESORT, LLC 2201 - 4'?' Street North Suite 200 St. Petersburg, FL 33704 Attn: J. Michael Cheezem with copies to: E. D. (Ed) Armstrong, III P.O. Box 1368 Clearwater, FL 33757 and Greene & Schermer 1301 - 6t" Avenue West Suite 400 Bradenton, FL 34205 Attn: Robert F. Greene, Esquire To the City: City of Clearwater 112 S. Osceola Avenue Clearwater, FL 33756 with copies to: Pam Akin, Esquire Clearwater City Attorney 112S. Osceola Avenue Clearwater, FL 33756 2. Notices given by courier service or by hand delivery shall be effective upon delivery and notices given by mail shall be effective upon receipt. Refusal by any person to accept delivery of any notice delivered to the office at the address indicated above (or as it may be changed) shall be deemed to have been an effective delivery as provided in this Section 18.03. The addresses to which notices are to be sent may be changed from time to time by written notice Amendment to Development Agreement Page 33 ADOPTED delivered to the other parties and such notices shall be effective upon receipt. Until notice of change of address is received as to any particular party hereto, all other parties may rely upon the last address given. 18.04. Applicable Law and Construction. The laws of the State of Florida shall govern the validity, performance and enforcement of this Agreement. This Agreement has been negotiated by the City and the Developer and the Agreement, including, without limitation, the Exhibits, shall not be deemed to have been prepared by the City or the Developer, but by all equally. 18.06. Venue; Submission to Jurisdiction. For purposes of any suit action, or other proceeding arising out of or relating to this Agreement, the parties hereto do acknowledge, consent, and agree that venue thereof is Pinellas County, Florida. 2. Each party to this Agreement hereby submits to the jurisdiction of the State of Florida, Pinellas County and the courts thereof and to the jurisdiction of the United States District Court for the Middle District of Florida, for the purposes of any suit, action, or other proceeding arising out of or relating to this Agreement and hereby agrees not to assert by way of a motion as a defense or otherwise that such action is brought in an inconvenient forum or that the venue of such action is improper or that the subject matter thereof may not be enforced in or by such courts. 3. If at any time during the term of this Agreement the Developer is not a resident of the State of Florida or has no office, employee, City or general partner thereof available for service of process as a resident of the State of Florida, or if any permitted assignee thereof shall be a foreign corporation, partnership or other entity or shall have no officer, employee, agent, or general partner available for service of process in the State of Florida, the Developer hereby designates the Secretary of State, State of Florida, its agent for the service of process in any court action between it and the City, or both, arising out of or relating to this Agreement and such service shall be made as provided by the laws of the State of Florida for service upon a non-resident; provided, however, that at the time of service on the Florida Secretary of State, a copy of such service shall be delivered to the Developer at the address for notices as provided in 18.03. 18.06. Estoppel Certificates. The Developer and the City shall at any time and from time to time, upon not less than ten (10) days prior notice by another party hereto, execute, acknowledge and deliver to the other parties a statement in recordable form certifying that this Agreement has not been modified and is in full force and effect (or if there have been modifications that the said Agreement as modified is in full force and effect and setting forth a notation of such modifications), and that to the knowledge of such party, neither it nor any other party is then in default hereof (or if another party is then in default hereof, stating the nature and details of such default), it being intended that any such statement delivered pursuant to this Section 18.06 may be relied upon by any prospective purchaser, mortgagee, successor, assignee of any mortgage or assignee of the respective interest in the Boat Docking Facilities, if any, of any party made in accordance with the provisions of this Agreement. Amendment to Development Agreement Page 34 ADOPTED 18.07. Complete Agreement; Amendments. This Agreement, and all the terms and provisions contained herein, including without limitation the Exhibits hereto, constitute the full and complete agreement between the parties hereto to the date hereof, and supersedes and controls over any and all prior agreements, understandings, representations, correspondence and statements, whether written or oral. 2. Any provision of this Agreement shall be read and applied in para materia with all other provisions hereof. 3. This Agreement cannot be changed or revised except by written amendment signed by all parties hereto. 18.08. Captions. The article and section headings and captions of this Agreement and the table of contents preceding this Agreement are for convenience and reference only and in no way define, limit, describe the scope or intent of this Agreement or any part thereof, or in any way affect this Agreement or construe any article, section, subsection, paragraph or provision hereof. 18.09. Holidays. It is hereby agreed and declared that whenever a notice or performance under the terms of this Agreement is to be made or given on a Saturday or Sunday or on a legal holiday observed in the City, it shall be postponed to the next following business day. 18.10. Exhibits. Each Exhibit referred to and attached to this Agreement is an essential part of this Agreement. The Exhibits and any amendments or revisions thereto, even if not physically attached hereto shall be treated as if they are part of this Agreement. 18.11. No Brokers. The City and the Developer hereby represent, agree and acknowledge that no real estate broker or other person is entitled to claim or to be paid a commission as a result of the execution and delivery of this Agreement, including any of the Exhibits. 18.12. Not an Agent of City. During the term of this Agreement, the Developer hereunder shall not be an agent of the City with respect to any and all services to be performed by the Developer (and any of its agents, assigns, or successors) with respect to the Boat Docking Facilities. 18.13. Memorandum of Agreement. The City and the Developer agree to execute, in recordable form, at the request of either party, a short form "Memorandum of Agreement" and agree, authorize and hereby direct such Memorandum to be recorded in the public records of Pinellas County, Florida, as soon as possible after execution thereof. The Developer shall pay the cost of such recording. 18.14. Public Purpose. The parties acknowledge and agree that this Agreement satisfies, fulfills and is pursuant to and for a public purpose and municipal purpose and is in the public interest, and is a proper exercise of the City's power and authority. 18.15. No General Obligation. In no event shall any obligation of the City under this Agreement be or constitute a general obligation or indebtedness of the City, a pledge of the ad valorem taxing power of the City or a general obligation or indebtedness of the Amendment to Development Agreement Page 35 ADOPTED 0 0 City within the meaning of the Constitution of the State of Florida or any other applicable laws, but shall be payable solely from legally available revenues and funds. Neither the Developer nor any other party under or beneficiary of this Agreement shall ever have the right to compel the exercise of the ad valorem taxing power of the City or any other governmental entity or taxation in any form on any real or personal property to pay the City's obligations or undertakings hereunder. 18.16. Other Requirements of State Law. Nothing in this Agreement shall be deemed to relieve either party from full compliance with any provision of State law which is applicable to any of the obligations or undertakings provided for in this Agreement. In the event that this Agreement omits an obligation to comply with any provision of State law in regard to any of the obligations or undertakings provided for in this Agreement, it is the intention of the parties that such applicable State law shall be deemed incorporated into this Agreement and made a part thereof. In the event that there is any conflict between the provisions of this Agreement and applicable State law, it is the intention of the parties that the Agreement shall be construed to incorporate such provisions of State law and that such provisions shall control. 18.17. Technical Amendments; Survey Corrections. In the event that due to minor inaccuracies contained herein or any Exhibit attached hereto or any other agreement contemplated hereby, or due to changes resulting from technical matters arising during the term of this Agreement, the parties agree that amendments to this Agreement required due to such inaccuracies, unforeseen events or circumstances which do not change the substance of this Agreement may be made and incorporated herein. The City Manager is authorized to approve such technical amendments on behalf of the City, respectively, and is authorized to execute any required instruments, to make and incorporate such amendment to this Agreement or any Exhibit attached hereto or any other agreement contemplated hereby. 18.18. Term; Expiration; Certificate. If not earlier terminated as provided in Section 12.05, this Agreement shall expire and no longer be of any force and effect on the fifth (5 h) anniversary of the Lease Commencement Date. The City shall have the unilateral option to renew this Agreement for five (5) successive renewal terms of five (5) years each by written notice to Developer. The date of expiration of this Agreement is the "Expiration Date". 2. If the City exercises all five (5) renewal options this Agreement shall expire on the date that is thirty (30) years after the Lease Commencement Date ("Final Expiration Date") and exclusive possession of the Boat Docking Facilities shall be relinquished by Developer to City together with ownership of all improvements within the Boat Docking Facilities (excluding the Slip Improvements) (Improvements"). At the request of the City, Developer shall execute and deliver to City a Bill of Sale as to all Improvements. In the event the City does not exercise one of the renewal options so that this Agreement expires prior to the Final Expiration Date, City agrees to pay to Developer an amount equal to the unamortized cost on the Expiration Date incurred by Developer in connection with the design, permitting and construction of all Improvements ("Project Costs") such unamortized Project Costs to be determined by amortizing the Project Costs on a straight line basis over the thirty (30) year period commencing on the Amendment to Development Agreement Page 36 ADOPTED 0 0 Lease Commencement Date. Upon expiration or termination of this Agreement, Developer may at its option and at its sole expense remove. the Slip Improvements. Costs relating to the Slip Improvements shall not be considered part of the Project Costs. The total Project Costs to be amortized as provided above shall not exceed $1,000,000.00. 3. Upon completion of the term of this Agreement including all renewal terms exercised by City, all parties hereto shall execute the Agreement Expiration Certificate. The Agreement Expiration Certificate shall constitute (and it shall be so provided in the certificate) a conclusive determination of satisfactory completion of all obligations hereunder and the expiration of this Agreement. 4. In the event of any dispute as to whether any party is required to execute the Agreement Expiration Certificate, the dispute shall be resolved by arbitration as provided in Article 14. 5. The Agreement Expiration Certificate shall be in such form as will enable it to be recorded in the public records of Pinellas County, Florida. Following execution by all of the parties hereto, the Agreement Expiration Certificate shall promptly be recorded by the Developer in the public records of Pinellas County, Florida and the Developer shall pay the cost of such recording. 18.19. Approvals Not Unreasonably Withheld. The parties hereto represent that it is their respective intent as of the Effective Date and do covenant and agree in the future that all approvals, consents, and reviews will be undertaken and completed as expeditiously as possible, in good faith, and will not be arbitrarily or unreasonably withheld, unless otherwise expressly authorized by the terms of this Agreement. 18.20 Severability. If any term, provision or condition contained in this Agreement shall, to any extent, be held invalid or unenforceable, the remainder of this Agreement, or the application of such term, provision or condition to persons or circumstances other than those in respect of which it is invalid or unenforceable, shall not be affected thereby, and each term, provision and condition of this Agreement shall be valid and enforceable to the fullest extent permitted by law. 18.21. Effective Date. The Effective Date shall be the date of the last signature to this Agreement. BALANCE OF PAGE INTENTIONALLY LEFT BLANK SIGNATURE PAGES FOLLOW Amendment to Development Agreement Page 37 ADOPTED IN WITNESS WHEREOF, the parties hereto have set their hands and their respective seals affixed as of this ? day of , 2007. Countersigned: Frank V. Hibbard Mayor A p ed as to Leslie K. Dougall i es Assistant City Att ey STATE OF FLORIDA ) COUNTY OF PINELLAS ) CITY OF CLEARWATER, FLORIDA William B. Horne II City Manager The foregoing instrument was acknowledged before me this /'q at day of i , 20.!?J, by FRANK V. HIBBARD, Mayor of the City of Clearwater, who is personally known to me. 0& at-ILL ?f . Print/Type Nam ' iANf E• 14A.,*V, Notary Public STATE OF FLORIDA ) COUNTY OF PINELLAS ) AW" DIANE E MANNI MY COMMISSION 0 DD526033 EXPIRES: Mar. 6.2010 t63 P"id.NotarySWIC&C«M The foregoing instrument was acknowledged before me this day of ?- , 20 b'Q by WILLIAM B. HORNE II, City Manager of the City of Clearwater, who is personally known to me. Print/Type Name: ?c3' Notary Public `? 4 ,? SANDRA HARMER Y My COMMISSION Y DD 278716 EXPIRES: January 4, 2008 9aidW 1MU Notary PubFc I1rMbrayll0?a Amendment to Development Agreement Page 38 ADOPTED THE SANDPEARL RESORT, LLC, a Florida limited liability company By: CBR Communities I, Ltd., a Florida limited partnership Managing Member By: JMC Communities of Clearwater V, Inc. a Floridp'-ckporatiV, General Partner By: Name: JTitle: STATE OF FLORIDA COUNTY OF PINELLAS The foregoing instrument was acknowledged before me this 4441'st- 15 dap--of 2007, J. Michael Cheezem, as CEO of JMC Communities of Clearwater Inc., a Florida corporation, the General Partner of CBR Communities I, Ltd., a Florida limited partnership, the Managing Member of The Sandpearl Resort, LLC, a Florida limited liability company, who is m-**" personally known to me or ? has produced a Florida driver's license or ? as identification. GMLM.C R SRI WtAM0 ? OD 507469 *? EXPIRE ; #404229 v2 - SandpearMmendment to Dev Agt S?. NOTARY PUBLIC Gail M. Cooper Printed Name: Commission No. r->n Sa-74 My Commission expires: o Amendment to Development Agreement Page 39 ADOPTED 0 a? s io ra s Ky W WA rRRtwri MW wam ae:? MRRS? a we ? M sirs n s w s wrr u?rs s; sRr? w• ? ? sR ss ? ? aor r, our ? fa rr aVA soils. 40 >rur?a s? Ris! M RINUM rie? we OL ?. . ? tRes>ZSR ? rRloi rQ !S tRO d ' f f MAMMM. op • s R? a go 10 ? t n -r . ? aiu?ra -?' APP9OKUM LRM!!'t sq (7 TWA= TAMM ? ? oocY Id 7\ 7M 9Tr 7L 77r 9? N +.la? ? ? ? ? ? J 71? ? f1? 1? 77CC '¢ T? ?C ? ? i /A7 ?A ?1 ? S. S $ S 3 S ? ? ? ? R' SOS -C -! 'C L' 7? ? ? 77R 77« ? >? RM.IW4 CLUU*N. t.R. F[.. t.S No.tiirf CLA" MCOMlIR/1Rr, q?yy Il?r w ?? s . ?R PL 4 Q?o7'??nfr Rlvvwe . Cdtler •T? S?MI? f -jo Sax rj R fs CTIw ?qc M -MW llt • ..¦. c N E rn Q c a) C Q a) a) 0 0 C 0 a) E c) a) o a as° 0 0 a a a astir ,.v +,? ? wta?r a r ? 1 ar ?s ps v AO ONO" 1¦M?IM¦1 ws? N S; It; PL a r - s aa>< an i! N ¦e /s ar Ar 44. . ADD=N& AUMMLY 1UCMIM CORM 70 A _ CVRTARI TO W DMnLUM DUMG crnocrms Ir r N ar M 'r v N as. N ova c? RAWAN >?I Mw= RBI= Iw : ??oa?utgc tam lfpMIA= TAM KF1: RM CLUSON. PA r?rn Tir ra CLARMI WA7ERUM1I F ?1L alas CYi+w'insrar Racr?otdar, CeTrtasr ; °?? „? .liANlE r =.lo' . >ucliav,: we. atsn ti, ° s as rsR R ra ,,,? , C 0 E a (D E CL 0 m (D 0 0 c 0 a? W E r d) ¢a¢ 0 0 EXHIBIT "B" CITY PROPERTY LEGAL DESCRIPTION Upland Property PID# 05129115100000133010100 BEG AT NW COR LOT 9 YACHT BASIN SUB RUN N'LY ALONG E R/W MANDALAY AVE 400 FT(S) TH FLY ALONG S R/W CLEARWATER ST 915 FT(S) TH SLY ALONG SEAWALL 195 FT(S) TH W'LY MEANDERING SHORELINE 700 FT(S) TH S'LY 100 FT(S) TH SW'LY ALONG SEAWALL 245 FT(S) TH S'LY 60 FT(S) TH W'LY 27 FT(S) TO POB CONT 4.13 AC(C) Amendment to Development Agreement Page 42 ADOPTED EXHIBIT "C" MAINTENANCE STANDARDS DAILY: • Inspect Boat Docking Facilities • Enforce use restrictions • Respond to emergency conditions • WEEKLY: • Trash removal (or more frequently as needed) • Lighting inspection and light bulb replacement • General maintenance inspection. Docking Facilities to be maintained in good condition and repair with all deteriorated or damaged materials and loose screws/nails replaced as needed. All repairs to be completed within ten (10) working days, however any repairs required for safe use of facilities shall be completed as soon as possible under the circumstances. QUARTERLY: • Thorough inspection of Docking Facilities with the City Harbor Master. All required repairs identified in quarterly inspection to be documented by written report and signed by a representative of Developer and City Harbor Master. All repairs to be completed in the time frame to be stated in the inspection report and Developer shall provide written certification upon completion. #404229 v2 - SandpearMmendment to Dev Agt Amendment to Development Agreement Page 43 ADOPTED Delk, Michael From: Home, William Sent: Thursday, September 06, 2007 12:00 PM To: City Council Cc: Senior Executive Team Subject: FW: Boat Slip Questions Councilmembers, Attached are staff responses to the Anne Garris questions. Since Ms Garris sent the questions to several of you if not all, I assume that VM Doran will pass the questions and responses to her electronically. We will provide a copy of this email at your seats prior to the council meeting tonight. Bill Bill Horne, ICMA-CM City Manager Clearwater, FL (727) 562-4046 -----Original Message----- From: Delk, Michael Sent: Thursday, September 06, 2007 9:19 AM To: Horne, William Cc: Clayton, Gina; Morris, William D.; Roseto, Joseph; Akin, Pam Subject: Boat Slip Questions Bill With Pam and Bill Morris' assistance, I have responses to most of Ms. Garris' questions. Questions 6, 7, 8, and portions of others, seem to be a combination of assertions and/or specifically directed to City Council. I have not attempted to address those. Please let me know if there are any staff issues we have not adequately responded to. michael Michael L. Delk, AICP Planning Director City of Clearwater, Florida myclearwater. com To the members of the Clearwater City Council RE: Boat docking facility at 69 Bay Esplanade From: Anne McKay Garris, citizen I have some questions about the Boat Docking Facility at 69 Bay Esplanade which is on the Thursday, September 6, agenda of the Clearwater City Council. 1. The land use designation of the property where the docks will be located is "Open Space Recreation". The city charter requires a referendum before the City issues a lease of Open Space Recreation property. Why has there not been a referendum? [Akin, Pam - The land use designation of the leased submerged land is Water not OSR. No uplands are being leased and no referendum is required.] 2. The City asked for bids before leasing the Pier Sixty pavilion, the South Beach Pavilion and other city owned lands. Was this Recreation Center parcel put out to bid? If not - why not? [Akin, Pam - There is no ordinance or charter requirement that the lease of submerged land (or other land) be bid out.] [Morris, Bill - The Marine and Aviation Department looked into the cost to build a similar facility several years ago at a cost of $1.5 Million dollars with the city doing the construction. It did not prove cost effective at that time. The Offer from the Sand Pearl was unsolicited at a time we would have liked to have more public slips and provided a no net cost to the city option. The plan has gone through multiple public meetings and reviews and redesigns to get a facility that will start out 1/3rd the city's, and eventually be completely the cities, with the option to buy up the remaining slips at anytime during the agreement term at the depreciated value. The offer had a responsible party building a high quality facility with a significant public benefit for beach access at no charge to the public for the city slips.] 3. The developer is paying only $5,000 a year rent for this very valuable property. Nothing else on Clearwater Beach is rented for $5,000 a year. Why did the City not ask for a better return on this land owned by the people of Clearwater? [Morris, Bill - The bottomland rent rates used are the rates the state charges for leasing state submerged land. We pay submerged land rent at the Sailing center and at pier 60 and are familiar with the rate structure.] 4. The City has a rule that docks may not extend beyond 25% of the waterway on which they are located. This dock has been approved to extend 69 feet of the waterway at one point. What is so special about this dock that it is allowed to do far more than the code allows? What about the rights of the opposite property owner who may, someday, want to go more than 25% of the waterway? What compelling reason did the developer give for going more than twice the distance allowed by isle City code? [Delk, Michael - The body of water is a basin and not a channel or open water. A minimum of 77 feet of navigational waterway at narrowest point will remain. Corps minimum is 50 feet.] [Morris, Bill - The Body of water is not a thoroughfare and as such is a fairway dead end much like a manmade marina. The normal standard for a fairway is 1.5 times the length of the maximum vessel moored in the designated slips. (Marinas and Small Craft Harbors, Tobiasson and Kollmeyer, Second Edition). The design was scaled back from its initial slightly more intrusive size but was also Placed further off shore to protect both sea grasses and coral on the north section of the basin submerged bottomland and provide enough light penetration.] 5. The code requires 12 parking places to service the 24 slips which the developer will sub-lease to its clients. The agreement says they don't have to provide the parking spaces. Theoretically, the slips will be rented only by people within walking distance of the slips, who, of course, will load all their gear on their shoulders and never, never use the public parking lot. 2 - City Recreation Center Marina The developer agrees to provide a shuttle so boat owners can use hotel parking. Did the hotel include 12 extra parking spaces in its site plan? Or will these parking spaces be "space available"? Will the shuttle be sitting there waiting for one of the 24 boats owners to decide to go for a spin, or will he have to wait impatiently for the shuttle to finish what its doing elsewhere? [Delk, Michael - The hotel met minimum parking requirements. The condominium met parking requirements. The hotel includes an extra 30 spaces to accommodate the accessory use of the Beach Club.] The sub-lease will forbid boat owners to use the public parking area which now serves the recreation center, the swimming pool and parking for beach goers. How is this requirement going to be enforced? If boat owners are found in violation, will they lose their lease? Pay a fine to the City? Get a slap on the wrist? Who will enforce the no-parking in city parking lot requirement? The hotel? The city? Does anyone really believe that 42 boat slips will not impact the availability of parking to the rest of the facilities? [Morris, Bill - The City of Clearwater parking enforcement will handle consistent with that provided at other City marina facilities] [Delk, Michael - I believe the Police Chief addressed enforcement issues during the work session. As he indicated, the CPD has the enforcement authority to investigate and engage inappropriate or criminal behavior emanating from the facility or vessels which may be occupying the slips. ] [Delk, Michael - Administrative staff believes that parking for the dock facility is adequately addressed given the purpose and intent of its establishment.] 6. If the City Attorney tells you.......... as she has done in other cases........ that you do not really have the power to say no to this project. Then why is it on the agenda? And why, as the people's representatives, can you not make this decision? If you don't make it, who does? And who gave them that right if they are not elected? 7. There are so many reasons why it is not in the best interests of the people of Clearwater for you to approve this project. I ask you to at least postpone it until you can give the owners of the property some answers to these, and other questions about the project. 8. If the developer threatens that, if you deny this, they will go ahead with a former, much bigger project. Let them. The larger project is less likely to pass the County and State review. Respectfully submitted by Anne McKay Garris, 38 Acacia Street, Clearwater, Florida 33767 446- 4410 Michael L. Delk, AICP Planning Director City of Clearwater, Florida myclearwater.com ? • • Page 1 of 4 Wells, Wayne From: Delk, Michael Sent: Wednesday, September 05, 2007 1:39 PM To: Horne, William; Akin, Pam Cc: Morris, William D.; Irwin, Rod; Wells, Wayne; Roseto, Joseph Subject: RE: Clearwater Beach Recreation Center Boat Slips I will be handling this tomorrow evening so please forward your comments/responses to me. I will prepare a unified reply to Bill. Thank you. Michael L. Delk, AICP Planning Director City of Clearwater, Florida myclearwater.com -----Original Message----- From: Horne, William Sent: Wednesday, September 05, 2007 10:10 AM To: Akin, Pam Cc: Morris, William D.; Irwin, Rod; Delk, Michael; Wells, Wayne; Roseto, Joseph; City Council Subject: RE: Clearwater Beach Recreation Center Boat Slips Pam, Thanks. Wayne/Michael/Bill Can you all coordinate on answering these questions? Wayne should be lead since he will present the item at the council meeting. The easiest way to respond is to provide Wayne with the information so he can insert the answer after the question. Need to have answers before the council meeting. Thanks. Bill Bill Horne, ICMA-CM City Manager Clearwater, FL (727) 562-4046 -----Original Message----- From: Akin, Pam Sent: Wednesday, September 05, 2007 9:49 AM 9/9/2007 f • • Page 2 of 4 To: Horne, William Subject: FW: Clearwater Beach Recreation Center Boat Slips Bill, from Frank, You may have already assigned this out. I will answer no. 1. Pamela Akin, City Attorney 112 5. Osceola Ave Clearwater, Florida 33758 727 562-4010 -----Original Message----- From: Hibbard, Frank Sent: Wednesday, September 05, 2007 8:58 AM To: Akin, Pam Subject: FW: Clearwater Beach Recreation Center Boat Slips Can you have these answered by staff, please. Thanks! -----Original Message----- From: Anne Garris [mailto:anneberle@mindspring.com] Sent: Tuesday, September 04, 2007 4:54 PM To: Doran, John Cc: Paul Gibson; George Cretekos; Hibbard, Frank Subject: Clearwater Beach Recreation Center Boat Slips To the members of the Clearwater City Council RE: Boat docking facility at 69 Bay Esplanade From: Anne McKay Garris, citizen I have some questions about the Boat Docking Facility at 69 Bay Esplanade which is on the Thursday, September 6, agenda of the Clearwater City Council. 1. The land use designation of the property where the docks will be located is "Open Space Recreation". The city charter requires a referendum before the City issues a lease of Open Space Recreation property. Why has there not been a referendum? 2. The City asked for bids before leasing the Pier Sixty pavilion, the South Beach Pavilion and other city owned lands. Was this Recreation Center parcel put out to bid? If not -- why not? 3. The developer is paying only $5,000 a year rent for this very valuable property. Nothing else on Clearwater Beach is rented for $5,000 a year. Why did the City not ask for a better return on this land owned by the people of 9/9/2007 t • • Page 3 of 4 Clearwater? 4. The City has a rule that docks may not extend beyond 25% of the waterway on which they are located. This dock has been approved to extend 69 feet of the waterway at one point. What is so special about this dock that it is allowed to do far more than the code allows? What about the rights of the opposite property owner who may, someday, want to go more than 25% of the waterway? What compelling reason did the developer give for going more than twice the distance allowed by the City code? 5. The code requires 12 parking places to service the 24 slips which the developer will sub-lease to its clients. The agreement says they don't have to provide the parking spaces. Theoretically, the slips will be rented only by people within walking distance of the slips, who, of course, will load all their gear on their shoulders and never, never use the public parking lot. 2 - City Recreation Center Marina The developer agrees to provide a shuttle so boat owners can use hotel parking. Did the hotel include 12 extra parking spaces in its site plan? Or will these parking spaces be "space available"? Will the shuttle be sitting there waiting for one of the 24 boats owners to decide to go for a spin, or will he have to wait impatiently for the shuttle to finish what its doing elsewhere? The sub-lease will forbid boat owners to use the public parking area which now serves the recreation center, the swimming pool and parking for beach goers. How is this requirement going to be enforced? If boat owners are found in violation, will they lose their lease? Pay a fine to the City? Get a slap on the wrist? Who will enforce the no-parking in city parking lot requirement? The hotel? The city? Does anyone really believe that 42 boat slips will not impact the availability of parking to the rest of the facilities? 6. If the City Attorney tells you.......... as she has done in other cases........ that you do not really have the power to say no to this project. Then why is it on the agenda? And why, as the people's representatives, can you not make this decision? If you don't make it, who does? And who gave them that right if they are not elected? 9/9/2007 • • Page 4 of 4 7. There are so many reasons why it is not in the best interests of the people of Clearwater for you to approve this project. I ask you to at least postpone it until you can give the owners of the property some answers to these, and other questions about the project. 8. If the developer threatens that, if you deny this, they will go ahead with a former, much bigger project. Let them. The larger project is less likely to pass the County and State review. Respectfully sumitted by Anne McKay Garris, 38 Acacia Street, Clearwater, Florida 33767 446-4410 9/9/2007 Page 1 of 4 W Wells, Wayne From: Morris, William D. Sent: Wednesday, September 05, 2007 12:49 PM To: Irwin, Rod Cc: Delk, Michael; Wells, Wayne; Roseto, Joseph Subject: RE: Clearwater Beach Recreation Center Boat Slips Rod/Joe, for information only, Michael, Wayne; I can give some input on several, not sure if it is enough to fully answer the question. I am heading over to moffit for an appointment and can add more to this when I get back if needed. 1. Pam says she has 2. The Marine and Aviation Department looked into the cost to build a similar facility several years ago at a cost of $1.5 Million dollars with the city doing the construction. It did not prove cost effective at that time. The Offer from the Sand Pearl was unsolicited at a time we would have liked to have more public slips and provided a no net cost to the city option. The plan has gone through multiple public meetings and reviews and redesigns to get a facility that will start out 1/3rd the cities, and eventually be completely the cities, with the option to buy up the remaining slips at anytime during the agreement term at the depreciated value. The offer had a responsible party building a high quality facility with a significant public benefit for beach access at no charge to the public for the city slips. A competitive bid would have brought in a variety of lesser quality designs focused on making a profit for the holder of the agreement and minimizing where possible the public benefit. 3. The bottomland rent rates used are the rates the state charges for leasing state submerged land. We pay submerged land rent at the Sailing center and at pier 60 and are familiar with the rate structure. 4. The Body of water is not a thoroughfare and as such is a fairway deadened much like a manmade marina. The normal standard for a fairway is 1.5 times the length of the maximum vessel moored in the designated slips. (Marinas and Small Craft Harbors, Tobiasson and Kollmeyer, Second Edition). The design was scaled back from its initial slightly more intrusive size but was also placed further off shore to protect both sea grasses and coral on the north section of the basin submerged bottom land and provide enough light penetration. Those are the ones I can contribute to, if you need more holler, if you want less , feel free to edit, Bill Morris -----Original Message----- From: Horne, William Sent: Wednesday, September 05, 2007 10:10 AM To: Akin, Pam Cc: Morris, William D.; Irwin, Rod; Delk, Michael; Wells, Wayne; Roseto, Joseph; City Council Subject: RE: Clearwater Beach Recreation Center Boat Slips Pam, Thanks. Wayne/Michael/Bill Can you all coordinate on answering these questions? Wayne should be lead 9/9/2007 Page 2 of 4 since he will present the item at the council meeting. The easiest way to respond is to provide Wayne with the information so he can insert the answer after the question. Need to have answers before the council meeting. Thanks. Bill Bill Horne, ICMA-CM City Manager Clearwater, FL (727) 562-4046 -----Original Message----- From: Akin, Pam Sent: Wednesday, September 05, 2007 9:49 AM To: Horne, William Subject: FW: Clearwater Beach Recreation Center Boat Slips Bill, from Frank, You may have already assigned this out. I will answer no. 1. Pamela Akin, City Attorney 112 5. Osceola Ave Clearwater, Florida 33758 727 562-4010 -----Original Message----- From: Hibbard, Frank Sent: Wednesday, September 05, 2007 8:58 AM To: Akin, Pam Subject: FW: Clearwater Beach Recreation Center Boat Slips Can you have these answered by staff, please. Thanks! -----Original Message----- From: Anne Garris [mailto:anneberle@mindspring.com] Sent: Tuesday, September 04, 2007 4:54 PM To: Doran, John Cc: Paul Gibson; George Cretekos; Hibbard, Frank Subject: Clearwater Beach Recreation Center Boat Slips To the members of the Clearwater City Council RE: Boat docking facility at 69 Bay Esplanade From: Anne McKay Garris, citizen I have some questions about the Boat Docking Facility at 69 Bay Esplanade 9/9/2007 .1 U E Page 3 of 4 which is on the Thursday, September 6, agenda of the Clearwater City Council. 1. The land use designation of the property where the docks will be located is "Open Space Recreation". The city charter requires a referendum before the City issues a lease of Open Space Recreation property. Why has there not been a referendum? 2. The City asked for bids before leasing the Pier Sixty pavilion, the South Beach Pavilion and other city owned lands. Was this Recreation Center parcel put out to bid? If not -- why not? 3. The developer is paying only $5,000 a year rent for this very valuable property. Nothing else on Clearwater Beach is rented for $5,000 a year. Why did the City not ask for a better return on this land owned by the people of Clearwater? 4. The City has a rule that docks may not extend beyond 25% of the waterway on which they are located. This dock has been approved to extend 69 feet of the waterway at one point. What is so special about this dock that it is allowed to do far more than the code allows? What about the rights of the opposite property owner who may, someday, want to go more than 25% of the waterway? What compelling reason did the developer give for going more than twice the distance allowed by the City code? 5. The code requires 12 parking places to service the 24 slips which the developer will sub-lease to its clients. The agreement says they don't have to provide the parking spaces. Theoretically, the slips will be rented only by people within walking distance of the slips, who, of course, will load all their gear on their shoulders and never, never use the public parking lot. 2 - City Recreation Center Marina The developer agrees to provide a shuttle so boat owners can use hotel parking. Did the hotel include 12 extra parking spaces in its site plan? Or will these parking spaces be "space available"? Will the shuttle be sitting there waiting for one of the 24 boats owners to decide to go for a spin, or will he have to wait impatiently for the shuttle to finish what its doing elsewhere? 9/9/2007 Page 4 of 4 The sub-lease will forbid boat owners to use the public parking area which now serves the recreation center, the swimming pool and parking for beach goers. How is this requirement going to be enforced? If boat owners are found in violation, will they lose their lease? Pay a fine to the City? Get a slap on the wrist? Who will enforce the no-parking in city parking lot requirement? The hotel? The city? Does anyone really believe that 42 boat slips will not impact the availability of parking to the rest of the facilities? 6. If the City Attorney tells you.......... as she has done in other cases........ that you do not really have the power to say no to this project. Then why is it on the agenda? And why, as the people's representatives, can you not make this decision? If you don't make it, who does? And who gave them that right if they are not elected? 7. There are so many reasons why it is not in the best interests of the people of Clearwater for you to approve this project. I ask you to at least postpone it until you can give the owners of the property some answers to these, and other questions about the project. 8. If the developer threatens that, if you deny this, they will go ahead with a former, much bigger project. Let them. The larger project is less likely to pass the County and State review. Respectfully sumitted by Anne McKay Garris, 38 Acacia Street, Clearwater, Florida 33767 446-4410 9/9/2007 • r Wells, Wayne From: Wells, Wayne Sent: Tuesday, August 28, 2007 11:50 AM To: Castelli, Joelle Wiley Cc: Delk, Michael; Clayton, Gina; Thompson, Neil; Akin, Pam; Dougall-Sides, Leslie; Morris, William D. Subject: Anne Garris, Clearwater Gazette - Sandpearl Docks Anne Garris came in this morning working on a story regarding the Sandpearl docks, to be constructed in the submerged lands adjacent to the Beach Recreation Center (69 Bay Esplanade). An Amended Development Agreement is scheduled for City Council review and decision on September 6, 2007. Anne asked a lot of technical issues with the dock construction, which were covered in the Staff Report and Development Order for the Flexible Development application, approved by the CDB on July 17, 2007 (Case No. FLD2007-02003). Some questions she asked were more appropriate to be answered by Pam Akin or Leslie Dougall-Sides, where I directed her to ask such questions. I gave her copies of Staff Reports, Development Order and drawings of the proposed docks. X1 .., ...w..,_ ?_rA R. . -- -- -- - l Back x i Address Favorites j Add._. ? Organize.' J Dell ; Bid Required? Flone Bid! tlLfmber: Funny S:_ift o her Bid J' Bid ExcetFons: NOYB t I ( '? G oog e L ) Links _j MEDIA Outside C7 Sports iLf) State Corporations -d 1 l 141 Go Links » _ =rct:ive: tterns, Ui? rls baynewsg.com - Be Better Guys BEG, _J Bill Currie Ford Tama r j College of Design C _j Contests at Tampa Certer Stage Costu.J i Dave's Garden Welc A f - S d Date Recc- ecl - v... Date AIis'.', e er1 .t' 11.1E.o"ss r. 0 rj uiaU _com pee =I Di0onary.corn € FAPA - Florida Chap' T HGT ?r Decorating, History d I Hooters presents Th p -ot,,vvfiImintlorid_ -- - - - ----- _ 1 Local intranet _ '? 71:1 i APB 'Start' Inbox - i'W9icroso? Tiderrrark Adva_. LE rrrails DocUnientl -,_--' 2 Internet E__ C: C Wells, Wayne From: Wells, Wayne Sent: Monday, August 20, 2007 10:48 AM To: Jayne Sears (E-mail) Cc: Dewitt, Gina Subject: DVA2007-00002, Sandpearl Development Agreement Jayne - Please submit two signed copies of the cleaned up version of the proposed amended Development Agreement to Gina DeWitt in our City Attorney's office no later than noon on Tuesday, September 4, 2007, for signature by the City. Wayne 0 0 Wells, Wayne Page 1 of 1 From: Wells, Wayne Sent: Wednesday, July 25, 2007 10:01 AM To: 'cart@clearwatergazette.com' Cc: Castelli, Joelle Wiley; Delk, Michael Subject: Sandpearl Revised Amended Development Agreement Carl - Too quick on the send button. I forgot to attach the document. Now I am. Wayne -----Original Message----- From: Wells, Wayne Sent: Wednesday, July 25, 2007 9:59 AM To: 'carl@clearwatergazette.com' Cc: Castelli, Joelle Wiley; Delk, Michael Subject: Sandpearl Revised Amended Development Agreement Carl - Attached is the revised Amended Development Agreement sent to us late yesterday (revision on Page 10). Wayne -----Original Message----- From: Wells, Wayne Sent: Tuesday, July 24, 2007 1:06 PM To: 'Carl Wagenfohr'; Castelli, Joelle Wiley Cc: Delk, Michael Subject: RE: Sandpearl Development agreement Carl - It was going to be scheduled for the August 14th Council meeting, but is being pushed back by the applicant to the September 6th Council meeting. There is also going to be a small revision to the Agreement defining low profile pilings and tie poles. As soon as I get the revised Agreement, I will forward on to you. Wayne -----Original Message----- From: Carl Wagenfohr [mailto:carl@clearwatergazette.com] Sent: Tuesday, July 24, 2007 12:35 PM To: Castelli, Joelle Wiley Cc: Wells, Wayne Subject: Sandpearl Development agreement At what Council meeting will approval for the revised Sandpearl Development Agreement (dock revision) be sought? Carl 7/25/2007 • Wells, Wayne From: Morris, William D. Sent: Friday, July 20, 2007 1:23 PM To: Wells, Wayne; 'Jayne Sears (E-mail)' Cc: Delk, Michael; Akin, Pam; Clayton, Gina; Dougall-Sides, Leslie Subject: RE: DVA2007-00002, Sandpearl Development Agreement Wayne, I strongly agree and have worked with Frank Dame who is on the CDB before on boat lift issues when he was on the Marine Advisory board. He has compiled a list of sources, researched them and in his comments strongly suggests the 4 foot height limit as to define "low profile. At the Marine Advisory Board last week, (no minutes yet) we discussed this and I presented the docks for discussion of this issue. At that meeting, mid chest was the consensus which is approximately 4 feet. There is one company that makes a No Profile lift nut it is expensive and would not elevate the dock above the dock height. They are expensive and would not help during storm surges. All the way around, 4 feet seems to be the best compromise and allows for an 8 foot storm surge if the dock is 4 feet above mean high water. Frank Dames message to me with the references docks listed. we would not be limiting people to one vendor or just a few there are many. Thanks, Bill M -----Original Message----- From: Frank Dame (mailto:fdame@yahoo.com] Sent: Tuesday, July 17, 2007 6:24 PM To: Morris, William D. Subject: Low Profile Boat Lifts Bill Here are 16 links to lift manufacturers that could most likely accommodate "Low Profile" boat lift specifications not to exceed 48" in height above the deck: http://www.eastcoastboatlifts.com/lift-lpl.htm http://www.noprofileboatlifts.com/?gclid=COTAyPnFr40CFQ5YgAodbGn-tQ (this is the manufacturer you had identified) http://www.decoboatlift.com/concept.html (a local company with low profile lifts) http://www.magnumlift.com/ http://www.lunmar.com/piling-mount-lift.htm (some of these are not low profile, but. the ones that are only need 48" above the deck). http://www.boatliftdistributors.com/boat-lifts-c-2l.html (check out their beamless boat lifts that could be placed on a piling 48" above the deck) http://www.goldenboatlifts.com/lowprofile.htm http://www.boatliftwarehouse.com/boat_lifts/4_piling_lifts/ (note that any of these lifts could be 48" high and considered "Low Profile") .http://www.theboatliftcompany.com/faq.htm (Note the comment on this company's FAQ section that "The size of the slip might limit your maximum boat size, but almost any size boat can be lifted with a custom designed low-profile boat lift). http://www.umlc.com/fo_paws.html http://www.sunstreamcorp.com/ssc/sunlift.html 1 • http://www.davitmaster.com/5-cradleLifts/cradleLifts.asp http://www.boat-lift.com/boat_dock_lift.html http://www.dolphinboatlifts.com/ http://www.ablboatlifts.com/vertical-silhouette.html http://www.aqua-lift.com/boat-lift-photos.htm (interesting concept with no pilings - May not be practical in salt water) The first company I provided for you (East Coast Boat Lifts) states the lift can be mounted on pilings from 36" to 48". Given that a fixed dock will usually be approximately 4' above mean high tide, if a "Low Profile" lift is defined as being no more than 48" above the deck, this would allow a boat owner to lift his boat 4' above the dock and accommodate an 8' tidal surge prior to being affected by the surge. If we are anticipating tidal surges beyond that, the owner probably will want to take his boat out of the water or anchor it in a sheltered area to handle the surge. Low profile lifts and would improve the visual views of the water when the boat was not on the lift. Over the past few years, I have heard many complaints about high lifts in Island Estates. Maybe using "low profile" lifts in the future would be a good thing to mitigate this type of complaint. I would suggest the city define a "low profile" lift as one that does not extend higher than 48" above the deck. Please let me know if you need further assistance. Best regards, Frank Frank L. Dame -----Original Message----- From: Wells, Wayne Sent: Friday, July 20, 2007 12:14 PM To: Jayne Sears (E-mail) Cc: Delk, Michael; Akin, Pam; Morris, William D.; Clayton, Gina; Dougall-Sides, Leslie Subject: DVA2007-00002, Sandpearl Development Agreement Jayne - Based on the questions and "non-answers" at the CDB meeting regarding the definition of "low profile pilings and/or tie poles" to be used in the Boat Docking Facilities, I would strongly suggest that such a definition be incorporated into the amended Development Agreement before it goes to City Council. Additionally, based on the testimony at the CDB meeting, the Planning Department suggests that such definition be limited to four feet (rather than five feet). I believe this question will arise again at the City Council meeting, so we ought to deal with it now proactively (now that we know there is a question) rather than at the meeting on August 14th. Wayne 2 Y I I NA CDB Meeting Date: July 17, 2007 ? Case Number: DVA2007-00002 Agenda Item: El Owner/Applicant: The Sandpearl Resort, LLC and The Residences at Sandpearl Resort, LLC Representative: E. D. D. Armstrong Hl, Esq., Johnson, Pope, Bokor, Ruppel & Burns, LLPEsq., Johnson, Pope, Bokor, Ruppel & Burns, LLP Addresses: 470 and 500 Mandalay Avenue and 11470 and 500 Mandalay Avenue and 11 Baont StreetStreet CITY OF CLEARWATER PLANNING DEPARTMENT STAFF REPORT GENERAL INFORMATION: REQUEST: Review of, and recommendation to the City Council, of an amendment to an adopted Development Agreement between The Sandpearl Resort, LLC (formerly known as CBR Development I, LLC) and The Residences at Sandpearl Resort, LLC (formerly known as CBR Development II, LLC) and the City of Clearwater (previously DVA2004-00005 approved by City Council on January 20, 2005) relating to the provision of a 42-slip marina dock in conjunction with the Sandpearl Resort project (39 wet slips and three day slips, of which 15 slips will be for public usage and 27 slips will be leased to the Sandpearl Resort) in the submerged lands adjacent to the Clearwater Beach Recreation Center (69 Bay Esplanade). EXISTING ZONING/ Tourist (T) District; Resort Facilities High (RFH) Category LAND USE: - PROPERTY SIZE: 9.77 total acres (hotel site 7.36 acres [3.69 acres zoned Tourist District; 3.67 acres zoned Open Space/Recreation District]; residential site 2.41 acres) PROPERTY USE: Current Use: Mixed use (253 overnight accommodation units at 68.56 units/acre on hotel portion of site and a height of 95 feet, 119 attached dwellings at 49.38 units/acre on residential/retail portion of site and a height of 150 feet and 11,000 square feet of retail sales and services at a FAR of 0.105 on residential/retail portion of site). Proposed Use: Mixed use (253 overnight accommodation units at 68.56 units/acre on hotel portion of site and a height of 95 feet, 119 attached dwellings at 49.38 units/acre on residential/retail portion of site and a height of 150 feet and 11,000 square feet of retail sales and services at a FAR of 0.105 on residential/retail portion of site). ADJACENT ZONING/ North: LAND USES: sales East: restaur South: West: Tourist District; Restaurant, overnight accommodations and retail Tourist and High Density Residential Districts; Retail sales, ants and attached dwellings Tourist District; Restaurant, retail sales and attached dwellings Open Space/Recreation District; Beach and Gulf of Mexico Community Development Board - July 17, 2007 DVA2004-00002A - Page 1 of 4 0 0 CHARACTER OF THE IMMEDIATE VICINITY: The surrounding area includes tourist-dominated uses, including overnight accommodations, restaurants, retail sales and services and attached dwellings. ANALYSIS: Site Location and Existing Conditions: The existing properties total 9.77 acres (hotel site 7.36 acres [3.69 acres zoned Tourist District; 3.67 acres zoned Open Space/Recreation District; residential site 2.41 acres) located on the west side of Mandalay Avenue between San Marco and Ambler Streets. The properties previously were developed with overnight accommodation uses and retail sales uses. These previous uses were demolished and a new hotel with 253 rooms is nearing completion north of Baymont Street and 119 attached dwellings and 11,000 square feet of retail sales floor area are under construction south of Baymont Street. The surrounding area is intensely developed with restaurants, motels, retail sales and services and attached dwellings. On December 14, 2004, the Community Development Board approved Flexible Development Case No. FLD2004-09068 for this property to construct a mixed use (253 overnight accommodation units at 68.56 units/acre on hotel portion of site and a height of 95 feet, 119 attached dwellings at 49.38 units/acre on residential/retail portion of site and a height of 150 feet and 11,000 square feet of retail sales and services at a FAR of 0.105 on residential/retail portion of site). The City Commission approved a companion Development Agreement on January 20, 2005 (Case No. DVA2004-00005). These development proposal approved included 141 rooms from the Density Pool, the hotel at a height of 95 feet, two residential towers at heights of 150 feet and 48.5 feet and the vacation of Beach Drive. The Development Agreement also provided for the establishment of docks at the Clearwater Beach Recreation Center site for a maximum of 57 slips, of which 19 slips were to be public slips and 38 slips to be leased to the Sandpearl project. Proposal: The proposed amended Development Agreement amends the previously approved 2005 Development Agreement to replace in its entirety Section 5.03(10) relating to the Boat Docking Facilities, replaces Exhibit N (boat docking facilities site plan) and replaces its entirety Exhibit N-1 relating to the boat docking facilities agreement. The reason for this amended Development Agreement is it was determined that the City owns fee simple the submerged land in the boat basin where the docks are proposed. As a result of this change in circumstances, revisions to the agreement in Exhibit N-1 were necessary. Additionally, due to the actual design of the boat docks (see FLD2007-02003 also on the July 17, 2007, CDB agenda), the site plan is being revised. The actual number of slips to be constructed has been reduced to a total of 42 slips,. of which 15 slips are to be public slips and 27 slips to be leased to the Sandpearl project. The amended Development Agreement sets forth the following main provisions: Revises and replaces Section 5.03(10) of the Development Agreement, due to the change in ownership of the submerged land where the boat docks are proposed. Previously, the Development Agreement assumed State ownership of the submerged land, requiring a sovereignty submerged land lease from the State of Florida. Both the adopted Development Agreement and the proposed amendment provides for: 1. the developer to pursue, at the developer's expense, permits to construct the docks; 2. an agreement between the City and the developer to permit the developer to construct the boat docks, at the developer's sole expense, and lease a revised number of slips (27) from the City, with the remaining revised number of slips (15) to be utilized by the City. These number of slips to be leased to the developer is a maximum 67% of the total number of slips; 3. the developer to pay all maintenance and repair costs; Community Development Board - July 17, 2007 DVA2004-00002A - Page 2 of 4 • • 4. the use of the boat slips leased by the developer be limited to owners, tenants and guests of the Sandpearl project; 5. the developer to provide a shuttle service from Sandpearl to the boat docks; and 6. the assignment of leases for the boat slips to project owners. The amended Development Agreement includes the following: 1. the use of the boat slips leased by the developer be expanded to include Beach Club members and other owners and tenants that own or lease residences within the geographical area bordered on the west by the Gulf of Mexico, on the east by Clearwater Bay, on the north by Rockaway Street and on the south by Papaya Street; and 2. the assignment of leases for the boat slips to also include Beach Club members and other owners and tenants that own or lease residences within the geographical area bordered on the west by the Gulf of Mexico, on the east by Clearwater Bay, on the north by Rockaway Street and on the south by Papaya Street. Replaces Exhibit N (boat docking facilities site plan), based on the site plan submitted under FLD2007-02003, which reduces the total number of slips from 57 to 42 slips and reduces the actual percentage of slips leased to Sandpearl to 64.3 percent (27 slips). • Replaces Exhibit N-1, which provides for the lease agreement provisions, including the following (many provisions are the same or are similar under both the adopted Development Agreement and the proposed amended Development Agreement): 1, the scope of the project with the number of slips to be constructed; 2. the hours of operation of the City controlled slips (5 am to midnight); 3. the ability to operate a fireboat or other boats operated by the City or governmental agencies for public purposes; 4. the ability to install gates or other access controls; 5. the restriction to utilize only low profile pilings and/or tie poles, the disallowance of any covered boat slips, the disallowance of any boat lifts in 40-foot or larger slips, a restriction as to the number of slips allowing boat lifts (no more than 13 or 50 percent of the slips if less than 27 slips) and the disallowance of refueling of any vessels; 6. the ability to install water and electric lines to both developer controlled and City slips, including lighting; 7. the developer to provide and pay for all maintenance and repair costs; 8. the use of the developer boats slips by owners, tenants and guests of the Sandpearl project, as well as Beach Club members and other owners and tenants that own or lease residences within the geographical area bordered on the west by the Gulf of Mexico, on the east by Clearwater Bay, on the north by Rockaway Street and on the south by Papaya Street; 9. the provision of a shuttle service from Sandpearl to the boat slips; 10. the assignment of a Sandpearl employee to respond to problems at the boat docks on a 24 hour/ 7 day per week basis, but does not require on-site security; 11. the developer to prepare and submit for approval for all permits and to bear all costs to prepare such applications and all permit and regulatory fees or charges; 12. sets out the annual rental to the City of the developer's leased area; 13. provides for the City share of common expenses and sets a cap to the amount of the City's share of the common expenses; 14. provides for commencement of construction within one year of receiving all permits; 15. provides for a five-year term for the lease, with the City's option for five successive renewal terms of five years each; and Community Development Board - July 17, 2007 DVA2004-00002A - Page 3 of 4 0 0 16. provides for City ownership of the docks at the end of the all lease and renewal options, or the ability for the City to pay a cost for the design, permitting and construction of the docks for City use for all slips at any lease renewal period. The Community Development Board has been provided with the most recently negotiated Development Agreement. The City Council may enter into Development Agreements to encourage a stronger commitment on comprehensive and capital facilities planning, ensure the provision of adequate public facilities for development, encourage the efficient use of resources, and reduce the economic cost of development. The Community Development Board is required to review the proposed Development Agreement and make a recommendation to the City Council. SUMMARY AND RECOMMENDATION: The Development Review Committee reviewed the application and supporting materials on June 7, 2007. The Planning Department recommends APPROVAL, and recommendation to the City Council, of an amendment to an adopted Development Agreement between The Sandpearl Resort, LLC (formerly known as CBR Development I, LLC) and The Residences at Sandpearl Resort, LLC (formerly known as CBR Development II, LLC) and the City of Clearwater (previously DVA2004-00005 approved by City Council on January 20, 2005) relating to the provision of a 42-slip marina dock in conjunction with the Sandpearl Resort project (39 wet slips and three day slips, of which 15 slips will be for public usage and 27 slips will be leased to the Sandpearl Resort) in the submerged lands adjacent to the Clearwater Beach Recreation Center (69 Bay Esplanade) for the sites at 470 and 500 Mandalay Avenue and 11 Baymont Street, with the following bases: Bases for Approval: 1. The amended Development Agreement is consistent with and furthers the goals, policies and objectives of the Comprehensive Plan. 2. The amended Development Agreement complies with the standards and criteria of Section 4-606. 3. The amended Development Agreement implements and formalizes the requirements for the construction of off-site improvements under the related site plan proposal (FLD2007-02003). 4. The amended Development Agreement is in compliance with Beach by Design. Prepared by: Planning Department Staff: ATTACHMENTS: Location Map Aerial Map Zoning Map Existing Surrounding Uses Map Application Wayne Wells, AICP, Planner III S: (Planning DepartmentlC D BIFLEX (FLD)IPending cases) Up for the next CDBIDVA2007-00002 Mandalay 500 Sandpearl Resort (T) - 7.17.07 CDB - WWIMandalay 500 Amended Dev. Agree. Staff Report for 7.17.07 CDB.doc Community Development Board - July 17, 2007 DVA2004-00002A - Page 4 of 4 • • O ROYAL AY HEILWOOD 3 O BAY AVALON Q F (n n n o KENDALL Juanita Z z c BAY m ESPLANADE ROCKAWAY PROJECT Amble r SITE BA MO ST U W W Q 0'or CD SAN MA CO W ir O 2 PAPAYA ST } < Q ? co z z O a ?'ier 60 Causeway Blvd Location Map The Sandpearl Resort, LLC and The Owner: Residences at Sand earl Resort, LLC Case: DVA2007-00002 Site: 470 and 500 Mandalay Avenue and Property 7.39 11 Baymont Street Size(Acre s): 08/29/15/78657/001/0010 PIN: 08/29/15/78657/002/0010 Atlas Page: 267A • • A. . i 'i { r ? ? y 1 I l y ? 1 - to 1 Lz 7' " .?'i A ! !1 ? ,t r7 r? ? y ? , ,, ? zA J J . - •e^ H e ?J11 }J `L Aerial Map Owner: The Sandpearl Resort, LLC and The Case: DVA2007-00002 Residences at Sand earl Resort, LLC 470 and 500 Mandalay Avenue and i Property 39 7 te: S 11 Baymont Street Size(Acres): . 08/29/15/78657/001/0010 PIN: 08/29/15/78657/002/0010 Atlas Page: 267A • • 40 ° y 8 0 4--. 57924 530 I 2 13 4 5 8 7 52 52, 51 PHASE I S 08-29-15FORRIR LfWO 0 1 500 507 - - g - - - _ ( q ] ? / ?L PHAS E 11 SEE SOr29 1 78657 _L 100 0SA? 1 P 5Z 80 4Q + p 1 7 w N N m 495 - 495 44 1 43 490 _6p - 2 492 2 61 2 _ - - 489 Q c0' - 1 3 3 490 viw ?- ? ? - 48$ 4 - - - ?J 479 480 1 [ 0 ] <c 4 4484 3.31 A c(c) ?„/ - y- - - 5 49 W 5 480 3 ' 6 475 6 W 47,1 470 ;7 Q - - - : g - ? 7 Q 7 31 47 4 (? 71 (? R 29 7 g NV7 a 9 9 ae W ? _'6 _ 4 - z7 4 W PHASE 1 74 4B - - 10 10 B 465 46 r'- 6- J 457 r 11 46 T U60 463 54658 7r - Q 455 24 1 l- - 45 Q ip 23 454 -? - 1 _" - ... 78 _ ?• 45.1 22 L12 _ 1c -71 13 7 9 81 11 -- -- Zoning Map The Sandpearl Resort, LLC and The Owner. Case: DVA2007-00002 Residences at Sand earl Resort, LLC 470 and 500 Mandalay Avenue and Property Site: 7.39 11 Baymont Street Size(Acres): 08/29/15/78657/001/0010 PIN: 08/29/15/78657/002/0010 Atlas Page: 267A • Park o o 40 ?- a z a r? E 57924 r, rnigb estau an 4 jc mmo Ws a 8 7 5 L 5 g g a 51 PHASE I S X29-,5 FOR R4R IIPFO mp Attached ,o dwellings Beach 0 50o sot - - - PHAS E II T- --1 SEE S05-29-1 78657 a 1. - ___t 3p?s 100 01) BAYMONT ST a -57- v v a° 1 so m mnmm eo nt v , 495 59- d4 490 1 r 7 ? Jwt?y 49 2 f ° r'J Beach 4a9 games- I/ ` - 4S5 ; 3 - 3- - 63 fa r--- - 4 480 O 4 7 4 " 477 3.31 Ac(? Ife _ - - -s -5 - - W 5 s Q 475 47: 470 s 41 - - - W $ - 7 7 0 32 - - 31 1 (/) _ -1 8 y s - 61 30 471 29 7- N 'etas 9_ O 9 W AAWhed 744 R 27 10 Q. ,p B W 465 -t - Beach rdweHingsl °? r ?? ?54658 ie 4 Q _ 78 Q 453 23 ® 45 g ?' ' 13 '-' 3 - - 11 Existing Surrounding Uses Map The Sandpearl Resort, LLC and The Owner. Case: DVA2007-00002 Residences at Sand earl Resort, LLC Sit 470 and 500 Mandalay Avenue and Property 7 39 e: 11 Baymont Street Size(Acres): . 08/29/15/78657/001/0010 PIN: 08/29/15/78657/002/0010 Atlas Page: 267A I View lookinz; SW at subject property S of Baymont St J!& I" 1 112 1 ® es rtAgPItsc EE i of 4 Xci C -?4 1.E?Zi r? 17. View looking SW at subject property north of Baymont Street (500 Mandalay Ave. - hotel) 1!4 1160 n+- View looking north of subject property on west side of Mandalay Ave. IF View looking SE at developments across Mandalay Ave. from subject property View looking NE at Belle Harbor (501 Mandalay Ave.) ANII.- :,I !? as View looking south at adjacent development at 490 Mandalay Ave. 470 & 500 Mandalay Avenue and 11 Baymont Street DVA2007-00002 ?` ''? ? • Page 1 of 3 Wells, Wayne From: Dougall-Sides, Leslie , Sent: Thursday, July 19, 2007 3:22 PM To: Dewitt, Gina Cc: Wells, Wayne Subject: RE: DVA2007-00002 No, I do not. I have not been involved in review of it. I only have a hard copy because I receive the CDB agenda packet. Pam states in a June 4 e-mail to Garry Brumback and Kevin Dunbar that she has been involved in the DVA amendment. -----Original Message----- From: Dewitt, Gina Sent: Thursday, July 19, 2007 2:11 PM To: Dougall-Sides, Leslie Subject: FW: DVA2007-00002 Do you have an electronic copy of the Sand Pearl amendment? -----Original Message----- From: Akin, Pam Sent: Thursday, July 19, 2007 1:45 PM To: Dewitt, Gina Subject: FW: DVA2007-00002 Pamela Akin, City Attorney 112 S. Osceola Ave Clearwater, Florida 33758 727 562-4010 -----Original Message----- From: Wells, Wayne Sent: Wednesday, July 18, 2007 5:40 PM To: 'Carl Wagenfohr' Cc: Akin, Pam; Delk, Michael; Castelli, Joelle Wiley Subject: RE: DVA2007-00002 Carl - By this response I am copying Pam Akin. The Planning Department does not have an electronic copy. Potentially Ms. Akin has the most up-to-date electronic copy of the proposed amended Development Agreement and, if so, I am asking her to forward such to you. If she does not have such, then we will ask the applicant to forward a copy to you and myself. Wayne 7/20/2007 Page 2 of 3 -----Original Message----- From: Carl Wagenfohr [mailto:carl@clearwatergazette.com] Sent: Wednesday, July 18, 2007 5:22 PM To: Wells, Wayne Subject: RE: DVA2007-00002 Wayne, Unfortunately, I'm not planning on coming to Clearwater again this week. Doesn't the City Attorney's office have an electronic copy? Surely it wasn't produced with a typewriter! Carl -----Original Message----- From: Wayne.Wells@myClearwater.com [mailto:Wayne.Wells@myClearwater.com] Sent: Wednesday, July 18, 2007 4:51 PM To: carl@clearwatergazette.com Cc: Sherry.Watkins@myClearwater.com Subject: RE: DVA2007-00002 Carl - only have a hard copy of the proposed amended Development Agreement, nothing electronic. Would you like for me to make a copy of the proposed amended Development Agreement and place it at our greeter area for your pickup Thursday? Wayne -----Original Message----- From: Carl Wagenfohr [mailto:carl@clearwatergazette.com] Sent: Wednesday, July 18, 2007 3:55 PM To: Wells, Wayne Subject: FW: DVA2007-00002 Wayne, Please forward to me a copy of the proposed revision to the Sand Pearl development agreement. Thanks ...Carl -----Original Message----- From: Sherry.Watkins@myClearwater.com [mailto: Sherry. Watkins@myClearwater.com] Sent: Friday, July 13, 2007 10:07 AM To: carl@clearwatergazette.com Subject: RE: DVA2007-00002 Please call me. 562-4582 -----Original Message----- From: Carl Wagenfohr [mailto:carl@clearwatergazette.com] Sent: Friday, July 13, 2007 9:42 AM To: Watkins, Sherry Subject: DVA2007-00002 7/20/2007 Page 3 of 3 Sherry, Please send me the documentation for the CDB hearing of the amendment to the Sand Pearl development agreement. Thanks ...Carl 7/20/2007 • • Page 1 of 1 Wells, Wayne From: Wells, Wayne Sent: Monday, July 16, 2007 5:07 PM To: 'nicholas fritsch' Cc: Delk, Michael; Clayton, Gina; Thompson, Neil Subject: RE: DVA Nick - From a procedural standpoint, this item meets the rules to be placed on the Consent portion of the agenda. By the CDB rules of procedure, any Board member may pull an item off Consent at the meeting when the Consent item is read. So for now, the item will stay on the Consent portion of the agenda. You may pull it off at the meeting. From a Development Order and Development Agreement standpoint, the Beach Club was approved under the FLD case and the DVA case in 2004 and 2005 respectively. As a suggestion, any discussion of the Beach Club should be in regard to the ability to lease a slip at these docks under the terms of the proposed amended Development Agreement. Wayne -----Original Message----- From: nicholas fritsch [mailto:nfritsch@tampabay.rr.com] Sent: Monday, July 16, 2007 11:32 AM To: Wells, Wayne Subject: DVA Please pull this from consent. Upon reflection, it deserves discussion of the Beach Club concept. Thanks, Nick 7/18/2007 0 1 0 Wells, Wayne From: Kambourolias, Sam Sent: Friday, July 06, 2007 1:32 PM To: Wells, Wayne Subject: DVA2007-00002 WWI OKLA] aerial.doc existing.doc FLD Map request location.doc zone.doc form.doc Sam Kambourolias G1S Tech. (727) 562-4769 www.myclearwater.com Case # DVA2007-00002 Sign Posting Acknowledgement I hereby acknowledge posting signs on the subject property that is undergoing an amendment to a previously approved Development Agreement so that they are readable from the most significant adjacent road a minimum of 15 days before the Public Hearing. WCL-41oz WPO Print Name wc?? n - \"-J ign N4 Public Hearing Date - CDB: 7-17-07 7 2-1 0-7 Date Posting Date - No Later Than: 7-2-07 CC: 8-14-07 7-2-07 • • Wells, Wayne From: Wells, Wayne Sent: Monday, July 02, 2007 6:33 PM To: Kambourolias, Sam Cc: Herman, Jason Subject: Map Request for DVA2007-00002, 470 and 500 Mandalay Avenue and 11 Baymont Street Sam - Attached is a map request for Case DVA2007-00002 for the property at 470 and 500 Mandalay Avenue and 11 Baymont Street. I will bring over the paperwork. The legal description is Lot 1, Block 1 and Lot 1, Block 2, Sandpearl, recorded in Plat Book 129, Pages 89-92. 1 do not have a survey, but hope to get one if you need it. Thanks- Wayne FLD Map request form.doc 9 0 Flexible Development Application - Map Request Planner Name: Wayne Wells Case Number: DVA2007-00002 Date Requested: July 3, 2007 Date Requested for (date): July 10, 2007 Maps Requested X? Location Map X? Aerial Map X? Zoning Map X? Existing Surrounding Uses Map Required Documents to be submitted to Engineering X? Legal Description ? Survey X? Map with Proposed Site Highlighted Map Nam e owner: The Sandpearl Resort, LLC and The ;case: DVA2007-00002 Residences at Sand earl Resort, LLC Site: 470 and 500 Mandalay Avenue and Property 9.77 1 1 Baymont Street Size(Acres): ;PIN: 08/29/15/78657/001/0010 08/29/15/78657/002/0010 Atlas Page: 267A ?s PVA &ow- ovvos IW?o it ?"''1 Ate.. 258A r~i-r L 1 N LL ° Clearwater - -j . ar GO i 11 111\ ared b Pr _ _ el y ep Engineering Department Geographic Technology Division r . 1 JOBS. Myrtle Ave, Clearwater, FL 33756 L:as* - Ph:(727)562-4750, Fax: (727)526-4755 -.MyClcarwater.com BAY MOM Disclaimer ® mn _-_°` L Pablic inlwmation Bale is tarnishes ey Na city o{Lleorwafor EnPmearxq oanan and must ba a ane „s N Dy me -p- wnn M, rna ---g (h1f af th, me ears mreroae amremae m.ae Pamoae olae.alopq a graphic X?( .m - J -- - ? inlmslrvcNre imentary. Aa such, fhe Cify of Cleanvafer moNas rro lehneu, reliebuee arvnOb'ee. cvnceminp fhe aaumry. mnp y. or sailabilifyol(his Bala for any 11 A r /' a n m?\% > 1? Y -"1 ? L dDerpaNCUlarusa. FUehemrore. (he Gyd Ckarxafer , ? -_ - --? msus no lieDlNtywhalsoaver esmcialetl with fhe usa or o oraam eam. ??T 5 - 1 inch equals 200 feet MA am D a 2 200 100 0 200 a Feel X % 7-- - -- a., GULF ax Legend -? jyq -- CLEARWATER ' X City Owned Property HARBOR Agreement to Annex OF MPAYA ST Q : - - ? Izaci SUB NUMBER (' - Refer to Plat) u MEXICO ? m BLOCK NUMBER nom- tO SUB PARCEL NUMBER PARCEL NUM13ER(M&B) 9 A ? LAND HOOK (COMMON OWNERSHIP) .vti cio -- _3" g v PLATTED SUBDIVISION BOUNDARY COUNTY HIGHWAY -- _sz w ? STATE HIGHWAY -- U.S. HIGHWAY % _ o _----___ a , X X wrt. \ % %O• (s c, E LVD ! -R BO -_- _ _?-^- ~?\ --- - Outside CllY °f'------- Clearwater ------- RESIDENTIAL DISTRICTS 1 X m s on - - .. ........ 1 I - LDR L w Densuy Resitlenlial 2 i) , - ?... ., ?..!. / I OS/T ` '- LMDR -Law Maeium Rih ROSieenlul MDR - M- Dimity ty Resitlenlal ..DR - Hi M1 Dansil ResitlonCm Ama h g y HOP High Density Resieential -- - O • MHP - Moeie Home Park _ I CRNCOD -OZ.y an F.S. NeigM1ba,hooa Conservation D"aLlc't L- J L IENLOD -I,-dEslatee NeigM1EarM1aoe Conservation ° n Duets /'\ T - --_ ve ay ?) '??''yy {l ? % ; I X SPECIAL USE DISTRICTS COMMERCIAL DISTRICTS IRT .MUtrelPnea,N aN ietlnabm O-Ofrca -InM-ona1 T -Tourism . alicnal C :Commerdal OSR O swrza wr, D p - -fim- Dowmown - BLYD Zoning Atlas - l e t ..... ................. ...... ...... ............ ..... . .Y 1 •' aor,'.a.. ............ ..... ... ............ .. .... ... Jun 12. 2007 . x L1_?, ., O J NW 114 of 8-29-15 rn 276A W 267A 10 0 Wells, Wayne From: Dougall-Sides, Leslie Sent: Tuesday, June 26, 2007 10:32 AM To: Wells, Wayne Cc: Akin, Pam; Delk, Michael; Clayton, Gina; Thompson, Jean Subject: RE: July 17, 2007, CDB Advertising Good, that is a more complete description Leslie K. Dougall-Sides Assistant City Attorney City of Clearwater P.O. Box 4748 Clearwater, Florida 33758 (727) 562-4010 phone (727) 562-4021 fax Board Certified in City, County and Local Government Law Admitted in Florida, Oregon, and the District of Columbia Senior Professional in Human Resources -----Original Message----- From: Wells, Wayne Sent: Monday, June 25, 2007 6:44 PM To: Dougall-Sides, Leslie Cc: Akin, Pam; Delk, Michael; Clayton, Gina; Thompson, Jean Subject: FW: July 17, 2007, CDB Advertising Importance: High As an addendum to Case 1, 1 have changed the end of the Request to state "under the provisions of Sections 2- 1502.A, 3-601.C.3 and 3-603". -----Original Message----- From: Wells, Wayne Sent: Monday, June 2S, 2007 6:17 PM To: Dougall-Sides, Leslie Cc: Akin, Pam; Delk, Michael; Clayton, Gina; Thompson, Neil Subject: July 17, 2007, CDB Advertising Importance: High Leslie - We have sent/are sending the July 17, 2007, CDB agenda to the City Clerk's office for advertising. Regarding the docks at the Clearwater Beach Recreation Center for the Sandpearl project, I am just trying to be cautious regarding proper wording for the requests. Following is what I have put in the agenda: 1. Case: FLD2007-02003 - 69 Bay Esplanade Level Two Application Owner/Applicant: City of Clearwater. Representative: E. D. Armstrong III, Esq., Johnson, Pope, Bokor, Ruppel & Burns, LLP (P.O. Box 1368, Clearwater, FL 33757; phone: 727-461-1818; fax 727-441-8617; e-mail: ed@ipfirm.com <mailto: edQpfirm.com>). Location: 4.26 acres located at the southeast corner of the intersection of Mandalay Avenue and Bay Esplanade. Atlas Page: 258A. Zoning District: Open Space/Recreation (OS/R) and Preservation (P) Districts. Request: Flexible Development approval to permit in the submerged lands adjacent to the Clearwater Beach Recreation Center a 42-slip marina dock in conjunction with the Sandpearl Resort project (39 wet slips and three day slips, of which 15 slips will be for public usage and 27 slips will be leased to the Sandpearl Resort) of 11,343 square feet with a deviation to allow the docks and tie poles to exceed the 25 percent of the width of the waterway and a reduction to required parking from 24 to zero spaces, under the provisions of Section 3-601.C.3. Proposed Use: Docks of 39 wet slips and three day slips, of which 15 slips will be for public usage and 27 slips will be leased to the Sandplwesort. • Neighborhood Association: Clearwater Beach Association (Jay Keyes, 100 Devon Drive, Clearwater, FL `i 33767; phone: 727-443-2168; email: papamurphy@aol.com <mailto:papamurphyic ,aol.com>); Clearwater Neighborhoods Coalition (Joe Evich, President, P.O. Box 8204, Clearwater, FL 33758). Presenter: Wayne M. Wells, AICP, Planner 111. 2. Case: DVA2007-00002 - 470 and 500 Mandalay Avenue and 11 Baymont Street Level Three Application Owner/Applicant: The Sandpearl Resort, LLC and The Residences at Sandpearl Resort, LLC. Representative: E. D. Armstrong III, Esq., Johnson, Pope, Bokor, Ruppel & Burns, LLP (P.O. Box 1368, Clearwater, FL 33757; phone: 727-461-1818; fax 727-441-8617; e-mail: ed@,ipfirm.com <mailto:edQpfirm.com>). Location: 9.77 total acres (hotel site 7.36 acres [3.69 acres zoned Tourist District; 3.67 acres zoned Open Space/Recreation District; residential site 2.41 acres) located on the west side of Mandalay Avenue between San Marco and Ambler Streets. Atlas Page: 267A Request: Review of, and recommendation to the City Council, of an amendment to an .adopted Development Agreement between The Sandpearl Resort, LLC (formerly known as CBR Development I, LLC) and The Residences at Sandpearl Resort, LLC (formerly known as CBR Development II, LLC) and the City of Clearwater (previously DVA2004-00005 approved by City Council on January 20, 2005) relating to the provision of a 42- slip marina dock in conjunction with the Sandpearl Resort project (39 wet slips and three day slips, of which 15 slips will be for public usage and 27 slips will be leased to the Sandpearl Resort) in the submerged lands adjacent to the Clearwater Beach Recreation Center. Proposed Use: Mixed use (253 overnight accommodation units at 68.56 units/acre on hotel portion of site and a height of 95 feet, 119 attached dwellings at 49.38 units/acre on residential/retail portion of site and a height of 150 feet and 11,000 square feet of retail sales and services at a FAR of 0.105 on residential/retail portion of site). Neighborhood Association(s): Clearwater Beach Association (Jay Keyes, 100 Devon Drive, Clearwater, FL 33767; phone: 727-443-2168; email: papamurphyna,aol.com <mailto:papamurphygaol.com>); Clearwater Neighborhoods Coalition (Joe Evich, President, P.O. Box 8204, Clearwater, FL 33758). Presenter: Wayne M. Wells, AICP, Planner lII. I have the following questions: 1. Regarding Case 1 above, normally we advertise the upland zoning district because the docks are accessory to the upland development (attached dwellings, hotel, etc.). In this case, the docks are "accessory" to the Sandpearl Resort, which is across Mandalay Avenue. I have added the Preservation District to the request. This was done because, as we have discussed previously with Pam Akin, Ed Armstrong and a group of people, the Development Agreement (Case 2) provides for the leasing of slips to people within a described geographic area, making it a "marina". As previously discussed, the request would include a reduction to parking for this marina. A marina is not a use listed in the Open Space/Recreation District, but.is listed in the Preservation District. This is why I have added the Preservation District to the zoning of the "property". Is this correct? 2. Regarding Case 2 above, I have added the language "relating to the provision of a 42-slip marina dock in conjunction with the Sandpearl Resort project (39 wet slips and three day slips, of which 15 slips will be for public usage and 27 slips will be leased to the Sandpearl Resort) in the submerged lands adjacent to the Clearwater Beach Recreation Center" in the request to explain the reason for the proposed amendment. Is this a correct way of advertising/explaining the proposed change to the Development Agreement? 3. Regarding Case 2 above, I have included only the addresses for the Sandpearl Resort (not including the address for the Clearwater Beach Recreation Center) as previously advertised under DVA2004-00005 and have included under the "Proposed Use" that which we used previously under DVA2004-00005 for the Sandpearl Resort proposed uses. Is these sufficient? If you can let me know Tuesday morning if these are correct/sufficient, I would appreciate it as the Clerk's office will be trying to get their advertising done for the cases on the agenda. Thanks. Wayne Wells, Wayne From: Dougall-Sides, Leslie Sent: Tuesday, June 26, 2007 10:32 AM To: Wells, Wayne Cc: Akin, Pam; Delk, Michael; Clayton, Gina; Thompson, Jean Subject: RE: July 17, 2007, CDB Advertising Good, that is a more complete description. Leslie K. Dougall-Sides Assistant City Attorney City of Clearwater P.O. Box 4748 Clearwater, Florida 33758 (727) 562-4010 phone (727) 562-4021 fax Board Certified in City, County and Local Government Law Admitted in Florida, Oregon, and the District of Columbia Senior Professional in Human Resources -----Original Message----- From: Wells, Wayne Sent: Monday, June 25, 2007 6:44 PM To: Dougall-Sides, Leslie Cc: Akin, Pam; Delk, Michael; Clayton, Gina; Thompson, Jean Subject: FW: July 17, 2007, CDB Advertising Importance: High As an addendum to Case 1, 1 have changed the end of the Request to state "under the provisions of Sections 2- 1502.A, 3-601.C.3 and 3-603". -----Original Message----- From: Wells, Wayne Sent: Monday, June 25, 2007 6:17 PM To: Dougall-Sides, Leslie Cc: Akin, Pam; Delk, Michael; Clayton, Gina; Thompson, Neil Subject: July 17, 2007, CDB Advertising Importance: High Leslie - We have sent/are sending the July 17, 2007, CDB agenda to the City Clerk's office for advertising. Regarding the docks at the Clearwater Beach Recreation Center for the Sandpearl project, I am just trying to be cautious regarding proper wording for the requests. Following is what I have put in the agenda: Case: FLD2007-02003 - 69 Bay Esplanade Level Two Application Owner/Applicant: City of Clearwater. Representative: E. D. Armstrong III, Esq., Johnson, Pope, Bokor, Ruppel & Burns, LLP (P.O. Box 1368, Clearwater, FL 33757; phone: 727-461-1818; fax 727-441-8617; e-mail: ed(a jpfirm.com <mailto: ed&pfirm.com>). Location: 4.26 acres located at the southeast corner of the intersection of Mandalay Avenue and Bay Esplanade. Atlas Page: 258A. Zoning District: Open Space/Recreation (OS/R) and Preservation (P) Districts. Request: Flexible Development approval to permit in the submerged lands adjacent to the Clearwater Beach Recreation Center a 42-slip marina dock in conjunction with the Sandpearl Resort project (39 wet slips and three day slips, of which 15 slips will be for public usage and 27 slips will be leased to the Sandpearl Resort) of 11,343 square feet with a deviation to allow the docks and tie poles to exceed the 25 percent of the width of the waterway and a reduction to required parking from 24 to zero spaces, under the provisions of Section 3-601.C.3. Proposed Use: Docks of 39 wet slips and three day slips, of which 15 slips will be for public usage and 27 slips • i will be leased to the Sandpearl Resort. Neighborhood Association: Clearwater Beach Association (Jay Keyes, 100 Devon Drive, Clearwater, FL 33767; phone: 727-443-2168; email: papamurphyQaol.com <mailto:papamurphy(o)aol.com>); Clearwater Neighborhoods Coalition (Joe Evich, President, P.O. Box 8204, Clearwater, FL 33758). Presenter: Wayne M. Wells, AICP, Planner III. 2. Case: DVA2007-00002 - 470 and 500 Mandalay Avenue and 11 Baymont Street Level Three Application Owner/Applicant: The Sandpearl Resort, LLC and The Residences at Sandpearl Resort, LLC. Representative: E. D. Armstrong III, Esq., Johnson, Pope, Bokor, Ruppel & Burns, LLP (P.O. Box 1368, Clearwater, FL 33757; phone: 727-461-1818; fax 727-441-8617; e-mail: ed@jpfirm.com <mailto:ed(aJpfirm.com>). Location: 9.77 total acres (hotel site 7.36 acres [3.69 acres zoned Tourist District; 3.67 acres zoned Open Space/Recreation District; residential site 2.41 acres) located on the west side of Mandalay Avenue between San Marco and Ambler Streets. Atlas Page: 267A Request: Review of, and recommendation to the City Council, of an amendment to anaadopted Development Agreement between The Sandpearl Resort, LLC (formerly known as CBR Development I, LLC) and The Residences at Sandpearl Resort, LLC (formerly known as CBR Development II, LLC) and the City of Clearwater (previously DVA2004-00005 approved by City Council on January 20, 2005) relating to the provision of a 42- slip marina dock in conjunction with the Sandpearl Resort project (39 wet slips and three day slips, of which 15 slips will be for public usage and 27 slips will be leased to the Sandpearl Resort) in the submerged lands adjacent to the Clearwater Beach Recreation Center. Proposed Use: Mixed use (253 overnight accommodation units at 68.56 units/acre on hotel portion of site and a height of 95 feet, 119 attached dwellings at 49.38 units/acre on residential/retail portion of site and a height of 150 feet and 11,000 square feet of retail sales and services at a FAR of 0.105 on residential/retail portion of site). Neighborhood Association(s): Clearwater Beach Association (Jay Keyes, 100 Devon Drive, Clearwater, FL 33767; phone: 727-443-2168; email: pgpamuiphy@aol.com <mailto:papamurphy@aol.com>); Clearwater Neighborhoods Coalition (Joe Evich, President, P.O. Box 8204, Clearwater, FL 33758). Presenter: Wayne M. Wells, AICP, Planner III. I have the following questions: 1. Regarding Case 1 above, normally we advertise the upland zoning district because the docks are accessory to the upland development (attached dwellings, hotel, etc.). In this case, the docks are "accessory" to the Sandpearl Resort, which is across Mandalay Avenue. I have added the Preservation District to the request. This was done because, as we have discussed previously with Pam Akin, Ed Armstrong and a group of people, the Development Agreement (Case 2) provides for the leasing of slips to people within a described geographic area, making it a "marina". As previously discussed, the request would include a reduction to parking for this marina. A marina is not a use listed in the Open Space/Recreation District, but is listed in the Preservation District. This is why I have added the Preservation District to the zoning of the "property". Is this correct? 2. Regarding Case 2 above, I have added the language "relating to the provision of a 42-slip marina dock in conjunction with the Sandpearl Resort project (39 wet slips and three day slips, of which 15 slips will be for public usage and 27 slips will be leased to the Sandpearl Resort) in the submerged lands adjacent to the Clearwater Beach Recreation Center" in the request to explain the reason for the proposed amendment. Is this a correct way of advertising/explaining the proposed change to the Development Agreement? 3. Regarding Case 2 above, I have included only the addresses for the Sandpearl Resort (not including the address for the Clearwater Beach Recreation Center) as previously advertised under DVA2004-00005 and have included under the "Proposed Use" that which we used previously under DVA2004-00005 for the Sandpearl Resort proposed uses. Is these sufficient? If you can let me know Tuesday morning if these are correct/sufficient, I would appreciate it as the Clerk's office will be trying to get their advertising done for the cases on the agenda. Thanks. Wayne Wells, Wayne From: Albee, Rick Sent: Monday, June 25, 2007 1:41 PM To: Elliott, Gayle; DRC Members Subject: RE: Resubmittal for the CDB Meeting on Tuesday, July 17, 2007 300 Belcher- Conditions met. 808 Ewing-No Issues. 699 Bay Esplanade-Updated conditions to be met at building permit. 69 Bay Esplanade-Updated conditions to be met at building permit. 500 Mandalay- No Issues. 1460 Missouri-No Issues. 200 Skiff Point-No Issues. -----Original Message----- From: Elliott, Gayle Sent: Monday, June 18, 2007 4:30 PM To: DRC Members Subject: Resubmittal for the CDB Meeting on Tuesday, July 17, 2007 Importance: High DRC Members, Plans for the following cases have been resubmitted for the July 17, 2007 CDB Meeting: FLD2007-05014 - 300 S Belcher - Planner - Wayne Wells FLD2007-03010 - 808 Ewing Ave - Planner - Robert Tefft FLD2007-03007 - 699 Bay Esplanade - Planner - Scott Kurleman FLD2007-02003 - 69 Bay Esplanade - Planner - Wayne Wells DVA2007-00002 - 500 Mandalay Ave - Planner - Wayne Wells FLD2007-02006 - 1460 S Missouri Ave - Planner - Wayne Wells FLD2007-05017 - 200 Skiff Point - Planner - Wayne Wells I Have placed one copy of the case resubmittal package on the cabinets outside of Room 216 in our office for your review (Please do not take it or any of the other copies as they are needed for the CDB members) Please review your comments/conditions for this cases in Permit Plan and determine if they are met. Whether the conditions are "met" or still "not met," please affirm to me via email. Please have these cases reviewed by Thursday June 21, 2007 by 4PM. Thank you, Gayle R Elliott Planning Department Staff Assistant (727) 562-4582 gayle.elliott@myclearwater.com 7-.J • Wells, Wayne From: Rice, Scott Sent: Tuesday, June 19, 2007 9:48 AM To: Wells, Wayne Cc: Elliott, Gayle; Watkins, Sherry Subject: FLD2007-02003 & DVA2007-00002 Wayne Condition of approval for FLD case. None for DVA. Prior to construction, provide copies of Pinellas County Dock Permit and Army Corps of Engineer's permit. Thanks, D. Scott Rice, PE Assistant Engineering Director City of Clearwater (727) 562-4781 0 0 Wells, Wayne From: Elliott, Gayle Sent: Monday, June 18, 2007 4:30 PM To: DRC Members Subject: Resubmittal for the CDB Meeting on Tuesday, July 17, 2007 Importance: High DRC Members, Plans for the following cases have been resubmitted for the July 17, 2007 CDB Meeting: FLD2007-05014 - 300 S Belcher - Planner - Wayne Wells FLD2007-03010 - 808 Ewing Ave - Planner - Robert Tefft FLD2007-03007- 699 Bay Esplanade - Planner - Scott Kurleman FLD2007-02003 - 69 Bay Esplanade - Planner - Wayne Wells DVA2007-00002 - 500 Mandalay Ave - Planner - Wayne Wells FLD2007-02006 - 1460 S Missouri Ave - Planner - Wayne Wells FLD2007-05017 - 200 Skiff Point - Planner - Wayne Wells I Have placed one copy of the case resubmittal package on the cabinets outside of Room 216 in our office for your review (Please do not take it or any of the other copies as they are needed for the CDB members) Please review your comments/conditions for this cases in Permit Plan and determine if they are met. Whether the conditions are "met" or still "not met," please affirm to me via email. Please have these cases reviewed by Thursday June 21, 2007 by 4PM. Thank you, Gayle R Elliott Planning Department Staff Assistant (727) 562-4582 gayle.elliott@myclearwater.com • Wells, Wayne From: Dougall-Sides, Leslie Sent: Tuesday, June 05, 2007 10:04 AM To: Wells, Wayne; Diana, Sue Cc: Hollander, Gwen Subject: A04-00163 Sandpearl Resort : Resolution No. 07-17--DVA2007-00002--500 Mandalay Ave.--Sandpearl Resort LLC IblNumAttach: 0 MessageGUID: {8922F2CD-D48A-4OF9-9FEE-B3FOAOCE65D9} OriginalDate: None Originator: SQL Style: Sandpearl Resort We have prepared Resolution No. 07-17 approving the amendment to Development Agreement between the City and The Sandpearl Resort, LLC. Please recall that per F.S. 163.3225, notice must be given by ad 7 days prior to public hearing on the item. The ad must list the proposed development uses, proposed population density, proposed building intensity and height, and specify a location where a copy may be obtained. Leslie K. Dougall-Sides Assistant City Attorney City of Clearwater P.O. Box 4748 Clearwater, Florida 33758 (727) 562-4010 phone (727) 562-4021 fax Board Certified in City, County and Local Government Law Admitted in Florida, Oregon, and the District of Columbia Senior Professional in Human Resources 1.25 pm Case Number: DVA2007-00002 -- 500 MANDALAY AVE Owner(s): Sandpearl Resort Llc 2201 4th St N Ste 200 St Petersburg, F133704 POX TELEPHONE: No Phone, FAX: No Fax, E-MAIL: No Email Representative: E. Armstrong Iii, Esquire ' Po Box 1368 Clearwater, Fl 33757 TELEPHONE: 727-461-1818, FAX: 727-441-8617, E-MAIL: jaynes@jpfirm.com Location: 9.77 TOTAL ACRES (HOTEL SITE 7.36 ACRES; RESIDENTIAL SITE 2.41 ACRES) LOCATED ON THE WEST SIDE OF MANDALAY AVENUE BETWEEN SAN MARCO STREET AND AMBLER STREET. Atlas Page: 267A Zoning District: T, Tourist Request: Review of, and recommendation to the City Council, of an amendment to an adopted Development Agreement between The Sandpearl Resort, LLC (formerly known as CBR Development I, LLC) and The Residences at Sandpearl Resort, LLC (formerly known as CBR Development II, LLC) and the City of Clearwater (previously DVA2004-00005 approved by City Council on January 20, 2005). Proposed Use: Mixed use Neighborhood Clearwater Neighborhoods Coalition Association(s): Clearwater, F133758 P O Box 8204 TELEPHONE: No Phone, FAX: No Fax, E-MAIL: No Email Neighborhood Clearwater Beach Association Association(s): Clearwater, FI 33767 100 Devon Dr TELEPHONE: 443-2168, FAX: No Fax, E-MAIL: papamurphy@aol.com Presenter: Wayne Wells, Planner III Attendees Included: CITY: WAYNE WELLS, NEIL THOMPSON, SCOTT RICE, LENNY RICKERT, BILL MORRIS, RICK ALBEE, HEATHER SHELL APPLICANT: ED ARMSTRONG, JAYNE SEARS, GAIL COOPER, LAUREN WATERS The DRC reviewed this application with the following comments: General Engineering: i _ No Issues Environmental: I . No Issues Fire: No Issues Harbor Master: 1 . 6/7/07 - WW It was agreed that the following would be added as a condition of approval on the FLD case at 69 Bay Esplanade. 5/30/07 - WW I have read the subject amendment in its entirety and find it in keeping with intent of the original document with adjustments made out of consideration for neighboring properties. While the requirement to provide (Article 2 section 2.03 Scope, Subparagraph 6) (on page 10 in the copied I reviewed) Where it states the Developer shall also provide an employee assigned to respond to problems at the boat docking facilities on a 24/7 per week basis, it does not provide the means by which the public of the city would contact the designated employee. My concern here is that in responding to concerns of citizens both for the City Marina and the airpark, providing a phone number for direct access to a person authorized to act and or respond as necessary has served the city well and resolved citizen concerns/complaints quickly. The default process would lead the general public to call the police or the city marina and delay response to an incident of perhaps urgent nature. A posted listing of emergency phone numbers for both dock tenants, the general public and local residents would go a long way to head off initial problems as the boating public becomes accustomed to the hours of operation, local resident and community concerns for both public safety and environmental protection. (Bill Morris) Development Review Agenda - Thursday, June 7, 2007 - Page 34 Legal: No Comments Land Resources: No Comments Landscaping: 1 , No issues. Parks and Recreation: No Comments Stormwater: 1 , No Issues Solid Waste: No Comments Traffic Engineering: 1 . No Issues with boat dock development agreement. Planning: 1 . First paragraph - My records indicate the Development Agreement was recorded in OR Book 14089, Pages 314-451. Revise. 2. Section 2.03.3 - This section does not require lighting on the City Slips. In concert with FLD2007-02003, lighting at the ends of the docks, including the City Slips, is advisable for a night visibility/safety purpose. Advise/revise as appropriate. Other: No Comments Notes: TO BE PLACED ON THE 7/17/07 CDB AGENDA, SUBMIT 15 COLLATED COPIES OF THE REVISED PLANS & APPLICATION MATERIAL ADDRESSING ALL ABOVE DEPARTMENTS' COMMENTS BY NOON, 6/18/07. PACKETS SHALL BE COLLATED, FOLDED AND STAPLED AS APPROPRIATE. Development Review Agenda - Thursday, June 7, 2007 - Page 35 1:25 Pm Case Number: DVA2007-000112 -- 500 MANDALAY AVE Owner(s): Sandpearl Resort Llc 2201 4th St N Ste 200 Petersburg, F133704 TELEPHONE: No Phone, FAX: No Fax, E-MAIL: No Email Representative: E. D. Armstrong Iii, Esquire f? Po Box 1368 Clearwater, F133757 TELEPHONE: 727-461-1818, FAX: 727-441-8617, E-MAIL: jaynes@jpfirm.com Location: 9.77 TOTAL ACRES (HOTEL SITE 7.36 ACRES; RESIDENTIAL SITE 2.41 ACRES) LOCATED ON THE WEST SIDE OF MANDALAY AVENUE BETWEEN SAN MARCO STREET AND AMBLER STREET. Atlas Page: 267A Zoning District: T, Tourist Request: Review of, and recommendation to the City Council, of an amendment to an adopted Development Agreement between The Sandpearl Resort, LLC (formerly known as CBR Development 1, LLC) and The Residences at Sandpearl Resort, LLC (formerly known as CBR Development 11, LLC) and the City of Clearwater (previously DVA2004-00005 approved by City Council on January 20, 2005). Proposed Use: Mixed use Neighborhood Clearwater Neighborhoods Coalition Association(s): Clearwater, F133758 P O Box 8204 TELEPHONE: No Phone, FAX: No Fax, E-MAIL: No Email Neighborhood Clearwater Beach Association Association(s): Clearwater, F133767 100 Devon Dr TELEPHONE: 443-2168, FAX: No Fax, E-MAIL: papamurphy@aol.com Presenter: Wayne Wells, Planner III Attendees Included: CITY: WAYNE WELLS, NEIL THOMPSON, SCOTT RICE, STEVE DOHERTY, LENNY RICKERT, BILL MORRIS APPLICANT: ED ARMSTRONG, JAYNE SEARS The DRC reviewed this application with the following comments: General Engineering: I . No Issues Environmental: I . No Issues Fire: 1 No Issues Harbor Master: 1 . I have read the subject amendment in its entirety and find it in keeping with intent of the original document with adjustments made out of consideration for neighboring properties. While the requirement to provide (Article 2 section 2.03 Scope, Subparagraph 6) (on page 10 in the copied I reviewed) Where it states the Developer shall also provide an employee assigned to respond to problems at the boat docking facilities on a 24/7 per week basis, it does not provide the means by which the public of the city would contact the designated employee. My concern here is that in responding to concerns of citizens both for the City Marina and the airpark, providing a phone number for direct access to a person authorized to act and or respond as necessary has served the city well and resolved citizen concerns/complaints quickly. The default process would lead the general public to call the police or the city marina and delay response to an incident of perhaps urgent nature. A posted listing of emergency phone numbers for both dock tenants, the general public and local residents would go a long way to head off initial problems as the boating public becomes accustomed to the hours of operation, local resident and community concerns for both public safety and environmental protection. (Bill Morris) Legal: No Comments Land Resources: No Comments Development Review Agenda - Thursday, June 7, 2007 - Page 32 Landscaping: 1 . No issues. Parks and Recreation: No Comments Stormwater: 1 . No Issues Solid Waste: No Comments Traffic Engineering: 1 . No Issues with boat dock development agreement. Planning: 1 . First paragraph - My records indicate the Development Agreement was recorded in OR Book 14089, Pages 314-451. Revise. 2. Section 2.03.3 - This section does not require lighting on the City Slips. In concert with FLD2007-02003, lighting at the ends of the docks, including the City Slips, is advisable for a night visibility/safety purpose. Advise/revise as appropriate. Other: No Comments Notes: TO BE PLACED ON THE 7/17/07 CDB AGENDA, SUBMIT 15 COLLATED COPIES OF THE REVISED PLANS & APPLICATION MATERIAL ADDRESSING ALL ABOVE DEPARTMENTS' COMMENTS BY NOON, 6/18/07. PACKETS SHALL BE COLLATED, FOLDED AND STAPLED AS APPROPRIATE. Development Review Agenda - Thursday, June 7, 2007 - Page 33 Wells, Wayne From: Wells, Wayne Sent: Monday, June 04, 2007 11:47 AM To: Akin, Pam Subject: RE: DVA2007-00002, 500 Mandalay Avenue Sure. When I send the Draft DRC comments out later on today, I will copy you and Leslie. -----Original Message----- From: Akin, Pam Sent: Monday, June 04, 2007 10:13 AM To: Wells, Wayne Cc: Dougall-Sides, Leslie Subject: RE: DVA2007-00002, 500 Mandalay Avenue Wayne, I have now received and reviewed the application which includes the amendment to the Development Agreement and the revised boat slip Agreement. Both appear to be consistent with Council directions and our previous discussions. May I see the draft DRC comments? Pamela Akin, City Attorney 112 5. Osceola Ave Clearwater, Florida 33758 727 562-4010 -----Original Message----- From: Wells, Wayne Sent: Monday, June 04, 2007 7:53 AM To: Akin, Pam Cc: Dougall-Sides, Leslie Subject: FW: DVA2007-00002, 500 Mandalay Avenue Importance: High Pam - I am sending out today the Draft DRC comments for the above referenced case for the Amended Development Agreement for Sandpearl. Do you have any DRC comments (items that need to be changed)? Wayne -----Original Message----- From: Dougall-Sides, Leslie Sent: Wednesday, May 30, 2007 8:38 AM To: Wells, Wayne Subject: RE: DVA2007-00002, 500 Mandalay Avenue Wayne, within our office Pam would have worked on this. I asked if she had any comments and have not yet received a response. Leslie K. Dougall-Sides Assistant City Attorney City of Clearwater P.O. Box 4748 Clearwater, Florida 33758 (727) 562-4010 phone (727) 562-4021 fax Board Certified in City, County and Local Government Law Admitted in Florida, Oregon, and the District of Columbia Senior Professional in Human Resources r • . -----Original Message----- From: Wells, Wayne Sent: Tuesday, May 29, 2007 2:49 PM To: Dougall-Sides, Leslie Subject: DVA2007-00002, 500 Mandalay Avenue Leslie - Thursday morning is our Pre-DRC meeting for cases on the June 7, 2007, DRC meeting. Will there be any comments from the Legal Department regarding the proposed Amended Development Agreement that I need to add into Permit Plan for you? Wayne Wells, Wayne From: Dougall-Sides, Leslie Sent: Monday, June 04, 2007 9:27 AM To: Akin, Pam; Wells, Wayne Subject: RE: DVA2007-00002, 500 Mandalay Avenue Importance: High The materials were with Gwen for preparation of an accompanying Resolution; I have placed them in your Inbox. I had previously e-mailed you as follows: r!Qi E FW D7-00002 500 Mand -----Original Message----- From: Akin, Pam Sent: Monday, June 04, 2007 8:07 AM To: Wells, Wayne Cc: Dougall-Sides, Leslie Subject: RE: DVA2007-00002, 500 Mandalay Avenue Leslie, I have checked my e-mail and see nothing on this from you, additionally there is nothing in my inbox. I assume the draft comments went to you. Pamela Akin, City Attorney 112 S. Osceola Ave Clearwater, Florida 33758 727 562-4010 -----Original Message----- From: Wells, Wayne Sent: Monday, June 04, 2007 7:53 AM To: Akin, Pam Cc: Dougall-Sides, Leslie Subject: FW: DVA2007-00002, 500 Mandalay Avenue Importance: High Pam - am sending out today the Draft DRC comments for the above referenced case for the Amended Development Agreement for Sandpearl. Do you have any DRC comments (items that need to be changed)? Wayne -----Original Message----- From: Dougall-Sides, Leslie Sent: Wednesday, May 30, 2007 8:38 AM To: Wells, Wayne Subject: RE: DVA2007-00002, 500 Mandalay Avenue Wayne, within our office Pam would have worked on this. I asked if she had any comments and have not yet received a response Leslie K. Dougall-Sides Assistant City Attorney City of Clearwater r P.O. Box 4748 Clearwater, Florida 33758 (727) 562-4010 phone (727) 562-4021 fax Board Certified in City, County and Local Government Law Admitted in Florida, Oregon, and the District of Columbia Senior Professional in Human Resources -----Original Message----- From: Wells, Wayne Sent: Tuesday, May 29, 2007 2:49 PM To: Dougall-Sides, Leslie Subject: DVA2007-00002, 500 Mandalay Avenue Leslie - Thursday morning is our Pre-DRC meeting for cases on the June 7, 2007, DRC meeting. Will there be any comments from the Legal Department regarding the proposed Amended Development Agreement that I need to add into Permit Plan for you? Wayne Wells, Wayne From: Morris, William D. Sent: Wednesday, May 30, 2007 6:07 PM To: Wells, Wayne Subject: DVA2007-00002 500 Mandalay Ave. The Sand Pearl Resort I have read the subject amendment in its entirety and find it in keeping with intent of the original document with adjustments made out of consideration for neighboring properties. While the requirement to provide (Article 2 section 2.03 Scope, Subparagraph 6) (on page 10 in the copied I reviewed) Where it states the Developer shall also provide an employee assigned to respond to problems at the boat docking facilities on a 24/7 per week basis, it does not provide the means by which the public of the city would contact the designated employee. My concern here is that in responding to concerns of citizens both for the City Marina and the airpark, providing a phone number for direct access to a person authorized to act and or respond as necessary has served the city well and resolved citizen concerns/complaints quickly. The default process would lead the general public to call the police or the city marina and delay response to an incident of perhaps urgent nature. A posted listing of emergency phone numbers for both dock tenants, the general public and local residents would go a long way to head off initial problems as the boating public becomes accustomed to the hours of operation, local resident and community concerns for both public safety and environmental protection. 11 % ft? Pinellas County Property App*r Information: 08 29 15 78657 002 0? Page 2 of 5 08 / 29 / 15 / 78057 / 001 / 0010 28-Jun-2007 Jim Smith, CFA Pinellas County Property Appraiser 15:11:17 Ownership Information Uacant Property Use and Sales SANDPEARL RESORT LLC OBK: 14400 OPG: 0150 2201 4TH ST N STE 200 ST PETERSBURG FL 33704-4300 EVRC: A EUAC Comparable sales value as Prop Addr: 0 of Jan 1, 2006, based on Census Tract: .00 2005 l f 2004 sa es rom - : 0 Sale Date OR Book/Page Price {Qual/UnQ} Vac/Imp Plat Information 0 /0 0/ 0 0 { } 2005: Book 129 Pgs 089-092 0 /0 0/ 0 0 { } 0000: Book Pgs - 0 /0 0/ 0 0 { } 0000: Book Pgs - 0 /8 01 0 0 { } 2006 Value EXEMPTIONS Just/Market: 12,110,300 Homestead: NO Ownership % .000 Govt Exem: NO Use %: .000 Assessed/Cap: 12,110,300 Institutional Exem: NO Tax Exempt %: .000 Historic Exem: 0 Taxable: 12,110,300 Agricultural: 0 2006 Tax Information District: Cu Seawall: Frontage: Clearwater View: 06 Millage: 2i.7640 Land Size Unit Land Land Land Front x Depth Price Units Meth 06 Taxes: 263,568.57 1} 0 x 0 100.00 147, 229. 3 S Special Tax .00 2} 0 x 0 .00 .00 3} 0 x 0 .00 .00 Without the Save-Our-Homes 4} 0 x 0 .00 .00 cap, 2006 taxes will be : 5} 0 x 0 .00 .00 263, 568. 57 6} 0 x 0 .00 .00 Without any exemptions, 2006 taxes will be 263, 568. 57 Short Legal SANDPEARL BLK i, LOT 1 Description (LYING IN SEC'S 5 & 8) L Building Information http://136.174.187.13/htbin/cgi-click?o=1 &a=1 &b=1 &c=1 &r=.16&s=4&t3=1 &u=0&p=0:.. 6/28/2007 P14ellas County Property App*r Information: 08 29 15 78657 002 0? 08 / 29 / 15 / 78057 / 001 / 0010 Page 3 of 5 28-Jun-2007 Jim Smith, CFA Pinellas COunty Property Appraiser 15:11:18 Vacant Parcel Property Use: 000 Land Use: 10 Vacatn? ExTra F?a?ur s Description Dimensions Price Units Value RCD Year 1) .00 0 0 0 0 2) 00 0 0 0 0 3) 00 0 0 0 0 4) .00 0 0 0 0 5) 00 0 0 0 0 6) 00 0 0 0 0 TOTAL RECORD VALUE: 0 Map With Property Address (non-vacant) F*_1 R 5t] 41 Fq ® http://136.174.187.131htbinlcgi-click?o=1 &a=1 &b=1 &c=1 &r=.16&s=4&t3=1 &u=0&p=0... 6/28/2007 ap? Pirifllas County Property Appler Information: 08 29 15 78657 002 000 w 4 i X24 7 .9 P 0 C K T'?V,',?4 C.1 ;? I ST T F ] a.) 23 S30 r 111<4 ` i t?1hD E J FY-) T i A L K SA ip , r. Page 4 of 5 r Y , P , , P P P , r r P P r V 1 P 1 1 r P P P 172(S) ro 78657 BAYMONT ts.P r?Y #-BAp,AON7 S T LAVEI r CD ? 1/8 Mile Aerial Photograph (2002) http://l 36.174.187.13/htbin/cgi-click?o=1 &a=1 &b=1 &c=1 &r=.16&s=4&t3=1 &u=0&p=0... 6/28/2007 41 Niellas County Property App er Information: 08 29 15 78657 002 000 -'a -`. . 1?4 x > r s r r r .It Pinellas County Property Appraiser Parcel Information Page 5 of 5 http://136.174.187.13/htbin/cgi-click?o=1 &a=1 &b=1 &c=1 &r=.16&s=4&t3=1 &u=0&p=0... 6/28/2007 F RP ellas County Property Appr er Information: 08 29 15 16416 002 03 08 / 2 / 15 / 78557 / 002 / 0010 Page 2 of 5 28-Jun-2007 Jim Smith, CFA Pinellas County Property Appraiser 15:10:47 Ownership Information Uacant Property Use and Sales RESIDENCES AT SANDPEARL RESORT LLC OBK: 14400 OPG: 0156 2201 4TH ST N STE 200 ST PETERSBURG FL 33704-4300 EVAC: A EUAC Comparable sales value as Prop Addr: 0 of Jan 1, 2006, based on Census Tract: .0 0 l f 2004 2005 es rom - : sa 0 Sale Date OR Book/P age Price (Qual/UnQ) Vac/Imp Plat Information 6 /2,005 14,400/ 156 5,023,400 (U) I 2005: Book 129 Pgs 089-092 0 /0 01 0 0 { ) 0000: Book Pgs - 0 /0 0/ 0 0 { ) 0000: Book Pgs - 0 /0 01 0 0 { ) 2006 Value EXEMPTIONS Just/Market: 8,638,200 Homestead: NO Ownership % .000 Govt Exem: NO Use %: .000 Assessed/Cap: 8,638,200 Institutional Exem: NO Tax Exempt %: .000 Historic Exem: 0 Taxable: 8,638,200 Agricultural: 0 2006 Tax Information District: Cu Seawall: Frontage: Clearwater View: 06 Millage: 21.7640 Land Size Unit Land Land Land Front x Depth Price Units Meth 06 Taxes: 188,001.78 1) 0 x 0 i 00. 00 105, 017. 5 S Special Tax .00 2) 0 x 0 .00 .00 3) 0 x 0 .00 .00 Without the Save-Our-Homes 4) 0 x 0 .00 .00 cap, 2006 taxes will be : 5) 0 x 0 .00 .00 188, 001.78 6) 0 x 0 .00 .00 Without any exemptions, 2006 taxes will be 188,001.78 Short Legal SANDPEARL BLK 2, LOT i Description L Building Information http://136.174.187.131htbinlcgi-click?o=1 &a=1 &b=1 &c=1 &r=.16&s=4&t3=1 &u=0&p=0... 6/28/2007 Fellas County Property Appr er Information: 08 29 15 16416 002 03 08 / 29 / 15 / 78057 / 002 / 0010 Page 3 of 5 28-Jun-2007 Jim Smith, CFA Pinellas COunty Property Appraiser 15:10:47- Vacant Parcel Property Use: 000 Land Use: 10 Vacant Extr2t Fcatures Description Dimensions Price Units Value RCD Year 1) .00 0 0 0 0 2) .00 0 0 0 0 3) .00 0 0 0 0 4) .00 0 0 0 0 5) .00 0 0 0 0 6) .00 0 0 0 0 TOTAL RECORD VALUE: 0 Map With Property Address (non-vacant) ®®®® http://136.174.187.131htbinlcgi-click?o=1 &a=1 &b=1 &c=l &r=.16&s=4&t3=1 &u=0&p=0... 6/28/2007 Ifiellas County Property Appr ' er Information: 08 29 15 16416 002 03 Page 4 of 5 BAYONT 1/8 Mile Aerial Photograph (2002) http://136.174.187.13/htbin/cgi-click?o=1 &a=1 &b=1 &c=1 &r=.16&s=4&t3=1 &u=0&p=0... 6/28/2007 ?11\ PT ellas County Property Appr r Information: 08 29 15 16416 002 01 ? f S r^h 5 , } F+ it k? 47 11 tl ' i µ U T? Pinellas County Property Appraiser Parcel Information Page 5 of 5 http://136.174.187.131htbinlcgi-click?o=1 &a=1 &b=1 &c=1 &r=.16&s=4&t3=1 &u=0&p=0... 6/28/2007 -6 0 CITY OF CLEARWATER MODIFICATION TO DEVELOPMENT AGREEMENT i3. A public hearing will be conducted before the City Council on Thursday, September 6, 2007 at 6:00 PM (or as soon thereafter as the matter may be heard), in City Council Chambers, 3`d floor of City Hall, 112 South Osceola Ave., Clearwater, Florida, to consider Resolution No. 07-17 approving an amendment to an adopted Development Agreement between The Sandpearl Resort. LLC (formally known as CBR Development I, LLC) and The Residences at Sandpearl Resort, LLC (formally known as CBR Development II, LLC) and the City of Clearwater (previously DVA2004-00005 approved by City Council on January 20, 2005) for property located at 470 & 500 Mandalay Ave. and 11 Baymont St. Sandpearl Blk 1, Lot 1 and Sandpearl Blk 2, Lot 1. (DVA2007- 00002) The Development Agreement allows for the proposed us of 253 overnight accommodation units at 68.56 units/acre on hotel portion of site and a height of 95 feet, 119 attached dwellings at 49.38 units/acre on residential/retail portion of site and a height of 150 ft and 11,000 sq ft of retail sales and services at a FAR of 0.105 on residential/retail portion of site. Interested parties may appear to be heard or file written notice of approval or objections with the Planning Department or the City Clerk prior to or during the public hearing. Any person who decides to appeal any decision made by the Council, with respect to any matter considered at such hearings, will need a record of the proceedings and, for such purpose, may need to ensure that a verbatim record of the proceedings is made, which record includes the testimony and evidence upon which the appeal is to be based per Florida Statute 286.0105. Additional information, including the Development Agreement, is available in the Planning Department at the Municipal Services Building, 100 S. Myrtle Avenue, Clearwater, Florida, or call 562-4567. Michael Delk Cynthia E. Goudeau, MMC Planning Director City Clerk City of Clearwater P.O. Box 4748, Clearwater, FL 33758-4748 A COPY OF THIS AD IN LARGE PRINT IS AVAILABLE IN THE CITY CLERK DEPARTMENT. ANY PERSON WITH A DISABILITY REQUIRING REASONABLE ACCOMMODATIONS IN ORDER TO PARTICIPATE IN THIS MEETING SHOULD CALL THE CITY CLERK DEPARTMENT WITH THEIR REQUEST AT (727) 562-4090. To learn more about presenting to Clearwater boards and City Council, go to http://clearwater.granicus.comNiewPublisher.php?view id=11 and click on "Resident Engagement Video." You can also check the informational video out from any Clearwater public library. Ad: 8/30/07 CITY OF CLEARWATER MODIFICATION TO DEVELOPMENT AGREEMENT A public hearing will be conducted before the Community Development Board on Tuesday, July 17, 2007, beginning at 1:00 PM (or as soon thereafter as the matter may be heard), in City Council Chambers, 3rd floor of City Hall, 112 South Osceola Ave., Clearwater, Florida, to consider Resolution No. 07-17 approving an amendment to an adopted Development Agreement between The Sandpearl Resort. LLC (formally known as CBR Development I, LLC) and The Residences at Sandpearl Resort, LLC (formally known as CBR Development Il, LLC) and the City of Clearwater (previously DVA2004- 00005 approved by City Council on January 20, 2005) for property located at 470 & 500 Mandalay Ave. and 11 Baymont St. Sandpearl Blk 1, Lot 1 and Sandpearl Blk 2, Lot 1. (DVA2007-00002) The Development Agreement allows for the proposed use of 253 overnight accommodation units at 68.56 units/acre on hotel portion of site and a height of 95 feet, 119 attached dwellings at 49.38 units/acre on residential/retail portion of site and a height of 150 ft and 11,000 sq ft of retail. sales and services at a FAR of 0.105 on residential/retail portion of site. Interested parties may appear to be heard or file written notice of approval or objections with the Planning Department or the City Clerk prior to or during the public hearing. Any person who decides to appeal any decision made by the Council, with respect to any matter considered at such hearings, will need a record of the proceedings and, for such purpose, may need to ensure that a verbatim record of the proceedings is made, which record includes the testimony and evidence upon which the appeal is to be based per Florida Statute 286.0105. Additional information, including the Development Agreement, is available in the Planning Department at the Municipal Services Building, 100 S. Myrtle Avenue, Clearwater, Florida, or call 562-4567. Michael Delk Cynthia E. Goudeau, MMC Planning Director City Clerk City of Clearwater P.O. Box 4748, Clearwater, FL 33758-4748 A COPY OF THIS AD IN LARGE PRINT IS AVAILABLE IN THE CITY CLERK DEPARTMENT. ANY PERSON WITH A DISABILITY REQUIRING REASONABLE ACCOMMODATIONS IN ORDER TO PARTICIPATE IN THIS MEETING SHOULD CALL THE CITY CLERK DEPARTMENT WITH THEIR REQUEST AT (727) 562-4090. To learn more about presenting to Clearwater boards and City Council, go to http://clearwater.granicus.com/ViewPublisher.php?view id=11 and click on "Resident Engagement Video." You can also check the informational video out from any Clearwater public library. Ad: 7/5/07 t L1V/1 V/-VVVVG, J4? 222 E 13TH STREET CORP 808 MANDALAY LLC aA W BEACH PROPERTIES LLC 44 EILEEN AVE 2429 N FAIRFAX DR 10 PAPAYA # 1202 PLAINVIEW NY 11803 - 5203 ARLINGTON VA 22201 - 2712 CLEARWATER FL 33767 - 2056 ABOOD, ROBERT G ABRAHAM, DAVID ACHARYA, RAVINDRA P ABOOD, CATHERINE C 11 SAN MARCO ST # 502 ACHARYA, KALPANA R 2256 MACKENZIE CT CLEARWATER FL 33767 - 2060 47 SAWMILL RD CLEARWATER FL 33765 - 2241 DUDLEY MA 01571 - 5849 AGAMI, DAVID AJAY ENDEAVORS INC ALIDINA, ARIF A ROMANO, IVETTE NANCY 12190 CONTEL BLVD ALIDINA, NOORA 11 SAN MARCO # 1502 BROOKVILLE FL 34613 - 11 SAN MARCO ST # 807 CLEARWATER FL 33767 - 2075 CLEARWATER FL 33767 - 2062 ALONSO, ARMANDO ALTNER, MARTIN L ANDERSEN, LARRY E ALONSO, SHARON ALTNER, JANIS C 2156 BASSWOOD DR 36007 LAKE UNITY NURSERY RD 212 WATER VIEW CT LAFAYETTE HILL PA 19444 - 2328 FRUITLAND PARK FL 34731 - 5816 SAFETY HARBOR FL 34695 - 2061 ANGELOCCI, RANDY ARRINGTON, WILLIAM H ATKINS, J MICHAEL CROSSLAND, RICHARD 501 MANDALAY AVE # 910 ATKINS, TERESA K 10 PAPAYA ST # 1106 CLEARWATER FL 33767 - 1703 1613 ELM SHORE DR CLEARWATER FL 33767 - 2056 PORT BYRON IL 61275 - 9092 AUGUSTINE, RICHARD J AVERY, JOSEPHINE AXEL, JONATHAN P THE 10 PAPAYA ST #506 ULINE, BRADLEY R AXEL, CORALS THE CLEARWATER FL 33767 - 2040 521 MANDALAY AVE # 704 11 SAN MARCO ST APT 903 CLEARWATER FL 33767 - 1794 CLEARWATER FL 33767 - 2062 B J E INC BABCOCK, SUSAN BADIE, BADIE A 630 S GULFVIEW BLVD PO BOX 801 32 BRAELOCH WAY CLEARWATER FL 33767 - 2642 OZONA FL 34660 - 0801 MONROE CT 06468 - 3013 BAKER, BARRY J BARRETT, WILLIAM T BARYLAK, EDWARD J BAKER, ANN F BARRETT, SHEILA M BARYLAK, CHRYSTINA 1435 STEVENSON DR 11 SAN MARCO ST # 306 3132 BRANCH RIVER RD LIBERTYVILLE IL 60048 - 2572 CLEARWATER FL 33767 - 2060 MANITOWOC WI 54220 - 8717 BASORE, GREGORY R BAUER, CHARLES L PROP LTD BAUER, CHARLES L 1067 WOODWIND TRL 6106 WADE ST BAUER, JANET W HASLETT MI 48840 - 8977 LEESBURG FL 34748 - 8099 11 SAN MARCO ST # 1005 CLEARWATER FL 33767 - 2062 BAYER, DAVID L BEHESHTI, ALI BELLE HARBOR LLC BAYER, PAMELA R BEHESHTI, TARANEH 2201 4TH ST N STE 200 710 DUNSCORE CT 11 SAN MARCO ST # 1402 ST PETERSBURG FL 33704 - 4300 ROSWELL GA 30075 - 6812 CLEARWATER FL 33767 - 2075 1 BELLE HARBOR OWNERS ASSN INC BERG, ANNA JACOBSEN 501 MANDALAY AVE 521 MANDALAY AVE # 1409 CLEARWATER FL 33767 - 1703 CLEARWATER FL 33767 - 1797 OBERGER, RALPH F LIVING TRUST 7131 ASHVILLE PARK DR COLUMBUS OH 43235 - 5013 BICZ, DANIEL S BIENSTOCK, JOSEPH S BODUCH, RAYMOND T BICZ, MARGARET C BIENSTOCK, PHYLLIS BODUCH, LINDA C 521 MANDALAY AVE # 802 10 PAPAYA ST # 701 521 MANDALAY AVE # 303 CLEARWATER FL 33767 - 1795 CLEARWATER FL 33767 - 2054 CLEARWATER FL 33767 - 1793 BOMERGER, DAVID RICHARD BOND, GEORGE L JR BONI, JOAN P 990 W OAK ST BOND, YVONNE N 19 ROCKAWAY ST # 4 ZIONSVILLE IN 46077 - 1209 1215 CAMINO CAPISTRANO CLEARWATER FL 33767 - 1739 ROSEVILLE CA 95747 - 6727 BOTWICK, ANDREW L BOULTON, CARLOS A BRENNAN, JAMES M BOTWICK, DIANNE S BOULTON, ANN-MARIE OTT, KARYN L 1422 NW 111TH AVE 211 WOODLAKE WYNDE 4505 W DALE AVE CORAL SPRINGS FL 33071 - 6448 OLDSMAR FL 34677 - 21 74 TAMPA FL 33609 - 3708 BROMBOZ, JONATHAN BROWN, SHERMAN D BURGESS, PATRICIA M BROMBOZ, VICKI BROWN, ANDREA D GRIMM, THOMAS L 11 SAN MARCO ST # 304 11 SAN MARCO ST # 705 3234 N 7TH ST CLEARWATER FL 33767 - 2060 CLEARWATER FL 33767 - 2061 WAUSAU WI 54403 - 3007 C & M 27 CO LLC CAMBAS, NICHOLAS A CARACO, JOSEPH 136 HARBOR DR 2939 ELYSIUM WAY IOCOLANO, FRANCO PALM HARBOR FL 34683 - 5403 CLEARWATER FL 33759 - 1414 800 S KEENE RD CLEARWATER FL 33756 - 4630 CASCIOLA, GENE M CASO, RONALD CHACONAS, ANGELINE CASCIOLA, SHEILA CASO, BERNADETTE 6 S MYRTLE AVE 7000 WEDDINGTON BROOK DR 3 SUTPHIN AVE CLEARWATER FL 33756 - 5518 WEDDINGTON NC 28104 - 7274 MATAWAN NJ 07747 - 3315 CHALAVARYA, GOPAL CHAMPAGNE, CHERYL A CHARETTE, RALPH J & LOIS J TRU CHALAVARYA, SADHNA 483 EAST SHORE DR # B4 CHARETTE, RALPH J THE 1510 JASMINE AVE CLEARWATER FL 33767 - 2033 2219 TAMPA RD TARPON SPRINGS FL 34689 - 5242 PALM HARBOR FL 34683 - 5847 CHASE, CHRISTIAN W CHASE, WALTER W CHIAVATTI DEVELOPMENT INC BAILEY, MATHEW S CHASE, JUDITH A 7725 BIRCHMOUNT RD # 37 505 MANDALAY AVE # 71 11 SAN MARCO ST UNIONVILLE ON L3R 9X3 00030 - CLEARWATER FL 33767 - 1718 CLEARWATER FL 33767 - 2066 CANADA CHRISTOLINI, CHARLES JR CHRISTOPHER, TODD C CHRISTOPHER, TODD CHRISTOLINI, DARLENE E CHRISTOPHER, WANDA CHRISTOPHER, WANDA 1759 MOREY RD 11 SAN MARCO ST # 1505 3743 PRESIDENTIAL DR SHELDON VT 05483 - 8343 CLEARWATER FL 33767 - 2075 PALM HARBOR FL 34685 - 1075 O SC CIOCIA, JAMES ITRUS COUNTY INVESTMENTS INC CLARK, ROBERT B CIOCIA, TRACY 905 DELAWARE ST CLARK, SANDRA H 187-11 PEPPER PIKE SAFETY HARBOR FL 34695 - 3840 13201 CLAYTON RD LUTZ FL 33558 - 5315 ST LOUIS MO 63131 - 1002 CLARK, TERRY M CLASSON, STEPHEN J COLLETTE, JAMES A CLARK, JANE H CLASSON, KAREN L VAUSE, ROBERT W 16756 WHITES STORE RD 801 HERITAGE RD STE A 10 PAPAYA ST # 806 BOYDS MD 20841 - 9673 DEPERE WI 54115 - 3292 CLEARWATER FL 33767 - 2068 COLLINS, WALTER W COLTER, GEORGE COYTON, JAMES A 9813 COMPASS POINT WAY COLTER, HELEN COLTON, LORI B TAMPA FL 33615 - 4218 521 MANDALAY AVE # 702 421 HAMPTON GREEN CLEARWATER FL 33767 - 1 794 PEACHTREE CITY GA 30269 - 2712 COMPTON VACATION HOME COOKE FAMILY REV TRUST CORAL INVESTMENTS OF PINELLAS REVOCABL 12 GAGE GIRLS RD 18316 DOLLYBROOK LN COMPTON, VICKI L THE BEDFORD NH 03110 - 4704 LUTZ FL 33549 - 5858 5712 SANDALFOOT CIR PLANO TX 75093 - 2912 CORAL MOTEL CONDO ASSN INC CORDEIRO, JACK CORE, CHRIS W PO BOX 1669 CORDEIRO, ALDA 124 CHARTWELL CLEARWATER FL 33757 - 1669 8209 W CRENSHAW ST BEACONSFIELD QC H9W 1 C3 00030 TAMPA FL 33615 - 2118 - CANADA COSTAWAY LLC COSTELLO, JAMES COULTER, WAYNE R 15 HEATH WAY COSTELLO, JENNY L COULTER, PAMELA W BARRINGTON IL 60010 - 9513 19103 MANDARIN GROVE PL 4407 W DALE ST TAMPA FL 33647 - 3095 TAMPA FL 33609 - 3706 COX, THOMAS D CRANOR, DAVID K CRISTIE ANNE ENTERPRISES LLC COX, SHARON K CRANOR, TOWANA K PO BOX 120 10 PAPAYA ST # 706 12043 HAWTHORN RIDGE BLOOMINGDALE IL 60108 - 0120 CLEARWATER FL 33767 - 2068 FISHERS IN 46037 - 8822 CRUDELE, MICHAEL J CUNNINGHAM, TODD W D'AMORE, EUGENE R CRUDELE, SHIELA M 9703 RHAPSODY DR 11 SAN MARCO ST # 607 1516 FOX HILL PL VIENNA VA 22181 - 3240 CLEARWATER FL 33767 - 2061 VALRICO FL 33594 - 4021 DAVIS, DEXTER C DAVIS, DEXTER C DAY, WILLIAM A THE ALEXANDER-DAVIS, LISA DAVIS, LISA ALEXANDER 1968 LAKEVIEW AVE 5806 GALLEON WAY 501 MANDALAY AVE # 1009 DRACUT MA 01826 - 3210 TAMPA FL 33615 - 3634 CLEARWATER FL 33767 - 1703 DAY, WILLIAM A LIVING TRUST DEFERRARI, DIANA DELETIOGLU, ISMET DAY, WILLIAM A THE 110 HARBOR DR 2581 1/2 N CLARK ST 473 EAST SHORE DR PALM HARBOR FL 34683 - 5403 CHICAGO IL 60614 - 1717 CLEARWATER FL 33767 - 2033 ? * DELLATERZA, ROBIN DENTICE, JOSEPH F THE IGIANNANTONIO, GILBERT DELLATERZA, JAMES DENTICE, ELLEN L THE DIGIANNANTONIO, PAULETTE 10 CYPRESS DR 5053 LAKEVIEW CT 3717 WOODRIDGE PL CEDAR KNOLLS NJ 07927 - 1558 OCONOMOWOC WI 53066 - PALM HARBOR FL 34684 - 2449 DIMMITT, LARRY H JR DIORIO, RONALD L DORSCH, DANIEL J 150 WILLADEL DR DIORIO, SANDRA R DORSCH, CYNTHIA P BELLEAIR FL 33756 - 1942 3944 NORTH FIELD DR 6326 W MACLAURIN DR BELLBROOK OH 45305 - 8802 TAMPA FL 33647 - 1163 DOUSE, ROBERT S DOWNS, JANE DOYEL, SEAN DOUSE, GWEN A 50 JONATHAN DR DOYEL, CHRISTOPHER 1605 CLAUDIA WAY NEW ULM MN 56073 - 3343 483 EAST SHORE DR # 2 NORTH WALES PA 19454 - 3679 CLEARWATER FL 33767 - 2033 EASON, GEORGE H ECKALL INVESTMENTS LLC EGAN, JOHN M 409 CLARA DR 2201 4TH AVE N # 200 10 PAPAYA ST # 1604 BRANDON FL 33510 - 3727 ST PETERSBURG FL 33713 - 7911 CLEARWATER FL 33767 - 2057 EGAN, LYNNE A EKREN TRUST ELIAS, SCOTT D 10 PAPAYA ST # 1604 3061 DOXBERRY CT 1435 N CLEVELAND # E CLEARWATER FL 33767 - 2057 CLEARWATER FL 33761 - 2003 CHICAGO IL 60610 - 1135 ELSAKR, ASHRAF ENGEBRETSEN, ARDEN B ENTEL, ROBERT J ELSAKR, MONA ENGEBRETSEN, ELEANORE A 521 MANDALAY AVE APT 902 808 SMOKERISE BLVD 10 PAPAYA ST # 1404 CLEARWATER FL 33767 - 1795 PORT ORANGE FL 32127 - 7783 CLEARWATER FL 33767 - 2058 EPSTEIN, JOEL EQUITABLE HOLDING CO LLC ESPOSITO, TONY EPSTEIN, DIANE A 7667 EQUITABLE DR # 201 501 MANDALAY AVE # 604 40 DEERPATH CT EDEN PRAIRIE MN 55344 - 4626 CLEARWATER FL 33767 - 1710 OLDSMAR FL 34677 - 2054 F S N PROPERTIES LLC FALLER, JANET L PERSONAL RESID FALLON, JOSEPH 9909 RACETRACK RD FALLER, JANET L THE FALLON, SHEILA TAMPA FL 33626 - 4458 521 MANDALAY AVE # 1209 1 RIVERSIDE PL UNIT 302 CLEARWATER FL 33767 - 1797 COVINGTON KY 41011 - 1766 FARRELL, BRIAN M FERRELL, CLIFFORD N FERRO, MICHAEL P FARRELL, CYNTHIA B FERRELL, ROSEMARIE A 3003 SOUTH WELLS 5116 WESTSHORE DR 2328 COLGATE DR CHICAGO IL 60616 - 2739 NEW PORT RICHEY FL 34652 - 8007 FAYETTEVILLE NC 28304 - 5309 FISHER, PAMELA M FISHER, PAMELA FLORIN, WOLFGANG M FISHER, LOUIS R FISHER, NELSON J FLORIN, SUSAN 907 BUNKER VIEW DR 817 BUNKERVIEW DR 13072 PONTOFINO APOLLO BEACH FL 33572 - 2813 APOLLO BEACH FL 33572 - 2812 TRINITY FL 34655 - FLOTO, RONALD J *FORLINI, DOMENIC *ORLINI, PAUL FLOTO, NANCY C FORLINI, FULVIA FORLINI, SHANNON 54 SASSOON ROAD 808 MANDALAY AVE 446 EAST SHORE DR POKFULAM 00000 - CLEARWATER FL 33767 - 1324 CLEARWATER FL 33767 - 2031 HONG KONG FOX, RALPH L III FULLBACH INVESTMENTS LLC FULTON HOMES INC FOX, JOAN A 2201 4TH ST N # 200 70 GIBSON DR UNIT 13 39 PINE RIDGE RD ST PETERSBURG FL 33704 - 4300 MARKHAM ON L3R 4C2 00030 - BUZZARDS BAY MA 02532 - 2118 CANADA GAHERTY, JOHN B SR GAREL-JONES, PHILIP THE GAUDIN, DANIELE GAHERTY, CECILIA G GAREL-JONES, BEATA THE 521 MANDALAY AVE # 305 5527 S PARK AVE 120 LANSDOWNE RD S CLEARWATER FL 33767 - 1793 HINSDALE IL 60521 - 5061 OTTAWA ON K1 M ON4 00030- CANADA GELEP, HELENA EST GELEP, MARY H GIANFILIPPO, JOHN F 2020 BAYSHORE DR GELEP, PAUL A GIANFILIPPO, LAURA L BELLEAIR BEACH FL 33786 - 3425 2020 BAYSHORE DR 162 DEVON DR BELLEAIR BEACH FL 33786 - 3425 CLEARWATER FL 33767 - 2438 GIANFILIPPO, JOHN GIANNAS, SPIRO P GIBSON, PAUL F BURKETT, FRANKLIN S GIANNAS, STATHIA P 521 MANDALAY AVE 1775 CEDAR WAXWING CT 25745 SANTOS WAY CLEARWATER FL 33767 - 1700 PALM HARBOR FL 34683 - 6676 WESLEY CHAPEL FL 33544 - 5513 GILBERT, DONNA J GONZALEZ, EDWARD A GRANT, ERIC GILBERT, HAROLD E GONZALEZ, MARITZA 1004 ROYAL PASS RD 10 PAPAYA ST # 705 9400 LAWS RD TAMPA FL 33602 - 5708 CLEARWATER FL 33767 - 2068 CLERMONT FL 34714 - 9262 GREENBERG, ROBYN B GRIECO, DANIEL J II GRUBER, CRAIG M 11 SAN MARCO ST # 804 GRIECO, DIANE Y 10 PAPAYA ST APT 502 CLEARWATER FL 33767 - 2061 521 MANDALAY AVE CLEARWATER FL 33767 - 2040 CLEARWATER FL 33767 - 1700 GRUDZIEN, SLAWOMIR GUIRGUIS, SAID N HAIST, SCOTT J GRUDZIEN, TERESA GUIRGUIS, MINERVA J HAIST, MELISSA KAY 6713 WEST IMLAY 479 EAST SHORE DR # 6 3659 JUSTIN DR CHICAGO IL 60631 - 1711 CLEARWATER FL 33767 - 2039 PALM HARBOR FL 34685 - 3603 HALE, CAROLYN SMITH HALL, ROGER W HALLERAN, EDWARD M FIELDS, ELIZABETH SMITH HALL, SYLVIA M SIKA, STEPHEN 1107 CONCORD ST 521 MANDALAY AVE.# 803 1005 VICTORIA DR CHATTANOOGA TN 37405 - 3101 CLEARWATER FL 33767 - 1795 DUNEDIN FL 34698 - 5749 HALLERAN, EDWARD M HANNA, ASHRAF F HANNA, VICTORIA SIKA, STEPHEN HANNA, MIRANDA Z HANNA, ATIF 11 SAN MARCO ST # 303 3509 SHORELINE CIR 29W 471 SUNSET RIDGE RD CLEARWATER FL 33767 - 2060 PALM HARBOR FL 34684 - 1727 BARTLETT IL 60103 - 2047 I HARMON, THOMAS S JR HARTMAN, DOLORES M THE WARTMAN, JEFFREY E HARMON, DEANNE L UTA 3-30-82 HARTMAN, MARISA A 3321 W SEVILLA AVE 1850 SAN MATEO DR 5 CORD GRASS LN TAMPA FL 33629 - DUNEDIN FL 34698 - 3719 OLD LYME CT 06371 - 2080 HAYDON, CHARLES R 1601 DRUID RD E CLEARWATER FL 33756 - 4512 HAYNES, ALVIN S HAYNES, BITA P 501 MANDALAY AVE # 401 CLEARWATER FL 33767 - 1708 HEALY, PATRICK J HEALY, MARY 19 DUNCKLEE ST BRIGHTON MA 02135 - 2116 HEALY, PATRICK HEALY, MARY 19 DUNCKLEE ST BRIGHTON MA 02135 - 2116 HEILMANS RESTAURANTS INC 447 MANDALAY AVE CLEARWATER FL 33767 - 2013 HEIDI INVESTMENT TRUST BENJAMIN BUILDERS REALTY TRUST 69 MASS AVE LUNENBERG MA 01462 - 1212 HILDEBRANDT, MARK THE 33 OLD LAKE RD HAWTHORN WOODS IL 60047 - 8018 HIND, GRAHAM R M HOERNIG, LAURA SILVER LODGE TWENTYPENCE RD 337 RIVER BEND RD WILBURTON GREAT FALLS VA 22066 - 4138 ELY CAMBRIDGESHIRE CB63RN 00009- UNITED KINGDOM HORVATH, KLARA HULLING, DON C ROWLAND, CLARENCE E III HULLING, TRICE D 11 SAN MARCO ST # 506 14008 SHADY SHORES DR CLEARWATER FL 33767 - 2060 TAMPA FL 33613 - 1931 HURLEY, G JOHN HYC, PETER HURLEY, MAUREEN JOYCE HYC, ANDY 22 FOXTAIL CIR 505 MANDALAY AVE CHERRY HILLS VILLAGE CO 80113 - CLEARWATER FL 33767 - 1716 4125 ISHAK, REDA H BISHAY, MANAR 12 PINEWOOD HILLS LONGMEADOW MA 01106 - 1663 IVERSON, DONALD D 1001 SAN MARCO ST # 1001 CLEARWATER FL 33767 - J & M PROP APOLLO BEACH 907 BUNKER VIEW DR APOLLO BEACH FL 33572 - 2813 J E C FUNDING INC PO BOX 4689 CLEARWATER FL 33758 - 4689 HEILMAN FAMILY LTD PTNSHP 941 BAY ESPLANADE CLEARWATER FL 33767 - 1002 HILL, ANNE M THE 2510 S DUNDEE ST TAMPA FL 33629 - 6411 HOERNIG, OTTO W HOERNIG, JUANITA S 521 MANDALAY AVE # 1201 CLEARWATER FL 33767 - 1797 HUNTER HOTEL CO PO BOX 7230 DES MOINES IA 50309 - 7230 HYDUK, RANDY HYDUK, APRIL 20539 COUNTRYSIDE DR MACOMB MI 48044 - 3589 IYER, VENKIT S IYER, LAKSHMI V 3469 SHORELINE CIR PALM HARBOR FL 34684 - 1727 J M C FAMILY INVESTMENTS LTD 2201 4TH ST N STE 200 ST PETERSBURG FL 33704 - 4300 J N E BEACH CONDOS LLC JACOBSEN, GLENN C JASIULEVICIUS, ROMAS J 6326 MACLAURIN DR JACOBSEN, BARBARA D 483 E SHORE DR # C-4 TAMPA FL 33647 - 1163 6 FERRAND WOODS CLEARWATER FL 33767 - 2033 SAINT LOUIS MO 63124 -1244 JENNINGS, MARK K JOHNSON 2003 LIV TRUST JENNINGS, VICKI B JOHNSON, GEORGE A THE 8471 FLOWERING CHERRY LN 10 PAPAYA ST # 401 LAUREL MD 20723 - 1010 CLEARWATER FL 33767 - 2040 JONES, THOMAS A GOFORTH, BOB C 14 ARLINGTON ST ASHEVILLE NC 28801 - 2006 JOPPERT, MARCOS SNODGRASS, SUSAN M 5010 W THE RIVIERA ST TAMPA FL 33609 - 3613 KAESTNER, JOHN T KAESTNER,JOANN M 777 CARMAN MEADOWS DR BALLWIN MO 63021 - 7174 KAIZER, JEFFREY R KAIZER, LISA B 3303 LEGAL CREST DR LONGWOOD FL 32779 - KEIR, LEONARD KEIR, BERNTRUD 11 SAN MARCO ST # 1605 CLEARWATER FL 33767 - 2076 KIEFFER, ALAN L KIEFFER, NELLI L 521 MANDALAY AVE # 501 CLEARWATER FL 33767 - 1793 KAHLER, PERRY E KAHLER, VICKI LEE 8927 MAGNOLIA CHASE CIR TAMPA FL 33647 - 2220 KAROUNOS, THEODORE P KAROUNOS, LORRAINE J 444 PINE HILL RD LEONIA NJ 07605 - 1420 KELLY, THOMAS L THE KELLY, KATHLEEN F THE 11 SAN MARCO ST # 401 CLEARWATER FL 33767 - 2060 KLABISCH, MATTHEW M KLABISCH, SUSAN M 11348 CEDARWOOD CT FRANKFORT IL 60423 - 7854 KNOWLTON, JOHN P THE KNUTSON, WILLIAM R II KNOWLTON, CATHIE L THE KNUTSON, CAROLE M W180 N8217 DESTINY DR 501 MANDALAY AVE # 802 MENOMONEE FALLS WI 53051 - 3503 CLEARWATER FL 33767 - 1712 KOENIG, NORBERT KOENIG, BRUNHILDE 44 EILEEN AVE PLAINVIEW NY 11803 - 5203 KOKOMO PROPERTIES LLC 657 SOUNDVIEW DR PALM HARBOR FL 34683 - 4246 KOSENE,STACY 521 MANDALAY AVE # 1102 CLEARWATER FL 33767 - 1797 KOTCHMAN, CASEY J THE 8442 125TH CT SEMINOLE FL 33776 - 3200 .JOHNSON, WILLIAM L 479 EAST SHORE DR # 1 CLEARWATER FL 33767 - 2039 JOYCE, JILL E 521 MANDALAY AVE # 602 CLEARWATER FL 33767 - 1794 KAHRS, CAROLYN J KAHRS, HENRY G 4834 QUILL CT PALM HARBOR FL 34685 - 3699 KARTES, BOB KARTES, MARIA 11 SAN MARCO ST # 1406 CLEARWATER FL 33767 - 2075 KER, G CAMERON KER, LISA A 2426 BUTTERNUT CT DUNEDIN FL 34698 - 2252 KLEINBERG, MILTON M KLEINBERG, MARSHA A 6034 COUNTRY CLUB OAKS PL OMAHA NE 68152 - 2009 KOCH, MYRON KOCH, ELIZABETH 501 MANDALAY AVE # 810 CLEARWATER FL 33767 - 1712 KOPANAKIS, WILLIAM A 501 MANDALAY AVE # 402 CLEARWATER FL 33767 - 1708 KOVACS, ALEX G KOVACS, SANDEE G 323 6TH AVE N INDIAN ROCKS BEACH FL 33785 - 2549 KOVACS, VIOLET K KOZMINSKI, JACEK KROLL, WOLFGANG 23 ROCKAWAY ST KOZMINSKI, GRAZYNA KROLL, LILLI CLEARWATER FL 33767 - 1739 4758 S PULASKI RD 521 MANDALAY AVE # 1006 CHICAGO IL 60632 - 4114 CLEARWATER FL 33767 - 1795 KSIAZEK, STANLEY *KULKARNI, VINEET ?KUNIS, SABINA KSIAZEK, STANISLAWA NAGALE, VISHWANATH KUNIS, NAUM 6713 W IMLAY 3426 DORAL DR 501 MANDALAY AVE # 801 CHICAGO IL 60631 - 1711 WATERLOO IA 50701 - 4628 CLEARWATER FL 33767 - 1712 LBJLLC 630 S GULFVIEW BLVD CLEARWATER FL 33767 - 2642 LA BELLE ELECTRIC INC 24546 21 MILE RD MACOMB MI 48042 - 5111 LA SAL MOTEL CONDO ASSN PO BOX 1054 DUNEDIN FL 34697 - 1054 LAMBRINIDES FAMILY IRREV TRUST 2175 VALLEY VIEW DR ROCKY RIVER OH 44116 - 2860 LEBRON, GEORGE LEBRON, SONIA DUDZIAK 506 TAMARACK DR BARTLETT IL 60103 - 1515 LEVY, MARK S LEVY, DEBORAH T 10005 RADELIFFE DR TAMPA FL 33626 - 2511 LOUIS DEVELOPMENTS LLC 630 S GULFVIEW BLVD CLEARWATER FL 33767 - 2642 LYLE, JOHN F LYLE, NANCY S PMB 247 8905 KINGSTON PIKE # 12 KNOXVILLE TN 37923 - 5021 MACRE, DANIEL M MACRE, ANNETTE 505 MANDALAY AVE # 75 CLEARWATER FL 33767 - 1718 LATCH TRUST 43 CLOUD VIEW RD SAUSALITO CA 94965 - 2006 LEE, PAUL J LEE, AGNES S 9715 STONECLIFF CT CLARENCE NY 14031 - 2439 LIEBERMAN, LAWRENCE T LIEBERMAN, DEBORAH S 10 WILLOWOOD LN OLDSMAR FL 34677 - 2058 LOWE, JEFF LOWE, KATHY 700 DEER VUE LN FENTON MO 63026 - 3562 M B C PROPERTIES II LLC 4500 NORTHWOODS LN BLOOMINGTON IN 47404 - 9420 MAGRATH, JAMES P MAGRATH, CAROL A 2 PRITCHARD LN WESTPORT CT 06880 - 5633 MAJEWSKI, DENISE M TR MALACHOWSKI, JERRY SCHNEIDER, CHRISTINE J MALACHOWSKI, DOROTHY 43 LAKE ADALYN DR 1426 SEMAR CT SOUTH BARRINGTON IL 60010 - 9542 MOUNT PROSPECT IL 60056 - 2984 LAWSON, PETER S 479 EAST SHORE DR # 2 CLEARWATER FL 33767 - 2039 LEVINE, RICHARD LEVINE, BARBARA 5047 OTIS AVE TARZANA CA 91356 - 4207 LOCKETT, THERESA 11 SAN MARCO ST # 1003 CLEARWATER FL 33767 - 2062 LOWRY, RICHARD M LOWRY, ALEXIS 1648 RIPARIAN DR NAPERVILLE IL 60565 - 4173 MACK, DAVID A REVOCABLE TRUST MACK, DAVID A THE 30 JELLIFF LN SOUTHPORT CT 06890 - 1482 MAGUIRE, PAUL J PO BOX 2925 SAN RAMON CA 94583 - 7925 MANDALAY 802 PO BOX 120 BLOOMINGDALE IL 60108 - 0120 MANDALAY BEACH CLUB CONDO MANDALAY BEACH CLUB LTD MANDALAY BUILDING ASSN 2201 4TH ST N STE 200 PARTNERSHIP 2201 4TH ST N # 200 ST PETERSBURG FL 33704 - 4300 499 MANDALAY AVE ST PETERSBURG FL 33704 - 4300 CLEARWATER FL 33767 - 2045 * . MANDALAY LAND TRUST MANION, JOSEPH M MARCO, SAN TRUST 3711 SWANN AVE MANION, JANINE M CHASE, WALTER W BEN TAMPA FL 33609 - 4521 10118 BENNINGTON DR 11 SAN MARCO ST # 1405 TAMPA FL 33626 - 2406 CLEARWATER FL 33767 - 2075 MAROTTOLI, ANTHONY MARRULLIER, ALAN H MARY G REALTY INC 10 PAPAYA ST # 306 501 MANDALAY AVE # 706 490 MANDALAY AVE CLEARWATER FL 33767 - 2040 CLEARWATER FL 33767 - 1711 CLEARWATER FL 33767 - 2007 MAUER, CHRISTOPHER M MAZAS LAND TRUST MC CARTHY, EUGENE REV TRUST CAPABIANCO, MONICA A MAZAS, BILL W THE 2505 ENTERPRISE RD 483 EAST SHORE DR # 2E 1600 GULF BLVD # 7117 CLEARWATER FL 33763 - 1100 CLEARWATER FL 33767 - 2033 CLEARWATER FL 33767 - 2973 MC CULLOUGH, JACKIE E MC DERMOTT, JAMES T MC DERMOTT, JAMES T 744 BAY ESPLANADE DRAPP, SHANNON M DRAPP, SHANNON M CLEARWATER FL 33767 - 1411 501 MANDALAY AVE # 702 521 MANDALAY DR # 904 CLEARWATER FL 33767 - 1711 CLEARWATER FL 33767 - 1795 MC LAY, DAVID THE MC SWIGGIN, JAMES MEEHAN, THOMAS P PO BOX 7153 MC SWIGGINS, CHERYL A 521 MANDALAY AVE # 810 CLEARWATER FL 33758 - 7153 12 SAXONY ST CLEARWATER FL 33767 - 1795 CLIFTON PARK NY 12065 - 1655 MENKE DEV MESTAS, DONALD M JR MIHOLICS, JOHN C 1053 ST GREGORY ST MESTAS, CAROL S MIHOLICS, MARIA T CINCINNATI OH 45202 - 1733 521 MANDALAY AVE # 1108 18 WINGATE PL CLEARWATER FL 33767 - 1797 YONKERS NY 10705 - 1533 MIKHAIL, MAGUED N MILLINGTON, CHARLES J MINA, GEORGE I MARZOUK, CHRISTIANE G MILLINGTON, JULIA B MINA, AMAL A 591 BELTED KINGFISHER DR N 11 SAN MARCO ST # 1006 4783 EDGE PARK DR PALM HARBOR FL 34683 - 6149 CLEARWATER FL 33767 - 2062 OLDSMAR FL 34677 - 4845 MITCHELL, SALLY P MOHR, GREGORY A MOLLER, ANDREW K 4 SMITH ST MOHR, KATHLEEN L 12175 OXBOW DR CHELMSFORD MA 01824 - 1702 2873 ROEHAMPTON CLOSE EDEN PRAIRIE MN 55347 - 4261 TARPON SPGS FL 34688 - 8426 MOMESSO, NOELLA MOMESSO, SERGIO F MORRIS, MICHELLE V MOMESSO, SERGIO MOMESSO, NOELLA NOORY 29 GAYLORD GLEN 10 JONQUILLE 10 JONQUILLE WATERBURY CT 06708 - 2100 KIRKLAND QC H9H 3C4 00030 - KIRKLAND QC H9H 3C4 00030 - CANADA CANADA MOULTS, JAMES M MUDD, JAMES A MURRAY, SUSAN L MOULTS, SUSAN B MUDD, CECELIA K 902 ANCHORAGE RD 3302 ROCKY BEACH RD 6919 CHANCELLOR DR TAMPA FL 33602 - 5754 MC HENRY IL 60051 - 9669 CEDAR FALLS IA 50613 - 6956 NAGALE, VISHWANATH T *NEAL,RALPH C *NEUWOLF PARTNERS NAGALE, PUSHPAMALA V NEAL, JULIE A 2100 CLEARWATER DR 521 MANDALAY AVE # 508 4622 OSAGE CT OAK BROOK IL 60523 -1927 CLEARWATER FL 33767 - 1793 GREENBAY WI 54313 - 9531 NOLL, STEPHEN A NORUS, KEVIN NOVICKY, STEVEN D NOLL, DEBORAH V 11816 MARBLEHEAD DR NOVICKY, KIMBERLY M 501 MANDALAY AVE #"701 TAMPA FL 33626 - 2553 5850 DEER SPRING RUN CLEARWATER FL 33767 - 1711 CANFIELD OH 44406 - 7613 NOVOGRATZ, JOSEPH O'HANLEN, PETER OLIVER, BRIAN C 7667 EQUITABLE DR O'HANLEN, TERRIE OLIVER, JEANINE H EDEN PRARIE MN 55344 - 3696 10 PAPAYA ST #1102 3739 MULLENHURST DR CLEARWATER FL 33767 - 2056 PALM HARBOR FL 34685 - 3661. OLIVER, ROBERT ORISSA PROPERTIES LTD P K & J K INC OLIVER, CHARLOTTE B 31 BROAD ST 5020 CENTRAL AVE 521 MANDALAY AVE # 1210 ST HELIER JERSEY JE4 CXW 00000 ST PETERSBURG FL 33707 - 1942 CLEARWATER FL 33767 - 1797 - CHANNEL ISLANDS P S B CREDIT SERV INC P S B CREDIT SERVICES INC PACK, JAMES D PO BOX 38 508 3RD ST PACK, MARY B PRINSBURG MN 56281 - 0038 PRINSBURG MN 56281 - 3700 30146 E TOPAZ DR SCOTTSDALE AZ 85258 - PAPAYA TRUST PAPPAS, PETER C PARADES, ANTONIO M 11 SAN MARCO ST # 1405 225 ROBINSON ST # 540 10 PAPAYA ST # 903 CLEARWATER FL 33767 - 2075 ORLANDO FL 32801 - 4321 CLEARWATER FL 33767 - 2055 PARAMOUNT LLC PARKDALE LLC PAULL, DENNIS M 1803 BRIAR CREEK BLVD PO BOX 17660 PAULL, DIANE P SAFETY HARBOR FL 34695 - 4696 CLEARWATER FL 33762 - 0660 10104 RADCLIFFE DR TAMPA FL 33626 - 2512 PECORARO, ERNEST A PENN COMMONS LP PERNICE, SALVATORE J PECORARO, NYDIA 871 BEAVER DR PERNICE, BARBARA F 11 SAN MARCO ST # 112 DUBOIS PA 15801 - 2511 3 N 614 CENTRAL CT CLEARWATER FL 33767 - 2066 ADDISON IL 60101 - 3052 PERRY, GREGORY G PERTILE, RICHARD K PETERS, MICHAEL L LAHN, MONICA L PERTILE, DEBORAH J PETERS, STEPHANIE S 1574 SHINING ORE DR 1137 MARINA DR 22 CLYDE GRUVER RD BRENTWOOD TN 37027 - 2218 TARPON SPRINGS FL 34689 - 6713 BINGHAMTON NY 13901 - 6022 PETH, NICK A PFAFF, ROBERT PHILLIPS, HAROLD PO BOX 580 PFAFF, BETTY 2459 TWINBROOKE RD WAYNESVILLE OH 45068 - 0580 521 MANDALAY AVE # 404 HICKORY NC 28602 - 8721 CLEARWATER FL 33767 - 1793 * PILATO, SAM A PIMENIDIS, JOHN H IMENIDIS, JOHN H PILATO, TALMA PIMENIDIS, CHRISTINA PIMENIDIS, CHRISTINA 3257 NICKS PL 1651 SAND KEY ESTATES CT # 11 440 EAST SHORE DR CLEARWATER FL 33761 - 2017 CLEARWATER FL 33767 - 2933 CLEARWATER FL 33767 - 2031 PITTMAN, C CHRISTOPHER PLANES, REGINA M PLANES, REGINA PITTMAN, KAREN G 32700 US HIGHWAY 19 N 854 CYPRESS LAKEVIEW CT 1099 SHIPWATCH CIR PALM HARBOR FL 34684 - 3119 TARPON SPRINGS FL 34688 - 7307 TAMPA FL 33602 - 5736 PODGURSKI, MICHAEL A POMS, ALAN M POOLE, WILLIAM L III PODGURSKI, LINDA G 521 MANDALAY AVE # 1007 ROBINSON, JOHN CONNIE JR 1125 W POWDERHORN RD CLEARWATER FL 33767 - 1795 3 HUNTERS CROSSING CT MACHANICSBURG PA 17050 - 2007 THE WOODLANDS TX 77381.- 4757 POTTER, PASCHOALENA POTTER, PASCHOALINA C PRESTON, MICHAEL G THE 463 EAST SHORE DR PO BOX 2535 419 E SHORE DR CLEARWATER FL 33767 - 2033 SALISBURY MD 21802 - 2535 CLEARWATER FL 33767 - 2028 RAGHAVAN, CHAKRAVARTHY RAMOS, JAMES A RE, C JOHN RAGHAVAN, VASANTHY RAMOS, CONNIE R PULLARA, JOSEPH A 8918 SOUTHERN BREEZE DR 501 MANDALAY AVE # 310 427 LOCH DEVON DR ORLANDO FL 32836 - 5012 CLEARWATER FL 33767 - 1707 LUTZ FL 33548 - 4282 RECEVEUR, RONALD L REHKEMPER, PHILIP A REINHARDT, MARK 6012 REGAL SPRINGS DR REHKEMPER, BARBARA A REINHARDT, CONNIE K LOUISVILLE KY 40205 - 3319 521 MANDALAY AVE # 1105 N3080 MEADE ST CLEARWATER FL 33767 - 1797 APPLETON WI 54913 - 9571 REISS, KENNETH P RENDEL, JEROLD S TRUST RESIDENCES AT SANDPEARL 11 SAN MARCO ST # 308 660 SNUG ISL RESORT CLEARWATER FL 33767 - 2060 CLEARWATER FL 33767 - 1829 2201 4TH ST N STE 200 ST PETERSBURG FL 33704 - 4300 RICCIARDI, DEBORAH RIGBY, GREGORY S ROBULAK, KENNETH J 7167 LANDMARK DR RIGBY, CAROLE J ROBULAK, PATRICIA J SPRING HILL FL 34606 - 6145 124 OWASCO ST 521 MANDALAY AVE # 302 AUBURN NY 13021 - 4114 CLEARWATER FL 33767 - 1793 RODWELL, ERIC V ROSCOE, GREGORY J ROSSDALE MGMT INC RODWELL, DONNA M ROSCOE, LINDA L 120 LANSDOWNE RD S 11 SAN MARCO ST # 408 PO BOX 308 OTTAWA ON K1 M ON4 00030 - CLEARWATER FL 33767 - 2060 DUBOIS PA 15801 - 0308 CANADA ROTH, ELIZABETH W ROWLAND, CLARENCE E III ROWLAND, CLARENCE E III 8826 NAUTILUS DR 2112 WATERS AVE HORVATH, KLARA TAMPA FL 33635 - 1339 TAMPA FL 33604 - 2748 11 SAN MARCO ST # 602 CLEARWATER FL 33767 - 2060 RUDE a LL, KEITH ORUKAVINA, JAMES *AID, NADER RUDELL, ROSAMAR RUKAVINA, DIANNE SAID, HALA 4143 CASTLE AVE BOX 6448 11 SAN MARCO ST # 1007 SPRING HILL FL 34609 - 2309 EDSON AB T7E 1T8 00030- CLEARWATER FL 33767 - 2069 CANADA SALTZMAN, MURRAY SAMEE, AHMED B SAMPSON, THOMAS A SALTZMAN, BARBARA 1182 PINE RIDGE CIR # E3 SAMPSON, CAROLYN L 1170 GULF BLVD # 306 TARPON SPRINGS FL 34688 - 6423 11 SAN MARCO ST # 1202 CLEARWATER FL 33767 - 2780 CLEARWATER FL 33767 - 2069 SAND KEY CONSULTING LLC SAND KEY CONSULTING LLC SANDOZ, DAVID C 1015 NORTH RIVER WALK E BOBAK, WLADYSLAW SANDOZ, ANN L CHICAGO IL 60610 - 7398 180 DINAH RD 523 N OKLAHOMA AVE MEDINAH IL 60157 - MORTON IL 61550 - 2373 SCHAEFER, RANDY THE SCHECHTER, JANIS ILENE SCHUTZENDORF, GILBERT H THE 3225 S MACDILL AVE # 268 REVOCAB SCHUTZENDORF, ALICE M THE TAMPA FL 33629 - 8171 12103 MARBLEHEAD DR 19029 US HIGHWAY 19 N # B8 TAMPA FL 33626 - 2505 CLEARWATER FL 33764 - 3015 SERAG, SHERIF SHEAR, MARILYN F SHEPPARD, KERILYN LEWIS-SERAG, MAHA 2650 MCCORMICK DR STE 130 SHEPPARD, KRISTIN 11 SAN MARCO ST # 1206 CLEARWATER FL 33759 - 1062 328 SIX MILE RD CLEARWATER FL 33767 - 2075 WHITMORE LAKE MI 48189 - 9565 SHIVERS, EDWARD T SIINO, WILLIAM J SMITH, DONALD F THE SHIVERS, HAZEL E SIINO, MICHAEL T SMITH, MARY H THE 10 PAPAYA ST # 505 13519 FALCON POINTE DR 11 SAN MARCO ST # 1506 CLEARWATER FL 33767 - 2040 ORLANDO FL 32837 - 5327 CLEARWATER FL 33767 - 2075 SMITH, MERLE W SNYDER, CLIFFORD D SOBEL, KATHY SMITH, DIANA T SNYDER, MARYLIN V 11 SAN MARCO ST # 503 11 SAN MARCO ST # 1201 1650 WACHTLER AVE CLEARWATER FL 33767 - 2060 CLEARWATER FL 33767 - 2069 SAINT PAUL MN 55118 - 3745 SOBOTKA, JOSEPH J SOLENZIO, STEPHEN M SOTEREANOS, STELLA SOBOTKA, SYLVIA R 131 COMMERCIAL PKWY # 3A SOTEREANOS, STACEY 52 THOROUGHBRED DR BRANFORD CT 06405 - 2539 307 S DITHRIDGE # 808 HOLLAND PA 18966 - 2570 PITTSBURGH PA 15213 - 3519 SPARKS, SUSAN M ST JOHN, DENNIS THE STANISLAWEK, DANIEL 11 SANMARCO ST N # 1105 ST JOHN, VALERIE STANISLAWEK, GRETA CLEARWATER FL 33767 - 2069 342 E JERICHO TPKE 501 MANDALAY AVE # 309 MINCOLA NY 11501 - 2111 CLEARWATER FL 33767 - 1707 STENBERG, ANDREW STEPHANS, SUSAN STOJAK, JAMES L 10 PAPAYA ST # 301 STEPHANS, DORIS STOJAK, ROBIN L CLEARWATER FL 33767 - 2040 803 S GULFVIEW BLVD # 308 3964 MULLENHURST DR CLEARWATER FL 33767 - 3004 PALM HARBOR FL 34685 - 3665 SUCHARSKI, FRANK J SSUN HARBOR CONDO ASSN INC •SWIDEREK, TIMOTHY J SUCHARSKI, CATHERINE J 479 E SHORE DR APT 6 SWIDEREK, JOSEPH A 248 AMERICAN DR CLEARWATER FL 33767 - 2039 4540 WEATHERVANE DR RICHBORO PA 18954 - 1141 ALPHARETTE GA 30022 - 3759 TADROS, HANI S TANKEL, ROBERT L TAYLOR, DAVID R YASSAOUI, SUZANNE TANKEL, TERRI G WALTERS, JAMES 2184 LAURENCE DR 1022 MAIN ST # D 11 SAN MARCO ST # 1004 CLEARWATER FL 33764 - 6466 DUNEDIN FL 34698 - 5237 CLEARWATER FL 33767 - 2062 TAYLOR, JOHN S III TEJEDA, RAFAEL E TEMA INVESTMENTS 400 MANDALAY AVE TEJEDA, IDELFIA A 3135 SW 3RD AVE CLEARWATER FL 33767 - 2011 3516 WOODRIDGE PL MIAMI FL 33129 - 2711 PALM HARBOR FL 34684- 2434 THOMAS-KIRSCHKE, HEIDI THWAITE, EDWARD W THWAITE, EDWARD 525 MANDALAY AVE # 24 THWAITE, PATRICIA A THWAITE, PATRICIA CLEARWATER FL 33767 - 1798 15 LOOK OUT POINTE TRL 15 LOOKOUT POINT TRL TOTOWA NJ 07512 - TOTOWA NJ 07512 - 1611 TILLY, CARL H TILLY, MARK A TOUCHTON, JOANN TILLY, JILL E DEL ROSE, MARYELLEN TOUCHTON, WALTER W 436 COUNTRY CLUB RD 266 LYNDHURST ST 10 PAPAYA ST # 702 BELLEAIR FL 33756 - 1005 DUNEDIN FL 34698 - 7578 CLEARWATER FL 33767 - 2054 TOUCHTON, WALTER W THE TSANGARIS, WILMA B TURLEY, STEWART TOUCHTON, JO ANN H THE TSANGARIS, NICHOLAS TURLEY, LINDA A 10 PAPAYA ST # 702 11 SAN MARCO ST # 1606 10 PAPAYA ST # 1504 CLEARWATER FL 33767 - 2054 CLEARWATER FL 33767 - 2076 CLEARWATER FL 33767 - 2057 URINO, FRANK N & NATALIE TRUST VISOSO, ROBERTO VITOLA, JOHN R 1627 MIDNIGHT PASS WAY VISOSO, GRACIELA VITOLA, GEORGINE A CLEARWATER FL 33765 - 1821 521 MANDALAY AVE # 307 218 S BROAD ST CLEARWATER FL 33767 - 1793 BROOKSVILLE FL 34601 - 2832 W J C C IRREVOCABLE RESIDENCE WANDACHOWICZ, BOGDAN WARD, MICHAEL S 10 PAPAYA ST # 606 10 PAPAYA ST # 1001 WARD, GISELLE V CLEARWATER FL 33767 - 2054 CLEARWATER FL 33767 - 2055 407 SOUTH ROYAL PALM WAY TAMPA FL 33609 - 3728 WARSTLER FAMILY TRUST WATSON, KENNETH WEBER, JED P WARSTLER, ARTHUR K THE 713 NEW YORK AVE WEBER, JILL E 521 MANDALAY AVE # 905 PALM HARBOR FL 34683 - 3426 505 MANDALAY AVE N # 42 CLEARWATER FL 33767 - 1795 CLEARWATER FL 33767 - 1717 WELLS, DARCY L WEST FINANCIAL CORP WILLIAMS, BERNABE REVOCABLE NALEY, STEVE W FORLINI, DOMENIC AFD TR 705 BAY ESPLANADE AVE 808 MANDALAY AVE WILLIAMS, BERNABE THE CLEARWATER FL 33767 - 1409 CLEARWATER FL 33767 - 1324 1204 SUNCAST LN STE 2 ELDORADO HILLS CA 95762 - 9665 WILSON, CHRISTINE DEFERRARI WILSON, MARK A 136 HARBOR DR PALM HARBOR FL 34683 - 5403 YOURTH, BRADLEY J YOURTH, VALERIE R 501 MANDALAY AVE # 405 CLEARWATER FL 33767 - 1708 ZILISCH, BARBARA L THE 11 SAN MARCO ST # 708 CLEARWATER FL 33767 - 2061 ?YEAROUT, JANE R YEAROUT, JANET A 806 NARCISSUS CLEARWATER BCH FL 33767 - 1334 ZAKHARY, ATEF S 11 SAN MARCO ST # 603 CLEARWATER FL 33767 - 2060 *OFAN, ABRAHAM REAL ESTATE TRU YOFAN, AVI THE 10 PAPAYA ST # 1202 CLEARWATER FL 33767 - 2056 ZAMANI, SAM S FEIZIPOUR, MAHVASH 1957 LOGAN MANOR DR RESTON VA 20190 - 3276 NFPA 303 CHAPTER 4 NFPA 303 CHAPTER 4 CHAPTER 4 MANAGEMENT CHAPTER 4 MANAGEMENT NFPA1 4.7* SMOKING RESTRICTIONS. CHAPT 4.1.1 SMOKING SHALL $E PROHIBITED (N THE FALLOWING AREAS; 4.6.1 SIGNS, P057ERS, OR POSTED INSTRUCTIONS SHALL 8E PROVIDED 4.1 GE (1) WHERE FUELS AND OTMER FLAMMABLE UQUIdS ARE STORED OR WHERE PRACTICAB4E TO REMIND THE PUBLIC OF BASK FIRE SAFETY 4.1,1 S DISPENSED PRACTICES AND TO WARN OF UNUSUAL dR EXTREME FIRE HAZARDS. ACCOR NFPA 14 CHAPTER ~ GH~A?PTER ~ SYSTEM! Ct~144PC3RIEidTS ANiJ H~4~ttT4~ARE 4.9 ~ GENEI~IL. 4.,'!,9 STANDPIPE SYSTEM COMPt~NENTS AND HARDV1fARE SHALL BE IN ~ACCC?RDANCE WITH THIS CHAPTER. (2) COVERED QR ENCLOSED BOAT STQRAGE AREAS 4.5.2 ALL BOAT dWNERS AT THE MARINA SHALL BE PROVIDEQ WITH 4.1.2 A (3) BATTERY ROOMS WRITTEN INSTRUCTIONS FOR REPORTING FIRES AND OTHER EMERGENCIES SHALL (4) LOCATIONS DESIGNATED BY MANAGEMENT OR THE AUTHORITY AND ACTIONS TO BETAKEN IN THE EVENT OF A FIRE. 4.1.3 C HAVING JURISDICTION 4.7 OPEN-FLAME DEVICES. OPEN-FLAME DEVICES USED FOR LIGHTING SUCH 4.1.2 "NO SMOKING' SIGNS SHALL BE POSTED IN THE AREAS IDENTIFIED OR DECORATION SHALL NOT BE USED ON A FLOAT, PIER, OR BULKHEAD TO BE IN 4.1.1. UNLESS APPROVED BY 7HE AUTHORITY HAVING JURISDICTION. 4.2 PIP 4.2 MAINTENANCE OF FIRE-FIGHTING EQUIPMENT AND SYSTEMS. A 4.2.1 PI MAINTENANCE PROGRAM THAT REQUIRES PERIODIC INSPECTION, TESTING, EXCEE AND QPERATiON OF FIRE-FIGHTING EQUIPMENT AND SYSTEPAS AND NFPA 303 CHAPTER 6 WITH 4. 4.'1,2 ALL DEVICES AND MATERIALS USED !N STANDPIPE SYSTEMS SHALL BE LISTED, EKGEPT AS PERMITTED tN 4.1.3. 4k.1,3 COMPONENTS THAT D© NOT AFFECT SYSTEM PERFORMANCE SUCH AS DRAIN PIPING, DRAIN VALVES, AND SIGNS SHALL NOT SE REC~UIRED TO BE LISTED. 4.2 PIPE B~?ND TUSE. 4.2.'I PIPE OR TUBE USED IN STANDPIPE SYSTEMS SHALL MEET t3R E~CCEED GIVE t)F THE STANDARDS IN TABLE 4.2.1 OR SHALL BE IN ACCORDANCE WITH 4.2.2 THFiC9UGH 4.2.6. ENSURES ACCESS TO ALL PARTS OF THE FACILITY FQR FIRE-FIGHTING PERSONNEL 6.6 HYDRANTS AND WATER $UPPUES. HYpRANTS AND WATER SUPPLIES q,y,2 W SHALL BE ADOPTED. FOR FIRE PROTECTION tN MARINAS AHD BOATYARDS SHALL BE PROVIDED TABLE 4.2.2 It1iHlRE DlfC7'flrE IRAN PIPE IS tNST'ALLED IN ACCORDANCE WITH TABt_E 4.2.1, !T SHALL BE LIMED IN ACCORDANCE WITH AWWA 0144, 4.2.1 ALL FIRE-FIGHTING EQUIPMENT ANd SYSTEMS SHALL BE INSPECTED IN ACCORDANCE WITH NFPA 13, STANDARD FOR THE INSTALLATION CEMEN CEtI~fE#VT fvlORT'~R LlJiffNG FAR ~3~CT1d.E fl4t'~f~ PfPE AfVC3 F1TTffVGS' FOR INA~"Ef~ . AND TESTED AT REGULAR INTERVALS. OF SPRINKLER SYSTEMS; NFPA14, STANDARD FOR THE fNSTALLATlON OF q,y,3 W 4.2.1.1 FIRE EXTINGUISHERS SHALL BE INSPECTED AT LEAST ANNUALLY STANDPIPE JOINED 4.7.3 INHERE STEEL PIPE SPEGII~IED !N TABLE 4.2,1 IS USE© AND JOINED BY V1fELD1~lG AS SPECIFIED IN SECTION 4.4 OR BY ROLL-GROOVED . AND HOSE SYSTEMS; AND NFPA 24, STANDARD FOR THE INSTALlATfON PIPE A 4.2.2 FIRE DEPARTMENT ACCESS. _ OF PRIVATE SIRE SERVICE MAINS AND THEfR APPURTENANCES. WALL 4.2.2.1 THE FIRE DEPARTMENT SHALL HAVE ACCESS TO FENCED, PIPE AND FITTlN~GS A~ SPECIFIED IN SECTION 4.4, THE MIN{MUM NOMINAL WALL THICKNESS FOIE PRESSURES UP TO 3f~6 PSI (Zd.7 BAR} SHAt.L BE IN GATED, OR LOCKED GROUNDS OR PIERS. 6.8 MAINTENANCE. ALL SPRINKLER SYSTEMS, STANDPIPE SYSTEMS, WATER ACCO 4.2.2.2 APPROPRIATE MEANS OF ACCESS SUCH AS KEYS, CARDKEYS, OR SUPPLY FACILITIES, AND FIRE PUMPS SHALL BE MAfNTAINED W p,~gq ~ COMBINATIONS SHALL BE PRQVIDED TO THE FIRE DEPARTMENT OR SHALL ACCORDANCE WITH NFPA 25, STANDARD FOR THE NV3PEGTtON, TESTING, (4.78 M - BE PERMITTED TO BE SECURED IN A LOCK BOX ON THE PREMISES AND MAINTENANCE flFWATER-BASED FIRE PROTECTfON SYSTEMS. 4.2.3.1 ACCESSIBLE TO THE FIRE DEPARTMENT.. LISTED ACCORDANCE 1NITH SCHEDULE 10 FUR PIPE SIZES UP TO 5 iN. {127 MM), 0,134 IN. (3.44 MIV1} FQR 6 IN. j150 Ml1t1} PIPE, AND 0.1881N. (4.78 MM} FUR 8 IIV. AND 10 IN. ~20~ MM AND 254 MM} PIPE, x.2.3.1 PRESSURE LIMITATIONS AND WALL- THICKNESS FC~R STEEL PIPE LISTED IN ACCORDANCE VS11TH 4.2,6 SHALL BE IN ACCOR©ANCE 1t~fITH THE 4.2.2.3 THE FIRE DEPARTMENT SHALL BE NOTIFIED IMMEDIATELY OF 3 7.11 LISTIN ANY CHANGES IN THE MEANS OF ACCESS. CHAPTER 7 WATER SUPPLY FOR FIRE PROTECTfON 4.2.4 W d.3* EMPLOYEE TRAINING. THREA 4.3.11 PRACTICE DRILLS SHALL BE HELD AT LEAST TWICE A YEAR. 7.1 HYDRANTS AND H03E CONNECTIONS. W~T~ p LISTING REQUIREMENTS. 4.2.41NHERE STEEL PIPE SPECIFIED IN TABLE 4.2.1 IS JOINED BY THREAQED FITTINGS AS SPECIFIED IN SECTION 4.4 ~?R 8Y FITTINGS EJSED VlfITH PIPE HAVING CUT GRC3UVES, THE MINIIItIUM MALL THICKNESS 4.3.2• AlL EMPLOYEES SMALL KNOW THE LOCATION OF FIRE-FIGHTING 7.1.1 A SUFFICIENT NUMBER OF ACCESSIBLE HYDRANTS OR 64 MM SHALL EQUIPMENT. (21/21N,) HOSE OUTLETS SHALL BE PROVIQED OH OR IMMEDIATELY ADJACENT AND L 4:3:3 EACH EMPLOYEE SHAlL;SE INSTRUCTED IN THE PROCEDURES TO EVERY PIER, WHARF, OR MARINE TERMINAL YARD FOR USE BY SHALL SE IN ACCORDANCE WITH SCHEDULE 30 [SIZES 8 IN. {263 MM} AND LARGER] OR SC;HEC3ULE 4Q jSit ES LESS THAN 8 !N. ~ZQ3 MM}] PIPE F~3R PRESSURES UP TQ~ 300 PSI X20.7 BAR). FOR RESPONDING TO A FIRE, RESPQNDING TO A FIRE ALARM, AND REPORTING PUBLIC OR PRIVATE FIRE DEPARTMENTS FOR EX1'iNGUISHING LARGE PIPE F STRUCTURE AND CONTENTS FIRES RND FOR USE IN PROV{DING EXPOSURE 4,2'4.7 A FIRE TO THE PROPER AUTHQRiTtES (AND TO DESIGNATES SPECI FACILITY EMPLOYEES), AS WELL AS THE EMPLOYEE'S DESIGNATED PROTECTION. WITH T ~.Z.4.1 PRESSURE L?t~~1ITATtt}NS ANC} WALL THICKNESSES FOR STEEL PIPE SPECIALLY LISTED f~! ACCORDANCE 1ftlITH 4.2.6 SHALL BE !N ACCORDANCE UVITH THE LISTING REQUIREMENTS. ROLE(S) IN PREFIRE PLANNING MATTERS. {SEE SEG710N 4.4.) 4.2.5 C 4.3.4 ALL EMPLOYEES, INCLUDW~ OFFICE PERSONNEL, SHALL BE 7.1.2 THE NUMBER AND LOCATION OF WYDRANT8 AND HOSE CQNNECTIONS TABLE 4.2.5 CAPPER TUBE AS SPECIFIED IN THE STANDARDS REFERENCED IN TABLE 4.2.1 SHALL~HAVE A WALL THICKNESS OF .TYPE K, L, QRNiWHERE GIVEN TRAINING IN THE USE OF PORTABLE FIRE EXTINGUISHERS. SHALL BE DETERMINEQ BY THE AUTHORITY HAVING JURISDICTI(1N USED ~ 4.4 FIRE DEPARTMENT LIAISON. BUT SHALL NOT BE SPACED FURTWER APART THAN 90 M (300 FT} QR 4.2.6 O 4.4.4 THE LOCAL FIRE DEPARTMENT SHALL VISIT THE FAC{LITY ANNUALLY MORE THAN 45 M (150 FT) FROM ADEAD-END AREA. INSTAL TO BECOME ACQUAINTED WITH EVERY PART Q~ THE FACILITY AND TO LIMITE CONDUCT EMPLOYEE TRAINING SESSIONS. 7.2.4 PIPING, PUMPS, AND OTHER FACILITIES SHALL BE DESIGNED SHALL USED IN STANDPIPE SYSTEIVIS. x.2.6 C~1'HER TYPES C7F PIPE C,)R TUBE INVESTIGATED FUR USE IN STANDPIPE INSTALLATIONS AND LISTED FC?R THIS SERVICE, INCLUDING, BUT NOT LIIVIlTED TCJ, STEEL DIFFERING FR{3M TMAT PROVIDED IN TABLE 4,2,1, SHALL BE PERMITTED WHERE INSTALLED IN ACCORDANCE ~fiflTH THEIR 4.4.2 MANAGEMENT SHALL ASSIST THE FIf2E DEPARTMENT IN PREFIRE AND INSTALLED IN ACCORDANCE WIFH THE REQUIREMENTS OF NFPR20, LISTIN PLANNING FOR THE FOLLOWING: STANDARD FdR THE INSTALLATION OF STATIONARY PUMPS FOR FIRE PROTECTION ; LISTING LIMITATIONS, INCLI,.IDING INSTALLATIdN tNSTRUGTION~. (1) ENTRIES AND ACCESS ROUTES FdR EQUIPMENT WITMIN THE PREMISES NppA 22, STANDARD FOR WATER TANKS FOR PRIVATE FIRE PROTECTION; AND (2) LOCATION, CONSTRUCTION, USE, AND ACCESSIBILITY OF ALL, BUILDWGS NFPA 24, STANDARD FOR-THE lNSTALLAT/0N OF PRIVATE FIRE SERVICE MAINS AND ALL THEIR SUBDIVISIONS INCLUDING BASEMENTS AND AND THEIR APPURTENANCES. STORAGE LOCKERS (3) LOCATIQN AND EXTENT OF OUTSIDE WORKING AREAS 7.2.5* FIRE DEPARTMENT PUMPER CONNECTIQNS AND SIMILAR {4}LOCATION AND MEANS OF ACCESS 70 BOTH DRY AND WET 80AT SUPPLEMENTAL OR AUXILIARY SUPPLIES THAT UTILIZE NONPOTABLE WATER CLASS ~LA~~ ~ SET NAND PIPE ~Y~TEM WIT~I PF~IMAFIY STORAGE AREAS OR ~iVATER SOURCES OTHER THAN THE PUBLIC WATER SYSTEM SHALL TIE TO (5) TYPE AND CAPACITY OF WATER LINES ON PIERS AND WALKWAYS, CONFORM TO LOCAL AND STATE LAWS AND REGULATIONS. WITH 6 tNCIUDING ALL POINTS WHERE CONNECTION OF HYDRANT OR TIE TO E~~ST'ING CITY OF' C~EARWATEF~ MAIN . WITH WET TAP. SYSTEM CON~I~T~ OP PVC PUMPER SUPPLIES CAN BE AFFECTED Zoos eolrioN C-9fl~ D ~-9~{~ DI~14 ~I~E MAIN LINE WITH- FDA 7~ BEET ~t~l~M (6) TYPES AND CAPACITIES OF FACILITY EQUIPMENT, INCLUDING WORK AND EX AND EXISTING ~IT'Y O~ ~LEARWATEI~ ~lFt~ dR TOW BOATS, PORTABI:E PUMPS, PIER-MOUNTED HOSE CABINETS, HYDRA AND ALL PORTABLE FIRE EXTINGUISHERS I--IYDRANT. THE SYSTEM 1=E~DS SEVEN ~ 11~'! 1=1F~E (7y VOLTAGES AND CAPACITIES OF ELEO7RICAl SYSTEMS ANO LOCATION HOSE C HOSE ~ONNEGT'IC~NS. SYSTEM FATED AT 1 PSI AT OF ELECTRICAL dISCdNNECTiNG MEANS 500 GPI 5 pR°~E~T: Clearwater Recreatipn Center s~{? GPM 1~=01~ 4 I'-~OURS. MICHAEL J. GAYLt'3R ~ ~ CERTIFIED PROFESSIONAL 4 ENGINEER ~ DRAWN BY: DATE: SCALE : CHECKED 8Y: DATE: OSPREY COVE PROFESSIONAL OFFICE PARK .STATE OF FLORIDA NO. 13098 X1764 STATE RC3AD 54, LUTZ, FL 33549 PH. {813} 949-5599 FAX {8~3} S49-Q818 _ . 2 APPD BY: DATE: R 1 DATE: 3~3~I~~ SHEET i , I ~P MICHAEL J. GAYLOR P.E. PROJECT No, REV NO. DESCRIPTION DATE ECT No. fl702~1 JUN 18 2007 CERTIFICATE OF AUTHORIZATION TITLE: ~yA~BNIt~~~'~R ~CV~SILllV~7 N0.2$186 FIRE LiN ~ ON,ST'RU`ClON PLAN NO~fiE cmr®F~L? f WATER SYSTEM NOTES: EROSION 1 SEDIMENT CONTROL NATURAL RESOURCE EI~~t3tV 1 SlEC~iEI~T CC~I~TROI. ~~4TllRa~iL RESOURCE i~rr.rre.YS~i r.~rerri rorrr .r.~...r.~rrn i~~ri ~o~.r i~.r.rren.r.ern.r+ 1. SANITARY SEWERS, FORCE MAINS, AND STORM SEWERS CROSSING PROTECTION: P#~C)TE~TIt3~I: WATER MAIN SHALL BE LA1D TO PROVIDE A MWIMUM VERTICAL DISTANCE OF 18 INCHES BETWEEN THE INVERT OF THE UPPER PIPE AND THE 1. EROSION CONTROL: THE CONTRACTaR IS TO PROVIDE EROSION NO GRACE CHANCES SHALL OCCUR 1~JITHIN THE DRIPLINE OF CROWN OF THE LOWER PIPE WHENEVER POSSIBLE. CONTROL/SEDIMENTATION BARRIER (HAY BALES OR SILTATION TREES TO RElVIAIN. WHERE SANITARY SEWERS, FORCE MAINS, RECLAIMED WATER MAINS CURTAIN}, AS SHOWN ON PLANS, AND AS REQUIRED TO PREVENT r AND STORM SEWERS MUST CROSS A POTABLE WATER MAIN WITH LESS SILi'ATION OF ADJACENT PROPERTY, STREETS, STORM SEWERS, AL.L TREE ROOTS EXISTING UVlTHlN APPROVED IMPROVEl1~ENT THAN 18 INCHES VERTICAL QISTANCE: (1) BOTH THE SEWER AND THE WETLANDS, AND WATERWAYS. IN ADDITION, THE CONTRACTOR ~?REAS AND C~RlGlNATING FR~3M A PROTECTED TREE, SHALL BE WATER MAIN SHALL BE CONSTRUCTED OF DUCTILE IRON PIPE (DIP) AT SHALL PLACE STRAW, MULCH, GRAVEL, OR OTHER SUITABLE SEVERED CLEAN AT THE LIMITS OF THE UTILITY TRENCH AREAS THE CROSSING. (DIP IS NOT REQUIRED FOR STORM SEWERS tF IT IS NOT MATERIAL ON THE GROUND, AS REQUIRED, IN AREAS WHERE ~f~IEREVIER THEY ARE V1llThllN 1 ~0' OF A TREE TO BE AVAILABLE IN THE SIZE PROPOSED I ALSO, A SANITARY SEWER OR FORCE CONSTRUCTION RELATED TRAFFIC IS TO ENTER AND EXIT THE Pl~ESERVEfl. MAIN MAY BE C900 PVC AT THE CROSSING} SUFFICIENT LENGTHS OF DIP SITE. IF, IN THE OPINION OF TWE ENGINEER AND/OR LOCAL MUST BE USED 70 PROVIDE A MINIMUM SEPARATION OF 10 FEET AUTHORITIES EXCESSIVE QUANTITIES OF EARTH ARE BETWEEN ANY TWO JOINTS (2}ALTERNATIVELY, QNE OF THE CROSSING TRANSPORTED OFF-SITE, EITHER BY NATURAL DRAINAGE OR BY CONTRA?CTOR SHALL COMPLY ~fVITH LOCAL, STATE, AND MAINS SHALL BE ENCLOSED WITH A 20 FOOT LONG STEEL OF PVC CASING VEHICLE TRAFFIC, THE CONTRACTOR iS TO REMOVE AND CLEAN FEDERAL REGULATIONS REt~ARDING POLL4JTlO[~ CONT'RC3L OF CENTERED ON THE CROSSING. WHERE WATER MAIN CROSSES BELOW SAID EARTH TO THE SATISFACTION OF THE ENGINEER ANDIOR STORED MATERIALS, FUEL, EC~UlPMENT, OR OTHER HAZARDOUS SEWER MAIN, ENCASEMENT OF BOTH MAINS IS MANDATORY. LOCAL AUTHORITIES. EROSION CONTROL BARRIERS MUST BE MATERRIALS USED ON SITE. ,ALL CONST`RUCTIOI~ DEBRIS SMALL ALL JOINTS ON THE WATER MAIN WITHIN 20 FEET OF THE CROSSING ERECTED PR10R TO LAND ALTERATION, INSPECTED DAILY AND BE STOCKPILED !N MANNER THAT DOES NOT CAUSE. SOIL, AIR, MUST BE LEAK FREE AND MECH/~NICALLY RESTRAINED. A MINIMUM MAINTAINED EFFECTIVELY DURING CONSTRUCTION, THEN t)R iIVATER POLLUTION ON SITE UNTIL DISPOSED IN VERTICAL CLEARANCE OF 6 INCHES MUST BE MAINTAINED AT THE REMOVED FOLLOWING SOIL STABILIZATION. ALL EROSION ACCORDANCE VVlTH LOCAL, STATE, ADD FEDERAL CROSSING. SEDIMENT AND STORMWATER CONTROLS SHAlL CONFORM 70 THE 'HE REGULATIONS. ALL CROSSING SHAL! BE ARRANGED SO THAT THE SEWER PIPE JOINTS FLORIDA STORMWATER EROSION AND SEDIMENTATICIN CONTROL L AND THE WATER MAIN JOINTS ARE EQUI~tSTANT FROM THE POINT OF INSPECTORS MANUAL. ~U. CC}NTRACTOR SHALL PROVIDE A DEIilIATERlNC3 PLAN TO CROSSING (PIPES CENTERED ON THE CROSSING). CONTROL SEDIMENT C~ISC~--IARCaE TC) OTHER tlVATER BODIES OR WHERE A NEW PIPE CONFLICTS WITH AN EXISTING PIPE, THE NEW PIPE 2. DURING LAND ALTERATION AND CONSTRUCT{ON ACTIVITIES, fT OFFSITE SO THAT IiVATER C~UALlTY C®MPLIES 1lVITH LOCAL, SHALL BE CONSTRUCTED OF DIP AND THE CROSSING SHALL BE SHALL BE UNLAWFUL TO REMOVE VEGETATION BY GRUBBING OR ~ STATE, ANC} FEDERAL TURBIDITY PARAMETERSp CONTRACTOR ARRANGED TO MEET THE REQUIREMENTS ABOVE TO PLACE SOIL DEPOSITS, DEBRIS, SOLVENTS, CONSTRUCTION SHALL DIRECT TURBID V~iIATER TO TEMPORARY SETTLING PARALLEL WSTALLATtONS MATERIAL, MACHINERY, OR OTHER EQUIPMENT OF ANY KIND BAS--INS IJIIITH VEUETATIVE ANDIOR STABILIZED FLOW TC~ _ 2. ALL WATER MAINS SHALL HAVE A MINIMUM OF 36 INCHES OF COVER. WITHIN THE COUNTY RIGHTS-OF-WAY. C3FFSITE DISCHARGE AREA. 3. ALL ON-SITE PVC WATER MAINS 4-12 INCHES SHALL BE ACCORDANCE WITH AWWA C-90Q STNNDARDS DR14 (CLASS 150} AND HAVE THE O.R. 3. C(3NTRACT~R SHALL SPRINKLE OR OTHERWISE APPLY WATER ~ . AI.L-EFFORTS DUST BE UNDERTAKEN TO PREVENT ANY DUCTILE IRON. TO AFFECTED CONSTRUCTION AREA TO CONTROL BOTH EROSLON OR TURBID ~fU'ATER FROM EYEING DISCHARGED INTO 4. ALL DUCTILE IRON PIPE SHALL CONFORM TO THE REQUIREMENTS OF SIGNIFICANT WIND EROSION OR FUGITIVE DUST. ~NETLANDS AND/OR VIIATER OF THE COUNTY. TURBID ANSI STANDARDS A21.51, MINIMUM CLASS 50. DISCI-#ARGES THAT E~CCEED JTU'S JACKSON TURBIDITY 5. RESTRAfNTS SHALL BE PROVIDED AT ALL FITTINGS AND HYDRANTS AS 4. REQUIRED TREE BARRICADES AND EROSION CONTRUL UNITS} CJR 29 NTU'S ~NE.PHELOi~iETRI~ TURBIDITY UNITS) ABOVE SHOWN ~N DETAILS AND W1TF! PRECAST THRUST BLOCKS AT EVERY MEASURES MUST REMAIN INTACT THROUGHOUT CONSTRUCTION. BACKC;ROUND LEVELS ARE A VIOLATION. .HAY SALES, SILT CHANGE IN DIRECTION. ENCROACHMENT INTO OR FAILURE TO MAINTAIN TREE SCREENS OR OTHER APPROVED METHODS OR 6. ALL PCV WATER MAINS 4° THROUGH 12" SHALL BE IN ACCORDANCE BARRICADES WILL RESULT IN ENFORCEMENT ACTION WHICH MAY ~ EROSIONI~`URBlI~ITY ~GC?NTROL IVI~Y BE REOUlRED. I`I` IS THE WITH AWWA C-90Q. PIPE SHALL BE CLASS 150 AND MEET THE INCLUDE CITATIONS ANDlOR PERMIT REVOCATION. RESPONSIBILITY OF THE OV1fNERlDEVELOPER TO INSURE THE REQUIREMENTS OF SDR 14 IN ACCORDANCE WITH ASTM Q-2241. INST~yALLA~TIONOF AC~EOUATE EROSION COt~TR~JL BARRIERS 7. MATERIALS AND CONSTRUCTION METHODS FOR WATER DISTRIBUTION 5. ALL TRIMMING UNDERTAKEN ON A TREE PROTECTED BY THE PRI VR Teti TIE V~~Y~77~EN ~E.YlENT ANY ~ITE 4 Y VR~Y Ti ,E~E SYSTEM SHALL BE IN ACCORDANCE WITH THE LOCAL AUTHORITY HAVING PROVISIONS ON 1'HE LAND DEVELOPMENT Ct?DE SHALL BE kN EROSION CONTROL flEVICES .MUST BE MAINTAINED. !N GOOD JURfSDICTION CODES, PLANS, AND SPECIFICATIONS FOR CONSTRUCTION, ACCORDANCE WITH THE NATIONAL ARBORIST ASSOCIATION (NAA) CC~NDlTlON THI~~3UC~HOUT THE CONSTRUCTION F'RC3CESS AND LATEST REVISION THEREOF AND SUPPLEMENTAk. SPECIFICATIONS PRUNING STANDARDS. UNTIL ALL LOOSE SOILS HAVE STABILIZED. IT IS STRONGLY THERETO. APPROVAL AND CONSTRUCTION OF ALL POTABLE WATER RECOMMENDED THAT ALL EROSION CONTROL DEVICES BE SERVICE MAIN EXTENSIONS AND CONNECTIONS MUST BE COORDINATED 6. DURING LAND ALTERATION AND CONSTRUCTION ACTIVITIES, IT REGULARLY INSPECTED DIJRlNt3 CONSTRUCTION AN~3 MCaDfFlED THROUGH THE LOCAL GOVERNING AGENCY. SHALL BE UNLAWFUL TO REMOVE VEGETATION BY GRUBBING OR IF CCJNC3ITl~,3NS WARRANT. TO PLACE SOIL DEPOSITS, bE~R1S, SOLVENTS, CONSTRUCTIt~N MATERIAL, MACHINERY OR OTHER EQUIPMENT C?F ANY KIND WITHIN HIN THE DRIPLfNE OF A TREE TO REMAIN ON THE SITE UNLESS OTHERWISE APPROVED BY THE. OWNER AND LOCAL AUTHORITIES. 4 PROJEQT: ~~~arwater R~creati~n Center DRAWN BY: BATE; SCALE : •`~L 3 OS CHECKED BY: DATE: 1"=X MICHAEL J. GAYLOR t CERTIFIED PRt~FESSIONAL ENGINEER OSPREY COVE I'ROFESSIOiVAL OI'FICE PARK STATE OF FLORIDA NO. 13098 21?54 STATE RtJAO 54, LUTZ, FL. 33549 PH. ~8~3} 949-5599 FA)C {8'13} 948-~?8~8 ~R 2 APPD BY: DATE: PH. ( 1 DATE: IUD 3/3/{37 SHEET JUN 181007 ftA1CHAEL J. GAYLOR P.E. PROJECT No. REV NO. DESCRIPTION DATE T No. ~~'n~Q PI.AP9NdtV(~DEPAR~PIT Ci11(®~ ~I.EARWATER N0.26186 FIRE LINE ~C V (SONS CERTIFICATE OF AUTHORIZATION TITLE: LINE CNSTRU~T~ON PAN NOTES i t ~ w~ ~ I ~ ~ u~ 1 ' i ~ > i ~ as=~~~ i ~ c ~ I Q~ ~ i ~ I~ 1 F ~ ~ ~ ic~i~ i I w 1 ~ t 1 r i t ~ ~ ` EXISTINGFIRE HYDRANT ~ Q~„? ~ ~ j ~ _ o _ _ _ _ _ _ BAY ESPLANDE WET TAP EXISTfNG EXlST(NG 6" WATER MAIN - - - - - . ` ~ ~ ' r .r......~ .ems Q i ~ ~ ^ ~ I ~ APPROXIMATE DISTANCE FROM ~ ~ ~ ~ ~ Q ~ ~ ~ - - - - - - ~ i ~ EXISTING FIRE HYD TD PROPOSED FDC ~ z ~ ~ ~ ~ ~ ~ ~ ~ ~ ~ I ~ VALVE BOX WITH F{]C ASSEMBLY ~ PROPUSED 4" C- I I I I I I I1 I DEDICATED FIRE ~ ~ ~ tiwrr ~ ~ ~ I ~ i i l 1 { ~ I ~ ~ ( ( ~ ~ ~ ~ ~ 90 BEND ~ I ! 1 # ~ Q ~ I t I I I i I I 45 BEND PROPOSED 4" C-900 DR14 PVC PIPE ~5 BEND i I I 1 1~ ~.S { I L _ _ J L _ _ J L _ _ J I ~ ~ ~ _ ~ DEDI~T-€~O-F-FR-E tI~A~€ 3-FT COVER MIN, ~ i I ~ ~u' ~ - - - - - - ~ ~ ~ =~J - - / 45 BEND I ! ! ~ ~ ~ _ r. - _ ~I~ _ _ ~ *2 'I /2" HC W/GV *2 1/2"' HC IN/GV ~ .~1 N - ! ' ~ ~ ~ y ~ ~ ~ 3~ 4„ -9Q0 DR14 PVG ~ 45 BEND \`J - ~ ~ I/ ti ~ Z~, ~ ~r 45 BEND EE ~ ~ 45 BEND ~ ~ I 4" C-900 DR14 PVC 3I ~ ~ ~ ~ ~~°28'1"E°I~,B~ ~ ~ ~ .J 45 BEND + . 4a BEAD ~ ~ f ~ ~ ~ ~ - 90 BENCH M-~.e.......-..,,,,..,,,, I j *2 1 /2" HC W/GVy ~ *2 ~ /2" HC W/GV . OI i ~ ~ , ~ 4" C-900 DR14 PVC t ? ? O ? • 4 O • • • • 9~ ~~ND t PROPOSED DOCK PROPOSED DOCKS ~ ~ 4" C-900 DR14 PVC • t • • • • e o a • • I PRt?PO N 89° 31' S4" W 22.69' T ¦ R ~oA 9 9 f Os~ Y ~f 1'~ 4 PR°'E~T: ~I~arvvater Recreation tenter DRAWN BY: ~A~: SCALE : g OSP CHECKED BY: DATE: 1"=60 2 APPD BY: DATE: PH. (8 -I DATE: M#C~{AEL J. ~AY~CJR ~ CERTIF#EQ PRt~FESS#E~NA.~. ENG#NEER OSPREY COVE PR~IFESS#C~NA~ OFF#~E F`AR{~ STATE CAF FLC~R##~A NC3, 13098 ~f ?64 STATE #~4AD 54, LUTE, FL 33549 . PH. (813} 949-5599 FAX {818} 949-0818 3/34/t~7 SHEET MICHAEL J. GAYLOR P.E. PROJECT No. REV NO. DESCRIPT{ON DATE CERTIFICATE OF AUTHORIZATION 71TLE: .~~1N 18 200 ~ ~#a, 07020 7 ~LANNlNG DC-AA1MMEiU1' F$EVISIONS No.2sies FIRE L ~[F~~ L~ ~[~~TF~I~~~'I~I ALA ~~®~~«A,~~ 5" FfRE DEPARTMENT CONNECTION STORZ 21/2" MALE BRASS HOSE CONRtEC 4" SCH 40 GALV PIPE ~0~~ ~GTlO VA~.~/~ 1l~~T~ CAP G~AL~I. ~30L`T FABRICATED FDC SUPPORT 3' MAX ALUMINUM VALVE BOX LID 2 112" G ALUMINUM VALVE SOX LID ? ~ l2" GAL1! ~'T~EL P~P~ NCH 4a 4" CHECK VALVE CONCRETE SEAT THRUST PROPOSE BLOCK WITH STRAPS OP05ED DC~C~C SAND ~~I~... S~~TE(~ I I f=111=11 I- ..n Q a~~ - - 4" CHECK VALVE ~ ~ I-I ~ ~~1) I I~II ~ I- 4"x2 x 2 ~ f~" R~~JUG~~1G FLA~IG~ • ~."GATE VALVE .d I I ICI J ICI 11~I I I- 1-I I Iwl l I= I ~ C~~ 4" TES . ~ - ~ ~ : I i 1-1 i 1=1 I 1=1 11=1 11= N~~. I I(--I i~-~ (~--I (l---f i E F~ow j (I I-~ I I-I 1 ~ l--- E~OT~! S~D~S OF T~~ 4" C-900 DR14 PVC b U ~ •a _ . ~ I 1 I-III-I I 1-I i L- 5/8" GRLV. 's ~~Ll~. '=t1" BOLT O~ BCJTi~ OF F1TTl~tG AT ~i~E~Y • i' ~ I~~ 7 ,y. SIDE OF FI b • I I 1 I I-I 11-I I J-- CHANG III=III+111:. C~A~IGE CAF DIR~GT~ON ~ROPO~E~ ~OC~ ST~~~GF~~ =1 I t-1 I 1=. 4" DI TEE #57 ROCK BED 6" TO 10" DRAIN W BOTTOM OF VALVE BOX CONCRETE VALVE BOX 4 F7, x 6 FT. x 4' DEEP W/6" WALL VALVE BUX d E1'AI L CONCRETE SEATS WITH STRAPS TYP 5 PR°~EC,-: Clearwater Recreation tenter MIChiAEL J. GAYLOR CERTIFIED PROFESSiONAI~ 4 ENGINEER 3 DRAWN BY; DATE: SCALE : OSP CHECKED BY: DATE: ~ ~ =x 2 2 APPQ BY: DATE: R~. (81 OSPREY COME PRC7FESSIONAL OFFICE PARi~ STATE C?F FL.ORtCJA NO. 1309 2~ 7S4 STATE ROAD 54, LUTE, FL 3354 Plyl. ~$13~ X49 ~5J9 FA?t {$13) 949~i3~~i $ ~ 1 DATE: 313t3i0~ OF JUN 18.2007 REV NO. DESCRtPTfOfV DATE MICHAEL J. GAYLOR P.E. PROJECT No. REV~SI~I~QS CERTiFiCA7EOFAUTMORI7ATION TITLE; tvo. t3?C~20 Pl~1Nlt~~ ~WA1~R~ N0.26186 FIRE LIN C(I~P ~ ~1~ CO`t'~~CT~O TAIL FlDOT Type S-3 Asph. Conc. patch to ba 2'° mM. thidceiess or match existing ~ p+~ir~ far thidcnsas in sxc~ee of Y tht 8 ~f i~t~ 4' MM Patch / Resurface full width of Mondithk #h t~ street vn ivn~itudinal s~ T+2" (8" MM. Replace 8aaa instdicttons 3,000 pai Fiber Compacted Thidcn~a Mew C~crete ' . ~ , r . ' . • a: e ? ~ ~ s ® ~ ~ . ~ ~ . i ` ~#g Replacement base Undisturbed Exist Base mateNal ahcll be QPProved by the ~ Ensin Amide qty 6» 12" Tr~ch 12" S» 18" Tronc Width Min. Width rr 1 Varies l/c~i~ undisturbed Ti~end~ Side nd~st~r~ ~ i~ Compacted Compocteci 8adcfgl 8adcflll i T=Thickness of ~ origin4l Base • ~ - then T==$~ ASPHALT STREET AND DRIVEWAY CONCRETE REPLA REPLACEMENT REQUIRED FUR FOR UTILITY UTILITY CONSTRUCTION ~PLAEM E T R Eli # RED T ~ TRH ~T~ ~ t~'~ C~.EARVYATER~ F'L~RI~~? Rt1~1~ ~R~~ ~®P~lf~~S1'R~~'~t~ ~~f~i~lE~RtP~ REDRAWN STREET Ai~D DRl'VEI~JAY ~ NOVG REPLACEMENT EAR 1 4/A/2Qp2 Rev. Noter, CHECKED Remove ~+~t 2 of 2 x'1'8• G.LB REV. GATE DESCRIPiIOPi APP. DE9GNED ~C~N~RETE ~ ASPN~LT1~ o~t~t~ a~ C.M. 5 PROJECT: Clearwater Recreation. tenter _ q ~QN~RETE ~URF~CES 1 ~ MICHAEL J. GA~LC)R d ~ CERTIFIEi~ PRC7FESStGNAL ENGINEER 3 BRAWN BY: dATE~ SCALE : ' CHECKED 6Y: DATE: OSPREY C~1lE PRUFESSIt3NA~. OFFICE PARti STATE (~F FLQRI(~A NU. X3498 2t7fi4 STATE RC3AQ 54, LUTZ, FL 33548 2 APPD BY: DATE: P y DATE: PN. ~813~ 84~-5599 FAX x$13} 94818 ~~~~9~, 313~rfl? SHEET .JUN 18 2007 MICHAEL J. GAYLOR P.E. PROJEGT No. REV NO. DESCRIPTION DATE CERTIFiCAFE OF AUTHORI7ATION TITLE: EG'T Ito. ~?~}~Q ~IANNINt~ ~~6RfME~~' Ciilf ®'F C~i~A~ER REVISIONS N°.261 F{RE ~~~T~~CT~~ ~TA1~ .A TYPICAL VALVE SETTING F'.V.C. PIPE n.t.s. THE F4U.OWING JOINTS MUST 8E RESTRAINED IN 1. BEND -INLET AND OUTLET 2. TEE -OUTLET BRANCH 3. OFFSETS -INLET AND OUTLET 4. CAPS ,,..._._n, 5. PLUGS 6. DEAD ENDS ~ 7. H1f~RANT RUNOUTS SHALL BE RESTRAINED AS E~V~ Ad ju~tabfe .5 Valva Box ° ~S , iNh~ Valve ~c~rs in Roadway. ~ yet Base ore 10--Common 8ridc. ~ i L Ebba 1 ~ Se~ie~ 'T ~ o ON ALl. TEES, A MINIMUM OF 5' SH,4l.L 8E RESTRAINED ON EACH RUN LEG L = MINiAAUM LENGTH TO BE ~t«, ~Q~ RESTRAINED ON EACH SIDE OF FlTl'ING {ft.) FlGURES BASED ON 3t?° DEPTH BURY, 150 PSI TEST PRESSURE. e MaCI1. ~~ftt Vl~11~ 8" PVC MAXIMUM SIZE USED IN SYSTEM NOTE: i~~~'E: T9-ffRt~~T REST~~?t~dT ~tT ~TT~~~~ AND V~~~ SH~t.~. ESE . RaatroM~eg Joie~t aY us ~~E qF EE3sA lF~t3t~ MECALIJ~ ~EST~~~hlE~S. TFd#~U~T R~ST~~I[~T ~E~~~ ~I~'E J~?~NT'S S~l~~..l.. ~ ~Y E~~~ ~R~~ ~Et~iE~ 1 ~C~~ NOM. ELBOWS (deg.) VALVE ~E ~ PIPE ~~5 DEAD RE~~~i~VE~S. SIZE 11.25 22.50 45 90 6RANCH AND CI'T'Y OF ClEARWATER~ FLORIDA 4 2 4 9 21 28 46 ~1~1' CAF ~l,E~?RVII~O'~E ~`ta.~R~~ PUBUC ENGINE~RMNG ~~A~~N 6 3 6 12 29 47 65 El~G~l~EERI~t~ p~ TYPICAL VALVE °t5 g2 $ 4 $ 16 38 66 $5 ® j'~~~ ~e~e® e7 ~rl~ q,~p~ ~ SETTING iN cwt ~ TH R S T CROSS-SECTION ~~#J ~~jj~~'' p/~~ RES. RAINING 1C6,?~i ~R~"r f~~ Al'Y~a iFs~sl t~v o~te oe~Ca~Pnoa G.C.H~ 1 OF 4 aEV DA iVOTE: ALL JOINTS NOT UNQER GRADE (ATTACHED TO PROPOSE DOCK) TO BE MEGA LUG WITH RED ENAMEL ,EPOXY OR E CORROSION INHIBITING PAINT SYSTEM QN ALL METAL SU pR°~E~T: Cle~r~nrater F~ecreation tenter ~l i ~o.7(V! 1Mr :1"AL ~I~RFACi~~ iV11~NAE~ J. GAYLQR o ~ CERTIFIED P~OFESSIGNAL 4 ENGINEER 3 DRAWfV BY: DATE; SCALE OSP CHECKED BY: DATE: ~ °-x 2 2 PH. (81 C)SPI~EY GC7VE PRGFI~SSI(~NAL OFFICE PARK STATE C3F FLI~RIDA NU.13098 ~ 9 754 STATE RCJAD 54, LUTE, FL 33549 RN. 489 3} 94~5~99 FAX ~~9 3} 943-039 F ~ APPD BY: DATE: y DATE: 3/30147 ~NEET C~1= JUN 18 2007 REV NO. DESCRIPTIO(V DATE MICHAEL J. GAYLOR P.E. PROJECT No. CERTIFICATE OF AUTHORtZ,4TION TITLE: No. 0?C~~O ~IAP~NING ®EPAR~~`~ Cl'I1F®FCLEARWATER REY~ti7~~IV~7 N0.26186 F~RE L~N , t, i ' ' ~ ~ ~ ~ fc i : ; ;~I ou or our ets. Use our ti s , o r:,9 ,#..1~jq.,o, l1 ~ D on t let the heat harm p St. Petersbur Times LAR ~ 7 7 6 1 Saturday, August 11, 2007 I 9 i ¦ , . t. , , ,:4 ~ ; - ~ - lur tips for protection. page s m ~ aba ,coin for more Pinellas Coun news _ ' .tamp y ry o ; I , o o sines - . ar • r~~ , , - _ „ ~ _ • { ~ 3~ BOAT SLIPS continued from 1 : , , ; , _ ~ . ¦ ¦ ; , , I , , , , , - r _ , ~ CLEAAWATER r,~.• ~ - . • i ~ 3, tampa ay.com ; , - I~~ Saturday, August 11, 2007, LAR. MAN IN CRITICAL... . uld `We voluntaril downsized it: said lie's happywith the newplan the city $5,400 annually in rent, as initially envisioned was esti- front developments, Clearwater, alsq feared the protect wo Y : ' ~ an renew the o tion mated at 1.2-million; but devel• though, has been working to add ' . lamts JMC because it addresses one worry: The city c P $ CQN~ITIDN AFTER ~ ' , • - , . ,harm wildlife, create, noise and because of the wmp + n said. boa co estion. But he still everyfiveyears orbuythe slips; opers arena sure how much the more: cause ollution• attorneyEdArmstro g tll?g. . P Voters in. March- signed off rF1N STRIKES IIIM ' Ci '°officialscountere sang The revised plan eliminates has concernsabputsecurity JMCwouldmamtainthefacil- smallerdesignwillcost. - tY d:, n • ' n said someone from ' ities install security gates at the, The council is expected to vote on the city's plan, to build 129 tdealon the ski s ro osed,forthe shal- Armstro g , , AClearwatermanwasin the citywas gettnig a Brea P P, P • and moves the Sand earl which is across',. public docksandhaveSandpearl on•theproposalmSeptembei: skips, a boardwalk andfishing ~ criticalconditionFridayafter , a protect tliat would lure vlsitoi~s. low part of the inlet P , , ~ , , `staffers lockthem at midni t. Boatslips are a hot commod='' pier near Coaclunan Park in the als some ski s to dee er water. The: , the streetfrom the skips, will be ~ ~ being struck by avan Thurs- - A month later;. JMC ofiici P P . • se'. orses,.:"' ' 15 ski s. on call at all times, to res and to If a proved, ,work should ity in Pinellas :County because downtown area. The protect, if ~ ' nts eedto. ci now ets P P dayafternoon.JerryWayne met vntti reside and agr ty g P . p ule, could be - . s ' from. Ken: Robin a Belle Harbor.: problems, begin in the fall. and take u to a hundreds have been elunmated it remains on sched i Groves, 59, was standing in reduce thenumber of lips - twhofou tthe ro'e Uridertheplan,JMCwillpay yeartocomplete:Costoftheslips- in recenfyears by.big water- .finished sometirtiein2009. residers P t ~ thetihraisedcentermedian 54 to 42. , . ~ , bf Gulf-to-Bay Boulevard at _ : ~ , ~ ~ at at L , horses an a o e . ~ ~ F • , n s emaciate Te : 3.39 .m.Thursda when ~ ~ J P Y , • , , 1 hewashitbyavaritlY- • PAL1Yl HARBOR p p O L a ar o; roe er an anon us` i o o ice. . Yin A p L ing to tum Ieftfrom Cross g . ,N p e. _ - ' Groce sho In Is easier at Publlx., ry pp Activit center seeks ~ ' . Y Boulevard to gowestori • . : , SU Ort fOC'SenlOr fair Guff-to-Bay Boulevard. evrAMARaeL•xttouRV went to the property Thursday ~ -".r_,..: , pp , TtiedriveroftfieFordvan, TimesStr~•Writer'„ . - ~ afternoon after Largo. police ;around the stole and Into he ar In ThePalniIiarborcommnnity i ' g MackC: Harvey, 57; of St - , • HOW t0 hel : - ° ~ P . - LARGO . , . Five.. emaciated received an anonymous call, ' Activity Center is koolang forven-, , , Petersburg; made if across, . - • ~ horses and a donkey were in `Hale was keeping-the horses - dors p p to artici ate m its senior Anyone interested in • ` the eastbound lanes. Harvey • n ct• 4• Cali 27 SPCA Tampa Bay custody:Friday in dirty pens with substandard helping to providefeed - r , health fair o 0 (7 ' ~ ~Ot: W2 Car OUt OUr ba S Or OU hitGrovesasheclearedthe - r 771 g after a ti stet directed authors- shade; according to SPCA direc- ors ecialized veten- , ry y g y -6000 or visit www• hrec•or i p p P eastbound lanes of Gulf to ,with no food or ; for of operations Conine Brooks, nary care to the rescued . I ties to dirty pens . forinformation. , ked to the east Ba and loo Y water, officials said. When found, authorities said; horses can make a tax- _ • forabreakmwestbound the Theanimalswereseizedfrom the,equines did`not have.an - nd take Y deductibledonation our car, a ~Oad t em In .y t Work OU ht traffic olicesaid.Groves • Ar Ists s 9 , P . George Hale; 39, wfio,authori- ahingtoeatordrink. throughtheWebsiteof , ' was flown to Bayfront Medi- • , for annual festlVal tiessaywaskeepingthehorsesat :',"Thiawasn'tjust:malnourish- ' theSPCATampaBay, cal Center rn St. Petersburg: ' 1200 Donegan Road merit;' Brooks said: "This was Www,SPCATampaBay.org. g y Artist. applications for the ' CarC back-nO tl In , 2aSe. W Nochar eshadbeenfledin pp p 9 The Society for the Prevention totalneglect;' For information, call (727) ~ . ' 33rd. Annual Fme Arts,; Crafts the incident One of the JIM DAMASKE; I T{mf~; ` One of the lesser abused horses munches on hay:Friday'at the of Cruelty to Anunals, :which Investigators Thursday night 586-3591. , ' and Music Festival are ova' - SPCA ro ° statelawauthorizestoinvestigate took away three,mustangs,that : P p SPCA property. The horse.was one of five confiscated from a able through the Greater Palm - _ • Group offers free See HORSES, 5 - ` largo rangy 0 where OU haV@ t0 d0 1t a~~ OUI"-~ _ , . cases of animalneglectoi'.,cruelty, ski Largo ranch showing signs of being malnourished' and abused p Y . y Harbor Area Chamber of Com , - vision screening.'.. . - merce,1151 Nebraska Ave.; Palm , j . Prevent Blindness Florida . < : • ' Harbor. 'Deadline .for appli- . ~ ' " ~ n IS a cations for the juried show is issponsoringafreevision ' • ' ` self. Come save. where sho I ' ' PP 9 $e t° 11. Call (727) 784.4287 or screenirigforchildrenand p , j • adultsfroml0a.m.to1 m. visit www,palmharborcc.org~ , p. MondayatthePinellas newsevents/decartfest,asp., : . ~eaSUre-a~~ the Wa OUt t0 OUr Cal:, ~ Coun Health De artment's Y Y ry p s , . COUNTYWIDE ClearwaterHealthCenter;.... ~ - : ~~4.,: ssr, r . _ ; - a ~ :y ,.7 ~ , , _ I 310 N MyrtleAve,Appoint- ~ ' , PSTA collectin Items - = , , - g ~ W r mentsareriotnecessary, , to send to the troo s , • , - p Thescreenin swill be ~ - . 9 , r ~ ~ _ ° _ . ~ • - , ~ The Pinellas Suncoast Tran- , ' conducted bynationally ? ` • , , srt Authori is collectin 'items certified Prevent Blindness d ° ~ : - ~ - ~ , , tY g ,q , , . Floridastaffandvolunteers...... ~ , • from bay area residents to send , t,1: r , to service members stationed' Childrenwi escreene ~ ~ , - • . - ~ ~ ~ , 4~.~ ` ~ forriskforambl o ia( oor Yp p - i~:. • overseas, ~ ; Ft s w,_ - • • , + ' _ onndistinctvision)andacu- g' tai ? 3~ - The'agency's goal is tofill sev- ' - ~ ; s I will esc 'r~~1t, , , erai buses with items for. men ity. Adu is b , a + and women in the military and for nskforacuiry, cataracts, ~ ~ _ - , r:. , , ` + ~ Air laricoma,oge-related '1~ >Q.: ~ , '16' ~ ~ . , deliver them to MacDill 9 ~~1Pr i }t~~s I ® ~ ~ i ForceBasemTampa;wherebase, - maculardegenerationand ~ ~ r • ~ ~ . 4 . ~ ersonnel will send them to the diabetic retinopathy. Call ?F . 4 • r~ y ' - ~ + h ~ j - ~ , . R P (813)874-2020orvisitwww: , ~ :.,•1i+ . ~ troops, reventblindnessflorida,or . 1, t,t',~ ' . ~ , ; ~ 4 , Items needed include insect p 9 Dasanl.Water ` - - _ repellent, sunblock, lip balm; a.. _ - , , ~,s-~ ~ `t ~ ,3 , breath' mints; disposable cam- LARGO ` ; w. ' I ' , , ~ , . erase batteries, stationery Sldent ~ , . ~ ~ Hospice pre , SAVE UP TO 3.98 ON 2 a . ~i . - , + : , , F 1 , , stamps; prepaid` phone' cards, e main' Baker: i v ~ x,... o.~ to b sp . ; ~ ~ , ~,,I paperbackbooks andmagazines, . ~ esident ~ Ma J. Lab ak,pr ~''y " microwave o corn instantoat-• ry Y ~ , • - PP . ; and chief executive officer meal: and `cgffee; tea bags and ~ j p , • i oftheHos icepft a on a ~ - r r.. i ,..f.• • _ ~ powderedhotchocolate. - - ~ Suncoast will bethefea v. i ; : ~ : ~ ~ onations maybe dropped off _ i D ~ , - ~ _ turedspeake r • g _ I ;;s - . ~durin business~lioursonweek- 9 . ~ , , _ days, and 8.a.m. to 4 p.m. week- ; I _ Mid-Pinellas ends at the Park Street customer h. Chamberof r'" , - , service center; Park Street and ~ . Commerce ; ~,.~,r ~ GardenAvenue in Clearwater. r: : + , , I. n - bUsinesslun= ~-,+,m , ~x ~ : r ~ r . - jl ~ ~d,` . To learn more, ..'visit i .m heori at11.45 + , c 5 wwwPSTA°net. 1- ~ . ,.y . M e d r- ~ - ~ ~ : ~ labyak a.m.Tuesday s rat. - , - ` ~ atPalmsof _ ~Y ~ ~ Guardians ad litem' 400 - ' ~ 1 ~ , ; ~ Largo-Cypress Palms, ' E needed for kids ~ Lake Ave.NE.Anationally , : BUY ONE GET ON t `More than 1 000 children in recognized expert in hos- ~ ~ - i I piceandpalliativecare she Pinellas County need someone to BaXESr has hel e • p be their voice m the courtroom; ( d shape legislative ~ t ,`pP °"rG'' I ; viewsonend-of-Irfeissues Mtf~ ; . and the county~s guardian ad ~ ; . Jp~ aF ~ ~ ' asamemberoftheFlonda ~ l Tics d ~ , . , ~ - ~ Q C 0~0 ate: D rl n litem program hopes that could i ~ Panel onEnd-of-Life Care: , - _ - - - ~ . _ ostis$10formembers i ' C 10- k, 6.5-oz box , JIM DAMASKE I Times r ~Y ~ , ,DRINK, FP 0`: ~ 0 0 , ~ P Guardians receive ongoing at Geor< ~ , , to-bsFl.ozlr , Ero , . P ~ e who reregister by Monday inkier Kaiser 7 stands on one le Frida d~rin a game of silent speedball at summer camp , . ~ ~ s a P ~ ~ SAVE UP TO 2. J9 , assistance to hel them make a p ~ . ~ 9 Y 9 ier camp at George C. McGough Nature Park. City staff ~ ` ~ .nu P n cu butafter ublic outc ' ci commit - . ~ ~ and $15 far members a d ,~ry- s ggested closing nature parks during the week to meet tax ts, p ry, • positive difference in the lives - ~ nonmembers on Tuesday: utcry,' city commissioners likely will not take such a step. of children: The average time Call (727} 584-2321. ~ ' ¦ needed is four to'six hours a 'month, The next training to , me certified`as a ardian COUNTYWIDE - eco . ' ~ , Dii- Pu lc,~'s.ays Fitness clubbacks ad kitem is scheduled to begin . se t; 4; ~ - blooddrive • - Call 727) .464-6528 or visit + y r3~ ( Sha es TotalFitnessfor c ' 9 ~ _ ~ ~ p he commission listens to young letter writers and others on u get cut www ardianadlitem6•org. rf , , , . 8u• Women is sponsoring a i budget cuts, especially those closing facilities. ' , blooddrivefrom4to8p.m. vLORRIe¢LPnNO Andasbudgettalksbegantliisweek, July celebration,elimi~ celebration, eliminating city sup _ 1 - - COUNTYWIDE , ` Monda at its centers at mes Ste~f Writer ~ y • D there' was yet .another group, Largo's port for school resoui I for school resource officers ` and Free e w merit for q p ~ 7570 Starkey Road, Largo, AGO _ parents e-mailed City Hall- Finance Advisory Board; that weighed closing Bayhead Teen ~I .19 N P Im ; - folks with Baring oss and32s72t>s a in, g, g th ng Bayhead Teen Center, two out- What's next? i centers, the George C. McGough Another 2007-08 budget - a,ding to keep resource officers at ur 'n officials, to scale back pro- reach centers;. a Geoi , le ~ ; p . eceive , p ~ ~ , Harbor, Donorswi r go schools, posedcutstocityservices. and John R, Bonnern~ fohn R. Bonner nature parks dur- work session is scheduled - , . ~ ~ BUY ONE GET CANE Florida residents with hearing.. - f ~ acouponfora30,dayfree :Residents confronted Mayor .Pat The parents;ahe library patrons, the ing the week, and th , _ ~ I ,loss can receive amplified tele= ,he week, and. the Largo public for 6 p.m. Tuesday. Watch it Shapesmembership,a _ raid at the grocery store, asking her _ appointed committee members and library on Sundays. hones and specialized equip= . , ~ P ' ~ - couponforafree pintof ` ~ nonSunda s. es eciall those luc kids:- they've Now City Commissi ryon Sundays. live on Largo channel 15 or 1w City Cominissioners are lean later on streaming video at ' , I. keep the library ope Y P Y ; P kY • merit for no cost at the, Deaf and < : - Blue Bellicecream,aT- : - ;oward keeping the'library open largo.com. Public meetings j Connec 'Andkidswrotecityofficials;warning allbeenheard~ ~ mg toward keeping l i tion for Tam a .~s,, ~ _ ~ ~ ~ ,Hearing P ' shirt,awellnesscheckup ' ~ 1 I r ~ f'tragic consequences if they closed No formal decisions have been made on Sundays and the na mdays acid the nature parks open to adopt the property tax ~ III $ Rlce I\rls le$ Brea Bay.. and more.Healthypeople _ , ~ afore parks onweekdays. yet, but'Thursday night City Commis- all week, and funding'. e - ~ , 99 n ~ Free hearing screenings, other - . , . ~ ~ ~ ~ agel6aridolderwhoweigh eek, and funding at least one out- rate and budget are sched- 1 center at Lake Palms.. uled for 6 p.m. Sept ll and 12 oz box Limit,two ntandlowcost "You will see aboiit300 or 400 fur- sinners suggested keeping several set- reach center atLakePa ( ~ deals on - - J' ,,Q- 4. ~ ; ~ ~ ( assistingequipme atleast110porahdsgener- les' each ear'on the streets because vices that were'on the chopping block ` Resource officers wi ;source officers weren't discussed Sept. 20 at City Hall, 200 N j rr- - selected advertised varieties.) hearing aids are also available at all can be blood donors. ' y Y he will be lookin for new homes amonthago. Tuesday,bntpolice Ch ~ , i SAVE UP TO 3.79 locations across Pinellas County. 'th° food" a kid named An e1 W. The original;Jist ofproposed reduc- pieviouslysaid he exp day, but police. Chief Lester Aradi Highland Ave. ~ ~ Identification is required. Call (72'T) 399-9983 or visit ~ . ` Formoremformation call _ , g r ~ ~ g arned° tions included cutting the Fourth of 115eePARKS,3-: iously;said he expec's'to keep the e PARKS, 3 t ~ wwwftri•or for locations and 1.800-682-5663 orvisit the ,T; , • ~ ~,r, information. • : µ ~ ~ FlondaBloodServicessite { t'r . ~ , ood.org. • , atwww.fbsbl • , i ~ _ , : CLEARWATER s. , ~ , • Residents- a once p Y r TARPON SPRINGS • - T- , ' ark all ear. at-beach le lookin for ¦ y Gal r p Y g q Clearwater is,, considering a, ' ' e theme folk 6 s • , Clearwater residents can buy'. , - _ ~;F proposal from annual beach parking permits ArtontheDocksgallery - , w ' `c~ a developer valid at five lots for only $40 invitesareaartiststobring ' a a year. Permits can be bought intheirfolklife-themedwork ;r s that wants to build v ~ • Unde anew ro osal, Clearwater would have fe. er public spaces. - from 8.30 a.m• to 4.30 p•m. Mon for reviewfor an upcoming p p 1 . - boat slips in _ _ ' daythoughFridayattheMunici- artexhibitentitled"Folk r • ev MIKe oNiu? _ -particularly now with money away, onthebeach's bay side. de. Na this inlet on ' pal Services Building,100 S Myr- ' L'rfe.° Iftheworkcari liarig Times Sta Writer being short - is that it's' diffi- .The plan was to build 33 slips 1 . f rest e tie Ave., Suite 220• Proof o on the wall, owner Jun 33 slips Clearwater WATER=Abeachhotel: cultforustodoaprojecthkethis for thenearbySandpearlprojeet: , • ~ dency and vehicke registration Middleton wantsto see it. project Beach. The a basin original plan P . I ~ and con ~ o develo er has scaled : without a partner," Vice Mayor ;.and 21 foi tl~e public in a basiir regnired° Call (727) 562-4704.. Bring itto the gallery at735 ~ ' down a boat sli project that : John loran said "And he best; on: the. east side of :Mandalay , mdalay % was to build ' t • ~ ~ 'Dodecanese Blvd. week- : • ~ ' a set so a nearbysesidents, but part of thisis'that the partner is Avenue, adjacent to city tennis - _ , daysfromnoonto7p.m.; ,P tennis y, 33 slips on i ~ it comes t a cost:-The public will. paying for all of it.' : courts and near arecreation cen- , , eptTuesdays when the ; , e:~,i , , ~ I' i ~ exc ~ getfewe slips, In•December, the City Coun- ter andparkingarea, on cen- r 4 the beach's gulf and 21 ` . 11 , ,gallery is closed.Formore . v ' ~ Evens ,City Council members ' cil agreed to let JMC Communi- But some beach residents sidents for the public- o- < . r ~ ~ ¦ information, call (727) 943- g Y 0 1 I ~ ~ o wh app veil the projecfs con-' ,ties of St.,Petersburg; developer objected, saying the city was Pnces effective Saturda , Au ust 11 throw h Monda ,.August 13,'2007. m. Y 9 : ® ~ i 9298. P , , _ condo ' "viii awa valuable.land and ty was in 6'basin. - Only in the following:counties: Hillsborough and Pinellas: , . , pt sti believe its a good deal ofthe Sandpearlhotel and. , gi g Y . , • , ~ ~ ~ ~ should build its awn sli s: The nd and The total has _ ` S' Tl e': been to cut Y, ' - Pncesnot effective at Publa Sabor• Quantity rights reserved: , WHERE . S H 0 P P ' I N G L S A PLEA 5 U R E ® 1 1 ~ ~ forthe c ty. protect On the beachs gulf side, p Y , ~ ~ .451556-01 ~ ~ ~ ~ ~ ~1 hOrt wa11C ' 1) See BOAT SLIPS 6 ~ One ~ f the dilemmas we face build a docking area a s . JIM'DAMASKE';,I Times back to 42..': ' 1. ' ~ ' - -~s - ~ ,c • , ~ ' - , i 2 I ,.Saturday; August 11; 2007 I St: Petersburg Times ° LAR ~ ~ - LAI o ? . , ,a i _ ~ ~ - LAR St. Petersburg Times I Saturday, August 11, 2007 1" 5 ° ar ~ sin - tampabay.com for more Pinellas County news I ° ~S z.. . ar o Imes I , ttampabaycom for more Pinellas County news - : Rel><g><onbr><efs I ~t ~'L ~ ) HORSES continued from 1 • bon t trued from 1 ADVENTIST - ; • Re istration is bein secs ted Lakeside Commun' Church Saturda noon to o .m. Tuesda g 9 . P RY Y, p y , p.m. Aug,.26• $15 a person; $25 Thursdays. ¦ ¦ t,; Clearwater Seventh-dayAdven• forchildren'ssocoer.Registra- .475 East Lake RoadN,Tarpon through Friday. acouple:Costincludesajarof ' - I . Shawshannah Ministries tilt Church,14451akeview, lion is $60 and includes ajersey, ".Springs. Call (727) 942.0229: E ilea aI Church o t e pickles. RSVP to Web site or call > ~ , p p f h Holy Radisson Hotel, 20967 U.S.19 N, Road. Call (727) 446.6427. , soccersocksandend-ofseason 7gg-g4pg, - Bible study:l0 a.m.Wednes- Spirit, 601 Phili a Parkwa Cleawater. ~ itwww ho a ~ eSt 11111 in imminen danger pp Yr s s w . , S1C1~11]S Will i' ~ •Dollardiriftshop:9a:m•tonoon p Y• p ctices a in n tro h Soccer ra g days and 9,30 a.m. Thursdays.. Safety Harbor. Call (727) 725- • Twist and Shout .Miriam shannahministries.net. ' thethtrdweekofAu ustFirstof, ~ 1 Tuesdays and10 a.m. to 2 p.m. 9 - _ ~ ~ u ~ _ ~ _ - ::.4726: Hodakovwillsharehersecrets •Mensministryifellowship,foed Freeteachln sesslon,7 •m. , ~ d" ~ ',r-_~~.~~.~, ei ht amesuvillbeSe , __.__v_..,~. .u~ were m imminent,danger, unablE danger," unable to stand, according to The SPCA is not sure how • Thursdays.Allitemsexceptthe g 9 pt1. g P anddevotionsat7 .m.Monda s. •Thriftsho :9a.m.to3 ,m. ofmakingchallahat7:30p.m. _ p . Y p p everyThursday accordin to Brooks: Officers' SPCAc _ ~ boutique are $1. , ' Au . 28: Free refreshmentswill be „ _ , 1 - ; ~ 4 g ' Officers SPCAofficials. long Hale has owned the don- Thursda throe h g ~ - : . ~ FlrstWednesda Coffee y g Saturday, COMMUNITY Y . / • Hotbreakfastfollowed b rake ® _ - - ' - ~ , i. , _ _ : e, ~ went back Frida mornin and On I served. Yp 1 1. - - _l_/~ Y g ling and On a 'scale 4.1 to 10 with 1 key'and the other two horses, ' Fellowship; 7 p.m.firstWednes- Yardsale:8a.m,to1 m. - - BAPT[ST Bayside Community Church, p. Aug.11: ' ; worshi and a lesson at10 a:m• the ~ ,a> took-two more horses and the -bein ` da ofeachmonth. rJudalcaglftshop.Opendally. and the being emaciated and 10 being which were munching on hay healthy; a veterinarian, scored Friday morning at the SPCA. Countryside Baptist Church, '3380StateRoad580,Safety Y ; , HolyTnnrtyEpiscopal(Angle thirdSaturdayeachmonth:Tick- ` I ~ ' ',~,~3Y~^# ~~a; ~ ! ~ ~ 'donkey. health, a I~ t ' Harhor.Call(727)6897212. ~CenteredonJesus raermin- can)Church3200McMullen~ ` ~ etsatthedoorare$12forbreakfast ' ! ' ui=I !,ii,, Hale signed overall theani- theth. ~ . ; 2525 N McMullen•Booth Road, p, Y , ; ~ _ ,;I : l II, ~ i ~ . ; the ani- the three horses taken Thurs- The adopted,mustangs tech- : LUT9IERAN - ~ ~ I I ,,<ir . - . ~r ist .7 .m. eve firstandthlyd Booth Road Clearwate ~ onf , C , ~ ~ , i , , , , ~ ' mals butone Brooks said, He da m _ ;Clearwater. Call (727)726.2550. Women Uplifting Women _ ry p ry _ , r. Call Y a , I ~ i I, ~ ~ ~ ~ , ~ , ; ; ~ ; ~ , . Y f Faith LutheranChurch,1620 „ ,I i said, He day night a 1. nically still belong to the federal " I Tuesda in the studentcenter• 21 796-5514, t I~ila~ y, Iii : 4 wanted to keep'one horse' but The • Lighthouse Clothes Closetwith seminarwith speaker, authorand Y (7 ~ ~ , ~ ~ TheSalvation Saloon Watering ~ ~ c , t ~ ~ r ~ ' + .I • ~ PmehurstRoad,Dunedm.Call~, - ~ ~ 1~ ; ~ ~I ~ theSPCAconfiscateditwiththe"Frida arse, but The two, horses' confiscated government, ` she `'said. Those with the "Friday were being held at the : who adopt horses must sign a g ~ ~ ~ Hole Church, 2950 Guffto-Bay ~ ' i ~ ~ ,i " worshi HearttoHeartwomensfellow- Healin Eucharistservice: ~ , , freeclothin ;10a.maolp•m: p g (727)733.2657.~~ j . der, I ~ t.r Y i Monda s• p p 6:30 .m. UVednesda s: Blvd., Clearwater, Call (727) 415• 4 8 ire, • f 'others; Brooks said she hopes alT SPCAs IeaderBelin- shi :7 ,m. eve Thursda Inthe hopes all SPCA's location in Largo. They contract allowing the govern- Y P y • Galilee Bythe Sea Bible study: 583 0 ~ is _ the animals will recover. were s I , daWomack ~ ' stutlentcenter. 1 rvisifwwwsalvatiae _ , ! 3.• , f . , Mount:Hermon Missions Ba Breakfast. 9 to 9 30 a m. Sun- were scored 3 on a scale of 10, ment to inspect the animals ry p- _ 7to9p.mahisMondaythrough; saloon.cam. - 'i~ , SPCAofficerJillPurlsaidHale Brook` , from 9:30 days; Includes eggs, pancakes,. _ ' ~ tistChurch,400SLevisAve•,Tar- Frida • , ' ' , _ rr5 __,I:.. r , ' • Fourth Sunda Bike Ni ht: 6 : Y ~ r told her he was overwhehned The ;aid Hale Brooks said. until they are given a. title, ;a whehned The donkey, which hadn't ' 12- to 14-month process; Banks r~ a.maol Y g • a pon Springs. Call (727) 9377015. • - french toast; bacorrsausage and, Services aflO a.m• Sundaywith , . y . , p.m~everyfourthSundayinthe' . • First Evan ehcalLutheran ~ ~ a° • and acknowledged that he Beene ,p,m:Aug.: • coffee.Adults$3 freeforvisltors g ~ worshipbythePosseBandand , : t that he been examined Friday by a vet, said. Neglected horses are con- • Revi6al: Witnessingftom 10 a.m. _ WorshipCenter• A live band, bike Church 1644 Nurse Road ~ - ~ owned too many animals. appear 25. COSt ~ s r ~ ~ antlchlldren. ry cometlybyLouAngelwolEThemes- Is. appeared to be underweight butfiscated by the government and . tolp•m,today.,Testimonyprayer ' is Oand r~,' blessingsandrefreshments,, ; Cleaiiwater..Call(727)462-8000. ~ : ' - ~ Hale works.as a tow truck ingooi ~ _ ' ~ ~ • Thrift sho :10 a.m. to 4 .m.: ~ sage is BeAII ThatYou Can Be. , at7p,m.SUnday,Prayermeet- p I? ; f; T - ~ 1 driver, Furl said.'. Ha16 w truck in good condition, Brooks said. rehabilitated. - Hale adopted each of the "It is'pretty rare that we have I I , - Includes • Teen Challenge Car Wash.10 Hel Ing Hands 10.30 a.m. to:'," i , . , l ~ . ' Ingat7p.m:Mondaythrough MondaythroughSaturday.- p , TheSpiirtualCenter,160SbtthSt' .,~F - Officials said'the I I lunch. Free Womack a.m. to 3 p.m. every Friday and noon Monda s. Knittln for the ` ' 1 , ~ ~ - ~ y Plan to 'three n plan to three mustangs in May for $125 horses that have been neglected w Thursday. St, Alfred's E rsco al Church • • • y' g SW, Largo. Call (721) 585.4985. ~ „ t ' , ' pursue animal cruelty charges throng r care avail- Saturday.. P p miht<n stationedoverseas. V _ ~ ' ~ _ • , i ry , , charges through the federal govern to the extent that these animals _ (Anghcan),160tCudewRoad, - - - RobertAustinandhls Sing- ~ 1 k,,- y, rc i against Hale, though no charges merits " ~SkycrestBa ttstChurch125 ableforchildren6and oun er. P ? _ Y . g GriefShare bereavement minis- • Adultexercises; l to 2 m. - - ~ • ' ! - i N Belcher Road Clearwater. I Palm Harbor. Call (727) 7851601- p• , ing Bowls in concert- 30 cry$tal r ' I "y _ ; had: been filed ~iriay. Hale ageme icharges meat's Bureau-of Land Man- have been neglected,"BanksSaid. iy. Hale agement, according to. agency; a y ug.23togetticketsor try.10a.maonooneveryTuesday . o Tuesdays sponsored byFatthtn andTibetanbowlsat7 :m: Au . ' v . declinedtocomment. ` rwsrtwwwstaHred.arg. p 9 - . . , - - , : spokes ~ ; CaIIC1271791.7107: informatpn.' Inthestudentcenter. , - Action. 256fetame•' spokeswoman `Shayne Banks: Times researcher CarynBairdcon I ` ` ' $ 18.Costis$20 reservations _ - The tires mustangs taken The m1 • Beach setvice:7;30 p.m: Aug• 21 ' • . _ ~ North Bay Community •Karate:6to7 .m.Tuesda s. re Crested. Thursda m twere em h ;s taken : The mustangs were captured in tributed to this report. TdmaraEl- on the Dunedin Causeway before P Y q Y b geld she We - ~ - ;'THE SALVATION ARMY7WORSHIP CENTER Church,317oMcMulleir Ages5toadult ; , ~ at a ovate roe • One was of 1 ;ing held . the West, where overpopulation Khoury can be reached at (727) 445-> Dne was of wild horses is a problem.. 4181 or tel-khoury@sptimes.com: ' the third bridge on the south side. Triumphant Life Church, - P P , P ~Y wi d 1625 North Belcher Road; Clearwater; - 725.9777 " Booth Road, Clearwater. • _ BOBCROSLIN I Times" ' Dresscasuall andbnn alawn Adult Biblestudy:9:45to ZS55HainesBayshoreRoad, z ~ tvww•salvatlonannyclearwater.org ! Coips Officers Majors Dean & Pamela Hipson ; L Call (72T) 796.0071 orvisit ' Y g -10:45 a.m. Gos el of chairorbeachblanket p Jahn. Clearwater, Call (727)787=8609. ~ r is ~ Come worship with us i0;45am worship Service • fi00pm Evening Service ' i www.northbaychurch•com.;: ' I i TOda ~ Our mission is to spread the gospel of Jesus Christ and ~ • Plnochle:l to 3 .m. Wednes- • S mtual Em owermentGrou ~ S y ` ' ArtclassesAug.l6through p p p p • ' meef human needs in His name wifhoutdiscrimination.." • BIble study:10:45a.m. and da s• Sin le and double deck . uvith God'sGotFriendsmi ' Jazz orblues?: Jazz musicians will tell you that the Hammond B3 organ is really a Y g rns . Real es Oct.4.Otl aintrn 10 a.m. to bY' tat@ N. a~S~ ~ Watch ourNpragnm"MarchinglnthaLlghtSaturdaysatl2;gOnoononOrlghtl~susegrannel2-. 6.30p.m.WedneSdayS. P g' ' e transacUonS ':noon: Watercolor,1to3 .m:$20 • Adultexercises:1to2 .m. 7:30 p.m.thefirstTuesdayofthe V Jazz mstiument, but you won't find many blues artists who agree Willi that assessment. P p z , ' ~ ~ foroneclass$40forboth.For ' Thursdas• ' ~ month;-. ~ ~ Atthisconcertboth ou sirnll beon stn e tobattle it out at :30 .m. a th ~ r„ ~ ~ ~ . , .EPISCOPAL Y , ~ ; p , P g 7 p t e Palls- CLEARWATER 4;,:,. " I . - . r ; - , ~ MmutryForAllAges , ;E iscti al'Churchof the painters of all levels. • Retired and Redeemed: Fourth ~ ; ` diem at St. Petersburg College, 253 Fifth Ave• N, St. Petersbur .Who's the best? Come 1612 cenay st, to Michael0; Hambly p P _ g i 1' lambly ` ~ ) ~ ' St. John'S E rsco aI Church ' PRESBYTERIAN Jean W. Ward, Tmstee, $149,Ob0,. Pmell: - ~ ~ _ " 'S)~tVICES ',i Ascensiona7ott)rangeAve., p p , Thursdayofeachmonth. make your owil decision, Admission. 10-. 75: Call 727 822-3590. ~ ' c , ~ ~ ( ) as/os/2oo7 149,0130,, Pinellas and Hillsborough transactions are $40,000 or more. ' 1676 S Belcher Road Presbyterian Church 255 I ~ Clearwater. Call (727) 447r3469. a ' ~ I - ' - Potluckandactiviry:11:30to „ ; , ~ 3ssslosthAve.NtoThaoH:Tran' -Trans Fifth Ave. S:, Safety HarboG Calh , ' ;30 PM (as srlr~ule~ Clearwater. Call (727) 531.6020.. rran ' Transactions are listed in ascending order of valuation. The listed I- ~ vl ~ Ra oriel W: Melhom Trustee addre; •TheShedthriftslio :9a.mao, 12:45p.m.Thursdays• ! w vin , p (727)726.2014. $1sl;aoo, as/oa/2oo7.• the do ! t . : ; ~ THURSDAYS 1 .m: ~ Thrift shop9:3o a.m. to _ _ ,steer addresses are the mailing addresses recorded by buyers on the deeds. Usually, those are the addresses of the property that ~ . r ~ , ' , . ~ p slur ays,9a.m.tonoon Worship andPraise:6,30to •gethMopreStud '.'Believin , 7 ••Costis$30perperson.Reserva- _ Harbor'smonthlyFirstFriday 25s96ramblewoodor.e coa~ieda 7:30 PM o v g Toda i r Thursda sandFnda s., 3.30p.m.Tuesdays,Thursdays '7 ,m.Sata ~ y Chang I ~ ~ ; ; ; # I,i„~~»:r ~,~b1o g ~ , ~ o Y_ Y ~ p t relays. ~ - God :.for ou ' - ~ a dons are required. Call (727) 937 eventand en'o arts craftsrides ~siatrehiec ay old Republic Natl. roe frieda changed hands. For Luther and Saturda s y rig mothers with chll Artof Peace : Robin Saen er I ~ ~ j~ _ ¢ + r tuurr l,r.tdnate ~ E ilia al Church ofthe Good Y • g 5049: J Y ~ ~ + Insurance, $214soo, o5/1a/zooz p p $andysCoffeehouse:7p.m. •.drenprogram:9:30to11:30a•m•-. ; sines colddnnksand reatfood . ss3s1o1scc lad. Title n 007. r ~ Member of Rhema II1f01'IOatiOll Call' . ' and JudithCouturewill resents g 9 P 14949 Feather Cove Rd., to Brenda B• a h>u,. nssc.lne Samaritan 2165 NE Coachman • - Sunda S Romanofl > ~ ~ 4~1-~~~3 (t~xo) f JEWISH Y • Wednesdays through Aug• 29. ° _ new line of arttowear attheopen- Opera rodeo: The opera video La to afamily-friendly atmosphere . - Marsn by Lee K. Erickson, $z32soo, nda da 5636101st Cir., to Thomas E. & Alicia 05/04/2007. B. Romanoff by Steven A. & Dorothy J. 530 82nd Ave. N, to Magdalene Lopez :32,500, Harrold, $198,000, 06/19/2007. by Rene & Rosa Roman, $184,700, Road, Clearwater., Call (727) wnhPastrns , , Con re ationBethSha• ` •Men'sbreakfastandstud:8 in of"TheArtofPeace"exhibit Rondme;byGlacomoPuccini, ftom6to11 .m.alon Florida os/12/2007, Harroid,$ StPre Siiet7 ~ ..UPS Palmetto St: r 447.9581. g g METIROOIST Y 1 g erforrned b the Newyork Ci g & 470188th Ave. #702, to David T. & Char 06/11/2007. 2103 Carriage Ln.; to Simon A & 470188th A ' .17c{~ulsox tleatwater : Iom,1325SBelcherRoad, a.m.SaturdayintheFel(owship at7p.m.atthehistoricArcatle P Y ~ Avenue betweenAltematel9and Ni IeneR.M Curlew United Methodist 0 era will be shown at1:30 .m. na zaidela'by Puite dome corp.; setween>3elcher&Herct~ •Thriftshopa0a•m.to5p.m. Hall. p p T Corp., lene R. Muzzey by Laura A. Hagan, 405 8th Ave. N, to Paul Lamed by Peter ;Clearwater. Call (727) 5311418. 7 Building Amum, 210 S Pinellas County Road1• Free: E-mail $z4ssoo, 06/15/2007, testes, $ ' Chunch,2210CathedralDrive, attheLee a-RattnerMuseumof Ave. Ta on S nn p 2220 Ham Blvd. to Israel Jimenez b Trustee, $215,000,06/15/2007.' Allen Nestoff, $185,000, 04/10/2007. nez by SEMINOLE " 375315th Ave. N, to George W. & Edith : ~ShabbatseniicesandTorah palm Harbor. Call •ThirdFndayforKids.Watershde c,, rp p gs.Theshow . FirstFridaysPalmHarbor@ y SEMIN f 7~ Art 600 E Klosterman Road Tar- PAID ADVERTISEMENT PAID ADVERTISEMENT stn :6,30 .m: Frida s and fun with hotdogs and s mores 6;;` ! ~ 7 will feature Steve Corrado s metal hotmail.com or call (727) 934 Edc & chdsry M. col8ns, $250,000, 993 Oaks U 0,000, Lamb by Diane E. Wegener, $185,000, 993 Oaks Ln., to Mark Applefield by Rick 05/15/2007. ' ~ P Y 7843424: on S tin s. Free to all a es. Call 06/12/2007.. 9 a.m, Saturdays: Family Shabbat 30 to 8 p•m: Fridayforchildren i r, imprinted images and assem-' p p g 9 -Applefieid ~ ~ ~ : ' 727 712.5762: 7001. 2644 Sabal Springs Dr, #s, to Howard coward Applefield, $85,000; 06/19/2007. 253 27th St N, to Paul U. Chistolini by ~~mm r g~n~ ' dinneronfirstFnda s.Services TheThrlftySpmtShop:10a.ma° ages5to11. I ; E, blagesandmixedmediapleces ( ) w•&candaceB.Brbeckerb Pm- 8151Heathe . . y Ptu- 8151 Heatherwood Dr. #712, to Elizabeth Bryan & Jaime Marshall, $205,000, ullull~l. Li1~l S ~nsl pn rye' p r Y 2 .m•Wednesda s: Dinner&musrc:5to8p•m.every' y elakewill Ul ill 1~ ~1 followed b memb r- p y by Corrado and Saen er. F ee. dermal Relocaeon inc., $zs~ ooo. y e oste TnnityF'resbyterianChurch, ~ ! "V g - r. COI1t111U111g SaturdayatAmericanLe ion Post i3sszl:a leswalkOr: toTina~& ` ferrnan,$ First United Methodist Call ; . kiddushluncheon:Childrenwel- . ~ 2001 Rainbow Drive; Clearwater.. ~ L (727)934.2379, g g . loosaa3rd 000. Blake Williams by Christina L. Hef- ; 06/01/2007. & ferrnan, $109,000, 06/15/2007. 6400 46th Ave. N #22, to Brian J. Lawa- • With a few more weeks of summer, the savor shave -The start of a new seasonmeans char es. Same must re lace or Largo art show. The Lai o Art . 11913 Arthur Wainwright by Charles Ken- , e. SW L8r Jahn & 1C g P come•Chlldcareavallablewtth Chunsh,421MainSt.,Dunedm. , Ca11446~6210. r East Lakefunforlads:Cftlldren g, 0 irstAv go•Ft1et nett; A ' & one M. Cheezem; $299,000: . ' never been:better. Consignors fiaveaotharized big ' add furniture to accommodate expected house guests.ln homes ,Call (721) 733.4139 orvisit Association will present its sum-. - ml non otato and salad will be os 1 > Ken- 10098 83rd Way, to Susan Moyer by Cecil ndus by Scott & Terry Vanderveer, 299,000. John & Kim Gilbert Mills, $117,000, $220,000,06/15/2007. ' markdowns on m items m e RSVP. • • ; . r 10 and older can have some real g ' P 1s1a s wghland Ave.,.to Kenneth & /?Izot tidy di Gallery. ghat are crowded, there 1s a need to dispose of the extra piece, wwuirdunedmfumc,o Class on the Religious World.,:, , merart show atthe Largo Com- featured. Cost is 6.50. Mu i 73'72Is1amo th & 06/12/2007: 695 61st St S, to Jane M. Steven A. • Lunch and team. Noon on third ~ ~ a summerfun atthe Hot Do s & $ , s c Margaret c. Delarbre byJere L. & Whatever oursituation; ou'llfmdthesolutionatCansi ent Around Us .Tau htb Be Tut g Y y gmn ~ 9 Y ttY munity Center, 65 Fourth St NW; 51,eila Pa a $ao5 ooo o61s 2oo7• s. Wilson L. & 7372 Islamorada Cir., to Robert & Carol. Neal by William C. Anderson, $220,000, /2007. S. Wilson by Beazer Homes Corp., 06/15/2007: ' Wednesda s' Free workshops on how to ton and EI Smithftom 6: r: Fire Hose Spray Down starting at provided byMn Marie. Call (727) g ' / / ' $355 000 ~ ~ Furniture Gallery, 1111 Court St,, Clearwater, It's a unique fur- Y • wyn 45 to ~ through Aug. 31. Hours are 8 a.m. 456713Ist Ave; N; to Andrew J: g i • , P ry Y g p Y Y teach En lish to adultswho are y g 1 m; atthe East Lake Comm to 8 p.m: weekdays and 7:30 a.m. niters slip :filled with furniture for eve room in our home: ~ JudaiCa IftSho :Dail and b 7:45 p.m: Wednesda SfromAu . p• u- 5842038•. Andrews by Randolph Clarke White,.. $355,000,06/15/2007. 245 38th Ave. NE, to Ross Hanchuck White, ST. PETERSBURG by Joseph Brian & Sheryl Manning, P 'r ' ~ Owners Matt sad Mazci S erber offer a constant) chap h , ' ; newtothlSCOUntryorhmltedEng- . - s nltyLlbrary,4125EastLakeRoad. • - $565,000 os/1s7zoo7. ' ST.PE7 P a ointment... 22ttiDec.4•Free: Arts lamed.TheLee aRattner • to 2.30 .m. Y Bt g Saturda s. C I pp a I (72 xp p $240,000, 06/15/2007. 5890 38th Ave. N, to Jane K. Brown by 295 7th St S, to Judy Judd-Price by ,r I ' . ; , ' • . lish s eskers from 9.30 a.m. to - I c ~ p Y ~ ' • Soso 3atn p ~t I i selection of clean, good condlaon,pre-owned furniture, and a p ~ EnJoy a hOt dog and then beatthe 518-3131. Museum ofArtoffers a coin h CLEARWATER BEACH Doroth E • ` CongregationBnaiEmmunah, , 3:30 .m. Se tl5and22.Th s vNITARIANUNiT7ERSALISTS;, P - y selection of model home furniture and factory order cancella- : P p D e i - heatwlth a gentlespray-dolntn, 40001 ICH Dorothy L Bowen, $50,000, Christopher Judd Price, $242,000, 06/ ~ S merits ' r ' ' ' tionsat tremendous savin s. 3374 Keystone Road,Tarpon Com ledn theworksho will Spirit of Life Unitarian llni• ~ i I Pursuing artistic excellence: ' ry. ocenttour at2 p•m, ` 15ao cull Blvd. #1ooa; to steven L & , g P 9 p courtesyoftheFireDepaltment• - Jagddob~ i L. & , 400012th St NE, to Ramnarace & Marva 06/2007. ' 1 Springs. Call (727) 938.9000, receive a tutorin ' Pablo Slebel Reflexioneslnh- . every Sunday. Meet In the lobby sands A: Anthony by Ross E. Kidy ` - ConsignmentFurroiture Gallery needs clean, up•to-date fern;- g certificate and versalists 18412 Burrell Road t Call (727)773.2665: ~ o6/tsl2ot ' i u Tmstee, $650,000, 06/19/2007. Kirk Jagdeo by Stephen Garofalo, $55,000, 5120 Castile Way S, to Ismay U. Payne by 17 06/18/2007. Rodrigo & Rosa Londono, $274,000, " `lure: The will ick u 6vo or more lar a ;sees ac no ex sole • Brotherhood Con 're ational be ass; ned to teach at a literac Odessa. Call (813) 7921622 or mss, a collecfion of works by of the museum, which is on the, 2ato Andatu Y P P. g P p 9 9 9 Y. Naturalwatercalors:Aitist ~ a the Chilean artist P e LlarJe . I ) ;r 1 to you and display,elri their showroom. After your fumiiu"re is family picnic: Noon Sunday at site. Ca11442.6881 forinformation visitwww spiritoflifeuu.org. ; V ably Siebel, Tarpon Springs Campus of St LARGO _ y y 2410 Andalusia Way NE, to Barry Kinney, 06/18/2007. by Luxley F. Farrell, Trustee, $85,500, 290 Valencia Cir., to Susan B. & Victor I , TerrySmith of Land 0 Lakes `o6/1a/tot 'sold the wills 1ltthe toceedswlth ouona50/506asis•Their . Shelter6 FretlHowardPark. 'andtore ;stet. , , T IsondrsplayuntilOct141nthe Petersbu Colle a 600KIos- 839aMeadowtirookOr.,toHueT ~ g + 2027 36th P ' ' ' g Worship sennce atthell a.m. ~ presents his ;rite relation of - i ~ Y., P P Y.: ~ ~ Rhoda Newb N en b American Housm Co . r T 06/14/2007. R. Collins by Travis & Tiffany Harper,' ~ t4'~ ' e •to-understand, const ent a eement.ex lams rt all Cal ; , Bnn a lawn chairorblanket..Cost 1, . erryReed Gallery 9uY y 0 m, terman Road:Admisslon isfree William M . -any _ g~ 8?,, P I i .g, , , St. Paul United Methodist - - , , everySunday. _ Flondathrou hhiswatercolors ~ _ ooooosl9zoos... `a ; - _ 447.0926 for details. 0' en 9.5.30 Mon: Fn:9.5 Sat: Is 5 ~ ' i 9 ; ; of tf(e Gulf Coast Museum ofA , .kd - ~ ~ _ . ~ ~ l D Corp., 2027 36th Ave. N, to James E. Dove by $310,000, 06/01/2007. William Mirro,.Trustee, $89,900; 05/10/ 9525 Blind Pass Rd. #1005, to David P r , $ a person, children age 5 and ;Church 1199 Hi hland Ave. f` ` tt' oti Sundays. Call (727)712-5762.. szss sznd w ` to oavid L. ' ` ~ ~ 2oo7•, _ ~ - s 9 , Perspectives discussion group: , ~ . ,pn displaythrough Sept 4 atthe ; 12211 Walsln ham Road Lar o: aY, & Maria 3ri113ra Ave • - ~ In the 5t. Petersburg area; tie sure to vest lhezr other store, Consrgnanent younger ere free. RSVP to 938 largo. Call (727) 584.8165 or 3 - g ; g ~ V. Jackson by Wayne C• Jackson, Vlana 2007.<' ' - Jiruska by Kendall J. & Reva F, Moeller,-- 36113rd Ave. S, to Liselle Murray by James' $325,000, 06/19/2007 (son, Izzolo, Trustee, $92,600, 05/25/2007. 825 Live Oak Ter: NE, to Byron S. Kiefer by The S erbers And Thew Staff At ' Coffee and conversation at10 a.rn. BrookerCreek Preserve Envlron Absorb Siebel s uni ue artistic Thespians unite: Adults inter- Izzolo, Tna; P FurnitureShourrcom,Inc.at6t30CentralAve.oronlineat 9000 requested: ; visitwww auluml:.o ~ I ~ q ' $s5,00o,06/OI/2oo7. 371128th Av Their Consignment Furniture Galler - , Sundays.:. , I 2 mental Education Center, 3940 ; style as he mirrors a I'Ife of myriad ested in drama, dance; music:. n3oo s6ch sL #3to, to Renee Taylor by Y wvvvv.consignment furniture Temple B nai Israel,1685 S • "The Fountain" contem ors by Robert ' p ry Unitarian Universalists of i Keystone Road East Lake, Open ' contrasts and contradictions, . appreciation and erforrnance Raintree condos atvlla Park LLC; p 13/2oo7. ylor by 371128th Ave. N, to Svetlana Zablotzka Trude A. Brinley, $350,000, 06/15/2007. sylor by Robert Towler Tandy, $115,000, 06/ 2100 Hampton Dr. N, to Maryann Bruton ',.Belcher Raad, Clearwater worshi :9:25 a.m: Sunda s in the ~ i ~ $rls 900 os/ol/zoo7. • p Y Clearwater, 2470 Nursery Road. I t .from9a.m.to8.30p.m.Wednes reflecting an untlerstanding.of canrrieethke-mindedenthtrslasts ;?3zOMelro; I ~ 14130 Rosemary Ln: #4202 to Francis Call(727)531-5829 or-visit; Life EnnchmentCehter. da and 9 a.m. to 4 .m. Thursda - 13/2007. by Elka Harms, $425,000, 06/20/2007. ,rancis ?320 Melrose Ave. S, to Rhonda Regina 4530 43rd St S, to Christopher A. & Jenny Call(727) 531.7704'orvisit ~ I Y P Y , human nature with all its pas- ; ata gathering ofthe Rerforming A: suilivan by Menelao Gonzalez, cummmg I ~ `wtluw.TBlclearwaterorg• 1;127000 dez, Cummings" by Charlie Ruth-Jackson, E. Dolan "by-G. Wayne & Leslee C. 7, $127,000,104/20/20017. Wihbey, $600,000,06/15/2007. . Kid's Kampj 10:30 a.m. to noon www.uuclearwaterorg. ~ ~ Sunday. Call {727)453-6800. .lions and entanglements. Free trustee $1ao ooo os rn zoos' ' = ArtsClubfrom6:30to8p.m: ~ ~ ~ 6924 Stone; ~Shabbatservlce8p.m:Fndays;f every.SundayinAUgustFortod- i !I .q Guidedhikes:Ex eriencethe for museum members$10for 7581cumbedandRa.#1,toEdriEast East 6924 Stonesthrow Cir. N #8104, to Susana 1208 Darlington Oak Cir. NE, to Philip & followed bymember-hosted DunedlnlawyerMarkBrandtwlll ~ p + everyMondayintheSafetyHar-, c;Mccou dlerstosixth-graders;, ~ naturalbeau of Floridawithfree uests•MUseum'hoursaret0a.m: by Brookecarber&DanielNeiaicn, discuss AShortEssayonHuman- ~ ~Y g borLibra Meetin R Valdes $1. G. McGough by Rasciel A. & Jorge H. Kimberly Mularoni by Robert R & Susan eidich, Valdes, $128,000,06/13/2007. M.•Nantais $789,000, 06/11/2007. • oneg. Children welcome. ; ~ ry g oom,101 $142,aoo, o6/1s/2oo7 ' • „ uidedhikesthroe p• Y- Y.. Camp Meeting worship: Ism and Spmtuality atthe10:30; g gh Brooker . to 4 m. Tuesda Saturda noon . ' 12ssa134th st to oaniel a 750 Seth Avg Second St N. Free. Call (727) 724 & C ssandra • Shabbat momin servit:e at ,Creek Preserve's Education Cen- to 4 .m. Sunda Closed Monda Bindman b T K H Global LLC by Wlliarr Sandra 750 58th Ave. NE, toJenna B. Weaver 320 Coffee Pot Riviera NE, to William ; C by William Mirro, Trustee, $160,000, W. Adams by William McGovern, g 10:30 a.m. to noon every5unday a.m. Sundayservice• ` p Y; Y•~ - v... , 10,30a•m.Saturda sstartin ~ ' C II 1525;ext,224• 53oo0 os os/rn/2oc Y g ~ inAugust• •Rehgiouseducationforchjldren j = terTra11,3940KeystoneRDad, a (727)518-6833. $1 ,/15/2007. , ' 527334thA 06/01/2007. $1,725,000, 06/20/2007. AU 25. ~ D'Ddeland dance: The Ba Slde 13224 Thoroughbred Loop, fA James g'- - •LighthouseYouthMinistryYouth throughfifthgrade,10:30a:m. EastLake,from9to11a.m,Sat- Flowersandmore:Enjoyflor- y -a i indapistui 5273, 34th Ave. N, to Andreas H. & Sener- ames inda Pistulli by Steven H. & Debbie M. & Fa th PanagiotacosbY Robert L - ~JudaicaShop;open'dailyand . ' Week:7a.m.to7p;m.Aug.1218, every Sunday: ~ . j r. urdays.Advancereglstrationis ida'snaturalbeauryattheFlor- Banjo Band playsDikielandand Hoideh,$17o,000,06/1a720oZ Leonard;9 obert L. Leonard' $167,500, 06/15/2007. Compiledfrompublicrecorclsby ; 564218th Ave. N, to Ronald R. Hamory by IMRInc.4Iorecomplete igorma- by appointment • Senn ' • ' ' ~ ; ! requlred.`Call (727)453-6800. ids Botanical Gardens at12520 old-time songs from 7:30 to 9:30 14981 Nan court, to Julienne i.- S6az lem As oraduRfellowshipond .Open Issue discussions, - ,tool Lynn I Toni Lynn Broad, $168,000, 06/05/2007. tionisavailablefromFIVBRInc. (813- I Corp., 3833 25th Ave. N, to Carly A. Muzzy by ` ` - ~ Wine and cheese reception for' Bibl ~ = ~ 0 ~ Ulmerton Road, Largo. Stroll : p.m. every.Monday atAmerican tiodwln by American Housing coip., estudy(JOY).10.15a.m.Tues 9.30a.m.everySunday. $sl5ooo os 1s 2007.> 3a3sz5thA • prospectivemembersat7p.m, da s $Ufldly through hundredsofblooming Legion Post7,1760TumerSt, ~ / cnoonDu Choon Duk & Jung Tae Kim, $176,000, 988-8148)• This is nota complete list- • . • • - • Ys • La Leche Lea ue Art Show at olio Maidstone court, to Matthew & g I s . Safety Harborart: Artistsftoln , flowers and plants and native and Clearwater. Call (727)4479204. Erin Marione b bon las M• Wil- Aug; 24, followed byShabbat set- y y g ew & ingofall the real estate transactions. an Ica a eMlnlst 6.15 I. i 3 ' p ' ry p.m, the church s Octagon ArtCenter. ~ Safe Harborwill have their non-native ornamentals. Free and liamson; $54s,ooo;os/t5/zoo7• . - vice led by Rabbi Arthur Baseman • Wednesdays in the Children s , Opening reception isfrom 7 to 9:. , i sin Farmers market. Held from )7. _ and introducingcantorial.intern ~ l V. p tings,pnnts,calhgraphy,pho; opentothepubhcfrom7a.m.to7 . St. Cecelia Church : LutheranCkurchBcSchool MlnlstryCenter. 3op.m.Aug:24,Showwillcontln- ~ c to ra h andthree-dimensional .m.dail .burin summer 9a.m.tolp.in.thelastWednes- PINELLASPARK Pe~tCe MelmUal`l~ F18r)1 E~ tMa narsa~Ra•, c~r,.as2-soon Jenn'Ifer Duretz. Special oneg i g p Y p y g week- Comer a1 Myrtlaava• s crud ad, ! S : t ue throe h Se t 5: Galls hours ' I ~ ~ da of the month at Ci Ha11112 r ; 6400 GSth st, to dusOn L smith by sa~mvmcka~arerpvlaerus4~~rs~•auaoa~, ILCMSI undayyMormngworsmp N aftertheserince,Chlldrenwel- SkycrestUnitedMethod. ,9 P ry 3 artworkshowcasedattheSafety' ends,toursthrroughtheToplary, y ~ + . am Fh~~~b~~ Church ' e a.M. & 10 30 A.M, > . are 9:30 a•m, t01 .m. Weektla s.:: ' I Wendell J. Klein, $133,000, 06/15/ t by Buyers and Sellers - -saraROartdassES- III . sands 'a ~irome.RSVPfortherece lion, istChurch,2045DrewSt•, p Y ~ 1 HarborMuseurriofRegionalHis- Butterfly, Celebration, Rose, Jazz, SOsceolaAve:,Clearwater.Visit zoo7. 4:00 8 5:30 P,M• 110 S FL Handson Ave.; Clearwater ~ ~ r School ForNl9:15 aM• ~ P I/15' of Diamonds and . =suNDArMASSES - - -Comamporaryworshlp, samrdayss,aBRM Clearvlrater. Call, 01.27) 446.2218. Unitadan Universalist Church,of s Cory, 329 Ba shore Blvd• S. The English Cottage and many other www•clearwaterfarmers s9os 57th sc, to Kelli McFerron by 9 Ru°e asailabla • Couples Club for mid 307 to mid ~ ~ y dA5 '8:00, 9:30 and 11;00 A•M. m Church Schoo19:15 AM " Ta byI 4 D6/ Fine EstiateJewelry M ~ wwwAmBulliaraa•iI oat . ` 507. Members Ian a ro res- Daniel and Cathy Bernard and rpon Springs,230 Grand Blvd.. , . ; exhibitopens at1 p.m., and many gardens are self-guided. For more marketcom orcall (727)4617674• Trudy E. Yourkoski, $144,000, os/ ' G~e Teeh Mass at 12:30.PM• ~ p p g ~ 18/2002 MisaenEs o016.00P.M.. 4 _ WOrShlp 10:30 AM RadioBmailcaslSuoday10,~0AMW+4Ba 1610 livedinnerfortheLaborDa familywllltalkaboutmamageat Call (727)937.4682. I 1 oftheuniqueltemswillbeavail- Information, call (727)582.2581 or plumb HouseMuseum:Tourthe 71so74thsr. tobavidv. i ~w• Y I & Km Burch i Burch ~ ~ the9a.m:andlla:m.SUnd set- •WriterandlecturerDr.Eric i ablefor urchase.Atlmission:$3 visitwww.flb o sEttvtca altonDCnsT N ; ; weekend. Call (727)725.4475for. pY , , P g' historic Plumb House Museum, a by chdstopnera & summer R. , . R. P RE" L O ttX CO rav>;orrwrAtv1340An1 b information. vlces•Amusicgroupalsowillbe Rhodeswllldlscuss Freedomo_f - foradults;$2forseniors,teens Youth art:ViewYouthArtCorps Cracker-s le housebuiltin1896. wdght,$1as,ooo,o6/la/zoo7. ~ur • C • ~ ; ~ 7 ~ 11004 Maxton W to Shannon Swartz www.peacememorlal.org featured. Bernardisthepresidentof Religion atthe10,30a.m.Sunday ; l and children underl2;freeforchil- studentwprksareondisplay • Swartz DIAMONDS & FINE JEWELRY • •BereavementGroup;"Families - T Ithousesperiodfurnishings;viii- , by sank ofluv;Trustee,$15s,ooo, °La Of „ • , _ SomebodyCare$;TampaBaylnc. service.. I dren under7. Museum hours.l0 through Sept19 atthe GulfCoast os/o5/2oo7. 100, Discreet Collateral Lending By'Appointment Y PU15CS That Endure Adjusting : s~= . loge photos and otherartafacts• • , „ r ahumansentice=organizationthat t a•m.to4p•m.Tuesday;Fndayand MuseumofArt,12211Walsingham sosl4acnst;to_HobertA.Johnsonby:; ?he Clearwater Hlstoncal Socie 428 LOltl'f~OS ~,hUr h ~ . Dr. M. Rebecca Burton Pastor to Loss C assistschurchestocarryouttheir vNITY. ~ I 1to4p.m•SaturdayandSunday. Road, Largo. Free admission. - NeiidaMudel,$17o,ogo,os/14/zoo7. WEST;BAY. atnoon ; I r. offersfreetoursthefirstantlthird a~meathAve:#zo7,toaaynaL. . _ - worklnthelrlocalcommunifies: Unity ChurchafClearwatey Call (727)726-1668ore-marl Artworkwlllbeavallablefor 750 San Sdradoe Drive; son b 428 Indian Rocks Road • Belleair Bluffs • 727-585-5700 ' COMMUNITY- .:Mondays. k5!. . . °in ~ I , 2465 Nurse Road Clearwater. ~ x info@safe harbormuseum.or . ' ' ' Thursda ofthe month from Estes by stepnen e. King, Trustee, °naea;a SylvanAbbeyllmtedMethod , rY r ry g purchasewithproceedsgoing YS itee, , By one a' ~ ".CHURCH Faclhtated I ~ $177,9oo,pslrn/2oo7. ` ~ r, ~ i C urch'2 Su CallC127)531-0992brvisitwww , totheYouthArtsPro ram:Call 8:30to11:30a.m.year-round. 733-366 . " ~ epee st h. , .817 nsetPoint Winetasting.Loversofthegra e 9 WekOme ' j" Jae o ouvan,aB: Largo y' l' Road Clearwater. Call housebuiltonlove:com. I - are invited to a Bur noel & Pin ; (727) 518.6833, ext 301, orvisit Thetwo-storyWOOtl house is at MASSES. Baseman r (727) I _ g y of " I ~ I www. outhartsco s:or . 1380 Martin Luther Kin r r 1 I r 796.3057. " The Rev.Ledd Hammockwlll NoirGrandTastin &Salefrom Y. rp 9 gJ •Ave•;;; ' Weekda s7i00end9;00A.M. _ = ands on- Y 9 J y _ Verse By Yerse P AorMorernormatton 'sored'ointl - address 5peaktheWord atthe . ~ 2to5 .m•atB-21Wine&S ;rite Fami -friend) fun: Winddowri Clearwater.Free:Call 727 446= ~ ° _ s • Saturda Eva' 1 J Y WonderfulWednesdayfel- . p p IY Y O • r ~ Musa BIble Teaching . Baseman 9:30and11a.m•Sunda sentices. ~ ' - S;ooaud9iooP,M• cau4463o01 6ythe . , -'lowshi Bible stud and dinner: Y 43380U.S.19N,TarponSprings. fromalongworkweekatPalm 2676 or (727)3991412. Highland Complex pr Y • 1 • 1 ~ 1 ~ 1 . . ~s a MusicianSUsanKayWyattwill : ; Pllle~~ Sunday Sehedule aoD N. Highland Ave• ~ yn gpgue 5.30 p.m. Wednesdays. Dinner is , aS deaths .8;00, 9:30 and 11;15 A.M. ~ ~ and Gulf Coast Jewish Family $6. Nursery provided. perform at I I _ Bron a Phili Samuel ; • • Sundays -11:30am ; g , _ p ' ' Holy Days of Obligation 595-3991 ` Services. Union Street United Method- both set,- ~ , 'Burke Eve + Vigil S•o0 P.M, a www.WestBavCommunity:com Ytun Israel•Chabad of Pinellas istChurch 1825 Union St. vises. ~ 't,,r ' r 1 1 ' > g r s ` ~ Butkus; Vella Z. ~~P . , Holy Day Masson ~ Caen 3696 Fisher Road Palm Clearwater.Call442.9300or , ,UnityCom• l . , Closeouts, Damaged . 7:00 and 9;00 A•M• a Harbor. Call (727 789-0408or 442,9386. munity j' ~ t' b ~ ~ Clanton, Larry Nil t 1,30P•M: and 7;15 P.M ) ~ To la : Fill in the rid so ~1 Holy Spirit Ecumenical Catkolic Church . • visitwww 'ohabad.com: Church,1315 ' , r b Y 9 Fetch Jeanne R. BEST 1 Mibnatch, Trade-ins BEST VALUE IN TAMPA BAY / y' Free workshops on howto I ~ i ' Bayshore thateveryrow,everycolumn ' ( A diverse;. inclusive alternative . ~ 1 7 , ,==M iii ilia Cuiholic tradition! ~ • Kabbalat Shabbatservices: teach English to adultswho are Blvd ~ ~ and every 3-by-3 framed . Hagstrom, PeterJ. ~ , SundayMaea;lOr30ain ~ 7:30p•m.Fndays• ' newtothiscountryorlimited I I boxcontainsthenumbersl, Johnson;Walter Dunedin. I ST. CATHERINE 114IPonce de Leon Blvd: ' ~ ~ Shab English speakersfrom 9 a.m. to throe h 9 exact) once. The - .TEMPLE OF LOVE & HEALING batmoming service: Call Hammock I g . Y Katz, Helmuth W. Jr. off of Clearwater-Lai o Rd , C1eaCWateL 522 ioo-~ oa, Ave. N. sr: Petersburg, FL . 3 p.m: Aug:20 22 and 24• ThOSe ~ i Solution IS uni ue. ' OF SIENA ( g ) 7133 Sun. & Wert: Bva wa56~P ~ P.M. 9 30 Saturdays,followed by a Kld- 734.0635• ~ q • ' 727 232-3918 wrvw.hol s ir;teoe:or coin letin theworksho swill " I • Knaggs, PhyllisJane ;e 1 y p g Sun , B 12 Revs Finn Dr er & Daw Panunno• ' uSh and Cholent P ~ ~ CATHOLIC;CHURCH' , ~ tours • : receiveatutorin certlficateand einMiracles:l0tp I Laughlin,DorothyL g 2 v- `You Too Canl3eaSu erHero i L i ~ d- I- Bit~ Tif Ax, ?i A n :Youth services:10:30'a.m. every ; I 1955 Soulh Belcher Road u , be ass; ned toteach ata literac 11:30a.m• Fridays: • Wed.B/15~LauraCuller roc:rs otherSaturda forbo sand Ir1s< . g Y ~ j Martin, EdwardJ. _ , Clearwater, F133?64 Mae c o- m y' Y g -site. Call442.6881forinformation Heali 0 U Ion - - Fri. 8 .l7 ens , Cir le 7.3 9 "F ~ UCIOI(U , / 9: P a es7to13• ngCenterByappointment I Pfaanschmidt,Henri• bAILY MASti; - g 2 r aan9soi • e e ds andtoregister. Participantsaretralnedinthe ; i ettaMarie I L n oftheTalmudclass Monday-F't•td:ir g g l s, • g Pil rims a ;rite rative healin I g 9 , Rice, Helen Holt 1 7,OOam&11:OOaln ~ ~9a.m.Sundays. ~ oTBER ~ ~ .process. - „r. i ' ' 1[onda 7:00' m ~ ~ ~ X 9 7 6 3 1 5 8' 2 4 Y P Hebrewschoolforbo solid- . IrtternahonalChurchoF RObert,Catherine ' Y is Saturday8;00am ~ ~ ;ilea es5to~13stadin Au .26. Ceti ~ R twater 2140 2 3 1 Ran a Ra 8 6 4 7 ad. 5 9 Ro e 9 9 I b rtson Adam Jr. g 9 r - g Send nezos of relagvous program8, , F or rates an i d nformation visit C the all 4 41'EENENDMASS; ~ 1,_ ~ (727)461.7729orvlsd eventeandseratcestoChrSSCvsdon ~ 8 4 5 7 9 2 6 3 1 Sweatman,Bnan E Satin' r'1. EEC11 ~~t,ljllCSC~11V synagogue Web site. wwwicclearwatero i - ~ • 9 g N+a ~ _ ~ r9 a t i,4GJ bJmailto710CourtSt,,Clearroater,., 6 8 3 2 4 7 9 1 5 ~ Edward Ent', Sun,lay;7;00atn,9am(Famliu~r+~s AnglirandrurdtofSS,Peter&Paul ,•KosherPicklemaking.1.30 •FamilyBiblestudyap.m. FL~3375s;byfaxto(127)445.4119ar I';~ ~ ~ Z ,5 4 9 -3 1 2 6 8 ~ ~ Tooke, Oscar sHORi ' Entire Seasonal Inventory SHORT SLEEVE SPORTSHIRTS • SHORTS- SWIM TR r 11;OOam(lhudltroiiattci,! 19288bokofCorrimonPrayer ~ ~ e~nuiltocosdon(~sptzmes•com: ~""1 ~ Wa net Ethel o bi)D m(Co1 •,i.,,~~,~~il~i - l 0 1. 2 9 5 8 6 3 4 7 9 - - - - - - - - - - - - - - - - o ~ J M.P. Holy.Communion 11AM Sundays , 0 PARISH ADMINISTRATIOti, $Union St: United MelhodistChurch-Chapel , a - ~ ° , 5 9 8 1 2 3 4 7 6 ~ 77iis listisfrom detailed ISPEND A via In =1 SPEND $100 OR MORE TOTAL MERCHANDISE' ID ahle 5 ~ - 1 OFFICE a tii25l1nionStreet,Clearwatc~ ~ L''a`'-'"~'r~ 1 / 1 4 1 2 6 .Z 8 5 9 3 obihtat•iespublishedtinSec- ISALEME 1 PURCHASE. WE'LL TAKE 10% OFF ANY NON-' i BIG 8 TALL - ieC- ISALEMERCHANDISE,TOO..Ends8/25/07.Not - ,valid for prior purchases or in conjunction with other dis- , "3200 E. BAY DR. - . 1 rlry t b , f".,~)~ { 1 1 ~ ! / I ! tionB. Ivaudtorpri~ 531-111 Rev.R•Rovelstad,Vicar(7271'596.3680 `o~o..n-s.------0----------- LARGO 727-531-8449 i 3 6 7 4 5 9 1$ 2 Coovriahf ©2007 PuzzleJunrainn:ram `~ua~s,~ i _ ~ ~ . I ' _ ) ® LAR St. Petersburg Times, I Saturday, Augustjl; 2007 I .3 Largo Times ' ' ' R tampabay.com for. more Pinellas County news i - - - , I ~ -----------_I i I 'i I i~ ' ~ i ly it Yes, it is hot and'humid. But don't let the heat stress you or our ets. p y , i Times Ste~'Writer , As the summer's temperatures ' ~ . 'y~~J~I ~ ~ 1, 7 MY1/K .i 1 • hit the 90s"and high humidity s t ~ ~ , - makes it feel like a ~sauna,the ; ~ ~ P ~ _a ~ ~ i ~ Pinellas County Health Depart- ~ i . merit I ' and of her health officials „ ~ sa oucand o a lot to ~ YY kee our- P Y i g J Accordin to the U ~ ~ , 1' ~ r• , ~ M:. for Disease Controlf and Centers I ` ~ 4 f•'~ ~,r ~ , ~k gr Preden- = w - ~ tion,.those at eatest risk for ~ ~ ~ , ' - heat-related illness are infants i ~ " I and children ages 4 and younger, ~ • ~ ~ , adults 65 and older, people who e~ - ~ ' ' are overweight and people who ' ' I i are ill or on certaan medications. , ; Heatstroke o - ccurs when the ' ~ bodybecomesunable to control I ~ j,..r ~ ' - ,W.K~'7 its tem erature• The bod s P Y - JOSEPH GARNETT, JR: I Times ~I perature uses ra idl , the s tem- - ~ _ _ _ _ • weat- When air temperature is high, heat from asphalt and vehicles ~ ~ frig mechanism fails and the 'can add several degrees to what your body feels. body is unable to cool down. - ~ , Heat stroke can cause death with cool water, spraying with chotropic drugs, which affect ~ I ' . or permanent chsability if emer- 'cool water from a garden hose, psychic function or b'ehavior,' ' ~ ' j ' gency treatment is not .pro- placing the person in a ,cool: medications for Parkinson's dis- vided. Warning signs include an shower ot`immersing in a tub of ease because they cane inhibit ~ ` d± ~ .extremely high body'tempera-. coolwater. ' perspiration, tranquilizers and ~iNl~~ tune (above 103 degrees); red, hot Get medical assistance as soon diuretic medications that affect.; ~ and dry skin, absence of sweat- as possible. If emergency medi- the body's fluid balance- - ' frig, rapid, strong pulse; throb- cal help is delayed, call a hoepi- ? j Bing headache, dizziness; nau- 'tat emergency room for further Keeplflg pets COOI sea;confusionandunconscious- .instructions. ~ .:..The American Society for ness. :Heat exhaustion is a milder the Prevention of Cruelty to ~ ~I' $t1y hydl'ilted ,form ofheat-related illness and. Animals offers these tips keep- ! ` , , can develop after inadequate or frig your pets from. overheat- y~,~,,, When temperatures are unbalanced fluid replacement or frig, becoming dehydrated or extremely high; the CDC recom- 'after several days of'exposure to - getting a sunburn in Florida's n f.." j mends avoiding hotfoods and ' hi tem ~ eratures• P extreme heat: hea ' meals because the add Warriin si s include hea • Make sure our` pet has ' Y g l~ vy Y t ' heattoyourliody. .sweating,. , paleness, muscle fresh, cool .water available at t ' I Drink plenty of ,fluids and cramps, tiredness; weakness; diz- all times- Have a container _ _ _ replace body salts'and minerals, zmess, headache; nausea orvom- of water ready when you are - - ' ` r but don't take salt tablets unless ~ iting'and fainting•.The skin. may walking your pet, involved in People'who work outdoors like Bobby Murdoc a roofer with Decke JosEaH cARmETr; JR: I Times' under medical supervision- be cool and moist, Pulse rate will other outside activities or just Clean~rater project, have to take extra precaut ons to keep their both swell hydrat d.rking on a ' Limit. sun exposure during mid- be fast and weak and breathing lounging outside. day hoursand uiplaces of poten- will be fast and shallow a Never leave your pet alone that requires immediate care. ` can be burned. tial severe. exposure such as : To cool the body during-heat in , a; car or truck Burin sum- with insecticides or other ~hem- Soak ou beaches. Wear appropriate cloth- ,exhaustion, the .CDC recom- mer months- Vehicle interiors water immedia ely and take it to .ling the surmme~be sure t is not icals. Such chemicals can sicken orkill an~animal• I ~ frig and sunscreen, pace yourself, mends drinking cool, nonalco- can quickly become death traps 'the nearest veterinarian. too short, or~it can suffer from Also be alert for coolant leak-'~ ' stay cool indoors, schedule out- holic beverages, resting, taking with temperatures reaching well • Don't exercise yourpets after. , sunburn and overheating, frig from your vehicle- Animals. I , door.. activities carefully;: moni- a cool shower, bath or sponge ' over 100 degrees; even with win- ' a meal in hot, humid. weather. • Never take a petto the beach. are attracted to the sweet taste ~ I for those at risk and adjust to the bath, finding an air-conditioned , Bows open,' - environment. Walk or exercise them in the cool 'unless you can provide shade of coolant and ingesting justa ' ' ~ ~ environrent and wearing light- .Signs of overheating include ofthe earlymorning or evening. and plenty of fresh water. Rinse small amount can cause death, ` If you see someone with any of weight clothing, heavy.panting `dark pink or even • Never leave your pet stand- the pet after he has been in salt 'Call your vet orthe RSPCA Ani= ~ the warning signs of heat stroke, Federal health officials also reddish gums. The pet may also frig on hot asphalt or sidewalks. water. G get them to a'shad area- Cool sa the 'risk of heat-related ill- feel hot tothe touch, Ifthesecon- .The animal s bod .can heat u mal Poison Control Center at l- - i' Y p . • Avoid walking your pet in 888-4264-4357 if .you'- suspect ~ y- chtions occur it is an emer en f the victim b uickl s on 'n ness rises for people'using ps g c1' .quickly and sensitive'paw pads `areas:-that have been-~s ra ed Y q• Y P ~ g P Y Yourpethasbeenpoisoned . ~ 4 y i L l I `PARKS continued fr ' oml ~ , _ I . w , ~~1~ ax. ra a ma , e . r ,_o~ se ~ ow e maximum eu ~w _ _ , . I ; resource officers. r:. ~ _ . ~ Most commissioners sug 'gested cutting he city's Fourth of ~s ` i , I July celebration from the budget, ~ - ~ ,._..~...w:.,_,.,~, ~ ~i l(1 ' but the don't intend'to cancel r V ~ ~ - i the event. They said they're con ~ I- I fident the city will secure a spon- ~ sor to cover costs estimated at ' c about $30,000. :k~' I~' 2 I ov o 'City leaders also have seen a , ° handful of complaints from resi- ti , ~ " { ' ' dents who want maximum prop- . ' ' ertytaxcuts. a ' ~e~h Co ' mini ssi on r e s di dnta~ isc uss • - s ~ the tax rate this week,'but they ' i will likely decide to reduce the , i' propertytaxratebelowthemaxi- i ' ~ ~ ~I~(~'~ r^1 mumsetlastmonth. ~ \ `~'yl ~ .Officials also have .received Q .heartfelt letters from some who ~ JiM oaMasKE I Times , took part in city outreach,pro• Children who wrote to the city, ' ~ . ~ gramswhentheywerekids. 'commissioners voiced their f Y~ ~ ; But children ,at McGough concerns over the well-being ' ~ ~ o Nature` Park's summer camp of the many animals that live ' , ; ~ a arguably led the. biggest and atthe GeorgeC. McGough • mast:"effective campaign. They Nature Park, such as J.R., the Summer campers wrote letters such wrote letters as part of camp.. great horned owl. The Idds - ~ ` as these to Largo city officials asking 'ty, - ~ active some with a heartfelt .were es ecia ~ gn Y P- man turtles thhe - commissioners not to shut down nature son. P Ily worried for tat • parks during the week, a move that inch ation worth of Lisa Sim safety of the y hve m the park's waters. ~ , ~ ' { ` would affect many summer children's "I am disturbed by the whole ~ programs held atGeorge C. McGough fact that you are closing down "If kids can't feed the turtles 1 ~ ' Nature Park and others in the cityr. - j ' George C. McGough. Nature '.they will have; to goto another Park!" a girl named Madeline park to get food," wrote a girl helps thosekids,"Guyettesaid: ~i ' wrote~"ThecityneedstheNature named Gina• "They might get':.. Other commissioners tom- ~a Jared, ' I 'Park. It helps people learn to runned over,: Don't close both merited that adults also frequent R. ~ Schlabach, respect nature and respect the parks!!" ~ ~ ~ ~ ~ ~ ! 6'/x, studies the parks,: which host various> environment." Thursda ni ht commission- events, including festivals, adult a display of l Some introduced city leaders ers giggled over the kids' turtle nature walks, Scout and school .z ~ ' ~ ~ y skeletons ' to theirfavorite park creatures, comments.. fieldMps• Friday during i ':.such as the great horned owl ' "We don't want them to be hit Recreation, Parks and Arts ~ ~ :a ' cammat I ~ J•R., rat snakes named Thunder by a car so we better keep the director Joan B p ' ~ and Houdini,.and a slew of tur- Yrne said there I _ ~ -'1- George C. parks open," joked Gerard- are few additional costs to kee McGough flea that swim in a and there. A The leas also touched Ci Bonner o en as well since P ' ' P P ~tY P the ~ ' i ~ few read those letters to officials Commissioner Andy' Guyette, same staff serves both parks. i Nature Park. . i at City Hall. , who wants to keep the prop- "I think that's'a deal, myself i The City. ~ ~ ® Others highlighted their fears erty tax rate as low as possible, ~ ~ r. ~ Commission $75,000 a year to keep both of i noted the ' ~ ~ o that wayward animals would be but: said he wants to keep' the :.those parks open,"Gerard sand. I ~ left to fend for themselves if the ~ parks are , ~ ~ parks, especially McGough, i parks were closed during the open~,ati LorrdHe>fandcanbereachedat445- ~Y`:- r Vourable ' week , ' s •ne lark that really : ~155orlorripsptimes,com, es k fr . j my uxmxsKt limes all resjuents.. I 1' {If , ' ~ ` ~ 4 !Saturday; August 11 2007 ~ St.`Petersburg Times LAR ' i ~ tampabay.com for more Pinellas County news largo Times Sports ' ~ . _ - - - , , . _ Barra a of birdi - I es halts ,g • . r ~ E~ I r ~ ~ ~ . ; ,d~ ~ = _ _ Messer ss arklin la - s------ ~ - - I - _ f I - e, After playing 27 holes in the I've finished in the top 10 before. r r - US. Women'sAmateur Cham i-' And if thi s dont ~ . I _ ~ T" ; P ng work out I 11 I I ~ ~w~ ~ 4~,~; ~ - ~,w onship on Tuesday and another return to the .(LPGA) Q-school - I , : ~ , ~ 27 in a sudden-death match- where I've been successful: I just ~.r ' ~ i _ ~ ~ ~ " playwinonWednesday,Andrea need ahigherfinishforpriority , I ~ M p o the 2008 tour, " ° ° ~ ~ ~ Messer should have been tired exem tion f r ~ i = t ~ ~ going to the first tee of her open- PRO IV[EN:: Greg Kraft- led a 4 * ~ , ~ ~ ~ py~< ,1 ~ ingmatchThursday, group of three Pinellas pros to ~ y I ~ ~ - ` L The Largo High senior said success atlast weekend's'Reno- . , I r ~ ~'~R~- ~ : 1 , ' ~ , _ r ~ a~% - ~ ' it wasn't fatigue that did her in; Tahoe Open. on the PGA Tour. - - r ~ - - z x ; - - , it was a slew of birdies by her He finished in the money at 25th ' ~ i ~ , ~ ~ ' µ ~ ' ' _ ~ - - 1~ opponent; 1yfFany Joh of -San (tie), shooting 69-69-72-75 ,for 3- , I r ~ ' ' ~ ~ _ _ _ was last e ears U,SUAmateur John Huston 2 followed by ~ , •r _r z Y; n ` (87) and Bob . Ii ~ r ~ - _ " ~ ~ Public Li ks Heintz(291). . : ~ ,r'~"~'~~ ~ r champion: I x° I Nonr; are playing in this week- ~ - ~ _ - ~ • "Fatigue end's; PGA Championship, .but - _ _ ' W - - ~ may have three other locally-connected ~ w played into rt," pros are: Tampa native Woody ~ ~ ~ ~ ~ ' Messer said, C ` Austin, Chamberlain High glad ~I e I ~ - i• ~ ~ ' ° ~ "I started ~ off ' Rygji hnada and former New -~l~ ~ ' b, r Thursda ` s . , , ,t~ ( y') Years Invitational (St, Peters- ' ` - y.' ~~I ~ , ; yam) ~ ~ match bad DAVE burg CC) winner Brandt Sne- . i ' - K q ~ ' ' t ~ ;1~ -then when I THEALL deker. ~ ~r ' , ~ got on a roll Golf WEST COAST WOMEN: Tam- _ - ~ ~ 'u " ~ .~s~1_ ~ , ~ when she pa's Pat Rogers won Monday's . ~ ~ ~ ° r t'' ~ t' started droppingbirdies. match on her home coursewith , ' - - ---~w ' ~ ' ' v "Overall, I'm happy with my 5-over 77. She is the leagte's 2007 I - uosEPH cARNETr JR:. f -Times experience but I could have gone champion, • _ , _ further. There are a lot of good Lake Jovita's BrendaBartley' ' • • players in this tournament and (81) finished second. The leading ~ P n I feel I played better than many, net scorers were Judy Tickles V S e In There's always the next two (7ljandJudySchnddt(73), ' ~ ~ years:' In Fli ht.B Mar etLe' ' gr. ~ • doh won 6 and 5 to advance of Countryside tied Maria V Y1 ~~yfin 07 7 V7 ~ to the round of 16 in' Carmel' Hyden of Tampa Palms with 89. ` 11 1 G ul '1 ~d, at Crooked Stick Golf Club 1Vlary Stiegler (90) of Belleair ' ' - which~played to 6;497-yards in finishedthird. , ' ' oppressiveheat. AnnaIiayes(92)ofSkPeters- . I -~ti, , ~ On Thesda Messer went an bur Count Club tied for sec- ' Y, g rY . ~ ~ ~ at O ~ ours e • extra nine holes in her duel with and in Flight C, andLindaLid- ' r Lauren Hunt from Little River. ' ster of Dunedin tied for second ~ ah ~ ~ - ~ S.C. On the par-5 ninth, Messer in ])with 100. . " reached the green in three then CGA: Odessa's Jefl'Neugebauer . ~ Water lilies,cari now flourish because debris and two-putted for the' win due to and Dick Clemens teamed up Hunt's bogey. for abetter-ball score of 6-under ' r : !other. harmful. vegetation has been removed from Messer advanced to the .top ss at crescent oaks forthewin - T ` ' ~ , , , prings Golf Club. Ken the p0I1dS Of the Tarpon S 64 (from a field of 156), posting , on Monday. Clemens shot 68 " , ~ , Anderson picks up debris floating. in one of the:: rounds of7s 73 for a5-over 149 on liis own bail: Seniors Larry , ~ ? • The U.S Golf. Assocratron, Vander Bie (Brooksville) and , f ponds at the c1Ub Friday morning. Anderson Works issued' a 'special news release Mike Sanderson improved on ' ` `f ~ ' for Florida Aquatic .Management, a SUbCOntraC- regarding Messer's choice not to that score; winning their division ,yi 4 x~ ~ ~ ~ tOr WhOSe job 1S. t0 keep the fOln1ta111S Working and . have a caddie. She carried her with 63, Sanderson, the league's S } 4 ~ clubs for27 holes both Tuesday senior, champion, crafted 65 on ,,y , ponds clear of debris along the golf course at 1310 and Wednesday, saying; 'T play his ownball. S Pinellas Ave. better when I don't have aced- There was athree-way ;tie , die; it gets me off rnygame:' at 62 for low net among Bob • I _ 'Practice partner ~an Jen- ,Hathaway with Larry Deav- ' JosEPH cARNETT Jlt. I Timee sen of Belleair also' advanced to ers; Richard Bullockwith Bill ' match play in the Women's Am, Sanders; and John Munk with ' shooting73-77-150. KurtDemarr. LEGAL NOTICE LEGAL NOTICE . ' ' ` " In her opening match, Jen- ' :Tournament' director. Ray `CITY OF LARGO „ , < ~ ~ Y . ~ ed the shot of T p f sen fell to 12- ear-old Alerns Goodman craft . ' ~r Thom son of Coral S nn s 3 the da on the 511 yard second N 0 1 ~ C E ~ F P U B L~ C H EAR ~ N G - ~ ~ ~C~~'~ 1~~ -and 2. pensen moves on to next hole, He hrt hLS 4-iron 208 `yard i . r ~+~~0 , ~ weekend's Ryan Wells Memorial, .second shot to the back edge of NOTICE IS HEREBY GIVEN that the Largo Cliy Commission will hold a public hearing at their qA , ~ C1aSSIC at h11T15bT00kr the green and. putted from, 25 regularly scheduled meetlng at 8:00 pm on Tuesday, August 21; 2007 In the Commission ~u~i~1 I _ TRAVELPLANS: Messerwillvisit "feet into the 4,25-inch o enin II Chamber at Largo City Hall, 201 Highland Avenue,Largo, Flodda toconsiderthefollowing: !f'+ ` _ P g MEDICARE PAYS POR MOST the University of Texas later this on the green. ` , oRDINANCE No:2oo7-ss ~ month, She has taken recruiting Askedhowhe didit; Goodman ~ WHEELCHAIR PARTS & REPAIRS , , AN ORDINANCE OF THE CITY OF LARGO, FLORIDA, ANNIXINGTHE WITHIN DESCRIBED `I~~jUQUBFIj' ~ trips to Wake Forest, Tennessee said: "Ihappenedtogetlucky." ~ TRACTS OF LAND LOCATED AT 2074, 2079, 2083; 2086 59TH STREET NORTH; 2D73, zo77 and the UniversityofVirginia. LARGO COURSE: The :winning 59TH WAY NORTH; 2909, 2913, 292fi 163RD AVENUE NORTH; 2977, 2989, 2995163RD TER- I LOANER EQUIPMENTAVAIIABLE ' RACE NORTH, PINELLAS OOUNTY, FLORIDA, AND CONTIGUOUS TO THE EXISTING CITY I PRO WOMEN: Jenny Gleason team at last week's .Scramble ' ' LIMITS OF THE.CITY OF LARGO, FLORIDA; WITH CITY LAND USE DESIGNATION OF RESI- ' ! 4""~ 1S On a TOIl. The Clearwater High .posted 16-under 46, The mem- ~ OENTIAL LOW; REDEFNING THE CORPORATE BOUNDARY OF THE CITY OF LARGO TO ~ , f ~ INCLUDE SAID ADDITION, ACCORDING TO THE PROVISIONS OF CHAPTER 171, FLORIDA ' ' _ i ~ giaduate (and UNC-Greensboro) hers were B~M>71er, St. Peters- STATUTES, AND PINELLAS COUNTY VOLUNTARY ANNEXATION ORDINANCE N0. 00.63; ~ ~ ' 't ~ ` ' ~ finished third in last weekend's burg; Mario Columbi;: aemi- PROVIDING FOR SEVERABILITY; AND PROVIDING FOR AN EFFECTIVE DATE, q, , ~ly~.~ i, ' Mures Tour event in Concord, Hole; George Brennon; Clear- ` ~ v~, oaolruNCE No.2ao7ao ~e--''"~ ~ t r j^ N.H,, with scores of 69-71-74 for water; -and Bill O'Hair; Hud- i eelchatrs ~ p,0,~n ' i; AN ORDINANCE OF THE CITY OF LARGQ FLORIDA, ANNEXING THE WITHIN DESCRIBED ~t r *2 ~ `~~,t~~ ~IUiprr~nt JRu - 2-under 214, Son. Twelve teams competed in TRACTS OF LAND LOCATED AT 2035 58TH WAY NORTH, 2986164TH AVENUE NORTH ANO - HeT W1nningS elevated her t0 theopen match; ' 2998164TH AVENUE NOFlTH, PINELLAS COUNTY, FLORIDA, AND CONTIGUOUS TO, THE , ~~iR~~~~~ 20th on the season's money list ~ Columbi uned up far the EXISTING CITYLIMITS OF THE CITY'OF LARGO, FLORIDA; WITH CrrY LAND USE DESIGNA- i TION OF RESIDENTIAL LOW;'REDEFINING THE CORPORATE BOUNDARY-0F THE CITY OF Wlth $16,000, The player in fifth scramble on Aug, 4 When he i LARGOTOINCLUDESAIDADDfTION,ACCORDINGTOTHEPROVISIONSOFCHAPTER171, 7920 CONGRESSSTREET~PORTRICHEY,FL34668 a oflolNANCE No. ~ o has $35,000. aced the 130-yard No, 2 `hole FLORIDA STATUTES, AND PINELLAS COUNTY VOLUNTARY ANNEXATION ` 00.63; PROVIDING FOR SEVERABILITY; AND PROVIDING FOR AN EFFECTIVE DATE. WW W. AARI ?CWUa~M~~i. CaMb Atop-five finish for the year with'a 9 iron. Scott Caking of will give- the ,aspiring exempt Largo also had an ace that day / oROINANCE No.2oo7at i LPGA member n LEGAL NOTICE LEGAL NOTICE p'ority status whenhissandwedgeteeshoton ;i AN ORDINANCE OF THE CITY OF LARGO FLORIDA ANNEXING THE WITHIN DESCRIBED I for 2008. Based On heT fin1Sh at N0.5 dT0 ed, Steve Grain of _ PP TRACTS OF LAND LOCATED AT 2066 59TH STREET NORTH AND 2067 59TH STREET NORTH, CITY OF LARGO ' , NOTICE OF PUBLIC HEARING last ear sLPGA -school tour- .Seminole scored the thii' PINELLAS COUNTY, FLORIDA, AND CONTIGUOl15 TO THE EXISTING CITY LIMITS OF THE Y Q. d ace Of CITY OF LARGO; FLORIDA; WrfH CITY LAND USE DESIGNATION OF RESIDENTIAL LOW- ' NOTICE IS HEREBY GIVEN that the Largo Cliy Commission will hold a public hearing nament, G1easOri has COndltl0nal' the day at the mUnlClpal COUrSe a REDEFINING THE CORPORATE BOUNDARY OF THE CITY OF LARGO TO INCLUDE SAID AD• at tneir regulazly scheduled meeting at 6:00 pm'on Tuesday, August 21, 2007 in the StatUS On the rime tonr, On the lOO- aTd 12th. . DITION, ACCORDING TO THE PROVISIONS OF CHAPTER 171 FLORIDA STATUTES AND P TY Y '.r. , 'Commission Chamber at Largo Ciry Hell, 201 Highland Avenue, L o,, Florida to ' + - PINELLAS COUNTY VOLUNTARY ANNEXATION ORDINANCE N0; 00-63; PROVIDING. FOR consider the followin : _ ~ T1uS Weekend Gleason 1S play- 7UNIOR BOYS: Ryan IiiCkS pf g ' m m the Futures Tour's Bets ` Coun Ldewa SEVERABIUTY; AND PROVIDING FOR AN EFFECTIVE DATE. g ' y tTyS n seven consecu- ' ' ~ ORDINANCEN0.20D7.51 ! Ao~ _ I - Pusker Classic in Morgantown, .tive North Suncoast Junior'tour- ~ oabmANCe»20ox7o ~ AN ORDINANCE OF THE CITY OF LARGO, FLORIDA SUBMITTING TO THE CITY ~ ASej L~ y:r I ELECTORS PROPOSED AMENDMENTS TO THE CITY CHARTER INCLUDING AN WVa,; aiming for'another top- namentsthisspringandsiunmer ' + ' Ji t; ' AMENDMENT TO DEFINE"DAYS" AS USED IN THE CHARTER; AN AMENDMENT TO three finish. lri the 8-9 age d1V1S10n 1nClUding ,e~„ 1 6(--I~~ ~ ~ SECTION 3.02 REGARDING REMOVAL OF THE CITY MANAGER TO CLARIFY THAT A "T sti1L have four (Futures .the recenttwo-day Tournament - 1 a lam" -I~- ~ FINAL RESOLUTION OF REMOVAL REQUIRES A VOTE OF FIVE OF THE MEMBERS OROINAN0Eal2o0Tfi9 assn- ue- OF THE CITY COMMISSION; AMENDING SECTION 5.05(b) TO CLARIFY WHEN AN TOUT) eventstOplaythls year and Of Champions. H1S 104V StTOke `~I I PI I Ii 'I ORDINANCEISREQUIREDTOAUTHORIZEACONTRACTORLEASE;ANAMENDMEM' pmconfidentIcanclosethe a avCTa TO SECTION 7.03(d) REGARDING' THE CERTIFICATION OF THE RESULTS OF AN g P ge was even par as he won ' ELECTION BY THE CITY'S CANVASSING BOARD; AND ANI AMENDMENTTO SECTION to get into the top five;' Gleason each tournament by four to six ~ ~ ~ _ •o~oir~~ Eu~a~~o1-u -7.03(e)REGARDINGTHECOMMENCEMENTOFTHETERMOFOFFICEOFMEMBERS OF THE COMMISSION; PROVIDING FOR REFERENDUM ELECTION; PROVIDING AN 3ald, I ll start right here where strokes. I ~ al w EFFECTIVE DATE: , • ~W' I - _ °lav~lj I ~ ORDINANCE N0,20D7.68 • I ~ ~ ~'""p°'°"'"" AN ORDINANCE OF THE CITY OF LARGO,' FLORIDA, AMENDING ORDINANCE Bas@1k~ll Jack Russell Stadium in Clearwa- ' l ohm°'" 2000.32, AS AMENDED, 8Y AMENDING THE FEES ESTABLISHED FOR SERVICES I ; The Ciry Commission may, with respect to any matter considered at this meeting, make a PROVIDED BY THE COMMUNITY DEVELOPMENT DEPARTMENT; SUPERSEDING ter. CaII51O.3991 Or46O.5920. ! i determloatien on the matter chat evening or may continue the meetlng wholly or In part to an- ORDINANCES OR PARTS THEREOF IN CONFLICT HEREWITH; AND PROVIDING AN i EFFECTIVE DATE: , IVIBadOWIaWn other data If the public hearing Is continued by the Cfty Commission, no fudher notice of Oldsmar LL continuancewlllbesentorpubllshed. The leaguetrUSteeswillCOndUCta i f , . ^ The City Commission may, with respect to any matter considered at this meeting, make Fall ball registration for base- Interested arUes ma a ear at the meetin :and he heard wKh ies ect to'the ro- a determination on the matter that day or may continue tho meeting wholly or In part to membership meeting atthe eon- P Y PP 9 p P another date. If the public hearing is continued bythe City Commission, no furthernotice -ball and Softball WIIIbe held On posed drdinances. CBSSIOn Stand 739018th Street of continuance will be sent or published. ( AUg.22, 25 and 29.0811786-9263. ~ north) to listen to suggestions an ' , Copies of the ordinances, complete metes and hounds legal descriptions, and related materials Interested parties may appearat the meeting and be Heard with respectte the proposed tl$a Patrl0t5 I are availableforpubllclhspectionateithertheCommunltyDevelopmentDepartmentortheCity ordinances. hOWtOreestabllShtheleague. s Clerk's office; City Hall;-201 Hignlahd Avenue; Largo, Flodda, daring regular haemeae houre The meeting is atnoontoday, Far AAUtryoutswill beAug.l7and I ~ (B:OO am-5:DO pml. Forfurther Information; caI1727.587.6749. Copies of the ordinances end related materials are available for public inspection at i I •w'k the City Clerk's-0ffice; City Hall, 2D1 Highland Avenue, Largo, Florida, during regular information,callThornasCarson 24at6p.m.atPatriotParkforthe I ~ _ _ Any pereonwhodecldeStoappealarrydeclsiohoftheClryCommissienwithrespecttoanymat- business hours(B:OOam-S:OOpm). Forfurtherinformatloncall727-587.6710, at577O441. ~ r 7t08•year•OIdS.COntaCLMlke .ter considered at this meeting will need a record of the proceedings and for such purpose may Gallnskl @.7275563200 Or a-mall i i ~ 'need toensurethataverbaUmrecordoftheproceedingsismade,whichrecordshalllncludethe Any person who decides toappeafanydecislohoftheCityCommissionwithrespectto NorthwestYouthLeagueS r w testimony and evidence upon whicnthe appeal isio be based, any matterconsidered atihis meeting will need a record ofthe proceedings, and for such mgallrlSl(I@ameCICaILCOm. I , I f " ~ - purpose may need to ensure that a verhatim record of the proceedings Is made, wnioh. Registratioli forthe fallseason r w " The City of Largo is committed to providing reasoeable accammodatlon far access forthe dis- record includes the testimony and evidence upon which the appea6ls to be based, r a = ~ beginstodayfrom 9 a.m: 2 p.m. abled. Anyone needing assistance wkh regard to this meeting should contact the City Clerk's i i r r" TheCityofLargoiscommittedtoproviding~easonableaccommodationforaccessforthe r, ofOceat587-6710ortheLibraryT.D.D:Line567.6778atleastlwddaysprlortothemeeting. atfheflBldClUbhOUSe,58O122nd I i disabled. Anyone needing assistance with regard to this meeting should contactthe City COUntrySldB LlghMing ~ Clerk'sOfficeat567-6710ortheLibraryT.D.D,•Lineat587-6778 atleasttwodayspriorto AVe.N.ThefeelS$6OfOrplayeTs Diane L. Bruner, cldc ` the mee0ng• p Y g The lea ue will hold recreational I ' r clry clerk age s-8 and $70for la ers a e 9- g I I X : Diane L. Bruner, cMC ' 15, The league offers a $15 sibling. registration on Aug,14, 23, 28 I I ~ August 4 & it, 2007: ; 4435sa m .city clerk discount, Registration will contin- from 6.8:30 p.m. and Aug, 25 ~ I tiuguatn, 2007 459957-0, from9a.m.-1 m.attheCouri Y ueAug.14,15and16frorn5.7p.m. P• tiY- F ' ~ ~ - The league's annual meeting and side Rec Center. Call 4817298 or , _ I , ' , >"~,,`t, : electionsforboardofdirectorsis gotowww,cysa.us. ..rv Aug.16at6:30p.m.Thefallsea-. SYAAHammers • I ~ ® ® ~ sonfocusesoninsfructionalball I~ ~ , i P~" Q ~ 9 TheU12teamisinneedofplay- r b ~ 1 and be instheweekofSe t10, i, ; ' ~ g P ers, Call Geoff McCarthyat235- • ' 4 ~ q3 lu' - k ~ ~ ~ Contacttheleagtaeat(727}345-; 34gq.{orinforlnation. o A 1902 orvisitvvww.northwestyouth I o baseball.org pty Gulf CoastTide Announcements should be I ° homes.tam aba com ~ . f The14-underteamislookingfor mailed to Times Sports,P.O.Box ~ ° ° piayurs. uyuuusareueingnema[ uzi,OLr~e[ersAUrg,r~ s~r~rr~izi.