Loading...
02/19/2008 COMMUNITY REDEVELOPMENT AGENCY AGENDA Location: Council Chambers - City Hall Date: 2/19/2008- 9 :00 AM 1. Call to Order 2. Approval of Minutes 2.1 Approve the minutes of the February 4, 2008 CRA meeting as submitted in written summation by the City Clerk. ~ Attachments 3. CRA Items 3.1 Adopt the Cleveland Street Logo Guidelines entitled "Cleveland Street Branding and Style Guide". ~ Attachments 3.2 Approve an Agreement for the disposition and development of the Cleveland Street and Prospect Lake Park site between the CRA and MDP-Clearwater, LLC of Atlanta, Georgia, delineating the terms and conditions of the disposition and development, and authorize the appropriate officials to execute same. ~ Attachments 4. Other Business 5. Adjourn Meeting Date:2/19/2008 Community Redevelopment Agency Agenda Council Chambers - City Hall SUBJECT / RECOMMENDATION: Approve the minutes of the February 4, 2008 CRA meeting as submitted in written summation by the City Clerk. SUMMARY: Review Approval: 1) Clerk Cover Memo Item # 1 Attachment number 1 Page 1 of 2 COMMUNITY REDEVELOPMENT AGENCY MEETING MINUTES CITY OF CLEARWATER February 4, 2008 Unapproved Present: Frank Hibbard Carlen Petersen John Doran George N. Cretekos Paul Gibson Also present: William B. Horne II Jill S. Silverboard Rod Irwin Pamela K. Akin Cynthia E. Goudeau Patricia O. Sullivan Chair/CRA Trustee CRA Trustee CRA Trustee CRA Trustee CRA Trustee City Manager Assistant City Manager Assistant City Manager/CRA Executive Director City Attorney City Clerk Board Reporter The Chair called the meeting to order at 1 :38 p.m. at City Hall. To provide continuity for research, items are in agenda order although not necessarily discussed in that order. 2 - Approval of Minutes 2.1 - Approve the minutes of the January 14, 2008 CRA meetinQ as submitted in written summation by the City Clerk Trustee Petersen moved to approve the minutes of the Community Redevelopment Agency meeting of January 14, 2008, as recorded and submitted in written summation by the City Clerk to each Trustee. The motion was duly seconded and carried unanimously. 3 - Community Redevelopment Agency Items: 3.1 - Approve the aQreement with CSDVRS, LLC, providinQ for the CRA to pay the City parkinQ fund $16.200 over 24 months to pay for parkinQ needed by CSDVRS for its headquarters in downtown Clearwater and authorize the appropriate officials to execute same. The Economic Development and Housing staff successfully worked with CSDVRS, LLC (Communication Service for the Deaf-Video Relay Services) to relocate their headquarters from South Dakota to Downtown Clearwater. CSDVRS is the world's first nationwide video relay service provider. The firm specializes in the technology called voice carry-over (VCO) for the deaf and hard-of-hearing. With VCO technology, the deaf and hard-of-hearing can speak directly to the hearing caller using a standard telephone while viewing a Video Interpreter relay. The hearing caller will hear the VCO user's voice during the conversation. The company chose the City of Clearwater over Maryland and Massachusetts as its new headquarters. The company forecasted the creation of 45 jobs by December 31,2008, and an additional 17 by December 31,2009, with an average annual wage of $69,666. To help induce the creation of these 62 new full-time jobs, the qualified target industry tax refund incentive (QTI) was approved by the State (OTTED), City of Clearwater, and Pinellas County in June Community Redevelopment Agency 2008-01-30 1 Item # 1 Attachment number 1 Page 2 of 2 2007. The QTI program provides pre-approved applicants refunds for corporate income taxes, sales and use taxes, ad valorem taxes, and certain other taxes paid by the business. CSDVRS, LLC can receive up to $651,000 over a five-year payout period. The City's portion of this commitment is $65,100. CSDVRS leased 6,000 square-feet at the Bank of America building located at 600 Cleveland Street, Suite 1000. The six-year lease includes only 17 paid parking spaces based on 2.7 parking spaces per 1,000 square-feet. CSDVRS needs an additional 15 parking spaces and is requesting economic assistance from the CRA to cover the cost. The CRA (Community Redevelopment Agency) established the Economic Development Incentive Fund to encourage job creation within the Downtown Business District. This program was used in the 1990s to attract companies to Downtown. The projects are evaluated based on wage levels, capital investment, economic impact, and commitment to the community. The Fund currently has approximately $147,000. Staff recommends that the CRA assist CSDVRS by providing a grant effective March 1, 2008, to pay the cost of 15 parking spaces in the Garden Avenue Garage for 24 months for the following reasons: 1) Creation of jobs faster than the initial QTI program commitment by December 31, 2008 (49 full-time and 26 part-time jobs were created by October 1, 2007 at the firm's downtown location); 2) Location of a downtown company headquarters; 3) Creation of high-wage jobs (average wage is $69,966); and 4) Company may not be able to take advantage of the full QTI award because of the firm's LLC structure. The total commitment from the CRA over the two years will be $16,200. The CRA will pay the City Parking System for the cost of providing the 15 parking spaces at $45 per space for 24 months. This parking incentive will be conditional upon confirmation of 30 full-time employees at the firm's downtown location verified by a notarized letter from an officer of CSDVRS and confirmed by Paychex Payroll Services report. Employment verification is required semi-annually. Trustee Petersen moved to approve the agreement with CSDVRS, LLC, providing for the CRA to pay the City parking fund $16,200 over 24 months to pay for parking needed by CSDVRS for its headquarters in downtown Clearwater and authorize the appropriate officials to execute same. The motion was duly seconded and carried unanimously. 4 - Other Business CRA Executive Director Rod Irwin reported the marketing brochure, highlighting the entire City, is available. 5 - Adjourn The meeting adjourned at 1:45 p.m. Chair Community Redevelopment Agency Attest: City Clerk Community Redevelopment Agency 2008-01-30 2 Item # 1 Meeting Date:2/19/2008 Community Redevelopment Agency Agenda Council Chambers - City Hall SUBJECT / RECOMMENDATION: Adopt the Cleveland Street Logo Guidelines entitled "Cleveland Street Branding and Style Guide". SUMMARY: After a year-long collaborative process with the public, the DDB, Public Communications and Economic Development, the CRA recently approved a new brand identity for downtown Clearwater. The "Cleveland Street District" brand and logo have been designed to reflect a new energy that captures the improvements downtown and the positive direction for the district as a destination for residents, visitors and potential businesses. As a follow-up to the approval, Economic Development and Public Communications was asked to provide a framework and guidelines for the use and application of the new brand identity. The "Cleveland Street Branding and Style Guide" is designed to give guidance to internal departments, downtown partners and interested businesses in the appropriate use and application of the logo in marketing and other materials. Review Approval: 1) Office of Management and Budget 2) Legal 3) Clerk 4) Assistant City Manager 5) Clerk 6) City Manager 7) Clerk Cover Memo Item # 2 If ~ I Attachment number 1 Page 1 of 12 " I ~" .. .. . . . " . . , ., . 0.. oe. . . . . , .0, . .,. ". ./' .... I . " .:,.. r' ; \ -".,~. \ \\; I .1 I . G2:- . " " I . . . ~ Attachment number 1 Page 2 of 12 GENERAL CLEVELAND STREET LOGO GUIDELINES The Cleveland Street logo has been designed to capture the vitality and tropical feel of Clearwater's revitalized downtown. It was selected to clearly depict that downtown Clearwater is unique from other Tampa Bay destinations, and a desirable new place to shop, dine and visit. The colors and the flower motif call to mind Florida palms and the colors of Clearwater's famous sunsets. The modern, abstract application of these elements help to reinforce Clearwater's unique identity in a region that offers multiple destinations for residents and visitors to choose from. ELEMENTS The new identity consists of three basic elements: the square Cleveland Street identity box, the icon above it, and the abstract flower motif below. Under different applications, the combination of these three elements may vary, which is outlined in this document. COLORS The Cleveland Street logo should always be reproduced using the designated orange, red, blue- green and black as outlined in this document. Specific Pantone colors are provided on page 4. For applications where full-color printing is not available, the logo should be reproduced in grayscale or black-and-white as outlined on page X. Under no circumstances should the colors be altered. All reproductions should be made from original digital files provided through the CRA web site or a representative of the city's Public Communications Department. SIZE No application of the Cleveland Street logo should be less than one-half inch in width (.5" x .5" for the square logo, .5" x .85" with the flower motif). This is to ensure readability and integrity of the logo. In one-color applications, it is recommended to use the black- and-white version of the logo for any size less than one inch wide. Grayscale versions of the logo begin to lose readability at this size. In all cases, it is preferred that the logo be at least one inch in width to ensure quality reproduction. FONTS The Cleveland Street logo consists of two fonts: Apex Sans Bold (120% width/+300em) and Mrs Eaves Italic. While this shouldn't be of concern for most uses, some designers may wish to incorporate these fonts in to their designs as appropriate. APEX SANS BOLD MrsEaves Italic 1 inch inch II Item # 2 LOGO VARIATIONS The Cleveland Street logo may appear in one of four variations, depending on the application and space available. Under all possible circumstances, users should use the full logo with flower motif Because of its vertical construction, however, there will be instances where use of the square logo form IS necessary. The choice of using the black logo form versus the white logo form will be dictated mostly by the associated design. EXCEPTIONS There may be specific cases where the logo must be presented without the surrounding colored (white or black) box. This could include embroidered merchandise or other circumstances where mechanical limitations prevent effective reproduction of the logo in its preferred form. Such occasions will be managed on a case-by-case basis in coordination with the CRA and the Public Communications Department. CUSTOM USES The CRA has created several sector-specific applications of the logo that may be used in the appropriate circumstances. These variations replace the flower motif at the top of the logo with a sector- specific identity marker, such as dining, nightlife, living, ete. These are outlined further on page 9. Attachment number 1 Page 3 of 12 '0 \ S T R I Cr \.~ CLEVELAND r e e t \) \ S T R 'e)' \t1 CLEVELAND r e e t CLEARWATER Icon Item # 2 TYPEFACES Attachment number 1 Page 4 of 12 APEX SANS BOLD (120%) ABCDEFGHIJKLMNOPQRSTUVWXYZ ABCDEFGHIJKLMNOP~RsTuvwxvz12345 MRS EAVES ITALIC AB CDEFGHIJKLMNOPQR S T UVWXYZ a bed e f g hi j k I m no p q r s t u v w xy Z 12 3 4 5 LEGACY SERIF ABCDEFGHIJKLMNOPQRSTUVWXYZ abcdefghijklmnopqrstuvwxyz 12 345 ABeD EFG H IJ abcdefghijkl APEX SANS Used for headlines and subheads. While the bold typeface has been used within the logo, other variations of the font may be used within documents and other applications. The font should be widened to 120% to conform with the logotype. MrsEaves Italic Used as a complementary font in the logo. This font may find similar uses in advertisements and other documents, but should not be used as a primary font for headlines, subheads or body text in narrative text or copy. LEGACY SANS 1< L M N 0 m n 0 p q r PQRSTUVWXYZ stuvwxyz12345 Legacy Serif The text of this document is set in Legacy Serif. This is the preferred font for body copy in printed materials. Legacy Sans Legacy sans is also acceptable for body copy, particularly when readability may become a factor in presentations, online and when reversed out from a background color. SUBSTITUTION If your computer does not have the fonts outlined, you may substitute with the following fonts for body copy. Fonts contained within the logo may not be substituted under any conditions. Legacy Serif Times New Roman Legacy Sans: Arial PURCHASING FONTS Apex Sans is available from Village Fonts at www.vllg.com. MrsEaves is available from Emigre Fonts at www.emigre.com. Legacy Serif and Legacy Sans are available from ITC at www.itcfonts.com. Item # 2 Attachment number 1 Page 5 of 12 CLEAR SPACE/MARGINS CLEAR SPACE Clear space equal to 1/2 the width of the logo on all sides. For example, if the logo used is I-inch wide, then there should be 1/2- inch of clear space on all sides of the logo. This requirement is intended to maintain the visual integrity of the logo, keeping it free from visual clutter of other logos, text, artwork or titles. EXCEPTIONS It is understood that there may be instances where use of the logo will not meet these requirements. Users are encouraged to use their best judgment and allow for adequate space between this and other elements in a layout or design. COLORS The colors of the logo are not to be altered under any circumstance. When reproduced, the Pantone (also known as PMS or spot) colors should be used, or an appropriate CMYK or RGB conversion of the original spot colors as specified in this document. The CRA, through the Public Communications Department, can provide original RGB and CMYK versions for use in electronic and 4-color print materials. 3 inches (.75" x 2) 1.75 inches Pantone 1375 White .~I~C~.. Pantone 1805 Pantone 5575 Pantone 5625 Item # 2 Attachment number 1 Page 6 of 12 GRAYSCALE/BLACK cD WHITE LOGO VARIATIONS GRAYSCALE The grayscale version of the logo is appropriate for one-color applications reproduced by a commercial press or high-quality printer. It should not be sued in photocopied applications, as the grays will become "muddy" resulting in an undesirable presentation of the logo. The grayscale version contains black and white, with grays consisting of 30% and 60% black. BLACK & WHITE The black & white version of the logo is ideal for photocopied one-color applications and may be substituted for the grayscale version in one-color press reproductions at the user's discretion. It is preferred, though, that the grayscale version be used whenever possible. O\~.~c> CLEVELAND STreet ERflorida CLEARWAT ~a~ 60% Black 30% Black '0 \ 5 T R I c- l' \tl CLEVELAND r e e t CLEARWATER '0 \ 5 T R J C l' ~~ CLEVELAND STreet CLEARWATERflorida Item # 2 GUIDELINES FOR USE GENERAL GUIDELINES The Cleveland Street logo and all of its variations are property of the City of Clearwater Community Redevelopment Agency. Use of the Cleveland Street logo in any form is only authorized for licensed resale uses or use by approved partners. As such, organizations wishing to use the logo in any materials are required to gain authorization through the CRA or its designee in advance. CRA & CITY DEPARTMENTS The City of Clearwater Community Redevelopment Agency (CRA) and City of Clearwater departments are authorized users of the logo. Any city use outside of CRA materials requires review and approval by the Economic Development and Public Communications Departments. AFFILIATED ORGANIZATIONS Associations and organizations affiliated with downtown Clearwater and the CRA may receive blanket approval for logo use by filing a Logo Use Request form with the CRA. The form is available online, or directly from the CRA, Economic Development or Public Communications Affiliated organizations may include groups such as Clearwater Main Street and the Downtown Development Board. While the blanket approval allows for open-ended use of the logo, all individual designs must be approved by the CRA or its designee in the Economic Development and/or Public Communications Departments of the City of Clearwater. NON-AFFILIATED ORGANIZATIONS & PRIVATE ENTERPRISES Any use by a non-affiliated organization or private enterprise requires the filing of a Logo Use Request with the CRA. This may include private business promotion organizations, individual retailers, Chambers of Commerce or other government organizations. Organizations seeking to produce logo-branded items for distribution or resale must also complete and file a Licensing Agreement with the CRA. In all cases, a proof of the item or publication bearing the Cleveland Street logo must be reviewed and approved by the CRA or its designee in the Economic Development and/or Public Communications Departments of the City of Clearwater. Attachment number 1 Page 7 of 12 FILE FORMATS It's important that the correct file format be used in order to ensure a quality reproduction of the Cleveland Street logo. To help with this, the CRA can provide the logo in electronic form as a PostScript (EPS), TIFF or JPEG file. In most cases, use of the EPS (print) or JPEG (online/video) is recommended. Copying online versions for use in print materials is explicitly prohibited, as the file resolution will result in poor reproductions. FILE FORMATS It's important that the correct file format be used in order to ensure a quality reproduction of the Cleveland Street logo. To help with this, the CRA can provide the logo in electronic form as a PostScript (EPS), TIFF or JPEG file. In most cases, use of the EPS (print) or JPEG (online/video) is recommended. Copying online versions for use in print materials is explicitly prohibited, as the file resolution will result in poor reproductions. INQUIRIESI SUPPORT For information and assistance on accessing and using the logo, contact the Clearwater Public Communications Department at 562-4682 or bye-mail at douglas. matthews@myclearwater.com. Item # 2 LETTERHEAD \II CLEVELAND 5Tree! ~.; COMMUNITY REDEVELOPMENT AGENCY ~ CR~O~xltc~I~I'VE DIRECTOR cD STATIONERY LETTERHEAD In order to contain costs, Cleveland Street letterhead should be used for official correspondence by the CRA and affiliated agencies. Letterhead and stationery are not customized for use by any single individual or department, and as such should be considered the same as any document or publication produced by the CRA. 112 S. OSCEOLA AVENUE C LEA R WA TE R 'p ~ L ~:i ~S^6 23.;~;~ FX 727.562.4052 WWW.MYCLEARWATER.COM January 30,2008 Jolm Doe 13usiness Owner 1 tlain Street Clearwater, FL 33756 DearJolm: Attachment number 1 Page 8 of 12 This is the standard for letterhead bearing the Cleveland Street logo. If possible, use the same font guidelines as are used for all other materials in the style manual. PH j~; .S5'6~~4COE400L~ ~~E7N2~~5~2~ig;: V:AvJ~~.~~~ ~~DAAR;"~i~:.~o M STATIONERY The Cleveland Street stationery is intended for use in memoranda and informal correspondence where the full-color letterhead may not be necessary. Item # 2 ENVELOPES Envelopes should, under most circumstances, be reproduced in their color version as represented below. It is understood that budgetary considerations may lead to the need for one-color versions. Is these cases, the black-and- Attachment number 1 Page 9 of 12 white variation of the Cleveland Street logo should be used in order to ensure the best clarity for reproduction. PO B,n 4748 Clearwater, FL 33758-4748 CLEARWATER COMMUNITY REDEVELOPMENT AGENCY BUSINESS Business cards bearing the Cleveland Street logo may be produced and used in coordination with CRA-specific business. They are not intended to replace standard City of Clearwater business cards, which are to be used when conducting regular city business. This is an important distinction to be made in light of the close association and staff crossover that occurs between the city and the CRA. CARDS DAVI D C H A I R DOWNTOWN DEVELOPMENT BOARD PO Box 4748 Oleaewa!ee_ FL 33758-4748 727XXXXXXX 727XXXXXXX DAVID.ALBRITTON@ MYCLEARWATER.COM Item # 2 Attachment number 1 Page 10 of 12 SECTOR-SPECIFIC ALTERNATES ALTERNATIVE LOGOS There are six approved alternative logos that may be used for sector-specific campaigns at the discretion of the CRA. For instance, if the CRA chooses to conduct a target marketing campaign to bring diners downtown, a dining-specific logo is available. These logos should be used judiciously and solely for these purposes. Under most circumstances, the primary logo should be used in marketing materials unless a specific campaign has been planned and put into action. Alternative logos are available for: . Culture . Nightlife . Shopping . Dining . Living . Events No other logo alternates should be created or used, unless specifically directed and approved by the CRA. Item # 2 Attachment number 1 Page 11 of 12 NOTES ON GENERAL PLACEMENT There are no specific rules regarding the placement or location of the logo within a design, other than the clear space recommendations outlined on page 4. As a general rule, though, designs should not interfere with or obscure the clear visibility of the logo within the design. If placed on a photograph or other artwork, ensure that there is enough contrast between the elements to allow the logo to be clearly visible on the page. Use of the Cleveland Street logo in printed or electronic materials indicates your agreement to adhere to these standards. You may not alter the logo in any manne~ including proportions) colors) elements and type. Any use or placement is upon expressed approval of the Clearwater Community Redevelopment Agenry. Item # 2 Attachment number 1 Page 12 of 12 ~ Clearwater 1'11r(j~d/tu'I~~ Meeting Date:2/19/2008 Community Redevelopment Agency Agenda Council Chambers - City Hall SUBJECT / RECOMMENDATION: Approve an Agreement for the disposition and development of the Cleveland Street and Prospect Lake Park site between the CRA and MDP-Clearwater, LLC of Atlanta, Georgia, delineating the terms and conditions of the disposition and development, and authorize the appropriate officials to execute same. SUMMARY: On September 17, 2007 the CRA, pursuant to CRA RFP/Q 23-07 and the recommendation of the Selection Committee: 1) designated Miles Development Partners of Atlanta, Georgia as Preferred Developer for the Purchase and Development of the Cleveland Street and Prospect Lake site; and 2) approved a ninety day period of exclusive negotiation during which the CRA Executive Director was authorized to negotiate a Development Agreement and Purchase Agreement, for subsequent CRA consideration, in general conformance with the Miles Development RFP/Q response. On December 17, 2007 the CRA approved an extension of the period of exclusive negotiation until February 18,2008 to allow orderly completion of negotiations. The purpose of this Agreement is to further the implementation of the Plan by providing for the sale and conveyance of the Project Site to the Developer and the development, construction and operation of the Project thereon in accordance with the Project Plans and Specifications, all to enhance the quality of life, add new residents to the Town Lake Character District, provide Workforce affordable housing and improve the aesthetic and useful enjoyment of the Area through the eradication of conditions of blight, all in accordance with and in furtherance of the Plan and as authorized by and in accordance with the Act. Negotiations have been successfully concluded with MDP-Clearwater, LLC for purchase of the CRA parcel and development of a project with 200-249 residential multi-family dwelling units-with the final unit count subject to Community Development Board approval-and up to 16,000 square feet of ground floor retail. The units shall be constructed and operated as rental units for a period not less than five years from receipt of a certificate of occupancy, after which the units may be converted to ownership units at the owner's discretion. Ten percent of the residential dwelling units will be reserved for workforce affordable housing for a period of twenty years. Workforce affordable housing means a residential dwelling unit leased or owned and occupied by a household with a household income of 120% or less of adjusted median income for Pinellas County. For non-rental units, the sale price may not exceed 90% of the average area price in the area as established by the U. S. Treasury Department annually. The primary business terms of the agreement are: 1. Purchase of Property: . $12,050 per unit @ 249 approved units= $3,000,450; Exact unit count will be determined by CDB and price adjusted by multiple of $12,050; . $250,000 performance deposit to be escrowed upon approval by CRA of DA; . Developer to purchase property on earlier of: 30 days after issuance of all building permits; or, October 1, 2009; . CRA may re-purchase at purchase price if Developer does not commence foundation construction within 24 months of CRA approval of DA. 2. Performance Schedule: . Developer must file complete application with CDB within 6 months of CRA approval of DA; . Developer must file complete building permit application within 16 months ofCRA approval ofDA; . Developer must commence foundation construction within 24 months of CRA approval of DA and vertical construction 4 months thereafter; . Developer must complete construction within 24 months of commencement of foundation. Cover Memo 3. Project Scope: Item # 3 . Approximately 220 units of rental @ market. Units must be maintained for 5 years after C of 0 before conversion . Approximately 24 Affordable units @120 %( or less) of AMI for 20 yrs. (Deed restriction). Units must be maintained for 5 years after C of 0 before conversion. . If converted to ownership after 5 years, balance of 20-year requirement to be met by sale, income and occupancy controls to assure 120% AMI achieved. . Developer to be initially responsible for qualification and monitoring of program, with cooperation of CRA. Upon sale of units owner will be responsible to work with Housing Division of City to insure affordability requirements met/maintained. 4. Utility Relocation: . CRA agrees to relocate, or reimburse Developer, for the relocation of necessary utilities on site to allow project to be constructed on parcel, in an amount not to exceed $250,000. Although not a provision of the CRA Development Agreement, the Developer has also agreed to contribute $570,000 for streetscape improvements proximate to the project site, on Cleveland Street, Prospect Street and Park Street in conjunction and consistent with the City's Cleveland Street Streetscape, Phase II project. This is a commitment that will be memorialized in the Development Order as a community benefit related to additional density pool units. As requested by the CRA, the developer is required to file a CBD application with a preliminary site plan and design consistent with their response to the RFP/Q, a copy of which will be attached to the Development Agreement as an exhibit, and agrees that any material changes to the preliminary site plan will be submitted to the CRA for approval. The site plan approved shall be the basis for the subsequent project plans and specifications, which shall be submitted to the CRA for review and approval as owner. Any material modification of the design and/or site plan by the CBD will require an amendment from the CRA. Finally, The City received a HUD grant in the amount of $1,295,000 for costs associated with the development of a regional stormwater retention facility which became the Prospect Lake project. Since a portion of the land not actually needed is to be conveyed for the Miles project, the City/CRA will be required to reimburse HUD in the amount of $542,097 from the proceeds of sale. At an estimated value of $35,000,000 (land and improvements) the project is estimated to generate $368,053 in tax increment in the first full assessment year the project is operational (estimated to be 2013). A total of $2,689,970 in TIF revenue is estimated to be generated through the expiration of the TIF authorization in 2019. Type: Current Year Budget?: Other None Budget Adjustment: None Budget Adjustment Comments: Current Year Cost: Not to Exceed: For Fiscal Year: o Annual Operating Cost: Total Cost: o $250,000 2009 to 201 0 Appropration Code 0388-94714 Amount $250,000 Appropriation Comment Review Approval: 1) Office of Management and Budget 2) Legal 3) Clerk 4) Assistant City Manager 5) Clerk 6) City Manager 7) Clerk Cover Memo Item # 3 Attachment number 1 Page 1 of 89 AGREEMENT FOR DEVELOPMENT AND DISPOSITION OF PROPERTY BETWEEN THE COMMUNITY REDEVELOPMENT AGENCY OF THE CITY OF CLEARWATER, FLORIDA AND MDP CLEARWATER, LLC, A GEORGIA LIMITED LIABILITY COMPANY Item # 3 Attachment number 1 Page 2 of 89 Table of Contents ARTICLE 1. DEFINITIONS... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... .... ... ... ... ... ... ... ........ Section 1.01 Definitions...... ...... ...... ...... ...... ...... ...... ...... ...... .......... .... Section 1.02 Use of Words and Phrases... ... ... ... ... ... ... ... ... ... ... ... ... ... .... Section 1.03 Florida Statutes... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... .... ARTICLE 2. PURPOSE; PROPOSAL... ... ... ... ... ... ... ... ... ... ... ... ....... ... ... ... ... ... ... ... ... Section 2.01 Intent; Purpose of Agreement... ... ... ... ... ... ... ... ... ... ... ... ... .... Section 2.02 Developer's Proposal... ... ..... ... ... ... ... ... ... ... ... ... ... ... ... ... .... Section 2.03 Cooperation of the Parties.... ... ... ... ... ... ... ... ... ... ... ... ... ... .... Section 2.04 Authorized Representative.... ...... ...... ...... ...... ... ...... ...... .... ARTICLE 3. PURPOSE; PROPOSAL... ... ... ... ... ... ... ... ... ... ... ... ....... ... ... ... ... ... ... ... ... Section 3.01 Zoning... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... Section 3.02 Redevelopment Plan.... ... ..... ... ... ... ... ... ... ... ... ... ... ... ... ... ... Section 3.03 Development of Regional Impact.. . ........... .......... ...... ...... ... Section 3.04 Permits... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... Section 3.05 Concurrency... ... ... ... ...... ... ... ... ... ... ... ... ... ... ... ... ... ... ..... .... Section 3.06 Not a Development Order or Permit... ... ... ... ... ... ... ... ... ... ..... Section 3.07 Permitted Uses... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ..... ... Section 3.08 Workforce Affordable Housing Units ARTICLE 4. PLANS AND SPECIFICATIONS... ...... ... ... ... ... ... ... ....... ... ... ... ... ... ... ... ... Section 4.01 Site Plan... .... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... Section 4.02 Preparation of Project Plans and Specifications... ... ........ ... ... Section 4.03 Coordination with City Review.... ... ... ..... ... ... .... ... ... ... ... ... ... Section 4.04 Agency Review of Plans and Specifications.... ... ... ... ... ... ... ... Section 4.05 Project Schedule... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ..... .... ARTICLE 5. PROJECT FINANCiNG..... ... ... ... ... ... ... ... ... ... ... ... ....... ... ... ... ... ... ... ... ... Section 5.01 Construction Financing... ...... ...... ...... ...... ...... ...... ... ...... ... Section 5.02 Notice of Developer's Default... ... ... ... ... ... ... ... ... ... ... ... ... .... Section 5.03 Cure of Developer's Default by Lender.. ... ... .... ... ... ... ... ... ..... Section 5.04 Construction Lender Not Obligated to Construct...... ...... ....... Section 5.05 Agency Cures Developer's Default... ... ... ... ... ... ... ... ..... ... ..... ARTICLE 6. PROJECT SITE CONVEYANCE... ... ... ... ... ... ... ... ........... ... ... ... ... ... ... ... Section 6.01 Findings; Representations... ... ... ... ... ... ... ..... ... ... ... ... ... ... ... Section 6.02 Agreement to Sell and Purchase.. ... ... .... ... ... ... ... ... ... ... ... ... Section 6.03 Purchase Price/Deposit... ... ... ... ... ... ... ..... ... ... .... ... ... ... ... ... Section 6.04 Site Evaluation... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... Section 6.05 Title... ... ..... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ..... ... .... Section 6.06 Survey... ... .... ... ... ... ...... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... 11 Item # 3 Section 6.07 Section 6.08 Section 6.09 Section 6.10 Section 6.11 Section 6.12 Section 6.13 Section 6.14 Section 6.15 Section 6.16 Section 6.17 Section 6.18 Section 6.19 Attachment number 1 Page 3 of 89 Rights and Duties of Agency. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . Rights and Duties of Developer... ... ... ... ... ... ... ... ... ... ..... ... ... Conditions to Closing...... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ..... Closing... ... ... ... ... ... ... ... ..... .... ... ... ... ... ... ... ... ... ... ... ... ..... Closing Procedure... ... ... ... ..... ... ... ... ... ... ... ... ... ... ... ... ... ... Possession... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... Cond ition of Title. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .. . . . Taxes and Assessments... ... ..... ... ... ... ... ... ... ... ... ... ... ..... ... Covenants, Warranties and Representations... ... ... ... ... ... .. ... Condem nation. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .. . . . Real Estate Commission... ... ... ..... ... ... ... ... ... ... ... ... ... ..... ... Maintenance of Project Site... ... ... ... ... ... ... ... ... ... ... ... ..... .... Radon Gas Notice... . . . . . . . . . .. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . ARTICLE 7. CONSTRUCTION OF THE PROJECT... ... ... ... ... ....... ... ... ... ... ... ... ... ... ... Section 7.01 Site Clearance... ... ... ... ... ..... .... ... ... ... ... ... ... ... ... ... ... ... ...... Section 7.02 Construction of the Project... ... ..... ... ... ... ... ... ... ... ... ... .. ... . ... Section 7.03 Maintenance and Repairs... ... ... ... ... ... ... ... ... ... ... ... ... ..... .... Section 7.04 Project Alterations or Improvements... ... ... ... ... ... ... ... ... ... .... Section 7.05 Completion Certificate... ... ... ..... ... ... ... ... ... ... ... ... ... ... ..... .... Section 7.06 Agency Not in Privity with Contractors... ...... ...... ...... ........... Section 7.07 Repurchase of the Project Site ... ... ... ... ... ... ... ... ... ... ... ... ... ARTICLE 8. INSURANCE... ... ... ... ... ... ... ... ... ... ... ... .... ... ... ... ... .... ... ... ... ... ... ... ... ..... Section 8.01 Insurance Requirements Generally... ...... ... ...... ...... ........... Section 8.02 Insurance Exclusive of Indemnity... ... ... ... ... ... ... ... ... ... ..... ... Section 8.03 No Waiver of Sovereign Immunity... ..... ... ... ... ... ... ... ... ... ... ... ARTICLE 9. INDEMNIFICATION... ... ... ... ... ... ... ... ....... ... ... ... ....... ... ... ... ... ... ... ....... Section 9.01 Indemnification by the Developer...... ...... ... ...... ...... .......... Section 9.02 Indemnification by the Agency.... ...... ...... ... ...... ................ Section 9.03 Limitation of Indemnification... ...... ...... ...... ... ...... .............. ARTICLE 10. REPRESENTATIONS, WARRANTIES AND COVENANTS OF THE DEVELOPER.................................................................................................... Section 10.01 Representations and Warranties...... ...... ... ... ......... ... Section 10.02 Covenants... ... ... ... .... ... ..... ... ... ... ... ... ... ... ... ... ..... ... Section 10.03 Covenant; Nondiscrimination... ...... ...... ...... ...... ........ Section 10.04 Survival... ... ... ... ... ... ... ... ... ..... ... ... ... ... ... ... ... ... ... ... ARTICLE 11. REPRESENTATIONS, WARRANTIES AND COVENANTS OF THE AGENCY... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ....... ... ... ... ... ... ... ......... Section 11.01 Representations and Warranties...... ...... ...... ... ... ...... Section 11.02 Covenants. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 111 Item # 3 Section 11.03 Attachment number 1 Page 4 of 89 Survival... ... ... ... ... ... ... ... ... ..... ... ... ... ... ... ... ... ... ... ... ARTICLE 12. DEFAULT; TERMINATION... ... ... ... ... .... ... ... ... ... ....... ... ... ... ... ... ... ... .... Section 12.01 Default by Developer........ ...... ...... ...... ...... ...... ...... Section 12.02 Default by the Agency.. ... ... ... ... ... ... ... ... ... ... ..... ... ... Section 12.03 Obligations, Rights and Remedies Cum ulative... ... .. ... Section 12.04 Non-Action on Failure to Observe Provisions of this Agreement... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... Termination... ..... ... ... ... ..... ... ... ... ... ... ... ... ... ... ..... ... Term ination Certificate... ... ... . ... ... ... ... ... ... ... ... ... .. ... Remedies... ... ... ... ... ... ... .... ... ... ... ... ... ... ... ... ... ... ... Section 12.05 Section 12.06 Section 12.07 ARTICLE 13. UNAVOIDABLE DELAY... ... ... ... ... ... ... ... ... ... ... ... ....... ... ... ... ... ... ... ... .... Section 13.01 Unavoidable Delay..... .... ... ... ... ... ... ... ... ... ... ... ... ... ... ARTICLE 14 FIRE OR OTHER CASUALTY; CONDEMNATION........ ... ... ... ... ... ... ....... Section 14.01 Loss or Damage to Project... ... ... ... ... ... ... ... ... ... ... ... Section 14.02 Partial Loss or Damage to Project... ........... .............. Section 14.03 Notice of Loss or Damage to Project... ...... ...... ... ...... Section 14.04 Subject to Financing... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ARTICLE 15. MISCELLANEOUS... ... ... ... ... ... ... ... ... .... ... ... ... ... ....... ... ... ... ... ... ... ... ... Section 15.01 Section 15.02 Section 15.03 Section 15.04 Section 15.05 Section 15.06 Section 15.07 Section 15.08 Section 15.09 Section 15.10 Section 15.11 Section 15.12 Section 15.13 Section 15.14 Section 15.15 Section 15.16 Section 15.17 Section 15.18 Section 15.19 Section 15.20 Assignments... .... ... ..... .... ... ... ... ... ... ... ... ... ... ... ... ... Successors and Assigns.. ... ... ... ... ... ... ... ... ... ... .. ... ... Notices... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ..... ... Severability... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... Applicable Law and Construction...... ...... ... .............. Venue; Submission to Jurisdiction....... ... ... ... ... ......... Agreement Not a Chapter 86-191, Laws of Florida, Development Agreement... ... ... ... ... ... ... ... ... ... ... ... ... Estoppel Certificates..... . ... ... ... ... ... ... ... ... ... ... ... ... ... Complete Agreement; Amendments..... ... ... ... ... ..... ... Captions... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... .... ... Holidays... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... ... .... ... ... Exhibits... ..... .... ..... .... ... ... ... ... ... ... ... ... ... ... ... ... ... ... No Brokers... ... ... ... ... .... ... ... ... ... ... ... ... ... ... ... ...... ... Not an Agent.. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .. .. . . . Memorandum of Development Agreement... ... ... .... ... Public Purpose. ... ... .. ... . ... ... ... ... ... ... ... ... ... ... ... ... ... No General Obligation... ..... ... ... ... ... ... ... ... ... ... ..... ... Technical Amendments; Survey Corrections... ........... Term; Expiration; Certificate... ...... ...... ...... ... ...... ... Effective Date... . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . IV Item # 3 Attachment number 1 Page 5 of 89 AGREEMENT FOR DEVELOPMENT AND DISPOSITION OF PROPERTY This Agreement for Development and Disposition of Property ("Agreement") is made as of this February 19, 2008, by and between the COMMUNITY REDEVELOPMENT AGENCY OF THE CITY OF CLEARWATER, FLORIDA, a public body corporate and politic of the State of Florida created pursuant to Part III, Chapter 163, Florida Statutes ("Agency"), and MDP CLEARWATER, LLC, a Georgia limited liability company ("Developer"). WIT N E SSE T H: WHEREAS, as of September 17, 2007, pursuant to the Request for Proposals, dated May 8, 2007, the Agency tentatively accepted the proposal of Developer, dated July 29, 2007, in response thereto, subject to negotiation of a definitive agreement with Developer pertaining to and setting forth the terms and conditions for the development of 200 to 249 residential multi-family dwelling units and up to 16,000 square feet of ground floor retail (the "Project") in the community redevelopment area of the City; WHEREAS, the Agency and Developer proceeded with the preparation of a definitive Development and Disposition Agreement to set forth the respective duties and responsibilities of the parties pertaining to the conveyance of the Project Site (as hereinafter defined), and the design, development, construction, completion, operation and maintenance of the Project; WHEREAS, the Agency and Developer have entered into and concluded negotiations for said definitive Development and Disposition Agreement, which negotiations have resulted in this Agreement; WHEREAS, at a duly called public meeting on February 19, 2008 the Agency approved this Agreement and authorized and directed its execution by the appropriate officials of the Agency; WHEREAS, the Developer is a single-member limited liability company organized under the laws of the State of Georgia and the member (as that term is defined in the operating agreement of the Developer) of Developer has approved this Agreement and has authorized and directed certain individuals to execute this Agreement on behalf of Developer; and NOW, THEREFORE, in consideration of the mutual promises and covenants contained herein, the parties hereby agree as follows: ARTICLE 1. DEFINITIONS. 1.01. Definitions. The terms defined in this Article I shall have the following meanings, EXHIBIT "C" Item # 3 Attachment number 1 Page 6 of 89 except as herein otherwise expressly provided: (1) "Act" means the Constitution of the State of Florida; Section 163.01, Florida Statutes, Part III, Chapter 163, Florida Statutes; Chapter 166, Florida Statutes, other applicable provisions of law, and ordinances and resolutions of the City and the Agency implementing them. (2) "Agency" means the Community Redevelopment Agency of the City, as created by Resolution No. 81-68 of the City, adopted by the City Council on August 6, 1981, including any amendments thereto, and any successors or assigns thereto. (3) "Agreement" means this Agreement for Development and Disposition of Property, including all exhibits and amendments hereto. (4) "Agreement Expiration Certificate" means the instrument executed by the parties hereto as provided in Section 15.19 certifying that all obligations of the parties hereto have been satisfied and this Agreement has expired in accordance with its terms, the form of which is attached hereto as Exhibit "E." (5) "Agreement Termination Certificate" means the instrument executed by the parties hereto as provided in Section 12.06 stating that this Agreement has been terminated prior to its Expiration Date as provided in Section 12.05. (6) "Allowable Retail Uses" means a retail establishment that sells or leases goods directly to the consumer, including, but not limited to, a book store, gift shop, antique store, florist, clothing store, video store; an art gallery; a gourmet grocery store, which may include accessory sales of alcoholic beverages; and prepared food for off site consumption; a restaurant with accessory sales of alcoholic beverages; a sidewalk cafe as accessory to the principal retail use. {7) "Alternative Retail Uses" means tailor or seamstress; dry cleaners; financial institution; or business office, but not medical or veterinary office. (8) "Area" means the area located within the corporate limits of the City having conditions of slum and blight (as those conditions are defined in the Act) as found by the City Council in Resolution No. 81-67, adopted by the City Council on August 6, 1981 and as amended by Resolution No. 03-22, adopted by the City Council on May 1, 2003. (9) "Authorized Representative" means the person or persons designated and appointed from time to time as such by the Developer or the Agency, respectively, pursuant to Section 2.04. (10) "Building Permit" or "Building Permits" shall mean, for all or any part of the Project to be constructed on the Project Site, anyone or more permits issued by the City authorizing, allowing and permitting the commencement, prosecution and completion of construction to the extent provided in said permit(s). 2 Item # 3 Attachment number 1 Page 7 of 89 (11) "City" means the City of Clearwater, Florida, a Florida municipal corporation, and any successors or assigns thereto. (12) "City Council" means the governing body of the City, by whatever name known or however constituted from time to time. (13) "Closing Date" means the date on which title to the Project Site is conveyed by the Agency to the Developer in accordance with and as contemplated by the provisions of Article 6 hereof. (14) "Commencement Date" means the earlier of: (i) the date of Commencement of Construction or (ii) the date which is twenty four (24) months after the date on which the CRA approves this Agreement. (15) "Commencement of Construction" or "Commence Construction" means the commencement of above grade beams, floor slabs or other foundation component on the Project pursuant to a properly issued foundation permit. (16) "Completion Certificate" means the certificate, in a form suitable for recording in the Public Records of Pinellas County, Florida, to be executed by Agency and Developer stating that construction of the Project has been substantially completed. (17) "Completion Date" means the date on which construction of the Project IS substantially complete as evidenced by a Completion Certificate. (18) "Contractor" means one or more individuals or firms constituting a general contractor or other type of construction contractor properly licensed by the State of Florida or other appropriate jurisdiction to the extent required by applicable law, authorized to perform construction contractor services in the State of Florida, registered with the City as required by applicable law, bonded and insured to the extent required by applicable law and this Agreement, including the Developer or any affiliates of the Developer. (19) "Construction Financing" means the funds provided by the Construction Lender to the Developer during the term of this Agreement to pay the cost of developing and constructing the Project, or any portion thereof, on the Project Site, including, but not limited to, acquisition of the Project Site, financing costs, "soft costs," overhead, and the design, construction and equipping of the Project. (20) "Construction Lender" means any person or persons providing the Construction Financing or any portion thereof. (21) "Developer" means MDP-Clearwater, LLC, a Georgia limited liability company, and any successors and assigns thereof. (22) "Effective Date" means the date determined in accordance with Section 16.21 when the Memorandum of Development Agreement is recorded and this Agreement 3 Item # 3 Attachment number 1 Page 8 of 89 becomes effective. (23) "Exhibits" means those agreements, diagrams, drawings, specifications, instruments, forms of instruments, and other documents attached hereto and designated as exhibits to, and incorporated in and made a part of, this Agreement. (24) "Expiration Date" means the date on which this Agreement expires, as evidenced by the Agreement Expiration Certificate being recorded in the public records of Pinellas County, Florida, as provided in Section 15.19 hereof. (25) "Impact Fees" means those fees and charges levied and imposed by the City, Pinellas County and any other governmental entity on projects located on the Project Site for certain services impacted by development such as the Project. (26) "Permits" means all zoning, variances, approvals and consents required to be granted, awarded, issued, or given by any governmental authority in order for construction of the Project, or any part thereof, to commence, continue, be completed or allow occupancy and use, but does not include the Building Permit(s). (27) "Plan" means the community redevelopment plan for the Area, including the Project Site, as adopted by the City Council on September 18, 2003, by enactment of its Ordinance No. 7153-03, and including any amendments to the Plan. (28) "Project" means the 200 to 249 residential multi-family dwelling units and appurtenant facilities, and up to 16,000 square feet allowable ground floor retail space, to be located on the Project Site as contemplated by the Proposal and this Agreement and constructed substantially in accordance with the Project Plans and Specifications. (29) "Project Plans and Specifications" means the plans and specifications pertaining to the construction, installation and equipping of the Project, including the schedule for completing the Project. (30) "Project Professionals" means any architects, attorneys, brokers, engineers, consultants, planners, construction managers or any other persons, or combination thereof, retained or employed by the Developer in connection with the planning, design, construction, permit applications, completion and opening of the Project, but does not include the Developer. (31) "Project Site" means the tract of land located in the Area which is to be conveyed to the Developer by the Agency on which the Project will be located, as more particularly described and depicted on Exhibit "A" (32) "Proposal" means the proposal for redevelopment of the Project Site, dated July 29,2007, submitted by the Developer to the Agency in response to the RFP. (33) "RFP" means the Request for Proposals initially published by the Agency on May 8, 2007, soliciting proposals from persons interested in redeveloping the Project Site 4 Item # 3 Attachment number 1 Page 9 of 89 in accordance with the Act and the Plan. (34) "Site Plan" means the depiction and description of the Project on the Project Site, the initial version of which is attached hereto as Exhibit "B." (35) "Public Amenities Incentive Pool" means the public amenities incentive pool established by the Clearwater Downtown Redevelopment Plan. (36) "Termination Date" means the date on which this Agreement is terminated by any party hereto as provided in Section 12.05, and as evidenced by the Agreement Termination Certificate. (37) "Unavoidable Delay" means those events constituting excuse from timely performance by a party hereto from any of its obligations hereunder; as such events are defined in and subject to the conditions described in Article 13 hereof. (38) "Vertical Construction" means commencement of work on the Project pursuant to a properly issued Building Permit. (39) "Workforce Affordable Housing Unit" means a residential dwelling unit leased or owned and occupied by a household with a household income of 120 percent or less of adjusted median family income for Pinellas County, Florida, as determined by the U.S. Department of Housing and Urban Development. The rental rates for leased units shall not exceed the rates published by the Florida Housing Finance Corporation for annual "Maximum Rents by Number of Bedrooms in Unit" for the Tampa-St. Petersburg- Clearwater MSA For non-rental units, the sales prices may not exceed 90% of the average area price for the Tampa-St. Petersburg-Clearwater MSA, as established by the annual revenue procedure which provides issuers of qualified mortgage bonds, as defined in Section 143( a) of the Internal Revenue Code, and issuers of mortgage credit certificates, as defined in Section 25(c) of the Internal Revenue Code, with the nationwide average purchase price for residences located in the United States. 1.02. Use of Words and Phrases. Words of the masculine gender shall be deemed and construed to include correlative words of the feminine and neuter genders. Unless the context shall otherwise indicate, the singular shall include the plural as well as the singular number, and the word "person" shall include corporations and associations, including public bodies, as well as natural persons. "Herein," "hereby," "hereunder," "hereof," "hereinbefore," "hereinafter" and other equivalent words refer to this Agreement and not solely to the particular portion thereof in which any such word is used. 1.03. Florida Statutes. All references herein to Florida Statutes are to Florida Statutes (2007), as amended from time to time. 5 Item # 3 Attachment number 1 Page 10 of 89 ARTICLE 2. PURPOSE; PROPOSAL. 2.01. Intent; Purpose of Agreement. (a) The purpose of this Agreement is to further the implementation of the Plan by providing for the sale and conveyance of the Project Site to the Developer and the development, construction and operation of the Project thereon in accordance with the Project Plans and Specifications, all to enhance the quality of life, add new residents to the Town Lake Character District, provide Workforce Affordable housing and improve the aesthetic and useful enjoyment of the Area through the eradication of conditions of blight, all in accordance with and in furtherance of the Plan and as authorized by and in accordance with the Act. (b) (1) The Project Site IS to be redeveloped according to Project Plans and Specifications. (2) As provided in this Agreement, the Agency shall undertake certain public actions pursuant to the Act and as implementation of the Plan, including making the Project Site available for redevelopment and assistance in obtaining such approvals by governmental authorities as are necessary for development of the Project. (c) As provided in this Agreement, the Developer shall carry out the redevelopment of the Project Site by obtaining approvals by governmental authorities necessary for development of the Project as more particularly described in Section 3.04 hereof, obtaining the Construction Financing, purchasing the Project Site from the Agency, constructing various private improvements on the Project Site, and causing the Project to be developed as described herein. 2.02. Developer's Proposal. (a) The Proposal for the redevelopment of the Project Site, specifically including the acquisition of the Project Site by the Developer from the Agency and the design, construction, equipping, completion and use of the Project, and each component thereof, is hereby found by the Agency and acknowledged by the Developer: (1) to be consistent with and in furtherance of the objectives of the Plan, (2) to conform to the provisions of the Act, (3) to be responsive to the RFP, (4) to be in the best interests of the citizens of the City, (5) to further the purposes and objectives of the Agency, (6) to provide Workforce Affordable housing and (7) to further the public purpose of eradicating conditions of blight in the Area. The parties recognize and agree that during the process of review and approval provided for in the Agreement the design of the Project may be subject to change and modification as may be either agreed to by the parties or required as provided herein or by the appropriate regulatory authority, and should any changes be necessary or desirable the parties agree that they will act expeditiously and reasonably in reviewing and approving or disapproving any changes or modifications to the Project. (b) Based upon and as a result of the findings set forth in subsection (a) above, the Proposal, including such changes and revisions as are provided by this Agreement, is 6 Item # 3 Attachment number 1 Page 11 of 89 hereby affirmed by the Developer and approved and accepted by the Agency. (c) The parties hereto find that the terms and conditions set forth in this Agreement do not, individually or collectively, constitute a substantial deviation from the RFP or the Proposal. 2.03. Cooperation of the Parties. The parties hereto recognize that the successful development of the Project and each component thereof is dependent upon continued cooperation of the parties hereto, and each agrees that it shall act in a reasonable manner hereunder, provide the other party with complete and updated information from time to time, with respect to the conditions such party is responsible for satisfying hereunder and make its good faith reasonable effort to ensure that such cooperation is continuous, the purposes of this Agreement are carried out to the full extent contemplated hereby and the Project is designed, constructed, equipped, completed and operated as provided herein. 2.04. Authorized Representative. (a) Each party shall designate an Authorized Representative to act on its behalf to the extent of the grant of any authority to such representative. Written notice of the designation of such a representative (and any subsequent change in the Authorized Representative) shall be given by the designating party to the other party in writing in accordance with the procedure set forth in Section 15.03 hereof. (b) Except as otherwise expressly provided in this Agreement, whenever approval or action by the Developer or the Agency is required by this Agreement, such action or approval may, in the discretion of the party considering such approval or action, be taken or given by the Authorized Representative thereof. A party to this Agreement may rely upon the representation of the other party's Authorized Representative that such person has the requisite authority to give the approval or take the action being done by that Authorized Representative. A party may not later deny that its Authorized Representative had the authority represented to and relied upon by the other party or revoke or deny any action taken by such Authorized Representative which was relied upon by the other party. (c) The Developer does hereby notify the Agency that its initial Authorized Representative for the Project is J. Jason Perry. (d) The Agency does hereby notify the Developer that its initial Authorized Representative is Rod Irwin, Executive Director. ARTICLE 3. LAND USE REGULATION AND RESTRICTIONS ON USE. 3.01. Zoning. On the Effective Date, the zoning classification for the Project Site is Downtown, abbreviated as "D." The parties recognize and acknowledge that the zoning classification of the Project Site as of the Effective Date permits residential development of the Project 7 Item # 3 Attachment number 1 Page 12 of 89 Site of 30 residential dwelling units per acre. The Project Site is approximately 4.13 acres which will currently allow development of 123 residential multi-family dwelling units. Developer shall apply to the City for an allocation of up to an additional 126 residential multi-family dwelling units and up to 16,000 square feet of retail use from the Public Amenities Incentive Pool, as more particularly described in Section 3.04 hereof. 3.02. Redevelopment Plan. The Agency represents to the Developer and the Developer acknowledges that as of the date of the RFP and the Proposal the provisions of the Plan pertaining to the Project Site are consistent with the Project as contemplated by the Proposal. 3.03. Development of Regional Impact. The parties hereto acknowledge and agree that the Project as contemplated by the Proposal and this Agreement was not and is not as of the Effective Date a "development of regional impact" within the meaning of Section 380.06, Florida Statutes. 3.04. Permits. (a) The Developer shall prepare and submit to the City by no later than August 1, 2008, (i) a complete and sufficient application for flexible development approval of a comprehensive infill redevelopment project to allow development of the Project in accordance with the Project Plans and Specifications; and (ii) a complete and sufficient public amenities incentive pool use application requesting that up to 126 residential multi- family dwelling units and up to 16,000 square feet of retail be allocated to the Project Site from the Public Amenities Incentive Pool (collectively, "Applications"). The Applications are subject to approval by the Clearwater Community Development Board ("CDB"). The parties acknowledge that the CDB is an independent entity which is not a party to this Agreement and will render its independent decision concerning the Applications. (b) The Developer shall prepare and submit to the appropriate governmental authorities, including the City, by no later that May I, 2009, the applications for each and every Building Permit and any and all necessary Permits for the Project, and shall bear all costs of preparing such applications, applying for and obtaining the Building Permits and Permits including applicable application, inspection, regulatory and Impact Fees or charges pertaining to the Project, including, but not limited to, any Building Permits or Permits, review, application, inspection, regulatory or Impact Fees. (c) The Agency, as the property owner, shall cooperate with the Developer in making the Applications, and the Agency shall cooperate with the Developer in obtaining all necessary Permits and the Building Permits required for the construction and completion of the Project. (d) The Agency's duties, obligations, or responsibilities under any section of this Agreement, specifically including but not limited to this Section 3.04 do not affect the Agency's or the City's right, duty, obligation, authority and power to act in its governmental 8 Item # 3 Attachment number 1 Page 13 of 89 or regulatory capacity in accordance with applicable laws, ordinances, codes or other building or project regulation. (e) Notwithstanding any other provisions of this Agreement, any required permitting, licensing or other regulatory approvals by the Agency or the City shall be subject to the established procedures and requirements of the Agency or the City with respect to review and permitting of a project of a similar or comparable nature, size and scope. In no event shall the Agency or the City, due to any provision of this Agreement, be obligated to take any action concerning regulatory approvals except through its established processes and in accordance with applicable provisions of law. 3.05. Concurrency. (a) The parties hereto recognize and acknowledge that Florida law (specifically, Part II, Chapter 163, Florida Statutes, and Rule 9J-5, Florida Administrative Code, collectively the "Growth Management Act") imposes restrictions on development if adequate public improvements are not available concurrently with that development to absorb and handle the demand on public services caused by that development. The City has created and implemented a system for monitoring the effects of development on public services within the City. The Developer recognizes and acknowledges it must satisfy the concurrency requirements of Florida law as applied to the Project. Specifically, the Developer covenants and agrees to comply with the City's land development code, including providing to the City any and all data and analysis that shows the Project will be consistent with the goals, objectives and policies of the comprehensive plan for the City, adopted by the City and in effect on the Effective Date, and the Developer further covenants and agrees to comply with concurrency certification provisions of the City's land development code. (b) The Agency represents and warrants and the Developer acknowledges that as of the Effective Date the Project as contemplated by this Agreement does not require any reservation of capacity or to seek any approvals as a result of the concurrency requirements described in subsection (a). If legally obligated in the future to comply with such requirements, the Developer agrees to seek issuance of a concurrency compliance certificate or other similar document by whatever name known and a reservation of services capacity under the City's concurrency management system, and does further agree to maintain such certificate and reservation. The Developer covenants and agrees with the Agency to not undertake any action or fail to take any action, which would cause the City to revoke or invalidate the concurrency compliance certificate or the reservation of services capacity. 3.06. Not a Development Order or Permit. The parties do hereby acknowledge, agree and represent that this Agreement is not intended to be and should not be construed or deemed to be a "development order" or "development permit" within the meaning of those terms in Section 163.3164, Florida Statutes. 3 07 Perm itted l Jses 9 Item # 3 Attachment number 1 Page 14 of 89 (a) The Project shall consist of no fewer than 200 and not more than 249 residential multi-family dwelling units and associated appurtenances. The approved multi-family dwelling units shall remain as rental units for a period of no less than five (5) years following the date of the issuance of the final certificate of occupancy for the last multi- family dwelling units. No less than ten percent (10%) of the total number of approved multi-family dwelling units shall be Workforce Affordable Housing Units for a period of no less than 20 years from the issuance of the final certificate of occupancy for the last multi- family units. After the expiration of such five-year period, some or all of the approved multi-family dwelling units may be converted to the condominium form of ownership. However, in any event, the income restrictions for Workforce Affordable Housing Units must be met as to ten percent (10%) of the un its for at least 20 years from the date of the issuance of the final certificate of occupancy for the last multi-family dwelling units.. (b) The Project shall contain up to 16,000 square feet of Allowable Retail Uses to be located on the first floor. (c) The Developer shall actively market and use his best efforts to obtain tenants for the first floor retail space as one or more of the Allowable Retail Uses described above However, should the Developer be unable to obtain a tenant for an Allowable Retail Use within one year of issuance of the temporary Certificate of Occupancy for the retail space, the City may allow, upon written request of the Developer, one or more Alternative Retail Uses to occupy the first floor retail space. (d) The following uses are prohibited: (1) All uses prohibited by the Clearwater Downtown Redevelopment Plan; (2) All other retail uses not specifically defined herein as Allowable Retail Uses or Alternative Retail Uses, pursuant to the Community Development Code's definition of retail sales and services; (3) Nightclub or bar; (4) Alcoholic beverage package store; (5) Medical or veterinary offices; (e) Developer or any person or entity proposing to use the Project Site for a use not consistent with this Section 3.07, shall file with the Agency a request for a release of part or all of the restrictions imposed by this section. The Agency shall consider such request and either deny the request, approve the request as filed, or approve the request subject to such terms, conditions and limitations as the Agency may require. Any such release of a restriction shall be evidenced by an instrument executed by Agency and recorded in the public records of Pinellas County, Florida, the cost of which recording shall be paid by Developer. Nothing in this Section 3.07 is intended to affect or override any law, ordinance, regulation or other legal restriction set forth in this Agreement. 3.08 Workforce Affordable Housing Units (a) No less than ten percent (10%) of the total number of approved multi-family dwelling units shall be Workforce Affordable Housing Units for a period of no less than 20 years from the issuance of the final certificate of occupancy for the 10 Item # 3 Attachment number 1 Page 15 of 89 multi-family units. (b) The Workforce Affordable Housing Units shall be mixed with and not clustered together or segregated in any way from the market-rate units. (c) The number of efficiency, one, two and three or more bedroom Workforce Affordable Housing Units shall be substantially proportional to the number of one, two and three or more bedroom market rate units. For example, if 50% of the market rate units are two bedroom, then at least 50% of the Workforce Affordable Housing Units shall be two bedroom or larger. (d) The Developer shall be responsible for qualifying eligible tenants or initial purchasers and for monitoring compliance with the conditions. Prior to each subsequent resale of any Workforce Affordable Housing Unit during the twenty (20) year restrictive period, the prospective purchaser shall provide evidence of compliance with the income limitations as described in this Agreement, satisfactory to the City of Clearwater Housing Division, in their discretion, reasonably exercised. (e) The Developer shall submit a mid-year and an annual report to the CRA, commencing six months following the issuance of the certificate of occupancy. The report shall identify the Workforce Affordable Housing Units, the monthly rent for each unit, the occupancy information for each month of the prior year, monthly income for the tenants of each unit and other information as may be required by the CRA to determine compliance with the conditions herein. (f) In the event the Workforce Affordable Housing Units are sold, any purchaser or occupant shall meet the eligibility requirements contained herein. (g) The restrictions on the Workforce Affordable Housing Units shall be included as restrictive covenants and deed restrictions upon the Property at the conveyance of the Property by the CRA to the Developer and all subsequent conveyances of the Property or the Workforce Affordable Housing Units. The restrictive covenant and deed restrictions shall be in substantially the form provided in Exhibit H hereto. ARTICLE 4. PROJECT PLANS AND SPECIFICATIONS. 4.01. Site Plan. (a) The Developer has prepared a preliminary Site Plan, a copy of which is attached hereto as Exhibit "B," that contemplates development of the Project consistent with this agreement. The Developer agrees that during the term of this Agreement any material changes to the preliminary Site Plan or any subsequent versions of the Site Plan will be subm itted to the Agency for approval. (b) The Site Plan approved by the Agency shall be the basis for and incorporated into 11 Item # 3 Attachment number 1 Page 16 of 89 the Project Plans and Specifications. 4.02. Preparation of Project Plans and Specifications. (a) The Developer shall prepare the Project Plans and Specifications in sufficient detail and description of the Project, graphically and narratively if requested, to allow the Agency the opportunity to determ ine if those plans and specifications are consistent with the Proposal, the Site Plan and the Plan. (b) (1) The Developer is responsible for the cost of preparing, submitting and obtaining approval of the Project Plans and Specifications (2) The Developer has retained and shall retain the Project Professionals to prepare the Project Plans and Specifications, and shall notify the Agency of the names of such Project Professionals and any subsequent changes thereto or additional Project Professionals retained with respect to the Project. The Developer shall cause the Project Professionals to prepare the Project Plans and Specifications. (c) (1) The Agency does hereby consent to the preparation of the Project Plans and Specifications, and any revisions thereto, by the Project Professionals, and the Agency will not withhold approval of the Project Plans and Specifications because they were prepared by the Project Professionals. The Agency hereby acknowledges and agrees that the selection of the Project Professionals is the sole responsibility of, and within the sole discretion of, the Developer, and the Agency will not participate, and has not previously participated, in such selection by the Developer. (2) The parties hereto mutually acknowledge and agree the Project Professionals are not, individually or collectively, agents or representatives, either expressed or implied, of the City or the Agency. (d) The Developer shall provide the Project Plans and Specifications to the Agency for review and approval, which approval shall not be unreasonably withheld, prior to submittal of the Applications. The Agency and the Developer recognize and acknowledge the need for expedited review of the Project Plans and Specifications and approval by the Agency. (e) The Project Plans and Specifications contemplated by this subsection (d) shall be sufficient for a determination by the City required by the ordinances and regulations of the City. 4.03. Coordination with City Review. The Developer has represented to the Agency and the Agency acknowledges the need to expedite the process for review of the Project Plans and Specifications and the issuance of any Building Permits and Permits. The Agency agrees to use its best efforts to coordinate and expedite its review of the Project Plans and Specifications with any review or approvals by the City or other governmental entities. 4.04. Agency Review of Project Plans and Specifications. 12 Item # 3 Attachment number 1 Page 17 of 89 (a) During the term of this Agreement, Agency review and approval of the Project Plans and Specifications is a prerequisite for issuance of the initial Building Permit for construction of the Project, or any part thereof. Rod Irwin, the Executive Director, is hereby delegated by the Agency to review and approve the Project Plans and Specifications for substantial compliance with the Site Plan. (b) Upon the Developer submitting the Project Plans and Specifications to the Agency for review, the Agency agrees to diligently proceed with and complete its review of the Project Plans and Specifications and respond to the Developer as soon as reasonably possible after receipt thereof, but in no event later than fifteen (15) days after receipt of such Project Plans and Specifications, and advise the Developer in writing of the Agency's reasonable objections thereto or that the Project Plans and Specifications have been approved as submitted. (c) If the Agency gives written notice of specific objections to or deficiencies in the Project Plans and Specifications as provided in subsection (b), then the Agency and the Developer shall expeditiously, diligently and reasonably negotiate to resolve such objections. (d) If the Project Plans and Specifications submitted to the Agency by the Developer substantially comply with this Agreement, including being substantially in accordance with the Site Plan, and further the purposes of the Plan, the Agency shall approve the Project Plans and Specifications as submitted, and shall notify the City and other pertinent governmental entities of such approval and recommend the City and such other pertinent governmental entities give such approvals and issue such Permits and Building Permits or licenses as are necessary for development of the Project. (e) If the Developer does not dispute the objections to any proposed Project Plans and Specifications contained in any notice from the Agency, it shall subm it revised Project Plans and Specifications satisfying such objections. Any changes in the Project Plans and Specifications made by the Developer in response to such a notice shall be made without charge to the Agency. 4.05 Project Schedule. (a) Developer shall submit complete applications for all necessary Permits and Building Permits, as described in Section 3.04(b) hereof, within twenty (20) months after the date on which the CRA approves the Development Agreement. (b) Developer shall Commence Construction of the Project within twenty four (24) months after the date on which the CRA approves the Development Agreement. (c) Developer shall commence Vertical Construction months within four (4) months of the Commencement of Construction. (d) Developer shall have substantially completed construction of the Project in 13 Item # 3 Attachment number 1 Page 18 of 89 accordance with S 7.05, within two (2) years after the Commencement Date. ARTICLE 5. PROJECT FINANCING. 5.01. Construction Financing. (a) If the Developer elects to obtain Construction Financing, the Developer shall use its reasonable efforts to obtain from a Construction Lender a term sheet for provision of the Construction Financing as soon as is reasonably possible. Upon obtaining such Construction Financing, the Developer shall notify the Agency that it has obtained said financing and provide to the Agency the name and address of the Construction Lender. (b) The Agency shall have an affirmative right, but not an obligation, to cure any default by the Developer under the Construction Financing. The parties recognize and acknowledge that the Agency's right under this paragraph (2) is not intended to be superior or ahead of any lien or right of the Construction Lender to enforce its rights and remedies under the financing documents pertaining to the Construction Financing. (c) The Developer covenants and agrees with the Agency that the proceeds of the Construction Financing shall be solely for the purpose of paying costs and fees related to the development and construction of the Project and that such proceeds, together with its own funds or other funds available to it, shall be sufficient to pay the costs of acquiring the Project Site and the development, construction and completion of the Project. 5.02. Notice of Developer's Default. (a) The Developer covenants and agrees with the Agency that Developer shall notify the Agency in writing within 5 days of Developer receiving notice that Construction Lender declares the Developer to be in default or if an event of default has occurred under the financing documents for the Construction Financing. The notice from the Developer to the Agency shall state the basis of the default by the Developer, shall identify the particular provision of the financing documents under which the Developer is in default and shall include copies of any pleadings in any proceeding instituted by the Construction Lender incident thereto. (b) Any notice from the Agency to the Developer specifying an event of default by the Developer under Section 12.01 hereof shall, at the same time it is provided to the Developer, be mailed by the Agency to any Construction Lender by certified mail, return receipt requested, at its address last given to the Agency by the Developer prior to such notice; provided, however, the failure of the Agency to mail any such notice or the Construction Lender to receive any such notice shall not constitute a material breach or default of this Agreement by the Agency, nor shall it constitute a waiver by or preclude or delay the Agency from proceeding with or enforcing any right or remedy available to it under this Agreement. The notice from the Agency to the Construction Lender shall state the basis of the default, the particular provision of this Agreement under which the Developer is in default and shall include copies of any pleadings in any proceedings instituted by the Agency incident thereto. 14 Item # 3 Attachment number 1 Page 19 of 89 5.03. Cure of Developer's Default by Lender. (a) (1) Following the Agency providing the notice under Subsection 5.02(b) hereof, the Construction Lender may, at its election, cure or remedy the default by the Developer described in such notice. If the Construction Lender elects to cure such default, it shall give notice of such election to the Agency and the Developer within sixty (60) days after the Agency issued its notice of default by the Developer as provided in Section 12.01 hereof. (2) So long as the Construction Lender proceeds to cure or remedy the Developer's default of this Agreement, the Agency agrees not to exercise any right or remedy available to it resulting from the Developer's default described in the notice and which the Construction Lender has elected to cure for such period of time as shall be reasonably necessary for the Construction Lender to cure or remedy such default, including any time reasonably necessary for the Construction Lender to obtain possession of the Project Site, if possession is necessary to enable the Construction Lender to cure or remedy such default. (b) If a default by the Developer under this Agreement is timely cured or remedied by the Construction Lender pursuant to this Section 5.03, then the Agency shall not have any rights or remedies against the Developer with regard to such default, except in such an event, the Developer shall be obligated to pay and the Agency may recover from the Developer any fees, costs or other expenses, including reasonable attorneys fees, incurred by the Agency as a result of said default by the Developer, plus interest on such fees, costs or other expenses from the date they were incurred at an annual percentage rate of twelve percent (12%). (c) If the Construction Lender elects to cure or remedy the Developer's default hereunder as provided in subsection (a) hereof, it shall then be subject to and bound by the provisions of this Agreement and the actions required to be taken to remedy or cure said default that, but for the default by the Developer, would have been applicable to the Developer. (d) If, as a result of the Construction Lender curing or remedying a default by the Developer under this Agreement, the Construction Lender completes the construction of the Project upon receipt of a written request by the Construction Lender to the Agency for a construction completion certificate, the Agency shall execute and deliver to the Construction Lender a construction completion certificate for the Project, in the same manner and procedure as if the Developer has requested such a certificate under Section 7.05 hereof. (e) Subsequent to a default under this Agreement by the Developer, if the Construction Lender does not timely elect to cure such default as provided in subsection (a) hereof, or makes such election and proceeds to construct and complete the Project, but fails to complete such construction by the Completion Date (subject to extensions for Unavoidable Delays) and such failure shall not have been cured within sixty (60) days (or 15 Item # 3 Attachment number 1 Page 20 of 89 such longer period as may be reasonably necessary and mutually agreed upon by the Agency and the Construction Lender), then the Agency may proceed with any remedies available to it under Section 12.01 hereof. 5.04. Construction Lender Not Obligated to Construct. (a) If the Construction Lender elects not to cure a default by the Developer hereunder as provided in Subsection 5.03(a) hereof, the Construction Lender and any other holder who obtains title to or possession of the Project Site, or any part thereof, as a result of foreclosure proceedings or any other action in lieu thereof, including (I) any other party who thereafter obtains title to the Project Site or such part from and through such holder or, (ii) any other purchaser at a foreclosure sale, or (iii) any other grantee under a deed in lieu of foreclosure, and any of such parties' successors and assigns, shall not be obligated by this Agreement to construct or complete the Project, or to guarantee such construction or completion or to perform any of the Developer's other agreements, obligations or covenants under this Agreement. (b) Nothing in this Section 5.04 or any other provisions of this Agreement shall be deemed or construed to permit or authorize any Construction Lender or any other party obtaining title to or possession of the Project Site, or any part thereof, to devote the Project Site, or any part thereof, to any use, or to construct any improvements thereon, other than the uses and improvements provided in the Plan and in the Project Plans and Specifications, unless prior to commencement of such use, approval thereof is obtained from the Agency, which approval shall not be unreasonably withheld or delayed. 5.05. Agency Cures Developer's Default. If prior to the issuance of the Project Completion Certificate, the Developer defaults under this Agreement or under, and to the holder of, any mortgage or other instrument creating an encumbrance or lien upon the Project Site, or any part thereof, the Agency may cure such default or breach. In such an event, the Agency, as the case may be, shall be entitled, in addition to and without limitation upon any other rights or remedies or payment of any other amounts to which it shall be entitled by this Agreement, operation of law, or otherwise, to reimbursement from the Developer for all costs and expenses, including, without limitation, reasonable attorneys' fees, incurred by the Agency in curing such default, together with interest thereon at a per annum rate equal to twelve percent (12%). Until such amount is paid. The Agency shall have a lien on the Project Site for the amount of such reimbursement; provided, that any such lien shall be subject and subordinate to the lien of any then existing mortgage of the Project Site in favor of the Construction Lender. ARTICLE 6. PROJECT SITE CONVEYANCE. 6.01. Findings; Representations. (a) The Agency is or will be, the owner of the Project Site by the closing date. (b) Developer desires to purchase from Agency and Agency desires to sell to Developer the Project Site. 16 Item # 3 Attachment number 1 Page 21 of 89 6.02. Agreement to Sell and Purchase. The Agency hereby agrees to sell and convey the Project Site to Developer and Developer hereby agrees to purchase the Project Site from Agency, upon the terms and conditions set forth in this Article 6. 6.03. Purchase PricelDeposit. (a) The Developer shall pay to the Agency as the purchase price for the Project Site the sum of Three Million and 00/100 Dollars ($3,000,000.00), which is subject to adjustment as set forth in this Section 6.03 ("Purchase Price."). (b) In the event Developer receives approval of the Project with less than 249 residential multi-family dwelling units, the Purchase Price shall be reduced by the sum of $12,050.00 for each dwelling unit under 249 units. For example, in the event the Project is approved for 244 units, representing a reduction of 5 units, the adjusted Purchase Price shall be $2,939,712 [$3,000,000 less $60,250 (5 x $12,050)]. (c) Upon execution of this Agreement by Agency and Developer, Developer shall deliver an earnest money deposit in the amount of $250,000.00 to Escrow Agent, to be held by Escrow Agent in accordance with the terms of an Escrow Agreement, in the form attached hereto and incorporated herein as Exhibit "F" ("Deposit"). The Deposit shall be paid to Agency and applied to the Purchase Price at Closing, unless otherwise disbursed in accordance with the terms of the Agreement and the Escrow Agreement. 6.04. Site Evaluation. (a) From and after the Effective Date hereof during the term of this Agreement, the Developer and its agents and representatives shall be entitled to enter upon the Project Site for inspection, soil tests, examination, and such other matters and investigations as Developer deems necessary and appropriate. In this regard, no such examination will be deemed to constitute a waiver or a relinquishment on the part of Developer of its right to rely on the covenants, representations, warranties and agreements made by Agency or upon the agreements provided to Developer by Agency. Developer will restore any disturbance to the Project Site caused by its acts and will hold Agency harmless and indemnify Agency from and against any and all damages and liability occasioned by any claim asserted against Agency caused by such examination, excluding all damages and liability as a result of (i) a pre-existing condition on the Project Site, including without limitation the existing groundwater conditions and required Groundwater Monitoring, or (ii) the negligence and willful misconduct of the Agency. (b) Notwithstanding any other provision of this Agreement, Developer shall have the absolute right for a period of forty-five (45) days following the date upon which the Community Development Board has approved the Applications, inclusive of any appeal period, in which to review and examine the Project Site and the items provided from Agency (herein referred to as the "Evaluation Period"). At any time prior to the expiration 17 Item # 3 Attachment number 1 Page 22 of 89 of the Evaluation Period, Developer may terminate this Agreement and shall be entitled to the return of the Deposit if, in its sole discretion, Developer determ ines that the Project Site or the contemplated development or construction thereon is not economically or otherwise acceptable to Developer. Developer may terminate this Agreement as provided in Section 12.05 hereof and receive a full refund of the Deposit. 6.05. Iitl.e. (a) Within twenty (20) days after the Effective Date, the Agency shall furnish to Developer, at Agency's expense, a commitment for the issuance of an owner's policy of title insurance for the Project Site by Commonwealth Land Title Insurance Company, through its agent, Johnson, Pope, Bokor, Ruppel & Burns, LLP (collectively, "Title Company"), in the standard form adopted by the American Land Title Association, at no more than the promulgated rate, accompanied by one copy of all documents affecting the Project Site which constitute exceptions to the commitment. This commitment shall be in the amount of the total Purchase Price of the Project Site, shall show in Agency or the City, a good and marketable title in fee simple, free and clear of all liens and encumbrances without exception other than those permitted under the provisions of Section 6.14 hereof (the "Perm itted Exceptions") in a form reasonably acceptable to Developer and shall be refereed to hereinafter as the "Title Commitment". (b) If the Title Commitment, any update thereof or subsequent title commitment or the survey delivered to Developer in connection with the Project Site shows that the title is defective or unmarketable or that any part of the Project Site is subject to liens, restrictions, easements, encroachments or encumbrances of any nature whatsoever other than the Permitted Exceptions, Developer shall give Agency a reasonable time (not to exceed sixty (60) days after Developer has given written notice to Agency of any unacceptable conditions of title) within which to remedy or remove any such unacceptable conditions of title. Failure of Agency to remedy or remove any such unacceptable condition of title shall constitute a grounds for termination as provided in Section 12.05, unless Developer gives Agency its written waiver of such unacceptable condition of title. (c) Within thirty (30) days after closing, Agency shall furnish to Developer, at Agency's expense, a standard AL TA Marketability Form B-1970 (Rev. 10/17/70 and Rev. 10/17/84) owner's policy of title insurance based on the Title Commitment. Such policy will be issued by the title company that issued the Title Commitment, will be in the amount of the Purchase Price and will insure Developer's fee simple title, as the case may be, to the Project Site subject to no exceptions other than the Permitted Exceptions. Agency shall pay the premium charged for the issuance of any owner's policy of title insurance to the extent of the Purchase Price showing Developer as the fee simple owner of the Project Site. 6.06. Survey. (a) The Developer, shall employ a surveyor licensed by the State of Florida to prepare a current survey of the Project Site. 18 Item # 3 Attachment number 1 Page 23 of 89 (b) The survey shall: (1) Include the sealed Survey Certification attached hereto as Exhibit "G" for the Project Site. (2) Set forth an accurate metes and bounds description of the Project Site, which metes and bounds description shall be used for the purposes of conveying the Project Site to Developer hereunder, and the gross number of acres contained in the Project Site. (3) Locate all existing easements and rights of way, whether recorded or visible (setting forth the book and page number of the recorded instruments creating the easement). (4) Show any encroachments onto the Project Site from adjoining property and any encroachments from the Project Site onto adjoining property. (5) Show all existing improvements (such as buildings, power lines, fences, roads, driveways, railroads, underground pipelines, cables, etc.) and all rivers, creeks, drainage ditches or other water courses. (6) Show all dedicated public streets providing access to the Project Site and whether such access is paved to the property line of the Project Site. (7) Identify any flood zones as defined on Federal Flood Insurance Rate Maps (F.I.R.M.) for Pinellas County, Florida that affect the Project Site. (8) backs. Show all applicable set back lines with reference to the source of the set In the event the survey shows any encroachments of any improvement upon, from or onto the Project Site or shows any other matter of survey which is objectionable to Developer, in Developer's sole discretion, then Developer shall provide Agency with notice of such defect and the same shall be deemed a title defect and shall be treated as an objection to title by Developer as provided under Section 6.05(b). 6.07. Rights and Duties of Agency. (a) Agency shall cooperate in good faith with Developer in Developer's evaluation of the Project Site and shall execute all documents or perform such other acts, reasonably necessary to enable Developer to satisfactorily complete its evaluation of the Project Site and shall provide to Developer and its consultants any information or documents reasonably required by Developer and in Agency's or its consultant's possession which would assist Developer in such evaluation and preparation. (b) Agency shall reaffirm in writing to Developer that the covenants, warranties and representations set forth herein are true and correct as of the Closing Date. 19 Item # 3 Attachment number 1 Page 24 of 89 6.08. Rights and Duties of Developer, Developer agrees to timely commence and pursue its evaluation of the Project Site hereunder in good faith; provided, however, at any time, Developer may cease such evaluations and terminate this Agreement as provided in Section 6.04(b). 6.09. Conditions to Closing. (a) The obligation of Developer to purchase the Project Site is subject to the following ("Conditions to Closing") unless waived by the Developer on or before the Closing Date: (1) Developer's purchase of the Project Site is contingent upon Developer obtaining approval of the Applications, resulting in a site plan approval of the Project for no fewer than 200 multi-family residential dwelling units and at least 10,000 square feet of ground floor retail space. Approval of more than 200 multi-family residential dwelling units and up to 16,000 square feet of ground floor retail shall be sought by Developer but are not conditions precedent to Closing. (2) The representations and warranties of Agency set forth herein being true on and as of the Closing Date with the same force and effect as if such representations and warranties were made on and as of the Closing Date. (3) The Project shall be in compliance with the zoning, land use and concurrency requirements for the Project for no fewer than 200 multi-family residential dwelling units. (4) Developer making a determination that the Town Lake has adequate capacity to accept stormwater drainage from the Project Site and obtaining any necessary stormwater drainage easements for the benefit of the Project Site. (5) The recordation of that certain Resolution described in Section 6.11 (I), below." In the event the Conditions to Closing are not satisfied on or before the Closing Date, as hereinafter defined, Developer may terminate this Agreement as set forth in Section 12.05 (b) The obligation of the Agency to convey the Project Site to the Developer is subject to the following unless waived by the Agency on or before the Closing Date: (1 ) The representations and warranties of the Developer set forth in Section 10.01 being true on and as of the Closing Date with the same force and effect as if such representations and warranties were made on and as of the Closing Date; (2) The Developer is not then in default of this Agreement as provided in 20 Item # 3 Attachment number 1 Page 25 of 89 Section 12.01. (3) The Agency shall have approved the Project Plans and Specifications. (4) The City shall have approved the Site Plan for the Project for no fewer than 200 multi-family dwelling units and 10,000 square feet of ground floor retail space. 6.10. Closing. Provided all conditions to conveyance of the Project Site to the Developer have been satisfied, Developer shall purchase the Project Site on or before the date which is the earlier to occur of: (i) 30 days after issuance of all Building Permits; or (ii) October 1" 2009 (herein referred to as the "Closing Date"). The parties may mutually agree to change the Closing Date. 6.11 . Closing Procedure. (a) At closing, the Agency shall convey to Developer by special warranty deed, in the form attached hereto as Exhibit "C", title in fee simple to the Project Site, free and clear of any and all liens, encumbrances, conditions, easements, assessments, restrictions except those permitted in this Agreement and the Permitted Exceptions. (b) At closing, the Agency shall execute and deliver to Developer and Title Company an Affidavit of No Liens in a form satisfactory to Title Company and Developer, so as to cause Title Company to remove the "gap," unrecorded easements and other standard exceptions from the Title Commitment including the construction liens and parties in possession. (c) At closing, the Agency shall deliver to Title Company and Developer a certified copy of the organic document (e.g. articles of incorporation, partnership agreement, trust agreement, etc.) and all amendments thereto, that legally formed Agency andlor pursuant to which Agency holds title to the Premises, along with evidence satisfactory to Title Company of Agency's authority to execute and deliver the documents necessary or advisable to consummate the transaction contemplated hereby. (d) At closing, the Agency shall deliver an endorsement to the title insurance commitment required herein and such further instruments as may be required by Developer, Developer's counselor the title company to vest in Developer title of the Project Site as provided herein, all at Agency's expense. (e) Developer shall pay the Purchase Price for the Project Site to Agency as provided in Section 6.03. (f) The Project Site is currently exempt from ad valorem real estate taxes. Commencing on the Closing Date, Developer shall be responsible for all ad valorem real estate taxes on the Project Site and any personal property taxes. 21 Item # 3 Attachment number 1 Page 26 of 89 (g) Agency shall pay all special assessments and taxes, interest and penalties levied against the Project Site prior to the Closing Date. (h) Agency has terminated all original leases, if any, for the Project Site or any part thereof and all tenants will have vacated the Project Site by the Closing Date. (i) Agency shall deliver to Developer all original documents pertaining to the Project Site including licenses and permits, if any. 0) Agency shall pay for all documentary stamps and transfer taxes, if any, for the deed, and for the preparation, recording and documentary stamps for all closing documents, lien releases and title curative instruments, its own attorney's fees, the premiums for the owner's title insurance policy, and for recording the deed and all other closing costs and expenses. (k) At closing, the Agency shall give Developer a credit against the purchase price for the cost of the Survey described in Section 6.06 of the Agreement. (I) The Agency shall provide a Resolution of the City dedicating the land described in Exhibit I as a public way. (m) Developer shall execute and deliver the Monitoring Easement referenced In Section 6.150), below. (n) Closing shall be conducted at the law offices of Johnson, Pope, Bokor, Ruppel & Burns, LLP, 911 Chestnut Street, Clearwater, Florida, or elsewhere by mutual agreement. 6.12. Possession. Possession of the Project Site shall pass to Developer upon completion of the Closing. 6.13. Condition of Title. Title to the Project Site at the time of conveyance shall be free of all liens, restrictions, easements, encroachments and encumbrances of any nature whatsoever except the following (the "Perm itted Exceptions"): (a) Real estate taxes for the year of Closing and subsequent years that are a lien but not yet due and payable. (b) Comprehensive land use planning, zoning and building ordinances, regulations and requirements adopted by governmental or municipal authority having jurisdiction. (c) Those additional exceptions as contained in the Title Commitment to be delivered by Agency to Developer at closing which Developer, in its sole and absolute discretion, has elected to accept. 22 Item # 3 Attachment number 1 Page 27 of 89 6.14. Taxes and Assessments. Agency agrees to pay all taxes and assessments that become a lien on the Project Site prior to the Closing Date promptly when due. All special assessments applicable to any portion of the Project Site, delinquent taxes and delinquent installment of special assessments, together with any penalties and interest thereon, shall be paid by Agency on or before the Closing Date. 6.15. Covenants, Warranties and Representations. Agency hereby covenants, warrants and represents to Developer that: (a) The title of Agency to the Project Site hereby sold is absolute, good and marketable and free and clear of all liens and encumbrances except for the Permitted Exceptions. (b) Agency will have the full legal power to own and convey the Project Site as provided for herein, following conveyance to the CRA of that portion of the property owned by the City. (c) There are no legal proceedings pending, threatened or contemplated against Agency or the City in any court, tribunal or administrative agency which affect the Project Site or which give or will give rise to any claims or liens against the Project Site or affect Agency's right to transfer the Project Site. The Agency entered into a prior Development Agreement on the Project Site, which Agreement has been terminated by the Agency in accordance with its terms. The Developer under that Agreement has not executed a term ination certificate as required by the Agreement. The Agency shall undertake all reasonably necessary actions to fulfill all of the requirements of Schedule B-1 of the Title commitment, including the bringing of suit, if necessary, in order to extinguish any rights of third parties that may exist in connection with the prior Development Agreement. (d) Except with regard to the prior Development Agreement as provided above, there are no rights of possession, use, rights of first refusal or otherwise to the Project Site outstanding in third persons by reason of unrecorded leases, land contracts, sale contracts, options or other documents. (e) No work has been performed or is in progress on or at the Project Site and no materials have been furnished to Agency or the Project Site or any portion thereof which after closing could give rise to any mechanics', materialmen, or other liens, and at the Closing Agency shall furnish to Developer an affidavit attesting to the absence of any such liens or rights to liens. (f) No assessment for public improvements or otherwise have been made against the Project Site which remain unpaid, including without limitation, any special assessments or those for construction of water, sewer, gas and electric lines, nor have any been proposed. 23 Item # 3 Attachment number 1 Page 28 of 89 (g) Except as disclosed in subsection 6.150), below, Agency has no information or knowledge of any change contemplated in the applicable laws, ordinances or restrictions, or any judicial or administrative action, or any action by adjacent land owners or natural or artificial conditions upon the Project Site which would prevent, limit, impede or make more costly the present or proposed use of the Project Site, provided, however, the City is in the process of adopting amendments to the land development code, but, if adopted, it will not adversely affect the proposed use or contemplated development of the Project Site. (h) From and after the date hereof, Agency shall refrain from (1) making any material changes on or about the Project Site; (2) creating and incurring or permitting to exist any mortgage, lien, pledge or other encumbrance in any way affecting the Project Site; or (3) committing any waste or nuisance on the Project Site. (i) From and after the date hereof, and at any time prior to transfer of title to Developer, Agency shall not grant, sell or convey any interest in the Project Site, including easements or rights of way, to any person, corporation (public or private), governmental body or political subdivision without the written permission of Developer. 0) The Agency warrants and represents that, subject to the Groundwater Monitoring (as defined below), it has completed all required environmental remediation of the Project Site in 2004 and remains in compliance with the attendant consent order. The Florida Department of Environmental Protection (FDEP) has approved a Restrictive Covenant Agreement for the Project Site, to reduce or eliminate the risk of exposure of contaminants to the environment and to users or occupants of the Project Site due to groundwater contamination and approved a plan for natural attenuation with monitoring, which will need to include four monitoring wells to show sufficient natural attenuation of the groundwater ("Groundwater Monitoring"). The details of the Groundwater Monitoring are set forth in the Revised Monitor Only Plan, Property B, 901-927 Cleveland Street, Clearwater, Florida, dated March 2004 and Response to Comments, Revised Monitor Only Plan, Dimmit Chevrolet Property B, 901-921 Cleveland Street, Clearwater, Florida, dated May 3,2004, which were approved by FDEP on June 25, 2004. The Agency, at its expense, shall be responsible for the Groundwater Monitoring on the Project Site in accordance with the approved Revised Monitor Only Plan, including without limitation installation of monitoring wells, and Developer shall deliver for recording, at Closing, an easement providing Agency with such access rights as may be required in connection with such Groundwater Monitoring (the "Monitoring Easement')(Exhibit J). In the event the Project Plans and Specifications shall require the relocation of existing groundwater monitoring wells on the Project Site, Agency agrees to relocate no more than two such wells at Agency's sole cost and expense. Agency hereby agrees for itself, its successors and assigns, to at all times indemnify and hold harmless Developer, its successors and assigns, against any and all claims, suits, actions, debts, damages, costs, charges and expenses, including court costs and attorneys' fees, as hereinafter defined, and against all liability, losses and damages of any nature whatsoever, that Developer shall or may at any time sustain or be put to, directly or indirectly, by reason of the contamination of groundwater on the Project Site described in the approved Revised Monitor Only Plan or related to relocation of any groundwater monitoring wells or failure to properly monitor same. Notwithstanding the 24 Item # 3 Attachment number 1 Page 29 of 89 provisions of Article 9 of this Agreement, the indemnification set forth in this Subsection 6.150) shall survive Closing, the Termination Date and the Expiration Date. (k) (1) Compliance with Environmental Law. Agency has: (I) materially complied with all applicable Environmental Law; and (ii) not received any notice of alleged outstanding violation of Environmental Law, nor does Agency have knowledge of any facts or circumstances that could constitute such a violation, other than the Groundwater Monitoring. To the best of Agency's knowledge, there are no Hazardous Substances on, above, within, underneath or in groundwater underlying the Property which exceed applicable standards under any Environmental Law, other than the contaminants described in the Revised Monitor Only Plan. (2) Definitions. For purposes of this Article 7, the terms in this paragraph (2) shall have the following meanings: (i) "Hazardous Substances" means any substance or material: (a) identified in Section 101 of the Comprehensive Environmental Response, Compensation and Liability Act of 1980,42 U.S.C. S9601, as the same may be amended from time to time; or (b) determined to be toxic, a pollutant or contaminant, under Federal, state or local statute, law, ordinance, rule or regulation or judicial or administrative order or decision, as same may be amended from time to time, including but not limited to (i) hazardous wastes as identified pursuant to the Resource Conversation and Recovery Act, 42 U.S.C. S6901, et seq., as the same may be amended from time to time, or (ii) pollutants, petroleum and petroleum products as defined in either Chapter 403 or Chapter 376, Florida Statutes, as the same may be amended from time to time. (ii) "Environmental Law" means any Federal, state or local statutory or common law relating to pollution or protection of the environment, including without limitation, any common law of nuisance or trespass, and any law or regulation relating to em issions, discharges, releases or threatened releases of Hazardous Substances into the environment (including without limitation, ambient air, surface water, groundwater, land surface or subsurface strata) or otherwise relating to the manufacture, processing, distribution, use, treatment, storage, disposal, transport or handling of Hazardous Substances. (I) Other than the Groundwater Monitoring, Agency has no knowledge of any adverse fact relating to the physical condition of the Project Site or any portion thereof which has not been specifically disclosed in writing to Developer, including without limitation landfills, hazardous wastes, fault lines, sinkholes or other geological conditions or adverse soil conditions. (m) Agency has no knowledge that any commitments have been made to any governmental authority, utility company, school board, church or other religious body, homeowners' association, or any other organization, group or individual relating to the Project Site which would impose an obligation upon Developer or its successors or assigns to make any contributions or dedications of money or land or to construct, install 25 Item # 3 Attachment number 1 Page 30 of 89 or maintain any improvements of a public or private nature on or off the Project Site. (n) There are no facts known to Agency materially affecting the value of the Project Site which are not readily observable by Developer or which have not been disclosed to Developer. (0) There exists no violation of any requirement or condition to current zoning or land use classifications applicable to the Project Site. (p) The Project Site is not included in any national, state, county or municipal historic registry or similar classification, nor does the Project Site include any historical or archeological artifacts. (q) The Agency has full power and authority to enter into this Agreement and consummate the transactions contemplated hereby and neither this Agreement nor the consummation of the transactions contemplated hereby will constitute a violation of any order, rule, regulation, agreement or instrument or any charter or organizational documents to which the Agency is subject. No further approvals or consents by third parties or governmental bodies are required in order for the Agency to enter into this Agreement and consummate the transactions contemplated hereby. (r) The covenants, representations and warranties of the Agency as contained herein shall be true and correct as of the Closing and shall survive the Closing of this transaction. 6.16. Condemnation. In the event that prior to the Closing Date, all or any portion of the Project Site or any rights or easements therein shall be taken by condemnation or rights of eminent domain or like process, or shall be threatened therewith, and the same, in Developer's reasonable opinion, would have a materially adverse impact upon Developer's use of the Project Site, Developer shall, within fifteen (15) days after having received notice thereof from Agency, elect in writing to either (a) continue this Agreement in full force and effect, notwithstanding such taking or threatened taking, in which case Developer shall be required to continue the purchase of the Project Site, in which event Agency shall assign or pay to Developer the applicable portion of the proceeds payable under such condemnation proceedings, (b) delete the portion of the Project Site condemned or threatened to be condemned from this Agreement, with a proportionate reduction in the Purchase Price, or (c) terminate this Agreement. 6.17. Real Estate Commission. Developer and Agency represent that they have not used any brokerage services with respect to the conveyance of the Project Site to the Developer as herein contemplated. The Agency and the Developer shall each hold the other harmless and indemnify the other party, its respective successors, assigns, employees, directors and agents from any and all costs, damages, liabilities and expenses, including reasonable attorney's fees, 26 Item # 3 Attachment number 1 Page 31 of 89 incurred by reason of any claim for fee or commission of any kind based on the sale contemplated herein. 6.18. Maintenance of Project Site. Through Closing during its continued position pursuant to FS S7.13, the Agency shall maintain the Project Site in good order and shall carry reasonable amounts of physical damage and liability insurance on the Project Site and any improvements thereon existing as of the date hereof. 6.19. Radon Gas Notice. (a) As required by Section 404.056(6), Florida Statutes, the following notice is hereby given to the Developer as the prospective purchaser of the Project Site, which may have buildings located thereon, and the Developer acknowledges receipt of such notice: "Radon Gas: Radon is a naturally occurring radioactive gas that, when it has accumulated in a building in sufficient quantities, may present health risks to persons who are exposed to it over time. Levels of radon that exceed federal and state guidelines have been found in buildings in Florida. Additional information regarding radon and radon testing may be obtained from your county public health unit." ARTICLE 7. CONSTRUCTION OF THE PROJECT. 7.01. Site Clearance and Utility Relocation. (a) The Developer shall be responsible for clearance of the Project Site such that it is in a condition ready for Commencement of Construction as of the Commencement Date. Permits issued by the City for pre-construction activities on the Project Site, including site clearance, shall not be considered a Building Permit for purposes of this Agreement. (b) To the extent required for construction of the Project, the Developer shall be responsible for relocation on the Project Site of the following City utilities: 310 feet of 8 inch sanitary sewer running north-south between Park Street and Pierce Street; 150 feet of 42 inch storm sewer and 200 feet of 36 inch storm sewer running north-south between Park Street and Pierce Street. Developer shall be responsible for design and permitting of the improvements to City standards. The Agency shall reimburse Developer for the costs of relocating said utilities in an amount not to exceed two hundred and fifty thousand dollars ($250,000). The reimbursement of these utility relocation costs shall be paid from funds legally available to the Agency subject to the limitations contained in S15.17. 7.02. Construction of the Project. (a) The Developer shall construct the Project on the Project Site substantially in accordance with the Project Plans and Specifications. Subject to Unavoidable Delay and the terms and conditions in this Agreement, the Developer shall Commence Construction 27 Item # 3 Attachment number 1 Page 32 of 89 of the Project no later than twenty four (24) months after the approval of this Agreement by the CRA (b) (1) After the Commencement Date and no later than June 19, 2010, the Developer shall commence Vertical Construction of the Project. The Developer shall continue, pursue and prosecute the Vertical Construction of the Project with reasonable diligence to substantial completion by the Completion Date and shall not at any time actually or effectively have abandoned (or its Contractor having actually or effectively abandoned) the Project Site. For purposes of this subsection (b), "abandoned" means to have ceased all construction work, including all or substantially all the construction work force withdrawing from the Project Site for a period of sixty (60) days. (2) All obligations of the Developer with respect to commencement, continuation and completion of construction of the Project shall be subject to delays and extensions from time to time for Unavoidable Delay. The Developer shall not be deemed to be in default of this Agreement to the extent construction or completion of the Project, or any part thereof, is not complete by reason of Unavoidable Delay. (c) For purposes of this Agreement, "completion," "complete," "substantially complete" or "substantial completion" means, that a certificate of occupancy for the shell of the retail portion of the structure (not including any tenant improvements for the retail space) and a Certificate of Occupancy for each residential building has been issued by the City. (d) (1) Commencing on the fifteenth (15th) day of the calendar month following the calendar month in which the Commencement Date occurs and continuing until the Completion Date, the Developer shall make quarterly reports to the Agency in such detail and in such form as may reasonably be requested by the Agency as to the actual progress of the construction of the Project. 2) If the Agency reasonably believes adequate progress in the construction of the Project is not being made, the Agency shall give written notice to the Developer that adequate progress is apparently not being made in the Project and Developer shall have a period of ten (10) business days after receipt of such notice in which to respond to Agency as to why adequate progress is or is not being made toward completion of the Project. (e) (1) The Developer agrees that each contract between the Developer and a Contractor for the Project shall provide, among other things, that: (i) notice shall be given to the Agency of any material defaults thereunder by the Developer or the Contractor; and (ii) in the event of a material breach by the Developer of such contract that is not being contested by the Developer, the Agency shall have the right, but not the obligation, to cure any defaults by the Developer under such contract without penalty to the Agency or stoppage of the work. (2) If the Agency elects to cure a material default by the Developer under a contract between the Developer and a Contractor, upon receipt of a notice to that effect from the Agency, the Developer shall immediately deliver to the Agency all plans, 28 Item # 3 Attachment number 1 Page 33 of 89 specifications, drawings, contracts and addenda thereto pertaining to the construction of that part of the Project which are in its possession or control (and shall instruct the Project Professionals and any other persons in possession or control of such plans, specifications, drawings and contracts to deliver them to the Agency). (3) The right of the Agency to cure any default by the Developer as provided in paragraph (1) above shall be subject and subordinate to the right of the Construction Lender to cure such default. 7.03. Maintenance and Repairs. During the construction of the Project, the Developer shall, at its own expense, keep the Project in good and clean order and condition and the Developer shall promptly make all necessary or appropriate repairs, replacements and renewals thereof, whether ordinary or extraordinary, foreseen or unforeseen. All repairs, replacements and renewals shall be equal in quality and class to the original work. When making such repairs, replacements or renewals, the Developer shall comply with all applicable laws, ordinances, codes and regulations. 7.04. Project Alterations or Improvements. During the construction of the Project, the Developer may, from time to time, make alterations and improvements, structural or otherwise, to the Project as the Developer deems desirable and consistent with the Project Plans and Specifications for the uses contemplated by this Agreement; provided, however, that prior to the commencement of any material alterations or improvements of sufficient size and scope as to constitute a material change in the previously approved Project Plans and Specifications, the Developer shall notify the Agency of such material change and shall submit a change, amendment or revision to the Project Plans and Specifications to the Agency for review as provided in Sections 4.03 and 4.04 hereof. Nothing in this Section 7.04 is intended nor shall be deemed to limit or restrict the exercise of governmental or regulatory powers or authority by the City or any other governmental entity or to enlarge its regulatory authority. 7.05. Completion Certificate. (a) (1) Upon the substantial completion of the construction of the Project in accordance with the provisions of this Article 7 (particularly including subsection 7.02(c)), the Developer shall prepare and execute the Completion Certificate, which shall then be delivered to the Agency. Upon receipt of the Completion Certificate the Agency shall promptly and diligently proceed to determine if construction has been completed substantially in accordance with the Project Plans and Specifications and this Agreement. Upon making such a determination the Agency shall execute the Completion Certificate and return it to the Developer. The date of the Completion Certificate shall be the date when the last of the parties shall have executed the Completion Certificate. (2) The Completion Certificate shall constitute a conclusive determination by the parties hereto of the satisfaction and termination of the obligations of the Developer hereunder to construct the Project; provided, however, that nothing in this Section 7.05 shall be a waiver of the rights, duties, obligations or responsibilities of the City or any other governmental entity acting in its regulatory or governmental capacity or an approval 29 Item # 3 Attachment number 1 Page 34 of 89 of said construction for purposes of the issuance of a certificate of occupancy for the Project. (3) The parties agree that it is their intent that the review by the Agency for purposes of the Completion Certificate determination pursuant to this Section 7.05 is not to be an additional or duplicate inspection over and above that required for purposes of the Building Permit, including the issuance of a certificate of occupancy. The Agency agrees that for purposes of determining if the Project has been substantially completed in accordance with the Project Plans and Specifications, the issuance of a certificate of occupancy shall be a conclusive determination of substantial completion for purposes of this subsection (a) and, if such certificate of occupancy has been determined to have been issued, then the Agency agrees to execute the Completion Certificate. (b) If the Agency shall refuse or fail to execute the Completion Certificate after receipt of a request by the Developer to do so, then the Agency shall, within ten (10) days after its receipt of such request, provide the Developer with a written statement setting forth in reasonable detail the reason(s) why the Agency has not executed the Completion Certificate and what must be done by the Developer to satisfy such objections so that the Agency would sign the Completion Certificate. Upon the Developer satisfying the Agency's objections, then the Developer shall submit a new request to the Agency for execution of the Completion Certificate and that request shall be considered and acted upon in accordance with the procedures in paragraph (a)(1) for the original request. (c) The Completion Certificate shall be in a form sufficient to be recorded in the public records of Pinellas County, Florida. After execution by the Agency, it shall be promptly returned to the Developer who shall record the Completion Certificate in the public records of Pinellas County, Florida, and pay the cost of such recording. 7.06. Agency Not in Privity with Contractors. The Agency shall not be deemed to be in privity of contract with any Contractor or provider of goods or services with respect to the construction of the Project. 7.07. Repurchase of the Project Site. (a) In the event Developer does not Commence Construction and commence Vertical Construction of the Project in accordance with the Project Schedule set forth in Sections 4.05 and 7.02 hereof, Agency shall have an option to purchase the Project Site upon the terms and conditions as set forth in this Section 7.07 (the "Property Option"). The Property Option shall be exercised by Agency within ninety (90) days following the date on which Developer was required to Commence Construction or commence Vertical Construction. The Property Option shall be exercised by Agency providing written notice to Developer of its intent to exercise the Property Option within said ninety (90) day period (time being of the essence with respect to such notice); provided, however, that Agency shall not have the right to exercise such Property Option in the event Developer cures its failure to Commence Construction or commence Vertical Construction within thirty (30) days following its receipt of such written notice. In the event that Agency should fail to provide such written notice of its exercise of the Property Option within said ninety (90) 30 Item # 3 Attachment number 1 Page 35 of 89 day period, then the Property Option shall immediately and automatically lapse. (b) Upon proper and timely exercise of the Property Option, Agency and Developer shall undertake to close the conveyance of the Project Site by Developer to Agency within sixty (60) days following the date of notice of the exercise of the Property Option upon the following terms and conditions: (1) The price to be paid by Agency to Developer for the Project Site shall equal the Purchase Price paid by Developer to Agency at Closing. (2) The Project Site shall be conveyed by Developer to Agency pursuant to a special warranty deed, which deed shall be subject to taxes for the year of Closing and the other Permitted Exceptions to which the Project Site was subject on the Closing Date. (3) Developer shall pay for the cost of any documentary stamp taxes imposed upon the deed conveying the Project Site from Developer to Agency. In addition, Developer shall pay for any surveyor title insurance Agency elects to obtain in connection with such conveyance. (c) Until the commencement of Vertical Construction by the Developer on the Project Site or the expiration of the date by which such Vertical Construction was to commence plus the ninety (90) day period during which the Agency may exercise the Property Option, the Developer covenants and agrees with the Agency that Developer shall not, without the prior consent of the Agency, cause any mortgage or lien to be levied, assessed or placed on the Project Site with respect to any financing of Developer's construction of the Project; provided, however, that Agency shall not have a right to consent to any mortgage or lien so long as such mortgage or lien is subordinate to Agency's Property Option. Upon the commencement of Vertical Construction by Developer in accordance with the Project Schedule, the Agency shall, within five (5) days of Developer's request, execute and deliver to Developer, in recordable form, a termination of the Agency's Property Option. (d) Upon conveyance of the Project Site to the Agency pursuant to the exercise of the Property Option, this Agreement shall terminate as provided in Section 12.05. (e) The Property Option shall survive a termination of this Agreement by the Developer pursuant to Section 12.05. ARTICLE 8. INSURANCE. 8.01. Insurance Requirements Generally. (a) The Developer agrees to purchase and maintain in full force and effect such insurance policies with coverages generally applicable to projects in the State of Florida and Pinellas County similar in size and scope to the Project. All insurance shall be obtained from financially responsible insurance companies either duly authorized under the laws of the State of Florida to do insurance business in the State of Florida (or subject 31 Item # 3 Attachment number 1 Page 36 of 89 to legal process in the State of Florida) and shall be issued and countersigned by duly authorized representatives of such companies for the State of Florida. (b) The insurance coverages and limits shall be evidenced by properly executed certificates of insurance, copies of which shall be provided to the Agency during the term of this Agreement. No less than thirty (30) days written notice by registered or certified mail must be given by the Developer to the Agency of any cancellation, intent not to renew, or reduction in the policy coverages. (c) Nothing in this Agreement is intended or shall be deemed to be designed by the Agency as a recommended insurance program for the Developer. (d) (1) The Developer alone shall be responsible for the sufficiency of its own insurance program. The Agency will in no way be responsible to the Developer or any other party for any inadequacy of the Developer's overall insurance program. (2) The Agency shall be responsible for the sufficiency of its insurance program. The Developer will in no way be responsible to the Agency or any other party for any inadequacy of the Agency's overall insurance program. 8.02. Insurance Exclusive of Indemnity. The insurance policies and coverages of the Developer contemplated by this Article 8 are exclusive of, and in addition to, any and all indemnity obligations of the Developer and the Agency under this Agreement. 8.03. No Waiver of Sovereign Immunity. Nothing in this Article 8 is intended or shall be deemed to constitute a waiver in whole or in part of any sovereign immunity applicable to and that may be asserted by the City or the Agency. ARTICLE 9. INDEMNIFICATION. 9.01. Indemnification by the Developer. (a) For consideration of $10.00 and other good and valuable consideration herein provided, the receipt of which is hereby acknowledged by the Developer, the Developer agrees to indemnify, defend and hold harmless, the Agency, its respective agents, officers, or employees from any and all liabilities, damages, penalties, judgments, claims, demands, costs, losses, expenses or attorneys' fees through appellate proceedings, for personal injury, bodily injury, death or property damage arising out of, or by reason of any act or omission of the Developer, its agents, employees or contractors arising out of, in connection with or by reason of, the performance of any and all services contemplated by this Agreement, or which are alleged to have arisen out of, in connection with or by reason of, the performance of any and all services contemplated by this Agreement, or which are alleged to have arisen out of, in connection with, or by reason of, the performance of such services. (b) The Developer's indemnity obligations under subsection (a) shall survive the earlier of the Termination Date or the Expiration Date, but shall apply only to occurrences, 32 Item # 3 Attachment number 1 Page 37 of 89 acts, or omissions that arise on or before the earlier of the Termination Date or the Expiration Date. (c) The Developer's indemnity hereunder is in addition to and not limited by any insurance policy and is not and shall not be interpreted as an insuring agreement between or among the parties to this Agreement, nor as a waiver of sovereign immunity for any party entitled to assert the defense of sovereign immunity. 9.02. Indemnification by the Agency. (a) To the extent permitted by law, specifically including Section 768.28, Florida Statutes, and any insurance coverage available to the Agency, the Agency agrees to indemnify, defend and hold harmless, the Developer, its respective, officers, and employees from any and all liabilities, damages, penalties, judgments, claims, demands, costs, losses, expenses or attorneys' fees through appellate proceedings, for personal injury, bodily injury, death or property damage arising out of, or by reason of, any act or omission of the Agency, its respective agents or employees arising out of, in connection with or by reason of, the performance of any and all obligations of the Agency contemplated by this Agreement, or which are alleged to have arisen out of, in connection with or by reason of, the performance of any and all obligations of the Agency contemplated by this Agreement, or which are alleged to have arisen out of, in connection with, or by reason of, the performance of such obligations. (b) To the extent permitted by law, specifically including Section 768.28, Florida Statutes, and any insurance coverage available to the Agency, the Agency shall indemnify, defend and hold harmless the Developer, its officers and employees from any and all liabilities, damages, costs, penalties, judgments, claims, demands, losses, or expenses (including, but not limited to, actual attorneys' fees and engineering fees) arising from or attributable to any breach by the Agency, as the case may be, of any covenants, representations or warranties contained in Section 3.02, Section 3.05, Section 6.15 or Section 11.01, or covenants contained in Section 11.02. (c) The Agency's indemnity obligations under this Section 9.02 shall survive the earlier of the Termination Date or the Expiration Date, but shall only apply to occurrences, acts or omissions that arise on or before the earlier of the Termination Date or the Expiration Date. The Agency's indemnity hereunder is not and shall not be interpreted as an insuring agreement between or among the parties to this Agreement, but is in addition to and not limited by any insurance policy provided that said obligation shall not be greater than that permitted and shall be limited by the provisions of Section 768.28, Florida Statutes, or any successor statute thereto. 9.03. Limitation of Indemnification. Notwithstanding anything to the contrary contained herein, with respect to the indemnification obligations of the Developer (as set forth in Section 9.01) and the Agency (as set forth in Section 9.02), the following shall apply: 33 Item # 3 Attachment number 1 Page 38 of 89 (a) the indemnifying party shall not be responsible for damages that could have been, but were not, mitigated by the indemnified party; (b) the indemnifying party shall not be responsible for that portion of any damages caused by the negligent or willful acts or omissions of, or the breach of any representations or warranties contained herein by, the indemnified party; and (c) there shall be no obligation to indemnify hereunder in the event that the indemnified party (1) shall have effected a settlement of any claim without the prior written consent of the indemnifying party, or (2) shall not have subrogated the indemnifying party to the indemnified party's rights against any third party by an assignment to the indemnifying party of any cause or action against such third party. ARTICLE 10. REPRESENTATIONS, WARRANTIES AND COVENANTS OF THE DEVELOPER. 10.01. Representations and Warranties. The Developer represents and warrants to the Agency that each of the following statements is currently true and accurate and agrees the Agency may rely upon each of the following statements: (a) The Developer is a Georgia Limited Liability Company duly organized and validly existing under the laws of the State of Georgia, has all requisite power and authority to carry on its business as now conducted, to own or hold its properties and to enter into and perform its obligations hereunder and under each document or instrument contemplated by this Agreement to which it is or will be a party, is qualified to do business in the State of Florida, and has consented to service of process upon a designated agent for service of process in the State of Florida. (b) This Agreement and, to the extent such documents presently exist in form accepted by the Agency and the Developer, each document contemplated or required by this Agreement to which Developer is or will be a party have been duly authorized by all necessary action on the part of, and have been or will be duly executed and delivered by, the Developer, and neither the execution and delivery thereof, nor compliance with the terms and provisions thereof or hereof: (1) requires the approval and consent of any other party, except such as have been duly obtained or as are specifically noted herein, (2) contravenes any existing law, judgment, governmental rule, regulation or order applicable to or binding on the Developer, (3) contravenes or results in any breach of, default under or, other than as contemplated by this Agreement, results in the creation of any lien or encumbrance upon any property of the Developer under any indenture, mortgage, deed of trust, bank loan or credit agreement, the Developer's articles of organization, or, any other agreement or instrument to which the Developer is a party or by which the Developer may be bound. (c) This Agreement and, to the extent such documents presently exist in form accepted by the Agency and the Developer, each document contemplated or required by this Agreement to which the Developer is or will be a party constitutes, or when entered into will constitute, a legal, valid and binding obligation of the Developer enforceable 34 Item # 3 Attachment number 1 Page 39 of 89 against the Developer in accordance with the terms thereof, except as such enforceability may be limited by applicable bankruptcy, insolvency or similar laws from time to time in effect which affect creditors' rights generally and subject to usual equitable principles in the event that equitable remedies are involved. (d) There are no pending or, to the knowledge of the Developer, threatened actions or proceedings before any court or administrative agency against the Developer, or against any controlling shareholder, officer, employee or agent of the Developer, which question the validity of this Agreement or any document contemplated hereunder, or which are likely in any case, or in the aggregate, to materially adversely affect the consummation of the transactions contemplated hereunder or the financial condition of the Developer. (e) The Developer has filed or caused to be filed all federal, state, local and foreign tax returns, if any, which were required to be filed by the Developer, and has paid, or caused to be paid, all taxes shown to be due and payable on such returns or on any assessments levied against the Developer. (f) All financial information and other documentation, including that pertaining to the Project or the Developer, delivered by the Developer to the City and the Agency, was, on the date of delivery thereof, true and correct. (g) The principal place of business and principal executive offices of the Developer are in Atlanta, Georgia, and, until the expiration or termination of this Agreement, the Developer will keep original or duplicate records concerning the Project (such as construction contracts, financing documents and corporate documents) and all contracts, licenses and sim ilar rights relating thereto at its office located in Atlanta, Georgia, copies of which shall be made available to Agency upon 24 hours' written notice. (h) As of the Closing Date, the Developer will have the financial capability to carry out its obligations and responsibilities in connection with the development of the Project as contemplated by this Agreement, including the purchase of the Project Site from the Agency as contemplated by Article 6. (i) The Developer (with the assistance of its Project Professionals) has the experience, expertise, and capability to develop, cause the construction, and complete the Project and, oversee and manage the design, planning, construction, and completion of the Project, and to acquire the Project Site as provided herein. 10.02. Covenants. The Developer covenants with the Agency that until the earlier of the Termination Date or the Expiration Date: (a) The Developer shall timely perform or cause to be performed all of the obligations contained herein which are the responsibility of the Developer to perform. (b) During each year this Agreement and the obligations of the Developer under this Agreement shall be in effect, the Developer shall cause to be executed and to continue to be in effect those instruments, documents, certificates, permits, licenses and approvals 35 Item # 3 Attachment number 1 Page 40 of 89 and shall cause to occur those events contemplated by this Agreement that are applicable to, and that are the responsibility of, the Developer. (c) The Developer shall assist and cooperate with the Agency to accomplish the development of the Project by the Developer in accordance with this Agreement, and the Project Plans and Specifications and will not violate any laws, ordinances, rules, regulations, orders, contracts or agreements that are or will be applicable thereto, including the Plan and the Act. (d) The Developer shall comply with all provisions of the financing documents for any Construction Financing. (e) Subsequent to the Effective Date, the Developer shall maintain its financial capability to develop, construct and complete the Project and shall promptly notify the Agency of any event, condition, occurrence, or change in its financial condition which materially adversely affects, or with the passage of time is likely to adversely affect, the Developer's financial capability to successfully and completely develop, construct and complete the Project as contemplated hereby. (f) The Developer shall promptly cause to be filed when due all federal, state, local and foreign tax returns required to be filed by it, and shall promptly pay when due any tax required thereby so as to avoid an uncured tax lien against the Project Site. (g) Subject to and except as permitted by Section 16.01, prior to the expiration or termination of this Agreement, the Developer shall maintain its existence, will not dissolve or substantially dissolve all of its assets and will not consolidate with or merge into another corporation, limited partnership, or other entity without the prior approval of the Agency, unless the Developer is the surviving entity or retains a controlling interest in the consolidated or merged corporation, in which case no consent by Agency shall be required. In any event, prior to the expiration or termination of this Agreement, the Developer, will promptly notify the Agency of any changes to the existence or form of the limited liability company of Developer. (h) The Developer shall not sell, lease, transfer or otherwise dispose of all or substantially all its assets without adequate consideration and will otherwise take no action which shall have the effect, singularly or in the aggregate, of rendering Developer unable to continue to observe and perform the covenants, agreements, and conditions hereof and the performance of all other obligations required by this Agreement. (i) Except for the removal of any structures, plants, items or other things from the Project Site after the Closing Date necessary for construction of the Project to commence and continue, the Developer shall not permit, commit, or suffer any waste or impairment of the Project Site prior to the earlier of the Termination Date or the Expiration Date. 0) Provided all conditions precedent thereto have been satisfied or waived as provided herein, the Developer shall design, construct and complete the Project such that it is substantially complete as set forth in Section 4.05 of this Agreement. 36 Item # 3 Attachment number 1 Page 41 of 89 10.03 Covenant. Nondiscrimination. The Developer covenants by and for itself and any successors in interest that there shall be no discrimination against or segregation of any person or group of persons on account of race, color, creed, religion, sex, marital status, ancestry or national origin in the marketing, sale, lease, sublease, transfer, use, occupancy, tenure or enjoyment of the Site, nor shall the Developer itself or any person claiming under or through it establish or permit any such practice or practices of discrimination or segregation with reference to the selection, location, number, use or occupancy of tenants, lessees, subtenants, sub lessees or vendees of the Site. 10.04. Survival The representations, warranties and covenants of Developer as contained in Section 10.01 and 10.02 hereof shall survive the conveyance of the Project Site to the Developer by the Agency. The representations, warranties and covenants of Developer as contained in Section 10.03 hereof shall survive the conveyance of the Project Site to the Developer by the Agency and Termination or Expiration. ARTICLE 11. REPRESENTATIONS, WARRANTIES AND COVENANTS OF THE AGENCY. 11.01. Representations and Warranties. The Agency represents and warrants to the Developer that each of the following statements is currently true and accurate and agrees that the Developer may rely on each of the following statements: (a) The Agency is a validly existing body corporate and politic of the State of Florida, is the duly created community redevelopment agency of the City under Part III, Chapter 163, Florida Statutes (known as the Community Redevelopment Act of 1969), has all requisite corporate power and authority to carry on its business as now conducted and to perform its obligations hereunder and under each document or instrument contemplated by this Agreement to which it is or will be a party. (b) This Agreement and, to the extent such documents presently exist in form accepted by the Agency and the Developer, each document contemplated or required by this Agreement to which the Agency is or will be a party have been duly authorized by all necessary action on the part of, and have been or will be duly executed and delivered by, the Agency, and neither the execution and delivery thereof, nor compliance with the terms and provisions thereof or hereof (1) requires the approval and consent of any other party, except such as have been duly obtained or as are specifically noted herein, (2) contravenes any existing law, judgment, governmental rule, regulation or order applicable to or binding on the Agency, (3) contravenes or results in any breach of, or default under or, other than as contemplated by this Agreement, results in the creation of any lien or encumbrance upon any property of the Agency under any indenture, mortgage, deed of trust, bank loan or credit agreement, applicable ordinances, resolutions or, on the date of this Agreement, any other agreement or instrument to which the Agency is a party, specifically including any covenants of any bonds, notes, or other forms of indebtedness of the Agency outstanding on the Effective Date. (c) This Agreement and, to the extent such documents presently exist In form 37 Item # 3 Attachment number 1 Page 42 of 89 accepted by the Agency and the Developer, each document contemplated or required by this Agreement to which the Agency is or will be a party constitute, or when entered into will constitute, legal, valid and binding obligations of the Agency enforceable against the Agency in accordance with the terms thereof, except as such enforceability may be limited by public policy or applicable bankruptcy, insolvency or similar laws from time to time in effect which affect creditors' rights generally and subject to usual equitable principles in the event that equitable remedies are involved. (d) There are no pending or threatened actions or proceedings before any court or administrative agency against the Agency, or against any officer of the Agency, which question the validity of any document contemplated hereunder, or which are likely in any case, or in the aggregate, to materially adversely affect the consummation of the transactions contemplated hereunder or the financial condition of the Agency. (e) Section 768.28, Florida Statutes, is the only statutory limitation on the Agency's indemnification obligations under this Agreement, and furthermore the Agency's indemnity obligations hereunder are not restricted by anything in its bylaws or in Part III, Chapter 163, Florida Statutes. 11.02. Covenants. The Agency covenants with the Developer that until the earlier of the Termination Date or the Expiration Date: (a) The Agency shall timely perform or cause to be performed all of the obligations contained herein which are the responsibility of the Agency to perform. (b) During each year that this Agreement and the obligations of the Agency under this Agreement shall be in effect, the Agency shall cause to be executed and to continue to be in effect those instruments, documents, certificates, permits, licenses and approvals, and shall cause to occur those events contemplated by this Agreement that are applicable to and are the responsibility of the Agency. (c) The Agency shall assist and cooperate with the Developer to accomplish the development of the Project in accordance with this Agreement and the Project Plans and Specifications, will carry out its duties and responsibilities contemplated by this Agreement, and will not violate any laws, ordinances, rules, regulations, orders, contracts, or agreements that are or will be applicable thereto, and, to the extent permitted by law, the Agency will not enact or adopt or urge or encourage the adoption of any ordinances, resolutions, rules, regulations or orders or approve or enter into any contracts or agreements, including issuing any bonds, notes, or other forms of indebtedness, that will result in any provision of this Agreement to be in violation thereof. (d) The Agency shall not request or recommend any rezoning of the Project Site, or any part thereof, which will prevent or adversely affect the development of the Project. (e) The Agency to the best of its ability, shall maintain its financial capability to carry out its responsibilities as contemplated by this Agreement and shall notify the Developer of any event, condition, occurrence, or change in its financial condition that adversely 38 Item # 3 Attachment number 1 Page 43 of 89 affects, or with the passage of time is likely to adversely affect, the Agency's financial capability to carry out its responsibilities contemplated hereby. 11.03. Survival. The representations, warranties and covenants of Agency as contained in Section 11.01 and 11.02 hereof shall survive the conveyance of the Project Site to the Developer by the Agency. ARTICLE 12. DEFAULT; TERMINATION. 12.01. Default by Developer. (a) Provided the Agency is not then in default of this Agreement under Section 12.02 hereof, the occurrence of anyone or more of the following after the Effective Date shall constitute an event of default by Developer ("Developer Event of Default"): (1) The Developer shall fail to perform or comply with any material provision of this Agreement applicable to it within the time prescribed therefor; provided, however, that suspension of or delay in performance by the Developer during any period in which the Agency is in default of this Agreement as provided in Section 12.02 hereof will not constitute an event of default by the Developer under this subsection (a); or (2) The Developer shall make a general assignment for the benefit of its creditors, or shall admit in writing its inability to pay its debts as they become due or shall file a petition in bankruptcy, or shall be adjudicated a bankrupt or insolvent, or shall file a petition seeking any reorganization, arrangement, composition, readjustment, liquidation, dissolution or similar relief under any present or future statute, law or regulation or shall file an answer admitting, or shall fail reasonably to contest, the material allegations of a petition filed against it in any such proceeding, or shall seek or consent to or acquiesce in the appointment of any trustee, receiver or liquidator of the Developer or any material part of such entity's properties; or (3) Within sixty (60) days after the commencement of any proceeding by or against the Developer seeking any reorganization, arrangement, composition, readjustment, liquidation, dissolution or similar relief under any present or future statute, law or regulation, such proceeding shall not have been dismissed or otherwise terminated, or if, within sixty (60) days after the appointment without the consent or acquiescence of the Developer of any trustee, receiver or liquidator of any of such entities or of any material part of any of such entity's properties, such appointment shall not have been vacated. (b) (1) If a Developer Event of Default shall remain uncured thirty (30) days after written notice thereof to the Developer, then, in addition to any remedy available under Section 12.03, the Agency may terminate this Agreement or pursue any and all legal or equitable remedies to which the Agency is entitled. In the event the Developer has commenced to cure the Developer Event of Default but it is of such nature that it cannot be completely cured within thirty (30) days, then Developer shall have such reasonable additional time as is necessary to cure the Developer Event of Default provided that the 39 Item # 3 Attachment number 1 Page 44 of 89 entire cure period shall not exceed ninety (90) days after Developer's initial receipt of notice of the Developer Event of Default. Notwithstanding any provision in this Agreement to the contrary, if a Developer Event of Default shall occur prior to Closing, Agency's sole and exclusive remedy shall be to terminate this Agreement and retain the Deposit as agreed upon liquidated damages and in full settlement of all claims. (2) Any time periods or deadlines provided in this Agreement shall be tolled or extended by the amount of time to cure any Developer Event of Default hereunder if such event affects the Agency's ability to perform by such deadline or the expiration of such period. (c) Subject to the rights of the Construction Lender, any Contractor, creditors of the Developer, and others claiming a legal or equitable interest in the Project, or a portion thereof, if the Agency elects under Section 5.05 to cure a Developer Event of Default and complete the construction of the Project, all plans and specifications, working drawings, construction contracts, contract documents, Building Permits, Permits, management agreements, and financial commitments (all only to the extent assignable) with respect to the Project shall, if such default has not been previously cured, on the day following receipt by the Developer of notice from the Agency of its election to cure under Section 5.05, be deemed then assigned to the Agency making said election, without necessity of any other action being taken or not taken by any party hereto. The Developer shall transfer and deliver to the Agency upon making said election, all assignable Project Plans and Specifications, working drawings, construction contracts, contract documents, financial commitments, management agreements, and all Permits. 12.02. Default by the Agency. (a) Provided the Developer is not then in default under Section 12.01, there shall be an "Agency Event of Default" under this Agreement in the event the Agency shall fail to perform or comply with any material provision of this Agreement applicable to it; provided, however, that suspension of or delay in performance by the Agency during any period in which the Developer is in default of this Agreement as provided in Section 12.01 hereof will not constitute an Agency Event of Default under this subsection (a). (b) If an Agency Event of Default described in subsection (a) shall occur, the Developer shall provide written notice thereof to the Agency, and, after expiration of the curative period described in paragraph (2) below, may terminate this Agreement, institute an action to compel specific performance of the terms hereof by the Agency or pursue any and all legal or equitable remedies to which the Developer is entitled; provided, however, if the Agency Event of Default occurs on or prior to the Closing Date, any monetary recovery by the Developer in any such action shall not include any lost profits or consequential damages and shall be limited to bona fide third-party out-of-pocket costs and expenses, including reasonable attorneys' fees, incurred by the Developer in connection with the negotiation of this Agreement as well as any investigation, due diligence, development, design or construction costs incurred by the Developer in connection with the proposed acquisition and development of the Project Site, unless any such Agency Event of Default was willful and committed in bad faith with reckless 40 Item # 3 Attachment number 1 Page 45 of 89 disregard for the rights of the Developer. Additionally, if the Agency Event of Default occurs prior to the Closing Date, Developer shall be entitled to return of the deposit provided in section 6.03. (c) The Developer may not terminate this Agreement or institute an action described in paragraphs (a) or (b) above if the Agency cures such Agency Event of Default within thirty (30) days after receipt by the Agency of written notice from the Developer specifying in reasonable detail the Agency Event of Default, or if any such Agency Event of Default is of such nature that it cannot be completely cured within such period, then within such reasonably longer period of time as may be necessary to cure such Agency Event of Default. If the Agency is proceeding diligently and in good faith to cure such Agency Event of Default, the curative period shall be extended for a period of not exceeding an additional thirty (30) days without any approval or consent of the Developer being required, but such approval will be required (and shall be given or withheld in Developer's sole discretion) if the curative period is to be extended beyond the aggregate of sixty (60) days after the notice of such Agency Event of Default has been given by the Developer to the Agency. If the Agency shall fail to cure such Agency Event of Default within said thirty (30) day or longer period (as extended above) or ceases to proceed diligently to timely cure such Agency Event Default, then the Developer may proceed with its available remedies without providing any additional notice to the Agency. (d) Any time periods or deadlines provided in this Agreement shall be tolled or extended by the amount of time to cure any Agency Event of Default hereunder if such event affects the Developer's ability to perform by such deadline or the expiration of such period. 12.03. Obligations, Rights and Remedies Cumulative. Unless specifically stated herein to the contrary, the specified rights and remedies to which either the Agency or the Developer are entitled under this Agreement are not exclusive and are intended to be in addition to any other remedies or means of redress to which the Agency or the Developer may lawfully be entitled and are not specifically prohibited by this Agreement. The suspension of, or delay in, the performance of its obligations by the Developer, while the Agency shall at such time be in default of their obligations hereunder shall not be deemed to be a Developer Event of Default. The suspension of, or delay in, the performance of the obligations by the Agency while the Developer shall at such time be in default of its obligations hereunder shall not be deemed to be an Agency Event of Default. 12.04. Non-Action on Failure to Observe Provisions of this Agreement. The failure of the Agency or the Developer to promptly or continually insist upon strict performance of any term, covenant, condition or provision of this Agreement, or any Exhibit hereto, or any other agreement, instrument or document of whatever form or nature contemplated hereby shall not be deemed a waiver of any right or remedy that the Agency or the Developer may have, and shall not be deemed a waiver of a subsequent default or nonperformance of such term, covenant, condition or provision. 12.05. Termination. 41 Item # 3 Attachment number 1 Page 46 of 89 (a) The Developer and the Agency acknowledge and agree that as of the Effective Date certain matters mutually agreed by the parties hereto are essential to the successful development of the Project have not been satisfied or are subject to certain conditions, legal requirements or approvals beyond the control of any of the parties hereto or which cannot be definitely resolved under this Agreement. In recognition of these events or conditions, the parties hereto mutually agree that, provided the appropriate or responsible party therefor diligently and in good faith seeks to the fullest extent of its capabilities to cause such event or condition to occur or be satisfied, the failure of the events or conditions listed in subsection (b) below to occur or be satisfied shall not constitute an event of default by any party under this Article 12, but may be the basis for a termination of this Agreement as provided in this Section 12.05. (b) In addition to any other rights of termination provided elsewhere in this Agreement, this Agreement may be terminated prior to the Closing Date as provided in subsection (c) after the occurrence of any of the following events or conditions: (1) Failure to satisfy the Conditions to Closing set forth in Section 6.09. (2) All of the Project Site is taken by the exercise of the power of eminent domain by a governmental authority (except the City or the Agency) or a person entitled to exercise such power or benefiting therefrom, or such part of the Project Site is taken by the power of eminent domain so as to render the Project, in Developer's sole discretion, commercially unfeasible or unusable for its intended uses as contemplated by this Agreement; (3) The appropriate governmental authority (but not including the City in exercise of its governmental and regulatory authority and responsibility), upon petition by the Developer, unduly delays or denies or fails to issue the Permits, issue the Building Permits, or approve any other land use approval necessary to Commence Construction of the Project on the Project Site; (4) A moratorium on new construction is imposed by a governmental authority within the City or Pinellas County so as to prevent construction of the Project to commence; (5) The City or other appropriate governmental authority has issued a concurrency compliance certificate or a reservation of services capacity as described in Section 3.05 and such certificate or reservation has been revoked, repealed, superseded, or otherwise no longer of any effect or the Developer is unable to rely upon such certificate or reservation, if such a certificate or reservation is required for development of the Project on the Project Site, and the Developer cannot obtain a new or replacement certificate or reservation for the Project; (6) The City approves an amendment to the Plan, which is inconsistent with the Project being located on the Project Site. (7) Utilities are not readily available at the boundaries of the Project Site at 42 Item # 3 Attachment number 1 Page 47 of 89 locations satisfactory to the Developer by the Closing Date. (c) In the event of a termination pursuant to Section 12.05(b), neither the Developer nor the Agency shall be obligated or liable one to the other in any way, financially or otherwise, for any claim or matter arising from or as a result of this Agreement or any actions taken by the Developer and the Agency, or any of them, hereunder or contemplated hereby, and each party shall be responsible for its own costs, excluding provisions of this Agreement which specifically survive the termination of this Agreement. (d) Notwithstanding anything to the contrary contained herein, in the event that any party shall have, but shall not exercise, the right hereunder to terminate this Agreement because of the non-satisfaction of any condition specified herein, and such condition is subsequently satisfied, then the non-satisfaction of such condition shall no longer be the basis for termination of this Agreement. 12.06. Termination Certificate. (a) In the event of a termination of this Agreement for any reason prior to the Expiration Date, each of the parties hereto do covenant and agree with each other to promptly execute a certificate prepared by the party electing to terminate this Agreement, which certificate shall expressly state that this Agreement has been terminated in accordance with its terms, is no longer of any force and effect except for those provisions hereof which expressly survive termination, that the rights, duties and obligations of the parties hereto have been terminated and released (subject to those surviving provisions hereof) and that the Project Site is no longer subject to any restrictions, limitations or encumbrances imposed by this Agreement. (b) The certificate described in subsection (a) shall be prepared in a form suitable for recording and promptly after execution by all of the parties hereto shall be recorded in the public records of Pinellas County, Florida. The cost of recording the termination certificate shall be paid by the terminating party. 12 07 Remedies' All remedies provided for herein and under Florida law shall be cumulative and shall survive the technical termination of this Agreement pursuant to execution, delivery and recordation of a Termination Certificate or otherwise hereunder. ARTICLE 13. UNAVOIDABLE DELAY. 13.01. Unavoidable Delay. (a) Any delay in performance of or inability to perform any obligation under this Agreement (other than an obligation to pay money) due to any event or condition described in paragraph (2) as an event of "Unavoidable Delay" shall be excused in the manner provided in this Section 13.01. 43 Item # 3 Attachment number 1 Page 48 of 89 (b) "Unavoidable Delay" means any of the following events or conditions or any combination thereof: acts of God, acts of the public enemy, riot, insurrection, war, pestilence, archaeological excavations required by law, unavailability of materials after timely ordering of same, epidemics, quarantine restrictions, freight embargoes, fire, lightning, hurricanes, earthquakes, tornadoes, floods, extremely abnormal and excessively inclement weather (as indicated by the records of the local weather bureau for a five-year period preceding the Effective Date), strikes or labor disturbances, delays due to proceedings under Chapters 73 and 74, Florida Statutes, restoration in connection with any of the foregoing or any other cause beyond the reasonable control of the party performing the obligation in question, including, without limitation, such causes as may arise from the act of the other party to this Agreement, or acts of any governmental authority (except that acts of the Agency shall not constitute an Unavoidable Delay with respect to performance by the Agency). (c) An application by any party hereto (referred to in this paragraph (c) and in paragraph (d) as the "Applicant") for an extension of time pursuant to subsection (a) must be in writing, must set forth in detail the reasons and causes of delay, and must be filed with the other party to this Agreement within thirty (30) days following the occurrence of the event or condition causing the Unavoidable Delay or thirty (30) days following the Applicant becoming aware (or with the exercise of reasonable diligence should have become aware) of such occurrence. (d) The Applicant shall be entitled to an extension of time for an Unavoidable Delay only for the number of days of delay due solely to the occurrence of the event or condition causing such Unavoidable Delay and only to the extent that any such occurrence actually delays that party from proceeding with its rights, duties and obligations under this Agreement affected by such occurrence. ARTICLE 14. FIRE OR OTHER CASUAL TV; CONDEMNATION. 14.01. Loss or Damage to Project. If economically reasonable as determined by Developer, the Developer covenants and agrees to diligently commence and complete the reconstruction or repair of any loss or damage caused by fire or other casualty or by eminent domain (provided the City or the Agency is not the condemning authority) to each and every part of the Project to substantially the same as existed prior to the occurrence of such loss or damage. Any reconstruction or repair of any loss or damage to the Project shall be to the standards, design, plans and specifications of the original construction unless any change therefrom is approved by the Agency. 14.02. Partial Loss or Damage to Project. Any loss or damage by fire or other casualty or exercise of eminent domain to the Project or Project Site, or any portion thereof, which does not render the Project or Project Site reasonably unusable for the use contemplated by this Agreement, shall not operate to terminate this Agreement or to relieve or discharge the Developer from the timely performance and fulfillment of the Developer's 44 Item # 3 Attachment number 1 Page 49 of 89 obligations pursuant to this Agreement, subject to an extension of time for an Unavoidable Delay. 14.03. Notice of Loss or Damage to Project. The Developer shall promptly give the Agency written notice of any significant damage or destruction to the Project stating the date on which such damage or destruction occurred, the expectations of the Developer as to the effect of such damage or destruction on the use of the Project, and the proposed schedule, if any, for repair or reconstruction of the Project. If the Developer determines the Project cannot be repaired or restored in an economically justifiable or other manner, then the Developer shall so notify the Agency and state reasons supporting its determ ination. 14.04. Subject to Financing. The Developer's obligations under this Article 14 are subject to the terms and conditions of the Construction Financing or any other mortgage financing in effect at the time any such obligations hereunder would otherwise be applicable. ARTICLE 15. MISCELLANEOUS. 15.01. Assignments. (a) (1) Prior to the earlier of the Termination Date or the Expiration Date, the Developer may sell, convey, assign or otherwise dispose of any or all of its right, title, interest and obligations in and to the Project, or any part thereof to any person with the prior written consent of the Agency, which shall not be unreasonably withheld, provided that such party (hereinafter referred to as the "assignee"), to the extent of the sale, conveyance, assignment or other disposition by the Developer to the assignee, shall be bound by the terms of this Agreement the same as the Developer for such part of the Project as is subject to such sale, conveyance, assignment or other disposition, except for the sale of a condominium in the ordinary course of business. (2) If the assignee of Developer's right, title, interest and obligations in and to the Project, or any part thereof, assumes all of Developer's obligations hereunder for the Project, or that part subject to such sale, conveyance, assignment or other disposition, then the Developer shall be released from all such obligations hereunder which have been so assumed by the assignee, and the Agency agrees to execute an instrument evidencing such release, which shall be in recordable form. (b) An assignment of the Project, or any part thereof, by the Developer to any corporation, limited partnership, limited liability company+ general partnership, or joint venture, in which the Developer is a general partner or has either the controlling interest or through a joint venture or other arrangement shares equal management rights with a financial institution and maintains such controlling interest or equal management rights for the term of this Agreement shall not be deemed an assignment or transfer subject to any restriction on or approvals of assignments or transfers imposed by this Section 15.01, provided, however, that notice of such assignment shall be given by the Developer to the Agency no less than thirty (30) days prior to such assignment being effective and the assignee shall be bound by the terms of this Agreement to the same extent as would the 45 Item # 3 Attachment number 1 Page 50 of 89 Developer in the absence of such assignment. If the Developer shall at any time withdraw or be replaced as a general partner or no longer have the controlling interest or management rights as described in this subsection, then that event shall constitute an assignment of the Developer's right, title, interest or obligations under this Agreement for purposes of this Section 15.01 and the prior approval of the Agency shall be obtained before such an event shall be effective. 15.02. Successors and Assigns. The terms herein contained shall bind and inure to the benefit of the Agency, and its successors and assigns, and the Developer, and its successors and assigns, except as may otherwise be specifically provided herein. 15.03. Notices. (a) All notices, demands, requests for approvals or other communications given by either party to another shall be in writing, and shall be sent by registered or certified mail, postage prepaid, return receipt requested or by overnight courier service, or by hand delivery to the office for each party indicated below and addressed as follows: To the Developer: To the Agency: MDP-Clearwater, LLC 3280 Peachtree Road, NW, Suite 600 Atlanta, GA 30305 Attention: Daniel Malino, Esquire Community Redevelopment Agency of the City of Clearwater 112 S. Osceola Avenue Clearwater, FL 33756 Attention: Rod Irwin with copies to: with copies to: E. D. Armstrong III, Esquire Johnson, Pope, Bokor, Ruppel and Burns, LLP 911 Chestnut Street Clearwater, FL 33756 City of Clearwater 112 S. Osceola Avenue Clearwater, FL 33756 Attention: City Attorney (b) Notices given by courier service or by hand delivery shall be effective upon deposit with the courier or delivery service, notices given by overnight delivery company shall be deemed received on the first (1 st) business day after deposit with the overnight delivery company and notices given by mail shall be deemed received on the third (3rd) business day after mailing. Refusal by any person to accept delivery of any notice delivered to the office at the address indicated above (or as it may be changed) shall be deemed to have been an effective delivery as provided in this Section 15.03. The addresses to which notices are to be sent may be changed from time to time by written notice delivered to the other parties and such notices shall be effective upon receipt. Until notice of change of address is received as to any particular party hereto, all other parties may rely upon the last address given. 15.04. Severability. If any term, provision or condition contained this Agreement shall, to 46 Item # 3 Attachment number 1 Page 51 of 89 any extent, be held invalid or unenforceable, the remainder of this Agreement, or the application of such term, provision or condition to persons or circumstances other than those in respect of which it is invalid or unenforceable, shall not be affected thereby, and each term, provision and condition of this Agreement shall be valid and enforceable to the fullest extent permitted by law. 15.05. Applicable Law and Construction. The laws of the State of Florida shall govern the validity, performance and enforcement of this Agreement. This Agreement has been negotiated by the Agency and the Developer, and the Agreement, including, without limitation, the Exhibits, shall not be deemed to have been prepared by the Agency or the Developer, but by all equally. 15.06. Venue; Submission to .Jurisdiction. (a) For purposes of any suit, action, or other proceeding arising out of or relating to this Agreement, the parties hereto do acknowledge, consent, and agree that venue thereof is Pinellas County, Florida. (b) Each party to this Agreement hereby submits to the jurisdiction of the State of Florida, Pinellas County and the courts thereof and to the jurisdiction of the United States District Court for the Middle District of Florida, for the purposes of any suit, action, or other proceeding arising out of or relating to this Agreement and hereby agrees not to assert by way of a motion as a defense or otherwise that such action is brought in an inconvenient forum or that the venue of such action is improper or that the subject matter thereof may not be enforced in or by such courts. (c) If at any time during the term of this Agreement the Developer is not a resident of the State of Florida or has no office, employee, agency, registered agent or general partner thereof available for service of process as a resident of the State of Florida, or if any permitted assignee thereof shall be a foreign corporation, partnership or other entity or shall have no officer, employee, agent, or general partner available for service of process in the State of Florida, the Developer hereby designates the Secretary of State, State of Florida, its agent for the service of process in any court action between it and the Agency arising out of or relating to this Agreement and such service shall be made as provided by the laws of the State of Florida for service upon a non-resident; provided, however, that at the time of service on the Florida Secretary of State, a copy of such service shall be delivered to the Developer at the address for notices as provided in Section 15.03. 15.07. Agreement Not a Chapter 86-191, Laws of Florida, Development Agreement. The Developer and the Agency acknowledge, agree and represent that this Agreement, including, without limitation, any of the Exhibits, is not a development agreement as described in Sections 19-31, Chapter 86-191, Laws of Florida, codified as Sections 163.3220-163.3243, Florida Statutes. 15.08. Estoppel Certificates. The Developer and the Agency shall at any time and from time to time, upon not less than ten (10) days prior notice by another party hereto, 47 Item # 3 Attachment number 1 Page 52 of 89 execute, acknowledge and deliver to the other parties a statement in recordable form certifying that this Agreement has not been modified and is in full force and effect (or if there have been modifications that the said Agreement as modified is in full force and effect and setting forth a notation of such modifications), and that to the knowledge of such party, neither it nor any other party is then in default hereof (or if another party is then in default hereof, stating the nature and details of such default), it being intended that any such statement delivered pursuant to this Section 16.08 may be relied upon by any prospective purchaser, mortgagee, successor, assignee of any mortgage or assignee of the respective interest in the Project, if any, of any party made in accordance with the provisions of this Agreement. 15.09. Complete Agreement; Amendments. (a) This Agreement, and all the terms and provIsions contained herein, including without limitation the Exhibits hereto, constitute the full and complete agreement between the parties hereto to the date hereof, and supersedes and controls over any and all prior agreements, understandings, representations, correspondence and statements whether written or oral, including the RFP and the Proposal. (b) Any provisions of this Agreement shall be read and applied in para materia with all other provisions hereof. (c) This Agreement cannot be changed or revised except by written amendment signed by all parties hereto. 15.10. Captions. The article and section headings and captions of this Agreement and the table of contents preceding this Agreement are for convenience and reference only and in no way define, limit, describe the scope or intent of this Agreement or any part thereof, or in any way affect this Agreement or construe any article, section, subsection, paragraph or provision hereof. 15.11. Holidays. It is hereby agreed and declared that whenever a notice or performance under the terms of this Agreement is to be made or given on a Saturday or Sunday or on a legal holiday observed in the City, it shall be postponed to the next following business day. 15.12. Exhibits. Each Exhibit referred to and attached to this Agreement is an essential part of this Agreement. The Exhibits and any amendments or revisions thereto, even if not physically attached hereto shall be treated as if they are part of this Agreement. 15.13. No Brokers. The Agency and the Developer hereby represent, agree and acknowledge that no real estate broker or other person is entitled to claim or to be paid a commission as a result of the execution and delivery of this Agreement, including any of the Exhibits, or any proposed improvement, use, disposition, lease, conveyance or acquisition of any or all of the Project Site, specifically including the conveyance of the Project Site by the Agency to the Developer. 48 Item # 3 Attachment number 1 Page 53 of 89 15.14. Not an Agent. During the term of this Agreement, the Developer hereunder shall not be an agent of the City or the Agency, with respect to any and all services to be performed by the Developer (and any of its agents, assigns, or successors) with respect to the Project, and the Agency is not an agent of the Developer (and any of its agents, assigns, or successors). 15.15. Memorandum of Development Agreement. The Agency and the Developer agree to execute, in recordable form, on the Effective Date, the short form "Memorandum of Agreement for Development and Disposition of Property," the form of which is attached hereto as Exhibit "D," and agree, authorize and hereby direct such Memorandum to be recorded in the public records of Pinellas County, Florida, as soon as possible after execution thereof. The Agency shall pay the cost of such recording. 15.16. Public Purpose. The parties acknowledge and agree that this Agreement satisfies, fulfills and is pursuant to and for a public purpose and municipal purpose and is in the public interest, and is a proper exercise of the Agency's power and authority under the Act. 15.17. No General Obligation. In no event shall any obligation, express or implied, of the Agency under this Agreement be or constitute a general obligation or indebtedness of the City or the Agency, a pledge of the ad valorem taxing power of the City or the Agency or a general obligation or indebtedness of the City or the Agency within the meaning of the Constitution of the State of Florida or any other applicable laws, but shall be payable solely from legally available revenues and funds. Neither the Developer nor any other party under or beneficiary of this Agreement shall ever have the right to compel the exercise of the ad valorem taxing power of the City, the Agency or any other governmental entity or taxation in any form on any real or personal property to pay the City's or the Agency's obligations or undertakings hereunder. 15.18. Technical Amendments; Survey Corrections. In the event that due to minor inaccuracies contained herein or any Exhibit attached hereto or any other agreement contemplated hereby, or due to changes resulting from technical matters arising during the term of this Agreement, the parties agree that amendments to this Agreement required due to such inaccuracies, unforeseen events or circumstances which do not change the substance of this Agreement may be made and incorporated herein. The Chairman of the Agency is authorized to approve such technical amendments on behalf of the Agency, respectively, and is authorized to execute any required instruments, to make and incorporate such amendment to this Agreement or any Exhibit attached hereto or any other agreement contemplated hereby. 15.19. Term; Expiration; Certificate. (a) If not earlier terminated as provided in Section 12.05, the term of this Agreement shall expire and this Agreement shall no longer be of any force and effect (except for those matters, which specifically survive such expiration) on the fifth (5th) anniversary of the Effective Date. 49 Item # 3 Attachment number 1 Page 54 of 89 (b) Upon completion of the term of this Agreement, all parties hereto shall execute the Agreement Expiration Certificate. The Agreement Expiration Certificate shall constitute (and it shall be so provided in the certificate) a conclusive determination of satisfactory completion of all obligations hereunder and the expiration of this Agreement; provided, however, and notwithstanding the foregoing provisions of this Section 16.19. (c) The Agreement Expiration Certificate shall be in such form as will enable it to be recorded in the public records of Pinellas County, Florida. Following execution by all of the parties hereto, the Agreement Expiration Certificate shall promptly be recorded by the Developer in the public records of Pinellas County, Florida, and the Developer shall pay the cost of such recording. 15.20. Effective Date. Following execution of this Agreement (and such of the Exhibits as are contemplated to be executed simultaneously with this Agreement) by the authorized officers of the Agency and by authorized representatives of the Developer following approval hereof by the Agency and the Developer this Agreement (and any executed Exhibits) shall be in full force and effect in accordance with its terms and upon the recording of the Memorandum of Development Agreement as contemplated by Section 15.15 hereof. 15.21. Cooperation of City. The City of Clearwater, municipal corporation, has joined in this Agreement for the sole purpose of reflecting its agreement to cooperate and support the CRA in meeting the obligations of the CRA as set forth in this Agreement, including without limitation, conveyance, at least thirty (30) days prior to the Closing Date, of that portion of the Property currently owned by the City to the Agency. IN WITNESS WHEREOF, the parties hereto have set their hands and their respective seals affixed as of the 19th day of February, 2008. COMMUNITY REDEVELOPMENT AGENCY By: Frank Hibbard Chairperson Approved as to form: Attest: Pamela K. Akin Attorney for Community Redevelopment Agency Cynthia E. Goudeau City Clerk 50 Item # 3 Attachment number 1 Page 55 of 89 STATE OF FLORIDA ) COUNTY OF PINELLAS ) The foregoing instrument was acknowledged before me this day of , 20_, by FRANK HIBBARD, Chairperson of the Community Redevelopment Agency, who is personally known to me. Print/Type Name: Notary Public 51 Item # 3 Attachment number 1 Page 56 of 89 MDP CLEARWATER, LLC, a Georgia limited liability company By: MDP Clearwater Manager, LLC, its manager By: As: STATE OF GEORGIA COUNTY OF FULTON The foregoing instrument was acknowledged before me this day of , 20_, by , as manger of MDP Clearwater Manager, LLC, the manager of MDP CLEARWATER, LLC, a Georgia limited liability company, on behalf of the company. HelShe is personally known to me or who produced as identification. Print/Type Name: Notary Public 52 Item # 3 Exhibit "A" Exhibit "B" Exhibit "C" Exhibit "D" Exhibit "E" Exhibit "F" Exhibit "G" Exhibit "H" Exhibit "I" Exhibit "J" Attachment number 1 Page 57 of 89 EXHIBIT LIST Property Description and Map Proposed Site Plan Special Warranty Deed Memorandum of Agreement for Development and Disposition of Property Agreement Expiration Certificate Escrow Agreement Survey Certification Declaration of Restrictions Public Way legal description Temporary Access Easement #416723 v1 - MilesOevlDevelopment Agt 53 Item # 3 Attachment number 1 Page 58 of 89 EXHIBIT A MmIIlIlUlANEAN il1LLAGE. 'TF...A. CT 2. B~GIN AT THE. SOUTHEAST COIl:NER. OF LOT II, BLOCK 2, MAGNOLIA PARK ~o\S REcm:DED IN PLAT BOOK 3, PAGE oil OF THE. PUBUC RECORDS OF PlNElLAS cmJNIT. FI.ml:IDA; THENCB 5.00"1 T515"EL A DISTANCE OF &.115 FEET, TImNCE. S.:!i!Jl"4:J:'(14 '1\r., A DISTANCE OF 2L42 llEfi:; THENCE SXI~:r42'1i:.. A lJIST.o\NCBOF25.71 FEET'. TImNCE. S.S~Tn'1\r..A DISTANC~ OF 46.151 mET; THENCE. S.~'43E.4 A DISTANCE. 00 Ui.04 FEElT TO THE soum RIGHT OF WAY LlNE OF PARK 5TREfi:; lHENCB SJl~5T12"'11l. ALONG SAID RIGHT OF 'L1lA Y OF PARK STREE.T, A DISTANCE OF 61.71 FEET; THENCEN21~!Jo'22"W..ADI5'TANCE OF M.41 FEBT; THENCE S1i&='30':M!""'l11.. A DI5'TANCE OF 14.!J04 mET; THENCE. N2J"2f)'ll""\\i 4 ~O\ DISTANCE OF 11.39' mET; THENCE. N. :J;3ojTOD"Vl. A IJISTANC1l: OF 18i..67 FEE!'; TImNCEN.oo>or~D'"E.4 A DISTNACE. 00 3..23 FEET TO A POINT ON THE NORm RIGlIT OF 1;1...A Y LINE OF PAlI'.K STREfi:; THENCE S.Mo5Tll"W. ALONG SAID RIGHT OF WAY OF PAB.KSTII.EET,A IJISTANC1l: OF 5X1:!iFEET; THENCE S.~B~13'3T'!1J'. A DI5'TANC~ OFB 51..H FHET:; THENCE N.03"41':B"'Ur., A DISTANCE OF 46.157 mET; THENCE. NJl.B olS']:IB~ A DISTANCE OF ~.gj. FEElT TO TIm EAST RlGHT OF WAY LINE OF PROSPECT AVENUE; THENCE. N .00"1T515"W. .ALONG SAID RlliHI 00 WAY OF PROSPE.c:T A \o'ENUE, A DISTANCE 0Ji 2D.ll mET; THENCE. 5.&1 ~li' 3IW., A DISTANCE. OF LD5 FEET; TImNCEN.IJS."41':li1"W~ A DISTANCE. OF 4<i.(j')'mEr; TImNCEN.:n~li'3T'E.4 A DISTA~ OF '1.91FEElTTO THBEASTRlmITOFWAYUNE OF PROSPECT AVENUE; TImNCEN.OO"lT515'1\'.A.LONG SAID RIGHT OF WAY OF PROSPE.CT A'i,'ENUB, A DISTANCE OF 143.79 FrnT TO TImSOIITH JtIGHT OF WAY LINE OF CLEAVELAND STR.EBT; THENCE N.i9"5T12'"E. ALONG SAID OOIITH RlliHIOF WAY OF ClHlilBLAND STREET ADI5'TANCE OF 4D1lXlO FrnTW TIm NORTImAST CORNER OF LOT~, BLOCK:2 OF SAID MAGNOLIA PAJ.X;; THENCE SXl~I')"5(j'1i:. ALONG-TImMST LINE.OO5..o\IDLOT S. A DISTANCE. OF I D2.50 mEr TO TIm SOUTHRAST COJtNEll. OF SAID LOT~; THENCE N.~j.T l:l:'"E... .ALONG THE NORm Lnm OF LOTS 12 & II, BLOCK 2. OF SAID MAGNOLIA Ro\R.K, A IJISTANCB OF 10L!Jo~ FEET TO mE NORmEAST CmtNElI.. OF SAID LOT 11; THENCE. 5.00"1 7'5 rn. AI...oNG TIm ~ST Lnm OF SAID LOT 11, A DISTANCB OF B2.~ TO TIm POINT OF BEGINNING. AREA OF TF..Acr 2: lli>,nU2 S.F.M.O.L. :J:.i"1:!lACRES M.O.L. 54 Item # 3 Attachment number 1 Page 59 of 89 MmIIlIlUlANEAN VH..LAGE. 'TF...A.CT 5 BEGIN AT NOR.THWEST CORNBF.. OF lNTERSBCTION OF PImtCE STII'.mT AND EVi'lNG AVENUE.; THENCE N.OD"JD'2];'''W., ALONG THE lllBSTEIU. Y F.lGHT OF WAY LlNE OF mlrrnG AVENtlE, A IJISTANCE OF 36.45 FEET; THENCE. S,.g4~lO"D5""1}.i'.. A DI5'TANCE OF 57.D3 mET; THENCE. Nj}:5"49'55""\\i ~ A DISTANCE OF l~jJO FEn:; THENC~N.21'2!Jo'2:!'''W.,.ADIS'IANCE OF U3 FEE!'; TImNCE S1i&='30'3~"lr. A DI5'TANCE OF HD FEE.T; THENCE N .:J;3019'n'1L, A DISTANCE. OF 126.00 FEET; THENCE, N_Mo3~'lll.""B~ A DISTANCE OF 46.151 mET; THENCE. SJ;3.19'2:!~ A DISTANCE. OF 34.41 FEET TO THE soum RIGHT OF '!1J'AY~ OF PAlI'.KSTREfi:; THENCE N.3:9'=j:1'l:J:'"E..ALONG SAID SOUTH RIGHT OFWAYOFPARKSTlI'.BllT, A DISTANCE OF iIlJ.71 mET; THENCE. N.OO 000 '4i""\\i. , A IJISTANCE OF 215.04 FEET; TImNCE N,3:9'=j:T n~ A DIST~rnCE. OF 4<i1ii' FEET; TEllNCE SXlO<"lJ"15'1i:.. A DI5'TANCE OF ~1.14 mill; THENCE N,.g9<'5T12'1i:.. A DISTANCE B 39.1 B nET; TImNCE SXlO 0 1.:1"1 'I'1i:.. A DI5'TANCE OF 1~.70 FEET TO THE NORTH RIGHT OF WAY LINE OF PIERCE. srn:EKT; THENCE SJI~5'j"'12""1}.i'. ALONG SAID RIGHT OF u..'AYOFPmRC~ STIrnEr.A DI5'TANCE OFB 79.']6 FEET TO THE. POINT OF BEGINNING. AREA OF 1'R.Acr 5: 59.,341.49 SIi. M.o.L., 1.M:! ACRES M.OL. ALSO: LESS AND EXCEPT THOSE n\'o PARCElLS ALONG PROSPE.CT A"VENtlE SHO\lilNHERE ON ASlmCORDED IN Olt. 1l'l!Jo3-,]i'2. (CONTAININGWSIi. M.Ol) :2 55 Item # 3 ~t ...... ~ NO'" r Ml"W aun =1 Ii ~i t li i 1 ~- ~J ill 1" aQUO WlrWE :It ..~ !i<l\ 8~ :1 56 ~~ i.J>'~ i.J>'~ ..... ~~ C)~ ~ " ~ ~ I'l X ::r: - to -I '" .. )> .. '" I~ Attachment number 1 Page 60 of 89 Item # 3 Attachment number 1 Page 61 of 89 EXHIBIT B I, I ~ ~I I .. 57 Item # 3 I I f ~.... ... ra-t'~ ~ ~ ~l.lMJ ~ ~.. .. -.. ~ .:If I8:If .:If ."11I ..,.. ..,.. ..,.. .. 58 Attachment number 1 Page 62 of 89 Item # 3 Attachment number 1 Page 63 of 89 EXHIBIT C SPECIAL WARRANTY DEED COMMUNITY REDEVELOPMENT AGENCY, also known as THE COMMUNITY REDEVELOPMENT AGENCY OF THE CITY OF CLEARWATER, a body politic and corporate of the State of Florida created pursuant to Part III, Ch. 163 Fla. Stat., whose address is 112 S. Osceola Avenue, Clearwater, Florida 33756, hereinafter called the GRANTOR, for and in consideration of Ten and 00/100 Dollars ($10.00), and other valuable consideration the receipt of which is hereby acknowledged, does bargain, sell, convey and grant unto MDP CLEARWATER, LLC, a Georgia limited liability company, whose address is 3280 Peachtree Road, NW, Suite 600, Atlanta, GA 30305 hereinafter called The GRANTEE, the federal tax identification number of which is: , its successors and assigns forever, the real property, situate, lying and being in Pinellas County, Florida, more particularly described in EXHIBIT "A" attached hereto. TAX PARCEL I.D. # Subject to taxes for current year and to those matters listed in EXHIBIT "_" attached hereto. TO HAVE AND TO HOLD unto the said GRANTEE, its successors and assigns forever, and said GRANTOR warrants and shall defend the title against the lawful claims of all persons claiming by, through, or under it, but against none other. TOGETHER with all and singular the tenements, hereditaments and appurtenances thereto belonging or in anywise appertaining. IN WITNESS WHEREOF, GRANTOR has caused these presents to be executed in its name by its Chairman this day of , 2008. [SIGNATURE PAGE FOLLOWS] PREPARED BY AND RETURN TO: C-1 59 Item # 3 Attachment number 1 Page 64 of 89 ATTEST: COMMUNITY REDEVELOPMENT AGENCY OF THE CITY OF CLEARWATER By: Executive Director Chairman WITNESSES (as to all signatures): Printed Name: Printed Name: STATE OF FLORIDA COUNTY OF PINELLAS The foregoing SPECIAL WARRANTY DEED was acknowledged before me this day of , 2008, by FRANK V. HIBBARD, as Chairman, and ROD IRWIN, as the Executive Director of the COMMUNITY REDEVELOPMENT AGENCY OF THE CITY OF CLEARWATER, a body politic and corporate, on behalf of said entity. Such persons are personally known to me or presented as identification. Notary Public, State of Florida My Commission Expires: My Commission Number: C-2 60 Item # 3 Attachment number 1 Page 65 of 89 EXHIBIT D MEMORANDUM OF DEVELOPMENT AGREEMENT [MDP] This Memorandum of Agreement for Development and Disposition of Property ("Memorandum") is made this _ day of , 2008, by and between the COMMUNITY REDEVELOPMENT AGENCY OF THE CITY OF CLEARWATER, FLORIDA, a public body corporate and politic of the State of Florida (the "Agency"), whose address is 112 S. Osceola Avenue, Clearwater, FL 33756, and MDP CLEARWATER, LLC, a Georgia limited liability company), whose address is 3280 Peachtree Road, NW, Suite 600, Atlanta, GA 30305. This Memorandum pertains to an Agreement for Development and Disposition of Property, by and between the Agency and the Developer, dated as of , 2008, (the "Development Agreement"), which provides, among other things, for the sale of property within a project site as described in Exhibit "A" attached hereto and made a part hereof for the development and construction of the Project, as same is defined in the Development Agreement. The Development Agreement is incorporated herein and made a part hereof by reference as fully as though it were set forth herein in its entirety. It is the intention of the parties to hereby ratify, approve and confirm the Development Agreement as a matter of public notice and record. Nothing herein shall in any way affect or modify the Development Agreement, nor shall the provisions of this Memorandum be used to interpret the Development Agreement. In the event of conflict between the terms of this document and those contained in the Development Agreement, the terms in the Development Agreement shall control. A copy of the fully-executed Development Agreement is on file with the City Clerk, City of Clearwater, Florida, located at City Hall, 112 S. Osceola Avenue, Clearwater, Florida, which is available for review and copying by the public. IN WITNESS WHEREOF, the parties hereto have set their hands and their respective seals affixed as of the day of , 2008. [SIGNATURE PAGE FOLLOWS] 61 Item # 3 (SEAL) ATTEST: By: Its: Executive Director (SEAL) ATTEST: By: Its: Secretary , as , as Attachment number 1 Page 66 of 89 COMMUNITY REDEVELOPMENT AGENCY OF THE CITY OF CLEARWATER, FLORIDA By: , as Its Chairman MDP CLEARWATER, LLC By: Its , as 62 Item # 3 Attachment number 1 Page 67 of 89 EXHIBIT E AGREEMENT EXPIRATION CERTIFICATE [MDP CLEARWATER] This Agreement Expiration Certificate ("Certificate") is made this _ day of , _, by and between the COMMUNITY REDEVELOPMENT AGENCY OF THE CITY OF CLEARWATER, FLORIDA, a public body corporate and politic of the State of Florida (the "Agency"), whose address is 112 S. Osceola Avenue, Clearwater, FL 32521, and MDP CLEARWATER, LLC, a Georgia limited liability company), whose address is 3280 Peachtree Road, NW, Suite 600, Atlanta, GA 30305. This Certificate pertains to an Agreement for Development and Disposition of Property (MDP Clearwater), by and between the Agency and the Developer, dated as of , 2008, (the "Development Agreement"), which provides, among other things, for the sale of property within a project site as described in Exhibit "A" attached hereto and made a part hereof for the development and construction of the Project, as same is defined in the Development Agreement. The Development Agreement has expired in accordance with its own terms as of _, , and is no longer of any force or effect, and the Project site is no longer subject to any restriction, limitation, or encumbrance imposed by the Development Agreement. This Certificate has been executed by the parties to the Development Agreement as provided in Section thereof and constitutes a conclusive determination of satisfactory completion of all obligations under such Agreement and that the Development Agreement has expired, except for those matters which survive as noted above. A copy of the fully-executed Development Agreement is on file with the City Clerk, City of Clearwater, Florida, located at City Hall, 112 S. Osceola Avenue, Clearwater, Florida, which is available for review and copying by the public. IN WITNESS WHEREOF, the parties hereto have set their hands and their respective seals affixed as of the _ day of ,. E-1 63 Item # 3 (SEAL) ATTEST: By: , as Its: Executive Director (SEAL) ATTEST: By: Its: Secretary , as Attachment number 1 Page 68 of 89 COMMUNITY REDEVELOPMENT AGENCY OF THE CITY OF CLEARWATER, FLORIDA By: Its Chairman , as MDP CLEARWATER, LLC By: Its , as E-2 64 Item # 3 Attachment number 1 Page 69 of 89 EXHIBIT F ESCROW AGREEMENT THIS ESCROW AGREEMENT ("Escrow Agreement") is made and entered into on ,2008, by and among the COMMUNITY REDEVELOPMENT AGENCY OF THE CITY OF CLEARWATER, FLORIDA, a public body corporate and politic of the State of Florida ("Agency"), MDP CLEARWATER, LLC, a Georgia limited liability company ("Developer"), and STEWART TITLE GUARANTY CO. ("Escrow Agent"). WITNESSETH: WHEREAS, pursuant to its Request for Proposals, dated May 8,2007, the Agency has tentatively accepted the proposal of Developer in response thereto, subject to negotiation of a definitive Development and Disposition Agreement with Developer ("Agreement") setting forth the terms and conditions by which Developer may develop and purchase from Agency the real property more particularly described on Exhibit "A" attached hereto and incorporated herein ("Property"); WHEREAS, Developer has agreed to deposit the sum of Two Hundred Fifty Thousand and 00/100 Dollars ($250,000.00) (the "Escrowed Funds") in escrow with the Escrow Agent as security for Developer's good faith negotiation of the Agreement and which shall become the security deposit required under the terms of the Agreement should the Agreement be executed; WHEREAS, Escrow Agent is a licensed title insurance company in the State of Florida, is independent of Developer and is duly qualified to act as escrow agent; WHEREAS, the parties have requested that the Escrow Agent act as escrow agent in accordance with the terms of this Escrow Agreement and Escrow Agent has agreed to do so. NOW, THEREFORE, in consideration of the foregoing and other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties hereto agree as follows: 1. Recitals. The above recitals are true and correct and are incorporated herein by reference. 2. Deposit of Funds. Simultaneously with the execution of this Escrow Agreement, Developer has delivered the Escrowed Funds to Escrow Agent. Escrow Agent hereby acknowledges receipt of the Escrowed Funds and agrees to hold same in escrow for the parties under the terms of this Escrow Agreement. All funds held in escrow shall be placed in an interest-bearing account, with interest accruing to the benefit of Developer. The Escrowed Funds shall be applied to the purchase price of the Property as set forth in the Agreement ("Purchase Price") at closing, unless Developer is in default under the Agreement, in which event the interest shall be paid to 65 Item # 3 Attachment number 1 Page 70 of 89 the Agency, or unless this Escrow Agreement is terminated pursuant to Section 3(d) hereof. 3. Disbursement of Funds from Escrow. The Escrowed Funds shall be disbursed as follows: (a) Unless otherwise disbursed as provided herein, the Escrowed Funds and shall be paid to Agency at closing and shall be credited to the Purchase Price. (b) In the event the parties enter into the Agreement and either party is in default under the terms of the Agreement, within days after receipt of notice of such default given by the non-defaulting party to Escrow Agent with copies to all parties set forth in Section 7 hereof, Escrow Agent shall promptly deliver the Escrowed Funds, and all accrued interest thereon, to the party entitled to the Deposit in accordance with the terms of the Agreement. (c) If a conflict shall have arisen as to the default described in subparagraph (b) above, upon receipt by the Escrow Agent of (i) joint written instructions signed by Developer and by the Agency directing payment of all or a portion of the Escrowed Funds, or (ii) a final judgment or order of a court of competent jurisdiction directing the payment of all or a portion of the Escrowed Funds held hereunder, the Escrow Agent shall promptly deliver to the person or persons specified, out of the escrow created hereunder and in the manner specified in the instructions, judgment or order, the amount or amounts of Escrowed Funds specified in such instructions, judgment or order, and the Escrow Agent shall thereupon be relieved and discharged from any responsibility or obligation with respect to such amount or amounts of the Escrowed Funds delivered in accordance with this Agreement. (d) In the event the parties do not enter into the Agreement on or before December 31,2007, then Escrow Agent shall disburse the Escrowed Funds, and all accrued interest thereon, to Developer, on or before January 4, 2008. (e) Notwithstanding the provisions of subparagraph (c) above, in the event a dispute should arise regarding the Escrowed Funds, the Escrow Agent shall have the right, in its sole discretion, to deposit with the registry of any State court located in the Pinellas County, Florida, the amount remaining in escrow. In such a case, the Escrow Agent shall implead Developer and the Agency in any such action filed with the court. 4. (a) Except as set forth in this Escrow Agreement or as may be agreed to in writing by Developer, Agency and Escrow Agent, Escrow Agent shall have no obligation to take any action or perform any act other than to receive and hold the Escrowed Funds and to disburse same in accordance with the terms and conditions of this Escrow Agreement. (b) Escrow Agent agrees to perform the duties herein required of it to the best of its ability and in such manner that the interests of Developer and Agency may be adequately and effectively protected. Escrow Agent shall not be answerable, liable or accountable except for its own bad faith, willful misconduct or negligence. Escrow 66 Item # 3 Attachment number 1 Page 71 of 89 Agent shall not be under any obligation to take any action toward the execution or enforcement of the rights or interests of Developer or Agency under the Agreement, whether on its own motion or on the request of any other person or entity, whether or not a party hereto. Escrow Agent is authorized to act on any document believed by it in good faith to be genuine and to be executed by the proper party or parties, and will incur no liability by so acting. Agency and Developer agree to indemnify and hold harmless Escrow Agent from any and all claims, actions, damages, demands and judgments from or to Agency, Developer, or third parties, arising out of any act or omission of Agency or Developer and not caused by bad faith, willful misconduct or negligence of Escrow Agent. (c) Escrow Agent shall be obligated to perform only such duties as are herein set forth, and no implied duties or obligations shall be read into this Escrow Agreement. (d) Should Escrow Agent receive or become aware of conflicting demands or claims with respect to this Escrow Agreement, the Escrowed Funds or the rights of any party hereto, Escrow Agent shall be entitled to refuse to comply with any such demand or claim, and in the event of such demand or claim, Escrow Agent shall deliver the Escrowed Funds to the registry of the appropriate court, whereupon Escrow Agent shall be relieved of any further duties or obligations hereunder. 5. This Escrow Agreement is to be performed in the State of Florida and shall be governed by and construed in accordance with the laws of the State of Florida. 6. This Escrow Agreement shall be binding upon and inure to the benefit of the successors and assigns of the parties hereto, provided that Escrow Agent shall not assign its rights, duties or obligations hereunder in whole or in part without the prior written consent of the Agency and Developer, and any such assignment without said consent shall be void. 7. All notices hereunder shall be deemed delivered (a) on the date of delivery, if hand delivered, (b) three (3) days after deposit, if sent by United States registered or certified mail, postage prepaid, addressed to the parties at the respective addresses shown below, (c) on the date of dispatch, if sent by Federal Express, UPS or other over-night courier, or (d) on the date of transmission if sent by fax, but only if a notice by fax is accompanied by another method permitted hereunder; in any event in accordance with the address set forth below, provided, however, the parties may, by like notice, designate any further or different addresses to which subsequent notices shall be sent: To Escrow Agent: Stewart Title Guaranty Co. clo Stewart Title of Pinellas, Inc. 11500 Seminole Boulevard Largo, FL 33778 Fax: (727) 393-4525 67 Item # 3 Attachment number 1 Page 72 of 89 To Agency: Community Redevelopment Agency of the City of Clearwater Attn: Rod Irwin 112 South Osceola Avenue Clearwater, Florida 33756 Fax: (727) With copy to: Pamela S. Akin, Esquire City of Clearwater 112 South Osceola Avenue Clearwater, Florida 33756 Fax: (727) 562-4021 MDP CLEARWATER, LLC Attention: Daniel Malino, Esquire 3280 Peachtree Road, NW, Suite 600 Atlanta, GA 30305 Fax: (882) 262-4004 To Developer: With copy to: E. D. Armstrong III, Esquire Johnson, Pope, Boko~ Ruppel & Burns, LLP 911 Chestnut Street Clearwater, FL 33756 Fax: (727) 462-0365 8. If any clause, provision or section of this Escrow Agreement shall be ruled invalid or unenforceable by any court of competent jurisdiction, the invalidity or unenforceability or such clause, provision or section shall not affect any of the remaining clauses, provisions or sections hereof. 9. This Escrow Agreement contains all of the escrow instructions to Escrow Agent and shall not be modified or supplemented without the written approval of Agency, Developer and Escrow Agent. 10. All personal pronouns used in this Escrow Agreement whether used in the masculine, feminine or neuter gender, shall include all other genders, and the singular shall include the plural and vice versa. 11. Developer and Agency hereby authorize, direct and request Escrow Agent to invest and reinvest the Escrowed Funds in such savings accounts, certificates of deposit, repurchase obligations, money-market funds or such other forms of investments as the Escrow Agent may determine in its sole discretion. 12. This Escrow Agreement may be executed in any number of counterparts, each of which shall be deemed to be an original instrument and all of such counterparts shall constitute one and the same agreement. 68 Item # 3 Attachment number 1 Page 73 of 89 13. Time is of the Essence of this Escrow Agreement. IN WITNESS WHEREOF, Developer, Agency and Escrow Agent acting by and through their respective duly authorized and empowered officers and representatives, have executed and sealed this Escrow Agreement the day and year first written. AGENCY: COMMUNITY REDEVELOPMENT AGENCY OF THE CITY OF CLEARWATER, FLORIDA By: Frank V. Hibbard Chairperson Approved as to form: Attest: Pamela K. Akin City Attorney Cynthia E. Goudeau City Clerk DEVELOPER: MDP CLEARWATER, LLC, a Georgia limited liability company By: ESCROW AGENT: STEWART TITLE GUARANTY CO. By: 02/14/0802:37 PM 48674.114340 #416189 v1 - MilesOev/Clwr/Escrow Agt 69 Item # 3 Attachment number 1 Page 74 of 89 EXHIBIT G SURVEY REOUIREMENTS The Survey shall comply with the following requirements which may be in addition to the requirements of Florida Administrative Code, Rule No. 21 HH-6. 1. Field Note Description. The Survey shall contain a certified metes and bounds description and shall comply with the following requirements: (i) The beginning point, which should be established by a monument located at the beginning point, or by reference to a nearby monument, shall be shown. (ii) The boundary of the Property shall be described by giving the distances and bearings of each. (iii) The distances, bearings, and angles shall be taken from a recent instrument survey, or recently recertified instrument survey, by a licensed Professional Engineer or Registered Surveyor. (iv) Curved sides shall be described by data including length of arc, central angle, radius of circle for the arc and chord distance, and bearing. (v) The legal description shall be a single perimeter description of the entire Property. (vi) The description shall include a reference to all streets, alleys, and other rights-of-way that abut the Property surveyed, and the width of all rights-of-way mentioned shall be given the first time these rights-of-way are referred to. (vii) If the Property surveyed has been recorded on a map or plat as part of an abstract or subdivision, reference to such recording data shall be made. 2. Lot and Block Description. If the Property is included within a properly established, recorded subdivision or addition, then a lot and block description will be an acceptable substitute for a metes and bounds description, provided that the lot and block description shall completely and properly identify the name or designation of the recorded subdivision or addition and give the recording information therefor. 3. Map or Plat. The Survey shall also contain a certified map or plat showing and identifying the following: 70 Item # 3 Attachment number 1 Page 75 of 89 (i) All of the distances, bearings, angles and curves used in the legal description. (ii) The relation of the point of beginning of said plot to the monument from which it is fixed. (iii) Any discrepancies between the map or plat and the description. (iv) All easements showing recording information therefor by volume and page. (v) The established building line, if any. (vi) All easements appurtenant to the Property. (vii) The boundary line of the street or streets abutting the Property, the width of said streets, and whether each street is dedicated or private. (viii) Ingress and egress to the Property by the name of street(s) or road(s) upon which the Property fronts, the same being a paved and dedicated public right-of-way; and the name of the governmental entity which maintains the same. (ix) Encroachments and the extent thereof in terms of distance upon the Property or any easement appurtenant thereto. 4. Improvements. The Survey shall also show all structures and improvements on the Property with horizontal lengths of all sides, and the distance from such structures and improvements to (a) all boundary lines of the Property, (b) easements, (c) established building lines, and (d) street lines. 5. Certification. The certification for the Property description and the map or plat should be addressed to Buyer, any lender involved in the transaction contemplated hereby, JOHNSON, BLAKELY, POPE, BOKOR, RUPPEL & BURNS, P.A and to the interested title company, if required by the title company, signed by the surveyor, bearing current date, registration number, and sealed and returned to JOHNSON, BLAKELY, POPE, BOKOR, RUPPEL & BURNS, P.A, 911 Chestnut Street, P.O. Box 1368, Clearwater, Florida 34617, in order that it be received along with the seven (7) copies of the survey by ,20_: The Survey shall contain the following certificate: 02/14/08 2:37 PM #426048 v1 - MILES DEVELOPMENT -SURVEY REQUIREMENTS 71 Item # 3 Attachment number 1 Page 76 of 89 SURVEYOR'S CERTIFICATE This survey is made for the benefit of and I hereby certify that this survey: (1) was made on the ground as per the field notes shown hereon, and correctly shows the boundary lines and dimensions, area of the Property indicated hereon and each individual parcel indicated hereon; (2) delineates all lot lines, shows the location and dimension of all buildings, structures, improvements, parking areas, and any other matters on the Property; (3) correctly shows the location and dimensions of all alleys, streets, roads, rights-of-way, easements, and other matters of record, or which are visible, of which the undersigned has been advised or as indicated in that certain Title Insurance Commitment issued by as Commitment No. , affecting the Property according to the legal description in such easements and other matters (with instrument, book, and page number indicated); and except as shown, there are no easements, rights-of-way, party walls, or conflicts, and there are no encroachments on adjoining premises, streets, or alleys by any of said buildings, structures, or other improvements, and there are no encroachments on the Property by buildings, structures, or other improvements situated on adjoining premises; and the distance of the nearest intersecting street and road is as shown hereon; (4) shows the means of access and location of all adjoining streets; and that ingress and egress to the Property is provided by [name(s) of street(s) or road(s)] upon which the Property fronts, the same being a paved and dedicated public right-of-way maintained by [governmental authority maintaining right-of-way]; (5) shows the zoning and land use designations of the Property; (6) shows the flood zone designation of the Property, and the community name and parcel number where the information was obtained; (7) shows the location of the coastal construction control line and Item # 3 Attachment number 1 Page 77 of 89 seasonal high-water line, as defined In Florida Statutes S161.053 (1985), if applicable; and (8) shows the location of any wetlands by which the Department of Environmental Regulation of the State of Florida andlor the Army Corps of Engineers has or may exercise jurisdiction pursuant to the Warren S. Henderson Wetlands Protection Act of 1984, the Federal Water Pollution Control Act Amendments of 1972 and the Clean Water Act. I do further certify that: (1) the Property does not serve any adjoining property for drainage, ingress, and egress, or any other purpose; (2) the street address of the Property is: ; and (3) the Property and all improvements located thereon comply with all dimensional and other requirements of the applicable zoning district; and the use upon the Property is permitted by the zoning and land use designations; (4) the total square-foot area, or acreage to the nearest one one- thousandth (1/1000) of an acre, of the Property is: ; and (5) that the survey represented hereon meets the requirements of the Florida Statutes S472.027 and the minimum requirements under Florida Administrative Code, Rule No. 21 HH-6. By: Registration No. (Affix Seal) 02/14/08 2:37 PM #426048 v1 - MILES DEVELOPMENT -SURVEY REQUIREMENTS 2 Item # 3 Attachment number 1 Page 78 of 89 EXHIBIT H This instrument prepared by and to be returned to: E.D. Armstrong, III, Esq. Johnson, Pope, Bokor, Ruppel & Burns, LLP 911 Chestnut Street Clearwater, FL 33756 (727) 461-1818 DECLARA TION OF RESTRICTIONS THESE RESTRICTIONS ("Restrictions") are made on the date hereinafter set forth by MDP Clearwater, LLC, a Georgia limited liability company ("MDP"), whose address is 3280 Peachtree Road, NW, Suite 600, Atlanta, GA 30305. WITNESSETH: WHEREAS, MDP is the owner of real property located in Pinellas County, Florida, which is more particularly described on Exhibit "A" attached hereto and incorporated herein ("Property"). WHEREAS, MDP and the Community Redevelopment Agency of the City of Clearwater, Florida, a public body corporate and politic of the State of Florida created pursuant to Part III, Chapter 163, Florida Statutes ("Agency") entered into an Agreement for the Development and Disposition of Property, dated February 19, 2008 ("Development Agreement"), to set forth terms and conditions of development of the Property, for which a Memorandum of Development Agreement is recorded in O.R. Book , Page , in the public records of Pinellas County, Florida and is kept on file with the Clerk of the City of Clearwater, Florida ("City"). WHEREAS, pursuant to the terms of the Development Agreement, MDP intends to develop _ residential multi-family dwelling units ("Residential Units"). WHEREAS, the Development Agreement requires no less than ten percent (10%) of the total number of approved multi-family Residential Units to be classified as Workforce Affordable Housing Units (hereinafter defined) for a period of twenty (20) years. WHEREAS, the Development Agreement provides that the restrictions related to Workforce Affordable Housing must be made restrictions running with the land. 3 Item # 3 Attachment number 1 Page 79 of 89 WHEREAS, MDP, on behalf of itself, its successors and assigns, desires to comply with the requirements of the Development Agreement by restricting the use of the Residential Units and Property as hereinafter defined. WHEREAS, MDP acknowledges that it has received adequate and valuable consideration in exchange for the imposition of these Restrictions upon the Property. NOW THEREFORE, MDP hereby declares that the Property shall be held, sold and conveyed subject to the following restrictions, covenants, limitations, and conditions, which shall run with the Property and be binding on all parties having any right, title or interest in the Property, their heirs, successors and assigns, and shall inure to the benefit of the Agency and City. The foregoing Recitals are true and correct and are incorporated into and form a part of these Restrictions. ARTICLE I RESTRICTIONS Section 1. These Restrictions shall remain in effect for a period of twenty (20) years commencing on the date of the issuance of the final certificate of occupancy for the last of the multi-family Residential Units constructed on the Property and continuing twenty (20) years thereafter ("Termination Date") (such period, the "Affordability Requirement Period"). Within twenty (20) days after issuance of the final certificate of occupancy for the last of the multi- family Residential Units constructed on the Property, MDP and the Agency shall record a certificate in the public records of Pinellas County, Florida, setting forth the date the final certificate of occupancy was issued. Section 2. During the Affordability Requirement Period, no less than ten percent (10%) of the Residential Units shall be Workforce Affordable Housing Units. For purposes of these Restrictions, "Workforce Affordable Housing Units" shall mean a residential dwelling unit leased or owned by a household with a household income of one hundred twenty percent (120%) or less of the adjusted median family income for Pinellas County, Florida, as determined by the U.S. Department of Housing and Urban Development. The rental rates for leased Workforce Affordable Housing Units shall not exceed the rates published by the Florida Housing Finance Corporation for annual "Maximum Rents by Number of Bedroom Unit" for the Tampa-St. Petersburg-Clearwater MSA. For non-rental units, the sales prices may not exceed 90% of the average area price for the Tampa-St. Petersburg-Clearwater MSA, as established by the annual revenue procedure which provides issuers of qualified mortgage bonds, as defined in Section 143(a) of the Internal Revenue Code, and issuers of mortgage credit certificates, as defined in Section 25( c) of the Internal Revenue Code, with the nationwide average purchase price for residences located in the United States. 4 Item # 3 Attachment number 1 Page 80 of 89 Section 3. During the Affordability Requirement Period, the Workforce Affordable Housing Units shall me mixed with and not clustered together or segregated in any way from the market- rate Residential Units. The number of efficiency, one, two and three or more bedroom Workforce Affordable Housing Units shall be substantially proportional to the number of efficiency, one, two, three or more bedroom market rate units. For example, if 50% of the market rate units are two bedroom, then at least 50% of the Workforce Affordable Housing Units shall be two bedroom or larger. Section 4. MDP shall qualify eligible tenants and initial purchasers of the Workforce Affordable Housing Units and monitor compliance with the conditions set forth in Section 2 above. After the initial sale of a Workforce Affordable Housing Unit, each subsequent resale of a Workforce Affordable Housing Unit during the Affordability Requirement Period shall first require: (i) the seller of the Workforce Affordable Housing Unit to inform the Agency in writing of the seller's intention to convey the Workforce Affordable Housing Unit; (ii) the seller shall arrange for a prospective purchaser to provide all reasonably required financial information ("Financial Information") to the Agency in order to allow the Agency to verify that the prospective purchaser meets the income requirements set forth in Section 2 above; and (iii) the prospective purchaser and seller must receive written acknowledgment from the Agency, which shall be provided by the Agency within ten (10) days after receipt of the Financial Information, that the prospective purchaser meets the income requirements set forth in Section 2 above, as reasonably determined by the Agency. ARTICLE II MISCELLANEOUS Section 1. C:ovemmt Running With the Lmd. These Restrictions shall be a covenant running with the land, as provided by law, and shall be binding upon the undersigned, and the heirs, successors, and assigns of the undersigned, and all parties claiming under them. Section 2. Governing T ,::IW. Any claim shall be governed by and interpreted in accordance with the laws of the state of Florida. Section 3 . Venue. Any action regarding the enforcement of these Restrictions shall be brought in the Circuit Court in Pinellas County, Florida. Section 4. W::Iiver. The waiver or invalidity of any part of these Restrictions shall not affect the validity or enforceability of the remaining portions. Section 5. Enforcement The Agency and the City shall have the right to specifically enforce these Restrictions and shall be entitled to all remedies at law or in equity in the event of MDP's (or its successors and assigns) non-compliance with the same. Section 6. Amendments. These Restrictions may not be amended, modified, altered or 5 Item # 3 Attachment number 1 Page 81 of 89 changed in any respect except by further agreement in writing duly executed by all parties that own property affected by such amendment. Section 7. C:::Iptions. The headings and captions contained herein are for convenience and reference only and in no way define, limit, or describe the scope or the intent of these Restrictions. Section 8. C:onstmction. All pronouns and any variations thereof shall be deemed to refer to the masculine, feminine or neuter, singular or plural, as the identity of the party or parties may reqUIre. Section 9. Time is of the Essence. For purposes herein, time shall be of the essence. Section 10. Notices. All notices, demands, requests for approvals or other communications given by either party to another shall be in writing, and shall be sent by registered or certified mail, postage prepaid, return receipt requested or by overnight courier service, or by hand delivery to the office for each party indicated below and addressed as follows: MDP: MDP Clearwater, LLC 3280 Peachtree Road, NW, Suite 600 Atlanta, GA 30305 Attention: Daniel Malino, Esquire With copy to: E.D. Armstrong, III, Esq. Johnson, Pope, Bokor, Ruppel & Bums, LLP 911 Chestnut Street Clearwater, FL 33756 Agency: Community Redevelopment Agency of the City of Clearwater 112 S. Osceola Avenue Clearwater, FL 33756 Attention: Rod Irwin With copy to: City of Clearwater 112 S. Osceola Avenue Clearwater, FL 33756 Attention: City Manager Notices given by courier service or by hand delivery shall be effective upon deposit with the courier or delivery service, notices given by overnight delivery company shall be deemed received on the first (1 st) business day after deposit with the overnight delivery company and notices given by mail shall be deemed received on the third (3rd) business day after mailing. Refusal by any person 6 Item # 3 Attachment number 1 Page 82 of 89 to accept delivery of any notice delivered to the office at the address indicated above (or as it may be changed) shall be deemed to have been an effective delivery as provided in this Section 10. The addresses to which notices are to be sent may be changed from time to time by written notice delivered to the other parties and such notices shall be effective upon receipt. Until notice of change of address is received as to any particular party hereto, all other parties may rely upon the last address given. IN WITNESS WHEREOF, the undersigned has hereunto set its hand and seal this _ day of , 200 Signed, Sealed and Delivered in the Presence Of: WITNESS: MDP CLEARWATER, LLC, a Georgia limited liability company Sign: Print: Its: Sign: Print: 7 Item # 3 Attachment number 1 Page 83 of 89 RXHTRTT "A" LEGAL DESCRIPTION 8 Item # 3 ~ ilia ~ ~ 9 Attachment number 1 Page 84 of 89 Item # 3 Attachment number 1 Page 85 of 89 EXHIBIT J PREPARED BY & RETURN TO: ED. Armstrong, III, Esquire Johnson, Pope, Bokor Ruppel & Burns, LLP 911 Chestnut Street Clearwater, FL 33756 TEMPORARY ACCESS EASEMENT AGREEMENT THIS AGREEMENT is made this _ day of , 200_, by and between MOP CLEARWATER, LLC, a Georgia limited liability company ("Grantor") and the COMMUNITY REDEVELOPMENT AGENCY OF THE CITY OF CLEARWATER, FLORIDA, a public body corporate and politic of the State of Florida created pursuant to Part III, Chapter 163, Florida Statutes ("Grantee"). WITNESSETH WHEREAS, Grantor is the owner of the real property described in Exhibit "A" attached hereto and incorporated herein by reference (the "MOP Property"); and WHEREAS, the MOP Property is encumbered by a Restrictive Covenant AQreement ("Restrictive Covenant Agreement"), recorded in O.R. Book Page , in the public records of Pinellas County, Florida. WHEREAS, the Restrictive Covenant Agreement and the Revised Monitor Only Plan, Property B, 901-927 Cleveland Street, Clearwater, Florida, dated March 2004 and Response to Comments, Revised Monitor Only Plan, Dimmit Chevrolet Property B, 901-921 Cleveland Street, Clearwater, Florida, dated May 3, 2004, which were approved by the Florida Department of Environmental Protection ('FDEP") on June 25, 2004 ("Monitor Only Plan"), a copy of which, together with related documents, is kept on file with the Clerk of the City of Clearwater, Florida, requires the Grantee to monitor the groundwater and install monitor wells on the MOP Property. WHEREAS, Grantor and Grantee entered into a development agreement, dated February 19.2008 ("Development Agreement"), to set forth terms and conditions of development of the MOP Property, for which a Memorandum of Development Agreement is recorded in O.R. Book , Page in the public records of Pinellas County, Florida. WHEREAS, Grantor has agreed to grant to Grantee a temporary non-exclusive easement for access and ingress and egress across, over, and under the MOP Property in accordance with the terms of this Agreement; and WHEREAS, Grantee accepts this easement; and 10 Item # 3 Attachment number 1 Page 86 of 89 WHEREAS, Grantor and Grantee have agreed to the following terms and conditions. FOR AND IN CONSIDERATION of Ten Dollars ($10.00) and the promises and mutual covenants hereinafter set forth, the receipt and adequacy of which are hereby acknowledged, the parties agree as follows: 1. Recitals. The above recitals are true and correct and are an integral part hereof and not merely recitals hereto. 2. Provisions Regarding Easement. a. Grant of Easement. Grantor hereby grants and conveys to Grantee, a temporary, non-exclusive easement on, over, under and across the MOP Property for the limited purpose of installing monitoring wells and performing monitoring activities, including, but not limited to, inspections and maintenance, in strict accordance with the Restrictive Covenant Agreement, the Monitor Only Plan and the Development Agreement. Grantee shall restore the MOP Property to its original condition upon the conclusion of each of its intermittent obligations (inspections, monitoring, etc.) under the foregoing documents and upon satisfying the conditions of the Restrictive Covenant Agreement and the Monitor Only Plan, the Grantee shall restore the MOP Property to its original condition. Grantee's obligation to restore the MOP Property shall survive the termination date of this Agreement. b. Term of Easement. The term of this easement, and the rights and privileges herein granted shall commence upon recording of this instrument and shall automatically terminate without further notice upon Grantee's satisfaction of the monitoring requirements set forth in the Restrictive Covenant Agreement and the Monitor Only Plan. In no event, however, shall the term extend beyond The parties agree to record a termination of this easement upon its expiration. c. Non-exclusivity. The easement, rights, and privileges granted herein are non- exclusive. d. Use by Grantor. Grantor also retains, reserves, and shall continue to enjoy use of the MOP Property for any and all purposes which do not interfere with and prevent the use by Grantee of the easements rights created herein. e. Not a Public Dedication. Nothing contained herein shall be deemed to be a dedication of any portion of the MOP Property to the general public or for any public use or purpose whatsoever. f. Indemnity. Grantee hereby agrees for itself, its successors and assigns, to at all times indemnify and hold harmless Grantor, its successors and assigns, against any and all claims, suits, actions, debts, damages, costs, charges, and expenses, including court costs and 11 Item # 3 Attachment number 1 Page 87 of 89 attorneys fees and against all liability, losses and damages of any nature whatsoever, that Grantor shall or may at any time sustain or be put to, directly or indirectly, by reason of the contamination of the groundwater on the MOP Property, related to relocation of any groundwater monitoring wells or failure to properly monitor same, or for any claim arising from the Grantee's exercise of its easement rights under this Agreement. The indemnification set forth in this paragraph shall survive the termination date of this Agreement. 3. Exercise of Rights. Notwithstanding anything herein to the contrary, any rights granted herein to Grantee shall be exercised to the greatest extent possible so as to avoid and/or minimize interference with the development, use and operation of the MOP Property by Grantor. 4. Severability. The invalidation of any of the provisions contained in this Agreement by judgment or court order shall in no way affect the validity of any of the other provisions hereof, and the same shall remain in full force and effect. 5. Amendment. This Agreement may not be amended, modified, altered or changed in any respect except by further agreement in writing duly executed by all parties that own property affected by such amendment. 6. Captions. The headings and captions contained herein are for convenience and reference only and in no way define, limit, or describe the scope or the intent of this Agreement. 7. Construction. All pronouns and any variations thereof shall be deemed to refer to the masculine, feminine or neuter, singular or plural, as the identity of the party or parties may require. 8. Applicable Law. The validity of this Agreement and all of its terms and provisions, as well as rights and duties of the parties hereunder, shall be interpreted and construed in accordance with the laws of the State of Florida. 9. Notices. Any notice given to any party under this Agreement shall be valid only if in writing and shall be deemed to be duly given only if delivered personally or sent by courier service, by overnight delivery service, or by registered or certified, postage prepaid, mail addressed to the following addresses: As to Grantor: MOP Clearwater, LLC 3280 Peachtree Road, NW, Suite 600 Atlanta, GA 30305 Attention: Daniel Malino, Esquire As to Grantee: Community Redevelopment Agency of the City of Clearwater 112 S. Osceola Avenue Clearwater, FL 33756 12 Item # 3 Attachment number 1 Page 88 of 89 Attention: Rod Irwin With copy to: City of Clearwater 112 S. Osceola Avenue Clearwater, FL 33756 Attention: City Manager or at such other address as that party may designate by notice to the other party. 10. Attorney's Fees, etc. Should either party employ an attorney or attorneys to enforce any of the provisions hereof, or to protect its interest in any matter arising hereunder, or to recover damages for the breach hereof, the party prevailing shall be entitled to recover from the other party all reasonable costs, charges and expenses, including attorneys' fees, the value of time charged by paralegals and/or other staff members operating under the supervision of an attorney, and other legal costs, expended or incurred in connection therewith, before, during and subsequent to any litigation, including arbitration and appellate proceedings, bankruptcy or similar debtor/creditor proceedings. 11. Time is of the Essence. For purposes herein, time shall be of the essence. [Signature Pages to Follow] 13 Item # 3 Attachment number 1 Page 89 of 89 IN WITNESS WHEREOF, Grantor has caused these presents to be signed in its name by its duly authorized officer and its corporate seal to be affixed the day and year first above written. Signed, Sealed and Delivered in the Presence Of: GRANTOR: MOP CLEARWATER, LLC, a Georgia limited liability company Sign: Print: Sign: Its: Print: GRANTEE: REDEVELOPMENT AGENCY OF THE CITY OF CLEARWATER FLORIDA, a Public body corporate and politic of the State of Florida created pursuant to Part III, Chapter 163, Florida Statutes Countersigned: By: William B. Horne II Frank V. Hibbard Mayor Approved as to form: Pamela K. Akin City Attorney By: Cynthia E. Goudeau City Clerk STATE OF FLORIDA) COUNTY OF The foregoing instrument was acknowledged before me this _ day of , 200_, by , as of MOP CLEARWATER, LLC, a Georgia limited liability company. He/she [ ] is personally known to me or [ ] has produced the following as identification: on behalf of the Company. Notary Public 14 Item # 3